36C24419B0045-002.pdf

VA Project No. 503-17-110 James E. Van Zandt VA Medical Center

AE Works Project No. 18014 Water Related Safety Issues

Version Date: 11-01-18

00 01 10 - 1

Table of Contents

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 15 List of Drawing Sheets 07-15

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 10-17

01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 04-13

01 33 23 Shop Drawings, Product Data, and Samples 05-17

01 35 26 Safety Requirements 02-17

01 42 19 Reference Standards 05-16

01 45 00 Quality Control 01-18

01 45 29 Testing Laboratory Services 11-18

01 45 35 Special Inspections 04-18

01 57 19 Temporary Environmental Controls

01 58 16 Temporary Interior Signage 07-15

01 74 19 Construction Waste Management 09-13

01 91 00 General Commissioning Requirements 10-15

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17

02 82 11 Traditional Asbestos Abatement 09-15

02 82 13 13 Glovebag Asbestos Abatement

02 83 33.13 Lead-Based Paint Removal and Disposal 08-16

DIVISION 03 – CONCRETE

03 30 53 (Short Form) Cast-In-Place Concrete

03 41 33 Precast Structural Pretension Concrete 07-11

DIVISION 06 – WOOD, PLASTICS, AND COMPOSITES

10-17

06 10 00 Rough Carpentry

DIVISION 07 – THERMAL AND MOISTURE PROTECTION

07 92 00 Joint Sealants 10-17

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 02-15

09 22 16 Non-Structural Metal Framing 06-18

09 29 00 Gypsum Board 09-18

Version Date: 11-01-18

00 01 10 - 2

Table of Contents

DIVISION 10 -

10 21 13 Toilet Compartments 12-15

10 28 00 Toilet, Bath, and Laundry Accessories 02-16

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 07-16

22 05 19 Meters and Gages for Plumbing Piping 09-15

22 05 23 General-Duty Valves for Plumbing Piping 09-15

22 07 11 Plumbing Insulation 09-15

22 08 00 Commissioning of Plumbing Systems 11-16

22 11 00 Facility Water Distribution 09-15

22 13 00 Facility Sanitary and Vent Piping 09-15

22 40 00 Plumbing Fixtures 09-15

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 09 23 Direct-Digital Control System for Water System 09-11

DIVISION 26 – ELECTRICAL

26 01 00 Basic Electrical Requirements

26 02 00 Quality Requirements

26 05 00 Common Work Results for Electrical

26 05 11 Requirements for Electrical Installations

26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17

26 05 26 Grounding and Bonding for Electrical Systems 01-17

26 05 33 Raceway and Boxes for Electrical Systems 01-18

DIVISION 31 – EARTHWORK

31 20 11 Earthwork 10-12

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 12 16 Asphalt Paving 07-11

32 17 23 Pavement Markings 07-11

DIVISION 33 – UTILITIES

33 08 00 Commissioning of Site Utility Systems 11-16

33 10 00 Water Utilities 03-17

DIVISION 46 – Water Treatment Equipment

46 60 00 Submersible Mixer 07-11

James E. Van Zandt VA Medical Center Altoona, Pennsylvania

WATER RELATED ISSUES INCLUDING MISC.

RESTROOM RENOVATIONS

Project No: 503-17-110

PROJECT MANUAL

100% CONSTRUCTION DOCUMENTS

Volume 1 of 1

Prepared by:

209 Sandusky Street Pittsburgh, PA 15212

412-287-7333

May 2, 2019

VA Project No. 503-17-110 James E. Van Zandt VA Me dical Center AE Works Project No. 18014 Water Related Safety Is sues Version Date: 10-1-17

01 00 00 - i General Requirements

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 SAFETY REQUIREMENTS

1.2 GENERAL INTENTION

1.3 STATEMENT OF BID ITEM(S)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.5 CONSTRUCTION SECURITY REQUIREMENTS

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS

1.8 DISPOSAL AND RETENTION

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS

1.10 RESTORATION

1.14 AS-BUILT DRAWINGS

1.15 USE OF ROADWAYS

1.16 RESIDENT ENGINEER'S FIELD OFFICE

1.17 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

1.18 TEMPORARY USE OF EXISTING ELEVATORS

1.19 TEMPORARY USE OF NEW ELEVATORS

1.20 TEMPORARY TOILETS

1.21 AVAILABILITY AND USE OF UTILITY SERVICES

1.23 TESTS

1.24 INSTRUCTIONS

1.25 GOVERNMENT-FURNISHED PROPERTY

1.26 RELOCATED // EQUIPMENT // ITEMS //

1.27 STORAGE SPACE FOR DEPARTMENT OF VETERANS AFFAIRS EQUIPMENT

1.28 CONSTRUCTION SIGN

VA Project No. 503-17-110 James E. Van Zandt VA Me dical Center AE Works Project No. 18014 Water Related Safety Is sues

