FBO_Amendment_0006.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

Please see attached

R5 AMD Customer Projects Contracting Team 230 S. Dearborn Street, Room 3500 Chicago, IL 60604

R5 AMD Customer Projects Contracting Team 230 S. Dearborn Street, Room 3500 Chicago, IL 60604

EQ5P2SS3P1-18-0029

47PF0018R0176

PAGE OF PAGES

1 9

3. EFFECTIVE DATE

12/06/2018

08/01/2018

INSTRUCTIONS (Back Page):

Instructions for items other than those that are self-explanatory, are as follows:

Item 1 (Contract ID Code). Insert the contract type identification code that appears in the title block of the contract being modified.

Item 3 (Effective date).

(1)

(2)

(3)

(4)

(5)

For a solicitation amendment, change order, or administrative change, the effective date shall be the issue date of the amendment, change order, or administrative change.

For a supplemental agreement, the effective date shall be the date agreed to by the contracting parties.

For a modification issued as an initial or confirming notice of termination for the convenience of the Government, the effective date and the modification number of the confirming notice shall be the same as the effective date and modification number of the initial notice.

For a modification converting a termination for default to a termination for the convenience of the Government, the effective date shall be the same as the effective date of the termination for default.

For a modification confirming the contracting officer's determination of the amount due in settlement of a contract termination, the effective date shall be the same as the effective date of the initial decision.

(a)

(b)

(c)

(d)

(e)

(f)

Item 6 (Issued By). Insert the name and address of the issuing office. If applicable, insert the appropriate issuing office code in the code block.

Item 8 (Name and Address of Contractor). For modifications to a contract or order, enter the contractor's name, address, and code as shown in the original contract or order, unless changed by this or a previous modification.

Items 9, (Amendment of Solicitation Number - Dated), and 10, (Modification of Contract/Order Number - Dated). Check the appropriate box and in the corresponding blanks insert the number and date of the original solicitation, contract, or order.

Item 12 (Accounting and Appropriation Data).

When appropriate, indicate the impact of the modification on each affected accounting classification by inserting one of the following entries:

(2) Accounting classification Net decrease $

Include subject matter or short title of solicitation/contract where feasible.

Item 16B. The contracting officer's signature is not required on solicitation amendments. The contracting officer's signature is normally affixed last on supplemental agreements.

(i)

NOTE: If there are changes to multiple accounting classifications that cannot be placed in block 12, insert an asterisk and the words "See continuation sheet".

Item 13. Check the appropriate box to indicate the type of modification. Insert in the corresponding blank the authority under which the modification is issued. Check whether or not contractor must sign this document. (See FAR 43.103.)

Item 14 (Description of Amendment/Modification).

Organize amendments or modifications under the appropriate Uniform Contract Format (UCF) section headings from the applicable solicitation or contract. The UCF table of contents, however, shall not be set forth in this document.

Indicate the impact of the modification on the overall total contract price by inserting one of the following entries:

(i) Total contract price increased by $

(ii) Total contract price decreased by $

(iii) Total contract price unchanged.

State reason for modification.

When removing, reinstating, or adding funds, identify the contract items and accounting classifications.

(g)

(h)

When the SF 30 is used to reflect a determination by the contracting officer of the amount due in settlement of a contract terminated for the convenience of the Government, the entry in Item 14 of the modification may be limited to --

(i) A reference to the letter determination; and

(ii) A statement of the net amount determined to be due in settlement of the contract.

(1)

(2)

(3)

(4)

(5)

(6)

STANDARD FORM 30 (REV. 11/2016) BACK

(1) Accounting classification Net increase $

Description of Amendment

RFQ 47PF0018R0176

DHS/ICE Perimeter Counter Measures Cabling Project Rosa Parks Federal Building 333 Mount Elliott Street Detroit, Michigan 48207 Amendment 0006

Amendment 0006 is issued to:

1. Provide a updated Standard Form 1442.

2. Provide clarification to the Scope of Work (SOW).

3. Include language from the original SOW to provide context in submitting a proposal.

Responses to Questions:

Question: At the 2nd Pre-Bid meeting, held November 20th, there was some discussion as to a possible “typo” in the last line of #5, which should read …..”removable lockable “non” K-Rated bollards.

Response: Item 5 should read "In lieu of providing two (2) removable, lockable non K-rated bollards as specified in Option B of Section 4 Execution of Scope of Work, Section A General, the Contractor shall provide three (3) removable, lockable non K-rated bollards."

Question: Also in the Scope of Work (from Amendment 4) there is a reference to 7. In lieu of the verbiage provided in Section 4 Execution of Scope of Work, Section C Architectural/Construction, the new verbiage shall read as follows:

Response: Item 7 references Section 4 of the Scope of Work document and is provided in this Amendment.

Question: In regard to “seeding and mulching,” once the project is complete, please clarify that after initial saturation, all other watering will be performed by the GSA/and/or their Client? I do not believe that you would want us to include daily trips to the site, at prevailing wages, to water the new seed & mulch?

