2022-Addendum4_02052026.pdf

Illinois State Toll Highway Authority Contract No. RR-25-2022 Addendum No. 4 Page 1 of 3 February 5, 2026

ADDENDUM NO. 4

TO

CONTRACT REQUIREMENTS

FOR CONTRACT RR-25-2022

ILLINOIS STATE TOLL HIGHWAY AUTHORITY

Date: February 5, 2026

For which bids will be received by the Illinois State Toll Highway Authority through electronic bidding via BidBuy until 10:30:00 A.M. local time, March 6, 2026.

NOTICE OF REVISION TO CONTRACT

NOTES:

1. The following revised required documents are included in the Contract with this Addendum: A-1RRR and T-2R.

2. A complete set of Schedule of Prices is included with this Addendum and must be inserted into the Contract Bid by the Bidder. The Bidder’s attention is called to page P-15R which has been revised and included as part of the Schedule of Prices.

3. The following revised Special Provisions pages are included in the Contract with this Addendum: J-4R, J-5R and J-7R.

4. The following revised Contract Drawing is included in the Addendum: Drawing No. 5.

Addendum No. 4 Page 2 of 3 February 5, 2026

CHANGES TO THE CONTRACT REQUIREMENTS

CHANGES TO THE REQUIRED CONTRACT DOCUMENTS

Change #1 Required Documents, Volume I, replace page A-1RR with page A-1RRR (attached) and replace page T-2 with page T-2R (attached). These replacements contain the following revision:

1.1. Revised Contract Completion Date from May 17, 2027 to October 8, 2027.

1.2. Revised Time of Performance Date from November 3, 2026 to October 8, 2027. Revised Contract Expiration Date from November 3, 2028 to October 8, 2029.

CHANGES TO THE SCHEDULE OF PRICES

Change #2 Required Documents, Volume I, replace page P-15 with page P-15R (attached). This replacement contains the following revision:

2.1. Included pay item 999NEG48 for LIQUIDATED DAMAGES FOR NON-COMPLETION PER S.P. 105.1.5.

CHANGES TO THE CONTRACT SPECIAL PROVISIONS

Change #3 Required Documents, Volume II, replace page J-4 with page J-4R (attached), replace page J-5 with page J-5R (attached) and replace page J-7 with page J-7R (attached). These replacements contain the following revisions:

3.1. Revised Contract Completion Date from November 3, 2026 to October 8, 2027. Revised Substantial Completion

Date from October 2, 2026 to September 8, 2027. Revised Commencement date from February 17, 2026 to May 18, 2026.

3.2. Inserted S.P. 103.5 Interim Completion Date.

3.3. Inserted S.P. 104.1 Work Restrictions. Work, Maintenance of Traffic, and/or detours cannot begin prior to April 15, 2027 at I-88 bridges (BN 1233 and BN 1234) over US-52.

3.4. Inserted S.P. 105.1.5 Liquidated Damages for Non-Completion Per S.P. 103.5.

3.5. Revised dates for IDOT Highway Permit and access to IDOT right-of-way from February 17, 2026 to July 1, 2026

Addendum No. 4 Page 3 of 3 February 5, 2026

CHANGES TO THE CONTRACT DRAWINGS

Change #4 Contract Drawing 5, Suggested Progress Schedule. This drawing contains the following revisions:

4.1. Notice to Proceed date and all subsequent dates including, Substantial Completion Date and Contract Completion

Date are updated in the Suggested Progress Schedule.

END OF ADDENDUM CHANGES

A-1

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

ADVERTISEMENT FOR BIDS

Bid Schedule and Information for

CONTRACT NO: RR-25-2022

Electronic submissions for the above numbered contract as described below will be received by the Illinois Tollway via BidBuy, the State of Illinois eProcurement System, until 10:30:00 a.m. local time on Authority (ISTHA) will no longer accept manual, hard copy bid submissions. All bidders are strongly encouraged to submit bids timely as the system will not accept late bid submittals. Bid results will be posted on the Tollway’s on-line plan room:

www.illinoistollwaybidding.com.

For assistance with registration in BidBuy or submitting electronic bids, please contact the BidBuy Vendor Help Desk at:

il.bidbuy@illinois.gov and /or phone: 866-455-2897.

The optional pre-bid meeting will be held through Microsoft Teams on October 24, 2025 at 2:00 p.m.. The meeting information is listed on the A-2 page.