01 00 00 - ii

01 00 00 -1

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

A. Refer to section 01 35 26, SAFETY REQUIREMENTS f or safety and infection control requirements.

B. Contractor is to assure that the requirements in Section 1.4.B, Fire

Protection During Construction, of the VA Fire Prot ection Design Manual are satisfied as well as NFPA 241.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for bui lding operations, including demolition and removal of existing struct ures, and furnish labor and materials and perform work for the renova tions and associated spaces as required by drawings and specifications. It is imperative that OSHA standard practices be observed by the con tractor and all contractor’s personnel before, during and after all project work.

Narrow and confined spaces must be treated in OSHA approved manners and all necessary safety measures must be adhered to fo r the health and safety of all personnel in and around the project a nd building site.

These and all safety measures, for the training of contractor personnel and for continual observation and follow-up are the responsibility of the contractor.

B. Visits to the site by Bidders may be made only b y appointment with the

Medical Center Engineering Officer.

C. Offices of AE Works, Ltd., as Architect-Engineer s, will render certain technical services during construction. Such servic es shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Gov ernment without affirmations by Contracting Officer or his duly aut horized representative.

D. Before placement and installation of work subjec t to tests by testing laboratory retained by Department of Veterans Affai rs, the Contractor

01 00 00 -2 shall notify the COR in sufficient time to enable t esting laboratory personnel to be present at the site in time for pro per taking and testing of specimens and field inspection. Such pri or notice shall be not less than three work days unless otherwise desi gnated by the COR.

E. All employees of general contractor and subcontr actors shall comply with VA security management program and obtain perm ission of the VA police, be identified by project and employer, and restricted from unauthorized access.

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, GENERAL CONSTRUCTION: Work includes gene ral construction, mechanical, plumbing, and electrical alterations, n ecessary removal of existing structures and construction and certain ot her items to replace all pneumatically controlled equipment to direct di gitally controlled

(DDC) equipment.

B. Bid Item #1: BASE BID .

C. Bid Item #2: DEDUCT ALTERNATE No 1 : Reduce the Quantity of 199

Temperature Sensors as shown on the Design Drawings to 132 Temperature

Sensors along with the cost of their installation.

D. Bid Item #3: DEDUCT ALTERNATE No 2 : Eliminate all demolition and proposed renovation work as shown on Design Drawing s sheets AD-101 and

A-101, which includes work in toilet rooms 140A, 30 7, 350A, 706, 708, 732@ and 734A.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

01 00 00 -3

1. The security plan defines both physical and admi nistrative security procedures that will remain effective for the entir e duration of the project.

2. The General Contractor is responsible for assuri ng that all sub-contractors working on the project and their employ ees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter t he project site without appropriate badge. They may also be subjec t to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shal l give one week’s notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice is sepa rate from any notices required for utility shutdown described lat er in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the pr emises in the event of a national emergency. The General Contrac tor may return to the site only with the written approval of the Cont racting Officer.

D. Key Control:

1. The General Contractor shall provide duplicate k eys and lock combinations to the Contracting officers representa tive (COR) for the purpose of security inspections of every area o f project including tool boxes and parked machines and take a ny emergency action.

2. The General Contractor shall turn over all perma nent lock cylinders to the VA locksmith for permanent installation. See Section 08 71

00, DOOR HARDWARE and coordinate.

01 00 00 -4

E. Document Control:

1. Before starting any work, the General Contractor /Sub Contractors shall submit an electronic security memorandum desc ribing the approach to following goals and maintaining confide ntiality of

“sensitive information”.

2. The General Contractor is responsible for safeke eping of all drawings, project manual and other project informat ion. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photograp hs and drawings may be marked “Law Enforcement Sensitive” or “Sensitive Unclassified”.

Secure such information in separate containers and limit the access to only those who will need it for the project. Re turn the information to the Contracting Officer upon request .

4. These security documents shall not be removed or transmitted from the project site without the written approval of Co ntracting

Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

6. Notify Contracting Officer and Site Security Off icer immediately when there is a loss or compromise of “sensitive in formation”.

7. All electronic information shall be stored in sp ecified location following VA standards and procedures using an Engi neering Document

Management Software (EDMS).

a. Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and track ed through the

EDMS system.

b. “Sensitive information” including drawings and o ther documents may be attached to e-mail provided all VA encryptio n procedures are followed.

