Attach_1-_contract_clauses.pdf

Solicitation No. F17PS00115 Title: Design/Build Site Building Improvements Location: Clark R. Bavin National Forensics Laboratory in Ashland Oregon (Jackson County)

Table of Contents

Page Number(s)

A – Solicitation/Contract Form 1 - 3

B – Supplies or Services/Prices 5

C- Description/Specifications 5

D – Packaging and Marking 5

E – Inspection and Acceptance 5 - 6

F - Deliveries or Performance 6 - 7

G – Contract Administration Data 8 - 9

H – Special Contract Requirements 9 - 10

I - Contract Clauses 10 - 20

J – List of Documents, Exhibits, and Other Attachments 21

K – Representations, Certifications, and Other Statements of Bidders 22 - 27

L – Instructions, Conditions, and Notices to Bidders 28- 30

M – Evaluation Factors for Award 31

A – Solicitation/Contract Form

Per attached Standard Form 1442.

B – Supplies or Services/Prices

See attachment 2 to complete bid schedule pricing

C- Description/Specifications

C.1 STATEMENT OF WORK

The Contractor shall furnish the necessary personnel, material, equipment, services and facilities (except as otherwise specified), to perform all duties associated with Statement of Work and associated attachments for the design and construction of upgrades, repairs, and replacements to the Clark R. Bavin National Forensic Laboratory

D – Packaging and Marking

No clauses.

E – Inspection and Acceptance

52.246-4 Inspection of Services—Fixed-Price (AUG 1996)

(a) Definition. “Services,” as used in this clause, includes services performed, workmanship, and material furnished or utilized in the performance of services.

(b) The Contractor shall provide and maintain an inspection system acceptable to the

Government covering the services under this contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Government during contract performance and for as long afterwards as the contract requires.

(c) The Government has the right to inspect and test all services called for by the contract, to the extent practicable at all times and places during the term of the contract. The Government shall perform inspections and tests in a manner that will not unduly delay the work.

(d) If the Government performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties.

(e) If any of the services do not conform with contract requirements, the Government may require the Contractor to perform the services again in conformity with contract requirements, at no increase in contract amount. When the defects in services cannot be corrected by reperformance, the Government may—

(1) Require the Contractor to take necessary action to ensure that future performance conforms to contract requirements; and

(2) Reduce the contract price to reflect the reduced value of the services performed.

(f) If the Contractor fails to promptly perform the services again or to take the necessary action to ensure future performance in conformity with contract requirements, the Government may—

(1) By contract or otherwise, perform the services and charge to the Contractor any cost incurred by the Government that is directly related to the performance of such service; or

(2) Terminate the contract for default.

(End of clause)

F - Deliveries or Performance

F.1 10181.13 TYPE OF CONTRACT

All line items are identified as firm fixed price line items.

F.2 PROTECTION OF HISTORIAL AND ARCHAEOLOGICAL DATA

a. Cultural Resource Study – Federal legislation provides for the protection, preservation, and collection of scientific, prehistorical, and historical, paleontological, and archaeological data (including relics and specimens) which might otherwise be lost due to alteration of the terrain as a result of any Federal construction project of Federal land-modifying activities.

b. Contractor Reporting – The contractor agrees that should it or any of its employees in the performance of a work order discover evidence of possible scientific, prehistorical, or archeological data it will notify the Contracting Officer immediately giving the location and nature of the findings. Written confirmation shall be forwarded within two days. The contractor shall exercise case so as not to damage artifacts or fossils uncovered during excavation operations and shall provide such cooperation and assistance as may be necessary to preserve the findings for removal or other disposition by the Government.

c. Subcontracts – The contractor agree to insert the above paragraph (b) in all subcontracts.

52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984)

The Contractor shall be required to (a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than November 30, 2018.* The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.242-14 Suspension of Work. (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed -

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

G – Contract Administration Data

G.1 10181.16 CONTRACT ADMINISTRATION DATA – RFP

1. Information in this section supplements contract administration information contained in other parts of this document.

2. Contracting Officer’s Authorized Representative (COR)

a. Lynn Moriarty is hereby designated as the COR (503-736-4440). The COR, or his/her designated representative shall act as the Contracting Officer’s Authorized Representative with respect to the following:

1. Acceptability of materials and equipment used by Contractor.

2. Acceptability of work performed by Contractor

3. Inspection

4. Interpretation of the plans and specifications

b. The contracting Officer’s Authorized Representative does not have any authority for the following:

1. Changes in the scope of work

2. Changes affecting the price of the work

3. Changes in any terms or conditions of the contract

4. A final decision on any matter which would be subject to appeal under the Disputes Clause contained in Section I. The Contractor shall promptly direct all such matters to the Contracting Officer.