The work to be done under this contract shall be started on or about May 18, 2026. All work under this contract shall be completed by October 8, 2027. The location of the services to be performed for this contract is the Reagan Memorial Tollway (I-

88) between Mile Post 53.9 and Mile Post 74.3, in Lee County, Illinois. The work under this contract includes bridge rehabilitation, pavement construction and overlay, site clearing, earthwork, grading, erosion and sediment control, landscaping, drainage improvements and cleaning, pavement markings and signage, maintenance of traffic and other miscellaneous work.

Bidders may be required to be pre-qualified by the Illinois Department of Transportation (IDOT).

IDOT Prequalification required: Yes

If ‘NO’, ignore any reference to IDOT Prequalification within the remainder of this document.

Joint Ventures shall be limited to no more than three (3) individually IDOT pre-qualified members.

Bidders are also required to be registered, or submit evidence of application, with the Illinois Department of Human Rights (IDHR). There are NO EXCEPTIONS.

Please note that written or oral communications received by the Illinois Tollway in connection with this solicitation may be required to be reported to the Procurement Policy Board as required by law. This provision is not intended to prohibit communications with State employees regarding a procurement matter, but rather only requires reporting of those communications when they occur.

All bids must be on forms prescribed by the Illinois Tollway and must comply with the terms and conditions set forth in the contract documents. Copies of the plans, special provisions, bid forms and other contract documents for this contract are available from BHFX Digital Imaging and can be viewed and/or ordered for purchase by visiting the On-line Plan Room via www.illinoistollwaybidding.com. Copies of the current Illinois Tollway Supplemental Specifications to the Illinois Department of Transportation Standard Specifications for Road and Bridge Construction can be purchased directly from BHFX Digital Imaging.

The current Illinois Tollway Supplemental Specifications may also be viewed in the ‘Doing Business’ section on the Tollway website.

Current Illinois Department of Transportation Standard Specifications for Road and Bridge Construction, Supplemental Specifications and Recurring Special Provisions can be viewed and purchased from the Illinois Department of Transportation website. Electronic copies of the contract documents are also available on compact disk (CD) from BHFX Digital Imaging. Copies are in a portable document format (PDF). Bidders with questions or in need of assistance in purchasing contract documents are to contact a BHFX Digital Imaging, Customer Service Representative at 630-393-0777, ask for the Plan Room.

Questions pertaining to the intent of the contract documents may be sent to the Illinois Tollway, attention 4949D.2022_Questions@docs.e-builder.net, to be received no later than 2:00 p.m. local time on October 31, 2025.

A completed Questionnaire and a statement of current contractual obligations on forms supplied by the Illinois Tollway will be required from the apparent low bidder once the apparent low bidder is determined. Each bid must be accompanied by a Bid Guaranty in the amount of five (5%) percent of the total amount shown in the bid for the contract. The Bid Guaranty shall be in the form of an acceptable bid bond or a bank draft, certified check or cashier's check drawn on a solvent bank made payable to the Illinois State Toll Highway Authority.

Award of the above contract, if any award be made, will be to the lowest responsive and responsible bidder or bidders. The Illinois Tollway reserves the right to reject any and all bids, to waive technicalities, or cancel the solicitation.

COPIES OF PLANS, SPECIAL PROVISIONS, BID FORMS, CONTRACT DOCUMENTS, STANDARD SPECIFICATIONS AND SUPPLEMENTAL SPECIFICATIONS ARE NOT AVAILABLE AT THE TOLLWAY CENTRAL ADMINISTRATION BUILDING.

DATE:

RRR February 5, 2026

March 6, 2026. The Illinois State Tollway Highway

February 5, 2026

Contract RR-25-2022 Addendum No. 4

Contract RR-25-2022 T-2R February 5, 2026

October 8, 2029.

October 8, 2027, in accordance with the contract book schedule.

S.P.