01 00 00 -5

F. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitt ed 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited number of (2 to 5) permits shall be is sued for General

Contractor and its employees for parking in designa ted areas only.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (inc luding storage of materials) on Government premises to areas authoriz ed or approved by the Contracting Officer. The Contractor shall hold and save the

Government, its officers and agents, free and harml ess from liability of any nature occasioned by the Contractor's perfor mance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the appr oval of the

Contracting Officer and shall be built with labor a nd materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the

Contractor and shall be removed by the Contractor a t its expense upon completion of the work. With the written consent of the Contracting

Officer, the buildings and utilities may be abandon ed and need not be removed.

C. The Contractor shall, under regulations prescrib ed by the Contracting

Officer, use only established roadways, or use temp orary roadways constructed by the Contractor when and as authorize d by the Contracting

Officer. When materials are transported in prosecut ing the work, vehicles shall not be loaded beyond the loading cap acity recommended by the manufacturer of the vehicle or prescribed by an y Federal, State, or local law or regulation. When it is necessary to cr oss curbs or sidewalks, the Contractor shall protect them from d amage. The

Contractor shall repair or pay for the repair of an y damaged curbs, sidewalks, or roads.

01 00 00 -6

D. Working space and space available for storing ma terials shall be COR.

E. Workmen are subject to rules of Medical Center applicable to their conduct.

F. Execute work so as to interfere as little as pos sible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any e xisting equipment, and with work being done by others. Use of equipmen t and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during co nstruction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other th an assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of

Veterans Affairs in quantities sufficient for not m ore than two work days. Provide unobstructed access to Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vaca ted portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and saf ety requirements.

G. Phasing:

The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses i n operation occur.

It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim lif e safety measure to be used during the work, and a schedule defining th e duration of the work with milestone subtasks.

01 00 00 -7

To insure such executions, Contractor shall furnis h the COR with a schedule of approximate phasing dates on which the Contractor intends to accomplish work in each specific area of site, b uilding or portion thereof. In addition, Contractor shall notify the C OR two weeks in advance of the proposed date of starting work in ea ch specific area of site, building or portion thereof. Arrange such pha sing dates to insure accomplishment of this work in successive phases mu tually agreeable to

COR and Contractor.

A general phasing plan will include, but not be lim ited to the following:

1) Install new 6” main piping in sub-basement wi thout making connections.

2) Install new 4” main from Fairway Drive as wel l as the 3” main to softeners. Make connections to existing 6” brass m ain and new 6” main installed in step 1. Connect new 4” main to existi ng 6” brass main to back feed the system. Connect to existing 4” main to feed the 1984 addition.

3) Transfer the various connections from the exi sting 6” main to the new 6” main in the sub-basement.

4) Commence work in the boiler plant once 4” mai n is installed and can supply to the building.

5) Make the changeover from the existing main to the new main.

6) Install new 6” mains to building East and Wes t.

7) Install new risers in all locations.

8) Make cross-over connections on each riser

9) Coordinate with COR to replace and piping and valves on each floor.

01 00 00 -8

Contractor shall take all measures and provide all material necessary for protecting existing equipment and pro perty in affected areas of construction against dust and debris, so t hat equipment and affected areas to be used in the Medical Centers op erations will not be hindered. Contractor shall permit access to Depa rtment of

Veterans Affairs personnel and patients through oth er construction areas which serve as routes of access to such affec ted areas and equipment. These routes whether access or egress s hall be isolated from the construction area by temporary partitions and have walking surfaces, lighting etc. to facilitate patient and s taff access.

Coordinate alteration work in areas occupied by Dep artment of

Veterans Affairs so that Medical Center operations will continue during the construction period.

J. When a building and/or construction site is turn ed over to Contractor, Contractor shall accept entire responsibility inclu ding upkeep and maintenance therefore:

1. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make arrangements for p re-inspection of site with Fire Department or Company (Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from

Contractor's employee or watchman.

K. Utilities Services: Maintain existing utility se rvices for Medical

Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uni nterrupted services.

Where necessary to cut existing water, steam, gases , sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (incl uding telephone), they shall be cut and capped at suitable places whe re shown; or, in absence of such indication, where directed by COR.

01 00 00 -9

1. No utility service such as water, gas, steam, se wers or electricity, or fire protection systems and communications syste ms may be interrupted without prior approval of COR. Electric al work shall be accomplished with all affected circuits or equipmen t de-energized.

When an electrical outage cannot be accomplished, w ork on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s p rior knowledge and written approval. Refer to specification Sectio ns 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, 27 05 11 REQUIREMENTS FOR

COMMUNICATIONS INSTALLATIONS and 28 05 00, COMMON W ORK RESULTS FOR

ELECTRONIC SAFETY AND SECURITY for additional requi rements.