3. Travel and Per Diem: In accordance with PL 9-234, “Federal Civilian and Contractor Travel Expense Act of 1985”, travel related expenditures for Contractor’s personnel are restricted to the limits established for federal employees. This includes mileage for the company-owned vehicles. Payments shall be processed in accordance with the Prompt Payment provisions of this contract.

Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (April 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice [CO to edit and include the documentation required under this contract}:

• Reference Purchase Order

• Invoice

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) prior to the contract award date, but no more than 3 - 5 business days of the contract award date.

Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP tor submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause)

H – Special Contract Requirements

H.1 CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM April

(a) The U.S. Fish and Wildlife Service (USFWS or Service) will submit an electronic record of contractor performance on this contract in the Past Performance Information Retrieval System (PPIRS) at http://www.ppirs.gov. The Service has implemented the Contractor Performance Assessment Reporting System (CPARS) to submit records to PPIRS. One or more past performance evaluations will be conducted on this contract in order to record contractor performance.

(b) The past performance evaluation process is a paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report.

Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

(c) The Contractor (you) must furnish the Contracting Officer with the name, position title, phone number, and email address for each person designated to have access to past performance evaluation(s) for this contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the USFWS Assessing Official. The report information must at all times be protected as source selection sensitive information not releasable to the public.

https://www.ipp.gov/ mailto:ippgroup@bos.frb.org http://www.ppirs.gov/

(d) When your Contractor Representative(s) (Past Performance Points of Contact) are registered in CPARS, they will receive an automatically-generated email with detailed login instructions.

Further details, systems requirements, and training information for CPARS is available at http://www.cpars.csd.disa.mil/. The CPARS User Manual, registration for On Line Training for Contractor Representatives, and a practice application may also be found at this site.

(e) Within 60 days after the end of a performance period, the USFWS Assessing Official (AO) for the contract will complete an interim or final past performance evaluation, and the report will be accessible at http://www.cpars.csd.disa.mil/. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment. Comments are limited to the space provided in CPARS and your comments must focus on objective facts in the AO's rating, narrative and your performance of the contract. In addition to the ratings and supporting narratives, review the accuracy of all information in the evaluation, as it includes key fields that will be used by the Government to identify the Contractor in future source selection actions. If you elect not to provide comments, acknowledge receipt of the evaluation by indicating "No comment" in Block 22 along with signing and dating Block 23 of the form.

Without a statement in Block 22, you will be unable to sign and submit the evaluation back to the Government. If you do not sign and submit the CPAR within 30 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment." Your response is due within 30 calendar days after receipt of the CPAR.

(f) The following guidelines apply concerning your use of the past performance evaluation:

(1) Protect the evaluation as "source selection information." After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason the form cannot be viewed and/or submitted through CPARS, contact the AO for instructions.

(2) Strictly control access to the evaluation within your organization, and ensure the evaluation is never released to persons or entities outside of their control.

(3) Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

(g) If you wish to discuss a past performance evaluation, send a request in writing to the AO no later than seven days following the date the FAA submits an evaluation to CPARS.

(h) If the parties cannot resolve any disagreement in the content of the past performance evaluation, the original evaluation as well as your comments will be referred to the Reviewing Official (RO). The RO will make a final determination on the performance evaluation.

(i) The completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting future source selection actions after it has been finalized.

I – Contract Clauses

52.202-1 Definitions. (NOV 2013)

52.203-3 Gratuities. (APR 1984) http://www.cpars.csd.disa.mil/ http://www.cpars.csd.disa.mil/

52.203-5 Covenant Against Contingent Fees. (MAY 2014)

52.203-6 Restrictions on Subcontractor Sales to the Government. (SEP 2006)

52.203-7 Anti-Kickback Procedures. (MAY 2014)

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

(MAY 2014)

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. (MAY 2014)

52.203-12 Limitation on Payments to Influence Certain Federal Transactions. (OCT 2010)

52.203-17 – Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights (Apr 2014)

52.204-2 Security Requirements (AUG 1996)

(a) This clause applies to the extent that this contract involves access to information classified

“Confidential,” “Secret,” or “Top Secret.”

(b) The Contractor shall comply with—

(1) The Security Agreement (DD Form 441), including the National Industrial Security Program Operating Manual (DoD 5220.22-M); and

(2) Any revisions to that manual, notice of which has been furnished to the Contractor.

