Attachment_7_-__Notice_of_Compliance.pdf

NOTIFICATION OF COMPLIANCE WITH INSURANCE REQUIREMENTS

Attachment 6

FA301018R0018

FAR 28.307-2 -- Liability.

(a) Workers’ compensation and employer’s liability. Contractors are required to comply with applicable Federal and State workers’ compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer’s liability section of the insurance policy, except when contract operations are so commingled with a contractor’s commercial operations that it would not be practical to require this coverage. Employer’s liability coverage of at least $100,000 shall be required, except in

States with exclusive or monopolistic funds that do not permit workers’ compensation to be written by private carriers. (See 28.305(c) for treatment of contracts subject to the Defense Base

Act.)

(b) General liability.

(1) The contracting officer shall require bodily injury liability insurance coverage written on the comprehensive form of policy of at least $500,000 per occurrence.

(2) Property damage liability insurance shall be required only in special circumstances as determined by the agency.

(c) Automobile liability. The contracting officer shall require automobile liability insurance written on the comprehensive form of policy. The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the contract. Policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/28.htm#P355_60621

NOTIFICATION OF COMPLIANCE WITH INSURANCE REQUIREMENTS

The undersigned Contractor hereby acknowledges that he/she has read and understands the insurance requirements specified in this contract and hereby provides notification (1) that such insurance shall be maintained in at least the amounts and types as stated in FAR 28.307-2 and during any modifications and/or time extensions granted thereto;

(2) that the required insurance policies shall contain an endorsement to the effect that any cancellation of material changes adversely affecting the Government's interest shall not be effective for such period as the laws of the State in which this contract is to be performed prescribe, or until thirty (30) calendar days after the insurer or contractor gives written notice to the Contracting Officer, whichever period is longer; (3) that Mississippi Workers'

Compensation Insurance, or letter of reciprocal agreement with another state, shall be maintained on this contract for and during the entire performance period and for any modifications and/or time extensions granted thereto; and (4) that a copy of all subcontractors' proofs of required insurance shall be maintained and shall be made available to the

Contracting Officer upon request.

This agreement shall be a part of subject contract and shall be legally binding and enforceable at law.

INSURANCE COMPANY

(NAME): ______________________________________________________

( ADDRESS): ___________________________________________________

(TELEPHONE NUMBER):_________________________________________

(E-MAIL ADDRESS): _____________________________________________

CONTRACTOR

(NAME): _______________________________________________________

(ADDRESS):.____________________________________________________

(TELEPHONE NUMBER): _________________________________________

(E-MAIL ADDRESS): _____________________________________________

(TYPED NAME AND TITLE):.________________________________________________________

(AUTHORIZED SIGNATURE) (DATE):.________________________________________________