2. Contractor shall submit a request to interrupt a ny such services to

COR, in writing, 7 days in advance of proposed inte rruption. Request shall state reason, date, exact time of, and approx imate duration of such interruption.

3. Contractor will be advised (in writing) of appro val of request, or of which other date and/or time such interruption w ill cause least inconvenience to operations of Medical Center. Inte rruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be reques ted, in writing, at least 15 calendar days prior to the desired time an d shall be performed as directed by the COR.

5. In case of a contract construction emergency, se rvice will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the c onstruction project, for such items as water, sewer, electricit y, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

01 00 00 -10

L. Abandoned Lines: All service lines such as wires , cables, conduits, ducts, pipes and the like, and their hangers or sup ports, which are to be abandoned but are not required to be entirely re moved, shall be sealed, capped or plugged at the main, branch or pa nel they originate from. The lines shall not be capped in finished are as, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or par titions; so that they are completely behind the finished surfaces.

M. To minimize interference of construction activit ies with flow of

Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to p arking and to occupied areas of buildings clear of construction m aterials, debris and standing construction equipment and vehicles. / / Wherever excavation for new utility lines cross existing roa ds, at least one lane must be open to traffic at all times with appr oval. //

2. Method and scheduling of required cutting, alter ing and removal of existing roads, walks and entrances must be approve d by the COR.

N. Coordinate the work for this contract with other construction operations as directed by COR. This includes the sc heduling of traffic and the use of roadways, as specified in Article, U SE OF ROADWAYS.

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contract or shall make a thorough survey with the COR and a representative o f VA Supply Service, of areas in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by b oth, to the

Contracting Officer. This report shall list by room s and spaces:

1. Shall note any discrepancies between drawings an d existing conditions at site.

2. Shall designate areas for working space, materia ls storage and routes of access to areas within buildings where al terations occur and which have been agreed upon by Contractor and C OR.

01 00 00 -11

B. Any items required by drawings to be either reus ed or relocated or both, found during this survey to be nonexistent, o r in opinion of COR and/or Supply Representative, to be in such conditi on that their use is impossible or impractical, shall be furnished and/o r replaced by

Contractor with new items in accordance with specif ications which will be furnished by Government. Provided the contract w ork is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "D IFFERING SITE

CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR 52.24 3-4 and VAAR

852.236-88).

C. Re-Survey: Thirty days before expected partial o r final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furn ish a report on conditions then existing, of resilient flooring, do ors, windows, walls and other surfaces as compared with conditions of s ame as noted in first condition survey report:

1. Re-survey report shall also list any damage caus ed by Contractor to such flooring and other surfaces, despite protectio n measures; and, will form basis for determining extent of repair wo rk required of

Contractor to restore damage caused by Contractor's workmen in executing work of this contract.

D. Protection: Provide the following protective mea sures:

1. Wherever existing roof surfaces are disturbed th ey shall be protected against water infiltration. In case of le aks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, ma terials handled and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately

01 00 00 -12 protected prior to starting work, and this protecti on shall be maintained intact until all work in the area is com pleted.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work remov ed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved and demolished items which are to remai n property of the

Government are copper, aluminum, brass, and stainle ss steel and stored in areas, on the VA campus, as designated by the COR. Items that remain property of the Government shall be rem oved or dislodged from present locations in such a manner as to preve nt damage which would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from the Medical Center.

3. Items of portable equipment and furnishings loca ted in rooms and spaces in which work is to be done under this contr act shall remain the property of the Government. When rooms and spac es are vacated by the Department of Veterans Affairs during the alter ation period, such items which are NOT required by drawings and s pecifications to be either relocated or reused will be removed by th e Government in advance of work to avoid interfering with Contracto r's operation.

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS

A. The Contractor shall preserve and protect all st ructures, equipment, and vegetation (such as trees, shrubs, and grass) o n or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contrac t. The Contractor shall only remove trees when specifically authorize d to do so, and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract per formance, or by the careless operation of equipment, or by workmen, the Contractor shall

01 00 00 -13 trim those limbs or branches with a clean cut and p aint the cut with a tree-pruning compound as directed by the Contractin g Officer.

B. The Contractor shall protect from damage all exi sting improvements and utilities at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any dam age to those facilities, including those that are the property o f a third party, resulting from failure to comply with the requireme nts of this contract or failure to exercise reasonable care in performin g the work. If the

Contractor fails or refuses to repair the damage pr omptly, the

Contracting Officer may have the necessary work per formed and charge the cost to the Contractor.