(c) If, subsequent to the date of this contract, the security classification or security requirements under this contract are changed by the Government and if the changes cause an increase or decrease in security costs or otherwise affect any other term or condition of this contract, the contract shall be subject to an equitable adjustment as if the changes were directed under the Changes clause of this contract.

(d) The Contractor agrees to insert terms that conform substantially to the language of this clause, including this paragraph (d) but excluding any reference to the Changes clause of this contract, in all subcontracts under this contract that involve access to classified information.

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper. (May 2011)

52.204-9 Personal Identity Verification of Contractor Personnel (Jan 2011)

(a) The Contractor shall comply with agency personal identity verification procedures identified in the contract that implement Homeland Security Presidential Directive-12 https://www.acquisition.gov/sites/default/files/current/far/html/FormsDDWH2.html#wp1150843

(HSPD-12), Office of Management and Budget (OMB) guidance M-05-24 and Federal Information Processing Standards Publication (FIPS PUB) Number 201.

(b) The Contractor shall account for all forms of Government-provided identification issued to the Contractor employees in connection with performance under this contract. The Contractor shall return such identification to the issuing agency at the earliest of any of the following, unless otherwise determined by the Government:

(1) When no longer needed for contract performance.

(2) Upon completion of the Contractor employee’s employment.

(3) Upon contract completion or termination.

(c) The Contracting Officer may delay final payment under a contract if the Contractor fails to comply with these requirements.

(d) The Contractor shall insert the substance of this clause, including this paragraph (d), in all subcontracts when the subcontractor’s employees are required to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system. It shall be the responsibility of the prime Contractor to return such identification to the issuing agency in accordance with the terms set forth in paragraph (b) of this section, unless otherwise approved in writing by the Contracting Officer.

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. (OCT 2016)

52.204-13 System for Award Management Maintenance (OCT 2016)

52.204-14 Service Contract Reporting Requirements (OCT 2016)

52.204-18 Commercial and Government Entity Code Maintenance (Jul 2016)52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters (JUL 2013)

52.204-21 Basic Safeguarding of Covered Contractor Information Systems (JUN 2016)

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (OCT 2015)

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013)

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015)

52.215-2 Audit and Records - Negotiation. (OCT 2010)

52.215-8 Order of Precedence - Uniform Contract Format. (OCT 1997)

52.219-6 Notice of Total Small Business Set-Aside (NOV 2011)

52.219-14 Limitations on Subcontracting (JAN 2017)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Applicability. This clause applies only to—

(1) Contracts that have been set aside or reserved for small business concerns or 8(a) participants;

(2) Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) participants; and

(3) Orders set aside for small business or 8(a) participants under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F).

(c) By submission of an offer and execution of a contract, the Offeror/Contractor agrees that in performance of the contract in the case of a contract for—

(1) Services (except construction). At least 50 percent of the cost of contract performance incurred for personnel shall be expended for employees of the concern.

(2) Supplies (other than procurement from a nonmanufacturer of such supplies). The concern shall perform work for at least 50 percent of the cost of manufacturing the supplies, not including the cost of materials.

(3) General construction. The concern will perform at least 15 percent of the cost of the contract, not including the cost of materials, with its own employees.

(4) Construction by special trade contractors. The concern will perform at least 25 percent of the cost of the contract, not including the cost of materials, with its own employees.

(End of clause)

52.222-3 Convict Labor. (JUN 2003)

52.222-4 Contract Work Hours and Safety Standards Act - Overtime Compensation. (MAY 2014)

52.222-6 Construction Wage Rate Requirements (MAY 2014)

52.222-7 Withholding of Funds. (MAY 2014)

52.222-8 Payrolls and Basic Records. (MAY 2014)

52.222-9 Apprentices and Trainees. (JUL 2005)

52.222-10 Compliance with Copeland Act Requirements. (FEB 1988)

52.222-11 Subcontracts (Labor Standards). (MAY 2014)

52.222-12 Contract Termination - Debarment. (MAY 2014)

52.222-13 Compliance with Construction Wage Rate Requirements and Related https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%208_4.html#wp1096389 https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2016_5.html#wp1095799

Regulations (MAY 2014)

52.222-14 Disputes Concerning Labor Standards. (FEB 1988)

52.222-15 Certification of Eligibility. (MAY 2014)

52.222-21 Prohibition of Segregated Facilities. (APR 2015)

52.222-26 Equal Opportunity. (SEPT 2016)

52.222-27 Affirmative Action Compliance Requirements for Construction. (APR 2015)