PAY ITEM

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

20101400 NITROGEN FERTILIZER NUTRIENT POUND 23

20101600 POTASSIUM FERTILIZER NUTRIENT POUND 68

* 20200100 EARTH EXCAVATION CU YD 623

* 20400800 FURNISHED EXCAVATION CU YD 429

20800150 TRENCH BACKFILL CU YD 6

28001100 TEMPORARY EROSION CONTROL BLANKET SQ YD 13,320

28100105 STONE RIPRAP, CLASS A3 SQ YD 34

28200200 FILTER FABRIC SQ YD 34

40600982

HOT-MIX ASPHALT SURFACE REMOVAL -

BUTT JOINT

SQ YD 453

42001300 PROTECTIVE COAT SQ YD 64

44000100 PAVEMENT REMOVAL SQ YD 1,039

44000157 HOT-MIX ASPHALT SURFACE REMOVAL, 2" SQ YD 247

44000400 GUTTER REMOVAL FOOT 179

44004250 PAVED SHOULDER REMOVAL SQ YD 1,147

50101700

REMOVAL OF EXISTING SUPERSTRUCTURES

NO. 1

EACH 1

50101800

REMOVAL OF EXISTING SUPERSTRUCTURES

NO. 2

EACH 1

50102400 CONCRETE REMOVAL CU YD 113.7

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

Addendum No. 4 P - 5 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

50104650 SLOPE WALL REMOVAL SQ YD 56

50200100 STRUCTURE EXCAVATION CU YD 397

50300100 FLOOR DRAINS EACH 6

* 50300225 CONCRETE STRUCTURES CU YD 121.8

* 50300255 CONCRETE SUPERSTRUCTURE CU YD 162.2

50300300 PROTECTIVE COAT SQ YD 3,908

50401105

FURNISHING AND ERECTING PRECAST

PRESTRESSED CONCRETE I-BEAMS, 54 IN.

FOOT 2,270

* 50800205 REINFORCEMENT BARS, EPOXY COATED POUND 373,300

* 50800515 BAR SPLICERS EACH 2,082

* 50800530 MECHANICAL SPLICERS EACH 52

51100100 SLOPE WALL 4 INCH SQ YD 56

51200957 FURNISHING METAL SHELL PILES 12" X 0.250" FOOT 1,295

51202305 DRIVING PILES FOOT 1,295

51203200 TEST PILE METAL SHELLS EACH 4

51204650 PILE SHOES EACH 32

52000037 PREFORMED JOINT SEAL, 3'' FOOT 90

52100010 ELASTOMERIC BEARING ASSEMBLY, TYPE I EACH 27

Addendum No. 4 P - 6 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

52100520 ANCHOR BOLTS, 1" EACH 48

52200010 TEMPORARY SHEET PILING SQ FT 1,277

550A0050 STORM SEWERS, CLASS A, TYPE 1 12" FOOT 37

550B0050 STORM SEWERS, CLASS B, TYPE 1 12" FOOT 100

58600101 GRANULAR BACKFILL FOR STRUCTURES CU YD 451

59100100 GEOCOMPOSITE WALL DRAIN SQ YD 201

60146304 PIPE UNDERDRAINS FOR STRUCTURES 4" FOOT 236

61000050 CONCRETE THRUST BLOCKS EACH 2

61000225 TYPE F INLET BOX, STANDARD 610001 EACH 2

61000335 TYPE G INLET BOX, STANDARD 610001 EACH 1

63200310 GUARDRAIL REMOVAL FOOT 1,081

* 66900530 SOIL DISPOSAL ANALYSIS EACH 4

* 70307120

TEMPORARY PAVEMENT MARKING - LINE 4" -

TYPE IV TAPE

FOOT 52,175

* 70307140

TEMPORARY PAVEMENT MARKING - LINE 8" -

TYPE IV TAPE

FOOT 459

70600280

IMPACT ATTENUATORS, TEMPORARY

(SEVERE USE,NARROW), TEST LEVEL 3

EACH 2

70600370

IMPACT ATTENUATORS, RELOCATE (SEVERE

USE, NARROW), TEST LEVEL 3

EACH 2

* X0322194

POLYMER MODIFIED PORTLAND CEMENT

MORTAR

SQ FT 80

Addendum No. 4 P - 7 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

* X0325747 BRIDGE DECK CONCRETE CRACK SEALER FOOT 53

GBSP X5030250 BRIDGE DECK GROOVING (LONGITUDINAL) SQ YD 2,188

* X5060704 CLEANING AND PAINTING EXPOSED REBAR SQ FT 22

GBSP X5080530 BAR TERMINATORS EACH 252

* X5110308 SLOPE WALL CRACK SEALING FOOT 536

* X5110310 SLOPE WALL REPAIR SQ YD 21

* X5230154

CLEANING BRIDGE SCUPPERS AND

DOWNSPOUTS

EACH 36

* X5230174 DRAINAGE SCUPPERS, DS-11 EACH 4

* X5510011

PROPOSED STORM SEWER CONNECTION TO

EXISTING MANHOLE

EACH 1

* X5537800 STORM SEWERS TO BE CLEANED 12" FOOT 165

* X7010216

TRAFFIC CONTROL AND PROTECTION,

(SPECIAL)