1.10 RESTORATION

A. Remove, cut, alter, replace, patch and repair ex isting work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, an d do not disturb any ducts, plumbing, steam, gas, or electric work witho ut approval of the

COR. Existing work to be altered or extended and th at is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restor ing work, shall conform in type and quality to that of original exi sting construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work comple te and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work , shall be patched, repaired, reinstalled, or replaced with new work, a nd refinished and left in as good condition as existed before commenc ing work.

C. At Contractor's own expense, Contractor shall im mediately restore to service and repair any damage caused by Contractor' s workmen to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications sy stems (including telephone) which are not scheduled for discontinuan ce or abandonment.

01 00 00 -14

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered b y adjustment to contract time and price in accordance with clause e ntitled "CHANGES"

(FAR 52.243-4 and VAAR 852.236-88) and "DIFFERING S ITE CONDITIONS" (FAR

1.14 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of t he project, to include all contract changes, modifications and cla rifications.

B. All variations shall be shown in the same genera l detail as used in the contract drawings. To insure compliance, as-built d rawings shall be made available for the COR review, as often as requ ested.

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the COR within 15 calendar days after each completed phase and after the acceptance of the project by the COR.

D. Paragraphs A, B, & C shall also apply to all sho p drawings.

1.15 USE OF ROADWAYS

A. For hauling, use only established public roads a nd roads on Medical

Center property and, when authorized by the COR, su ch temporary roads which are necessary in the performance of contract work.

1.17 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

A. Use of new installed mechanical and electrical e quipment to provide heat, ventilation, plumbing, light and power will b e permitted subject to written approval and compliance with the followi ng provisions:

1. Permission to use each unit or system must be gi ven by Resident

Engineer in writing. If the equipment is not instal led and maintained in accordance with the written agreement and following provisions, the Resident Engineer will withdraw per mission for use of the equipment.

2. Electrical installations used by the equipment s hall be completed in accordance with the drawings and specifications to prevent damage to

01 00 00 -15 the equipment and the electrical systems, i.e. tran sformers, relays, circuit breakers, fuses, conductors, motor controll ers and their overload elements shall be properly sized, coordina ted and adjusted.

Installation of temporary electrical equipment or d evices shall be in accordance with NFPA 70, National Electrical Cod e, (2014

Edition), Article 590, Temporary Installations. Voltage supplied to each item of equipment shall be verified to be corr ect and it shall be determined that motors are not overloaded. The e lectrical equipment shall be thoroughly cleaned before using it and again immediately before final inspection including vacuu m cleaning and wiping clean interior and exterior surfaces.

3. Units shall be properly lubricated, balanced, an d aligned.

Vibrations must be eliminated.

4. Automatic temperature control systems for prehea t coils shall function properly and all safety controls shall fun ction to prevent coil freeze-up damage.

5. The air filtering system utilized shall be that which is designed for the system when complete, and all filter elemen ts shall be replaced at completion of construction and prior to testing and balancing of system.

6. All components of heat production and distributi on system, metering equipment, condensate returns, and other auxiliary facilities used in temporary service shall be cleaned prior to use; maintained to prevent corrosion internally and externally during use; and cleaned, maintained and inspected prior to acceptance by the Government.

Boilers, pumps, feedwater heaters and auxiliary equ ipment must be operated as a complete system and be fully maintain ed by operating personnel. Boiler water must be given complete and continuous chemical treatment.

B. Prior to final inspection, the equipment or part s used which show wear and tear beyond normal, shall be replaced with iden tical replacements, at no additional cost to the Government.

01 00 00 -16

C. This paragraph shall not reduce the requirements of the mechanical and electrical specifications sections.

D. Any damage to the equipment or excessive wear du e to prolonged use will be repaired replaced by the contractor at the contr actor’s expense.

1.18 TEMPORARY USE OF EXISTING ELEVATORS

A*. Use of existing elevators for handling buildi ng materials and

Contractor's personnel will be permitted subject to following provisions:

1. Contractor makes all arrangements with the COR f or use of elevators.

The Resident Engineer will ascertain that elevators are in proper condition. Personnel for operating elevators will n ot be provided by the Department of Veterans Affairs.

2. Contractor covers and provides maximum protectio n of following elevator components:

a. Entrance jambs, heads soffits and threshold plat es.

b. Entrance columns, canopy, return panels and insi de surfaces of car enclosure walls.

c. Finish flooring.

3. Government will accept hoisting ropes of elevato r and rope of each speed governor if they are worn under normal operat ion. However, if these ropes are damaged by action of foreign matter such as sand, lime, grit, stones, etc., during temporary use, the y shall be removed and replaced by new hoisting ropes at the c ontractor’s expense.