Response: Property Management has confirmed that GSA will assume responsibility for daily watering of seeding and mulch after initial saturation.

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

47PF0018R0176

R5 AMD Customer Projects Contracting Team 230 S. Dearborn St.

Room 3300 Chicago, IL 60604 USA

See attached.

5P1QCD

R5 AMD Customer Projects Contracting Team 230 S. Dearborn St.

Room 3300 Chicago, IL 60604 USA

EQ5P2SS3P1-18-0029

5P1QCD

Kendrall Masten 312-385-3052

26248

1 48/01/2018

12/12/2018

3:00 PM (CST)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

27. PAYMENT WILL BE MADE BY

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

5P1QCD

R5 AMD Customer Projects Contracting Team 230 S. Dearborn St.

Room 3300 Chicago, IL 60604 USA https://finance3.gsa.gov/ / PBS PAYMENTS BRANCH

P.O. BOX 17181

FORT WORTH, TX 76102-0181 USA

Jennifer Styzek

PAGE

GENERAL SERVICES ADMINISTRATION

OF

ITEM NO., FORM OR

STOCK NUMBER DESCRIPTION OF ARTICLES OR SERVICES QUAN-

TITY

UNIT

OF

ISSUE

UNIT

PRICE

AMOUNT

0003 DHS/ICE Perimeter Counter 1

Measures Cabling Project

E. Jefferson Ave. (Alternate B added per Addendum)

Installation of K4 Rated Cable

PoP: 01/30/2019 - 04/01/2019

DHS/ICE Perimeter Counter

Installation of K12 Rating Along

E. Jefferson Ave. (Alternate A

(Option B per original SOW)

Measures Cabling Project

LS

Lockable Non K-Rated Bollards

PoP: 01/30/2019 - 04/01/2019

Measures Cabling Project

Installation of K8 Rating Along

(Option A per original SOW)

DHS/ICE Perimeter Counter

DHS/ICE Perimeter Counter

LS

PoP: 01/30/2019 - 04/01/2019

LS

__________LS

Measures Cabling Project

Installation of Removable, Measures Cabling Project

Addendum)

LS

Lockable K-Rated Bollards

DHS/ICE Perimeter Counter

Installation of Removable, added per Addendum)

PoP: 01/30/2019 - 04/01/2019

Barrier (Base Bid per SOW and

PAGE

GENERAL SERVICES ADMINISTRATION

OF

ITEM NO., FORM OR

STOCK NUMBER DESCRIPTION OF ARTICLES OR SERVICES QUAN-

TITY

UNIT

OF

ISSUE

UNIT

PRICE

AMOUNT

PoP: 01/30/2019 - 04/01/2019 may mean considerable after hours work. If testing cannot be accomplished during normal day time hours, then it shall be scheduled for the early evening at the earliest time acceptable to the Property Manager. Any tests proposed on weekends, holidays, or early morning hours must be approved by the Property Manager, Project Manager, Contracting Officer, and the GSA Regional Fire Protection Engineer.

4. EXECUTION OF SCOPE OF WORK (GC & GSA Responsibilities)

A. GENERAL NOT APPLICABLE

1. There is NO parking available on site.

2. There are NO toilet facilities available on site.

Cost proposals shall be submitted as follows, as described herein, with the following phases and options broken out as separate, complete sub-bids. GSA may award any combination of phases and options. Bids must be valid for one-hundred (120) calendar days from bid closure:

BASE BID

INSTALLATION OF AN ENGINEER-RATED, K-RATED VEHICLE RETARDING CABLING SYSTEM

1. The Contractor shall provide and install an engineer-rated, K-rated vehicle retarding cabling system at the Rosa

Parks Federal Building in Detroit, MI.

2. The engineer-rated, K-rated vehicle retarding cabling system shall be installed at the high speed avenues of approach toward the facility at the fence along E. Jefferson Ave. (approximately 210 linear feet) and at the fence along Mt. Elliott St. (approximately 140 linear feet).

3. The engineer-rated, K-rated vehicle retarding cabling system along Mt. Elliot St. shall end at the pedestrian gate of the wrought iron fence and its associated sidewalk.

4. The engineer-rated, K-rated vehicle retarding cabling system shall meet or exceed the requirements of an ASTM International Designation F 2656-07 M30 P2 system through an engineered dynamic analysis.

OPTION A

INSTALLATION OF REMOVABLE, LOCKABLE K-RATED BOLLARDS

1. The Contractor shall provide and install two (2) removeable, lockable K-rated bollards at the Rosa Parks Federal

Building in Detroit, MI.

2. The removable, lockable K-rated bollards shall be installed at the Mt. Elliot St. pedestrian gate to allow for pedestrian traffic.

3. The removeable, lockable K-rated bollards shall meet or exceed the requirements of an ASTM International

Designation F 2656-07 M30 P2 system through an engineered dynamic analysis.