52.222-35 Equal Opportunity for Veterans. (OCT 2015)

52.222-36 Equal Opportunity for Workers with Disabilities. (JUL 2014)

52.222-37 Employment Reports on Veterans. (FEB 2016)

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (DEC 2010)

52.222-50 Combating Trafficking in Persons. (MAR 2015)

52.222-54 Employment Eligibility Verification. (OCT 2015)

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts. (SEP 2013)

52.223-3 Hazardous Material Identification and Material Safety Data. (JAN 1997)

52.223-5 Pollution Prevention and Right-to-Know Information. (MAY 2011)

52.223-6 Drug-Free Workplace. (MAY 2001)

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. (AUG 2011)

52.225-9 Buy American-Construction Materials (MAY 2014)

(a) Definitions. As used in this clause-

“Commercially available off-the-shelf (COTS) item”-

(1) Means any item of supply (including construction material) that is-

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%202_1.html#wp1145508 http://uscode.house.gov/

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means-

(3) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(4) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means-

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if-

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

______NONE__________________________________________

[Contracting Officer to list applicable excepted materials or indicate “none”]

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2012_5.html#wp1077123

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

FOREIGN AND DOMESTIC CONSTRUCTION MATERIALS PRICE COMPARISON

Construction Material Description Unit of Measure Quantity Price (Dollars)*

Item 1:

Foreign construction material _______ _______ _______

Domestic construction material _______ _______ _______ Item 2: _______ _______ _______

Foreign construction material _______ _______ _______ Domestic construction material

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.] [* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).]

52.225-13 Restrictions on Certain Foreign Purchases. (JUN 2008)

52.228-2 Additional Bond Security. (OCT 1997)

52.228-5 Insurance - Work on a Government Installation. (JAN 1997)

52.228-11 Pledges of Assets. (JAN 2012)

52.228-15 Performance and Payment Bonds - Construction. (OCT 2010)

52.229-3 Federal, State, and Local Taxes. (FEB 2013)

52.232-5 Payments under Fixed-Price Construction Contracts. (MAY 2014)

52.232-10 Payments under Fixed-Price Architect-Engineer Contracts (APR 2010)

52.232-17 Interest. (MAY 2014)

52.232-23 Assignment of Claims. (MAY 2014)

52.232-27 Prompt Payment for Construction Contracts. (Jan 2017)

52.232-33 Payment by Electronic Funds Transfer – System for Award Management. (Jul 2013)

52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors (DEC 2013)

52.233-1 Disputes. (MAY 2014)

52.233-3 Protest after Award. (AUG 1996)

52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004)

52.236-2 Differing Site Conditions. (APR 1984)

52.236-3 Site Investigation and Conditions Affecting the Work. (APR 1984)

52.236-5 Material and Workmanship. (APR 1984)

52.236-6 Superintendence by the Contractor. (APR 1984)

52.236-7 Permits and Responsibilities. (NOV 1991)

52.236-8 Other Contracts. (APR 1984)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (APR 1984)

52.236-10 Operations and Storage Areas. (APR 1984)

52.236-11 Use and Possession Prior to Completion. (APR 1984)

52.236-12 Cleaning Up. (APR 1984)

52.236-13 Accident Prevention. (NOV 1991)

52.236-14 Availability and Use of Utility Services. (APR 1984)

52.236-15 Schedules for Construction Contracts. (APR 1984)

52.236-21 Specifications and Drawings for Construction. (FEB 1997)

52.236-22 Design Within Funding Limitations (APR 1984)

52.236-23 Responsibility of the Architect-Engineer Contractor (APR 1984)

52.236-24 Work Oversight in Architect-Engineer Contracts (APR 1984)

52.236-25 Requirements for Registration of Designers (June 2003)

52.236-26 Preconstruction Conference. (FEB 1995)

52.239-1 Privacy or Security Safeguards (AUG 1996)

52.242-13 Bankruptcy. (JUL 1995)

52.243-4 Changes (JUN 2007)

52.244-6 Subcontracts for Commercial Items (JAN 2017)

52.246-21 Warranty of Construction (MAR 1994)

52.247-34 F.o.b. Destination. (NOV 1991)

52.248-3 Value-Engineering-Construction (OCT 2015)

52.249-2 Termination for Convenience of the Government (Fixed-Price), , Alt I (APR 2012)

52.249-7 Termination (Fixed-Price Architect-Engineer) (APR 1984)

52.249-10 Default (Fixed-Price Construction). (APR 1984)