1.20 TEMPORARY TOILETS

A. Contractor may have for use of Contractor's work men, such toilet accommodations as may be assigned to Contractor by the COR. Contractor shall keep such places clean and be responsible for any damage done thereto by Contractor's workmen. Failure to maintai n satisfactory condition in toilets will deprive Contractor of the privilege to use

01 00 00 -17 such toilets and at the COR’s discretion result in contractor supplying their own toilet facilities.

1.21 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably require d amounts of utilities available to the Contractor from existing outlets a nd supplies, as specified in the contract. The amount to be paid by the Contractor for chargeable electrical services shall be the prevail ing rates charged to the Government. The Contractor shall carefully cons erve any utilities furnished without charge.

B. The Contractor, at Contractor's expense and in a workmanlike manner, in compliance with code and as satisfactory to the Con tracting Officer, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to meas ure the amount of electricity used for the purpose of determining cha rges. Before final acceptance of the work by the Government, the Contr actor shall remove all the temporary connections, distribution lines, meters, and associated paraphernalia and repair restore the inf rastructure as required.

C. Heat: Furnish temporary heat necessary to preven t injury to work and materials through dampness and cold. Use of open sa lamanders or any temporary heating devices which may be fire hazards or may smoke and damage finished work, will not be permitted. Mainta in minimum temperatures as specified for various materials:

1. Obtain heat by connecting to Medical Center heat ing distribution system.

E. Electricity (for Construction and Testing): Furn ish all temporary electric services.

1. Obtain electricity by connecting to the Medical Center electrical distribution system. The Contractor shall meter and pay for electricity required for electric cranes and hoisti ng devices, electrical welding devices and any electrical heati ng devices

01 00 00 -18 providing temporary heat. Electricity for all other uses is available at no cost to the Contractor.

F. Water (for Construction and Testing): Furnish te mporary water service.

1. Obtain water by connecting to the Medical Center water distribution system. Provide reduced pressure backflow preventer at each connection as per code. Water is available at no co st to the

Contractor.

2. Maintain connections, pipe, fittings and fixture s and conserve water-use so none is wasted. Failure to stop leakag e or other wastes will be cause for revocation (at COR’s discretion) of use of water from Medical Center's system.

G. Fuel: Natural and LP gas and burner fuel oil req uired for boiler cleaning, normal initial boiler-burner setup and ad justing, and for performing the specified boiler tests will be furni shed by the

Government. Fuel required for prolonged boiler-burn er setup, adjustments, or modifications due to improper desig n or operation of boiler, burner, or control devices shall be furnish ed and paid by the

Contractor at Contractor's expense.

1.23 TESTS

A. As per specification section 23 05 93 the contra ctor shall provide a written testing and commissioning plan complete wit h component level, equipment level, sub-system level and system level breakdowns. The plan will provide a schedule and a written sequence of what will be tested, how and what the expected outcome will be. This document will be submitted for approval prior to commencing work. The contractor shall document the results of the approved plan and submit for approval with the as built documentation.

B. Pre-test mechanical and electrical equipment and systems and make corrections required for proper operation of such s ystems before requesting final tests. Final test will not be cond ucted unless pre-tested.

01 00 00 -19

C. Conduct final tests required in various sections of specifications in presence of an authorized representative of the Con tracting Officer.

Contractor shall furnish all labor, materials, equi pment, instruments, and forms, to conduct and record such tests.

D. Mechanical and electrical systems shall be balan ced, controlled and coordinated. A system is defined as the entire syst em which must be coordinated to work together during normal operatio n to produce results for which the system is designed. For example, air conditioning supply air is only one part of entire system which provide s comfort conditions for a building. Other related components are return air, exhaust air, steam, chilled water, refrigerant, hot water, contr ols and electricity, etc. Another example of a system which involves sev eral components of different disciplines is a boiler installation. Eff icient and acceptable boiler operation depends upon the coordi nation and proper operation of fuel, combustion air, controls, steam, feedwater, condensate and other related components.

E. All related components as defined above shall be functioning when any system component is tested. Tests shall be complete d within a reasonably period of time during which operating an d environmental conditions remain reasonably constant and are typic al of the design conditions.

F. Individual test result of any component, where r equired, will only be accepted when submitted with the test results of re lated components and of the entire system.

1.24 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operati ng manuals (hard copies and electronic) and verbal instructions when requir ed by the various sections of the specifications and as hereinafter s pecified.