OPTION B

INSTALLATION OF REMOVEABLE, LOCKABLE NON K-RATED BOLLARDS

1. The Contractor shall provide and install two (2) removeable, lockable non K-rated bollards at the Rosa Parks

Federal Building in Detroit, MI.

2. The removable, lockable non K-rated bollards shall be installed at the Mt. Elliot St. pedestrian gate to allow for pedestrian traffic.

B. DEMOLITION NOT APPLICABLE

1. Work shall be performed per the attached construction documents; Drawings G001, C1, A1, A2, A3 and Specifications; including Division 01 – General Requirements as prepared by the GSA contracted A/E, A3C, and as described herein.

2. The existing wrought iron fence that encloses the entire facility is to remain in-place during and after installation of the engineer-rated, K-rated vehicle retarding cabling system.

3. Sections of the existing wrought iron fence that encloses the entire facility may be removed for access/installation of the engineer-rated, K-rated vehicle retarding cabling system. If the Contractor chooses to remove sections of the existing wrought iron fence for performance of work, it shall be re-installed at the conclusion of construction activities each day.

4. The GSA will consider installation of a temporary chain link fence to restrict pedestrian access to the site in lieu of removing sections of the existing wrought iron fence and re-installing them at the conclusion of construction activities each day.

5. If the Contractor chooses removal of sections of the existing wrought iron fence and/or installation of a temporary chain link fence for performance of the work, the Contractor shall provide a written program for each phase of the process for review/approval by the GSA.

6. During all phases of the project, the Contractor shall protect the site and/or existing wrought iron fence to prevent damage and deterioration. The Contractor shall restore/repair the site and/or existing wrought iron fence where damage occurs.

C. ARCHITECTURAL/CONSTRUCTION NOT APPLICABLE

1. Work shall be performed per the attached construction documents; Drawings G001, C1, A1, A2, A3 and Specifications; including Division 01 – General Requirements as prepared by the GSA contracted A/E, A3C, and as described herein.

2. The engineer-rated, K-rated vehicle retarding cabling system shall be installed behind the existing wrought iron fence and shall be designed to have a minimal impact to the existing setting of the property.

3. The post system of the engineer-rated, K-rated vehicle retarding cabling system shall be spaced so that it coincides with the vertical elements of the existing wrought iron fence to minimize impact to the existing setting of the property (reference 5/A2 - Post Detail).

4. With the exception of the cable elements, the engineer-rated, K-rated vehicle retarding cabling system and removable bollards shall be finished to match the existing wrought iron fence. The cable elements of the engineer-rated, K-rated vehicle retarding cabling system shall have a galvanized finish.

D. ELECTRICAL NOT APPLICABLE

1. Work shall be performed per the attached construction documents; Drawings G001, C1, A1, A2, A3 and Specifications; including Division 01 – General Requirements as prepared by the GSA contracted A/E, A3C, and as described herein.

E. LIGHTING NOT APPLICABLE

1. Work shall be performed per the attached construction documents; Drawings G001, C1, A1, A2, A3 and Specifications; including Division 01 – General Requirements as prepared by the GSA contracted A/E, A3C, and as described herein.

F. TELECOMMUNICATION NOT APPLICABLE

1.

G. SECURITY NOT APPLICABLE

H. MECHANICAL (HVAC) NOT APPLICABLE

I. PLUMBING NOT APPLICABLE

J. FINISHING NOT APPLICABLE

K. FIRE AND LIFE SAFETY NOT APPLICABLE

L. ADDITIONAL INFORMATION NOT APPLICABLE

1. The Rosa Parks Federal Building is eligible for inclusion on the National Register of Historic Places (NRHP).

The Contractor shall perform all work in accordance with the Secretary of the Interior’s Standards for Rehabilitation.

2. The Contractor shall attend a pre-construction meeting. This meeting shall be held no more than one (1) week prior to the start of work on site. This meeting shall be held on-site and last no longer than one (1) hour. This meeting will be scheduled with the Project Manager.

3. The Contractor shall hold bi-weekly progress meetings. These meetings shall be held on-site and last no longer than one (1) hour. These meetings will be scheduled with the Project Manager.

4. The Contractor shall attend a close-out/punch-list walk through. This meeting shall be held on-site and last no longer than one (1) hour. This meeting will be held once the contractor feels the work and documentation for the project is complete and is ready for final inspection/acceptance by the GSA. This meeting will be scheduled with the Project Manager.

5. The Contractor shall be available via telephone for the duration of the project to discuss project coordination and/or any issues that may arise.

M. WARRANTEE/GUARANTEE NOT APPLICABLE

1. The Contractor shall provide all warrantees/guarentees on all materials and workmanship per the attached construction documents; Drawings G001, C1, A1, A2, A3 and Specifications; including Division 01 – General Requirements as prepared by the GSA contracted A/E, A3C, and as described herein.