52.252-2 Clauses Incorporated by Reference. (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/far/

52.253-1 Computer Generated Forms. (JAN 1991)

1452.201-70 Authorities and delegations (SEP 2011)

1452.203-70 Restriction on Endorsements (JUL 1996)

1452.204-70 Release of Claims (JUL 1996)

1452.215-70 Examination of Records by the Department of the Interior (APR 1984)

1452.228-70 Liability Insurance (JUL 1996)

(a) The Contractor shall procure and maintain during the term of this contract and any extension thereof liability insurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer. The named insured parties under the policy shall be the Contractor and the United States of America. The amounts of the insurance shall be not less than as follows:

$100,000.00 each person*

$500,000.00 each occurrence*

$1,000,000.00 property damage*

(b) Each policy shall have a certificate evidencing the insurance coverage. The insurance company shall provide an endorsement to notify the Contracting Officer 30 days prior to the effective date of cancellation or termination of the policy or certificate; or modification of the policy or certificate which may adversely affect the interest of the Government in such insurance. The certificate shall identify the contract number, the name and address of the Contracting Officer, as well as the insured, the policy number and a brief description of contract services to be performed. The contractor shall furnish the Contracting Officer with a copy of an acceptable insurance certificate prior to beginning the work.

*These amounts to be set by the Contracting Officer.

1452.233-2 Service of Protest (JUL 1996)

J – List of Documents, Exhibits, and Other Attachments

J.1 ATTACHMENTS

The attachments for this project are as follows:

1. Contract Clauses (28 pgs)

2. Bid Schedule (2 pgs)

3. Forensic Lab Statement of Work dated March 2017 (37 pgs)

4. Wage Decision number OR170026 dated 03/10/2017 (8 pgs)

5. Non-Disclosure Statement (1 pg)

6. Cover Letter (1 pg)

7. Attachments 1 through 25 and 30 through 36 of the Statement of Work *

8. Drawings (160 pgs) *

* Page 37 of the Statement of Work provides a summary of other attachments 1 through 25 and 30 through 36 that will be provided to interested firms by mail (or shared web site if available) with a copy of drawings after signing and returning the non-disclosure statement.

K – Representations, Certifications, and Other Statements of Bidders

52.204-8 Annual Representations and Certifications (JAN 2017)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is 36.5 million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in the System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

□ (i) Paragraph (d) applies.

□ (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain

Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal

Confidentiality Agreements or Statements-Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that— https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1137850 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1137850 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1137583 https://www.acquisition.gov/sites/default/files/current/far/html/FARTOCP13.html#wp271421 https://www.acquisition.gov/sites/default/files/current/far/html/FARTOCP13.html#wp271421 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1137684 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1150648 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1137777 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1137850 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1149919

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(vii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance.This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans’ Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, GSA, DoD and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA–designated items; or include the clause https://www.acquisition.gov/sites/default/files/current/far/html/52_207_211.html#wp1144766 https://www.acquisition.gov/sites/default/files/current/far/html/52_207_211.html#wp1144909 https://www.acquisition.gov/sites/default/files/current/far/html/52_207_211.html#wp1146404 https://www.acquisition.gov/sites/default/files/current/far/html/52_214.html#wp1129381 https://www.acquisition.gov/sites/default/files/current/far/html/52_215.html#wp1144523 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1135900 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1135943 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147663 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147711 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147704 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147711 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1148142 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1168958 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168785 at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA–designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals–Representation. This provision applies to solicitation that include the clause at 52.204-7.

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American—Free Trade Agreements—Israeli Trade Act Certificate.

(Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in

Sudan—Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.] __ (i) 52.204-17, Ownership or Control of Offeror.

__ (ii) 52.204-20, Predecessor of Offeror.

__ (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End

Products.

__ (iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment- Certification.

__ (v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Certification.

__ (vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material

Content for EPA–Designated Products (Alternate I only).

__ (vii) 52.227-6, Royalty Information.

https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168786 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168826 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1197892 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1137850 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169013 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1192900 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169071 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169038 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169193 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169151 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1181379 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1188714 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169667 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1152369 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1152940 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1160855 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1152427 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1162560 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168892 https://www.acquisition.gov/sites/default/files/current/far/html/52_227.html#wp1139116

__ (A) Basic.

__(B) Alternate I.

__ (viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date].

These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR CLAUSE # TITLE DATE CHANGE

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.209-7 Information Regarding Responsibility Matters (JUL 2013)

(a) Definitions. As used in this provision— “Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options;

and

(2) The total value of all current, active orders including…