B. Manuals: Maintenance and operating manuals and o ne compact disc (four hard copies and one electronic copy each) for each separate piece of equipment shall be delivered to the COR coincidenta l with the delivery of the equipment to the job site. Manuals shall be complete, detailed

01 00 00 -20 guides for the maintenance and operation of equipme nt. They shall include complete information necessary for starting , adjusting, maintaining in continuous operation for long period s of time and dismantling and reassembling of the complete units and sub-assembly components. Manuals shall include an index covering all component parts clearly cross-referenced to diagrams and illustrati ons. Illustrations shall include "exploded" views showing and identify ing each separate item. Emphasis shall be placed on the use of specia l tools and instruments. The function of each piece of equipmen t, component, accessory and control shall be clearly and thorough ly explained. All necessary precautions for the operation of the equi pment and the reason for each precaution shall be clearly set forth. Man uals must reference the exact model, style and size of the piece of equ ipment and system being furnished. Manuals referencing equipment simi lar to but of a different model, style, and size than that furnishe d will not be accepted.

C. Instructions: Contractor shall provide qualified , factory-trained manufacturers' representatives to give detailed tra ining to assigned

Department of Veterans Affairs personnel in the ope ration and complete maintenance for each piece of equipment. All such t raining will be at the job site. These requirements are more specifica lly detailed in the various technical sections. Instructions for differ ent items of equipment that are component parts of a complete sy stem, shall be given in an integrated, progressive manner. All instructo rs for every piece of component equipment in a system shall be availab le until instructions for all items included in the system h ave been completed.

This is to assure proper instruction in the operati on of inter-related systems. All instruction periods shall be at such t imes as scheduled by the COR and shall be considered concluded only when the COR is satisfied in regard to complete and thorough covera ge. The contractor shall submit a course outline with associated mater ial to the COR for review and approval prior to scheduling training to ensure the subject matter covers the expectations of the VA and the co ntractual requirements. The Department of Veterans Affairs r eserves the right to

01 00 00 -21 request the removal of, and substitution for, any i nstructor who, in the opinion of the COR, does not demonstrate suffic ient qualifications in accordance with requirements for instructors abo ve.

1.25 GOVERNMENT-FURNISHED PROPERTY

A. Storage space for equipment will be provided b y the Government and the

Contractor shall be prepared to unload and store su ch equipment therein upon its receipt at the Medical Center.

B. Notify Contracting Officer in writing, 60 days i n advance, of date on which Contractor will be prepared to receive equipm ent furnished by

Government. Arrangements will then be made by the G overnment for delivery of equipment.

1. Immediately upon delivery of equipment, Contract or shall arrange for a joint inspection thereof with a representative of the Government.

At such time the Contractor shall acknowledge recei pt of equipment described, make notations, and immediately furnish the Government representative with a written statement as to its c ondition or shortages.

2. Contractor thereafter is responsible for such eq uipment until such time as acceptance of contract work is made by the Government.

C. Equipment furnished by the Government will be de livered in a partially assembled (knock down) condition in accordance with existing standard commercial practices, complete with all fittings, f astenings, and appliances necessary for connections to respective services installed under contract. All fittings and appliances (i.e., couplings, ells, tees, nipples, piping, conduits, cables, and the li ke) necessary to make the connection between the Government furnishe d equipment item and the utility stub-up shall be furnished and installe d by the contractor at no additional cost to the Government.

D. Completely assemble and install the Government f urnished equipment in place ready for proper operation in accordance with specifications and drawings.

01 00 00 -22

E. Furnish supervision of installation of equipment at construction site by qualified factory trained technicians regularly employed by the equipment manufacturer.

1.26 RELOCATED / EQUIPMENT / ITEMS

A. Contractor shall disconnect, dismantle as necess ary, remove and reinstall in new location, all existing equipment a nd items indicated by symbol "R" or otherwise shown to be relocated by the Contractor.

B. Perform relocation of such equipment or items at such times and in such a manner as directed by the COR.

C. Suitably cap existing service lines, such as ste am, condensate return, water, drain, gas, air, vacuum and/or electrical, a t the main whenever such lines are disconnected from equipment to be re located. Remove abandoned lines in finished areas and cap as specif ied herein before under paragraph "Abandoned Lines".

D. Provide all mechanical and electrical service co nnections, fittings, fastenings and any other materials necessary for as sembly and installation of relocated equipment; and leave such equipment in proper operating condition.

E. Contractor shall employ services of an installat ion engineer, who is an authorized representative of the manufacturer of th is equipment to supervise assembly and installation of existing rem ote dictating machine, X-ray, dental and laundry equipment, requi red to be relocated.

F. All service lines such as noted above for reloca ted equipment shall be in place at point of relocation ready for use befor e any existing equipment is disconnected. Make relocated existing equipment ready for operation or use immediately after reinstallation.

1.27 STORAGE SPACE FOR DEPARTMENT OF VETERANS AFFAIRS EQUIPMENT

A. "Completion Date" shall mean that date as establ ished by Contracting

Officer upon which Contractor will turn over entire project or portions thereof to the Government.

01 00 00 -23

1.28 CONSTRUCTION SIGN

A. Provide a Construction Sign where directed by th e COR. All wood members shall be of framing lumber. Cover sign frame with 0 .7 mm (24 gage) galvanized sheet steel nailed securely around edges and on all bearings. Provide three 100 by 100 mm (4 inch by 4 inch) posts (or equivalent round posts) set 1200 mm (four feet) int o ground. Set bottom of sign level at 900 mm (three feet) above ground a nd secure to posts with through bolts. Make posts full height of sign. Brace posts with 50 x 100 mm (two by four inch) material as directed.

B. Paint all surfaces of sign and posts two coats o f white gloss paint.

Border and letters shall be of black gloss paint, e xcept project title which shall be blue gloss paint.

C. Maintain sign and remove it when directed by the COR.

D. Detail Drawing of construction sign showing requ ired legend and other characteristics of sign is shown on the drawings.

- - - E N D - - -

VA Project No. 503-17-110 James E. Van Zandt VA Med ical Center AE Works Project No. 18014 Water Related Safety Iss ues Version Date: 10-01-17

01 32 16.15 - 1 Project Schedules

SECTION 01 32 16.15

PROJECT SCHEDULES

(SMALL PROJECTS – DESIGN/BID/BUILD)

PART 1- GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Critical Path Met hod (CPM) plan and schedule demonstrating fulfillment of the contract requirements

(Project Schedule), and shall keep the Project Sche dule up-to-date in accordance with the requirements of this section an d shall utilize the plan for scheduling, coordinating and monitoring wo rk under this contract (including all activities of subcontractor s, equipment vendors and suppliers). Conventional Critical Path Method ( CPM) technique shall be utilized to satisfy both time and cost applicati ons.

1.2 CONTRACTOR'S REPRESENTATIVE:

A. The Contractor shall designate an authorized rep resentative responsible for the Project Schedule including preparation, rev iew and progress reporting with and to the Contracting Officer's Rep resentative (COR).

B. The Contractor's representative shall have direc t project control and complete authority to act on behalf of the Contract or in fulfilling the requirements of this specification section.

C. The Contractor’s representative shall have the o ption of developing the project schedule within their organization or to en gage the services of an outside consultant. If an outside scheduling co nsultant is utilized, Section 1.3 of this specification will ap ply.

1.3 CONTRACTOR'S CONSULTANT:

A. The Contractor shall submit a qualification prop osal to the COR, within

10 days of bid acceptance. The qualification propos al shall include:

1. The name and address of the proposed consultant.

2. Information to show that the proposed consultant has the qualifications to meet the requirements specified i n the preceding paragraph.

3. A representative sample of prior construction pr ojects, which the proposed consultant has performed complete project scheduling services. These representative samples shall be of similar size and scope.

B. The Contracting Officer has the right to approve or disapprove the proposed consultant, and will notify the Contractor of the VA decision

01 32 16.15 - 2 within seven calendar days from receipt of the qual ification proposal.

In case of disapproval, the Contractor shall resubm it another consultant within 10 calendar days for renewed cons ideration. The

Contractor shall have their scheduling consultant a pproved prior to submitting any schedule for approval.

1.4 COMPUTER PRODUCED SCHEDULES

A. The contractor shall provide monthly, to the Dep artment of Veterans

Affairs (VA), all computer-produced time/cost sched ules and reports generated from monthly project updates. This monthl y computer service will include: three copies of up to five different reports (inclusive of all pages) available within the user defined rep orts of the scheduling software approved by the Contracting Off icer; a hard copy listing of all project schedule changes, and associ ated data, made at the update and an electronic file of this data; and the resulting monthly updated schedule in PDM format. These must be submitted with and substantively support the contractor’s monthly payment request and the signed look ahead report. The COR shall identif y the five different report formats that the contractor shall provide.

B. The contractor shall be responsible for the corr ectness and timeliness of the computer-produced reports. The Contractor sh all also responsible for the accurate and timely submittal of the update d project schedule and all CPM data necessary to produce the computer reports and payment request that is specified.

C. The VA will report errors in computer-produced r eports to the

Contractor’s representative within ten calendar day s from receipt of reports. The Contractor shall reprocess the compute r-produced reports and associated diskette(s), when requested by the C ontracting Officer’s representative, to correct errors which…