L SUM 1

GBSP Z0001899 JACK AND REMOVE EXISTING BEARINGS EACH 5

* Z0004552 APPROACH SLAB REMOVAL SQ YD 333

* Z0010400 CLEANING BRIDGE SEATS SQ FT 257

* Z0010615 CLEANING EXISTING INLETS EACH 104

* Z0041895 POLYMER CONCRETE CU FT 7

* Z0050400 REMOVE AND REPLACE ANCHOR BOLTS EACH 10

Addendum No. 4 P - 8 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

* Z0073200 TEMPORARY SHORING AND CRIBBING EACH 1

* JI211124 TOPSOIL FURNISH AND PLACE, 4" SQ YD 2,565

* JI406107 ASPHALT TACK COAT POUND 3,035

* JI406510

WARM-MIX ASPHALT SURFACE COURSE, MIX

"D", N70

TON 496

* JI420040 BRIDGE APPROACH SLAB SQ YD 612

* JI420041 TRANSITION APPROACH SLAB SQ YD 778

* JI420046 TRANSITION APPROACH SHOULDER SLAB SQ YD 136

* JI440015

HOT-MIX ASPHALT REMOVAL, VARIABLE

DEPTH

SQ YD 3,119

* JI440022 SHOULDER RUMBLE STRIP REMOVAL SQ YD 923

* JI442300 CLASS D1 PATCHES, TYPE II, 12 INCHES SQ YD 46

* JI481070 AGGREGATE SHOULDERS SPECIAL, TYPE C TON 160

* JI481130

AGGREGATE SHOULDERS WITH FILTER

FABRIC, TYPE B 4"

SQ YD 308

* JI481140 AGGREGATE WEDGE SHOULDER, TYPE B TON 26

* JI482104 WARM-MIX ASPHALT SHOULDERS (6 IN.) SQ YD 1,032

* JI503010

HIGH PERFORMANCE CONCRETE

SUPERSTRUCTURE

CU YD 682.1

* JI506011 CLEANING JOINTS FOOT 857

* JI521510 LAMINATED ELASTOMERIC BEARING EACH 2

Addendum No. 4 P - 9 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

* JI601215 SLOPE DRAIN, 15" FOOT 40

* JI602120

CATCH BASINS, TYPE G-3, TYPE G-3 FRAME

AND GRATE

EACH 1

* JI606020 GUTTER, TYPE G-3 FOOT 208

* JI631110

TRAFFIC BARRIER TERMINAL, TYPE T1

(SPECIAL) TANGENT

EACH 3

* JI642014 ASPHALT SHOULDER RUMBLE STRIP, 16 INCH FOOT 4,567

* JI664402 FENCE TO BE REMOVED AND RE-ERECTED FOOT 465

* JI669016

REGULATED SUBSTANCES MONITORING AND

FIELD SCREENING

CAL DAY 120

* JI680131 SLOPED HEADWALL TYPE III, 12", 1:4 EACH 2

* JI680132 SLOPED HEADWALL TYPE III, 15", 1:4 EACH 1

* JI701001 DETOUR SIGNING, LOCATION 1 L SUM 1

* JI701002 DETOUR SIGNING, LOCATION 2 L SUM 1

* JI701003 DETOUR SIGNING, LOCATION 3 L SUM 1

* JI703996

TEMPORARY PAVEMENT MARKING TAPE

REMOVAL

SQ FT 17,698

* JI704001

TEMPORARY CONCRETE BARRIER, CROSS-

BOLT CONNECTION

FOOT 1,975.0

* JI704006

RELOCATE TEMPORARY CONCRETE

BARRIER, CROSS-BOLT CONNECTION

FOOT 1,812.5

* JI781000 RAISED PAVEMENT LANE MARKER EACH 16

* JI781010

RAISED PAVEMENT LANE MARKER

REFLECTOR

EACH 182

Addendum No. 4 P - 10 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

** JS120100

TRAILER MOUNTED FULL MATRIX PORTABLE

CHANGEABLE MESSAGE SIGNS

EACH 1

** JS120710 ENERGY ATTENUATOR EACH 1

** JS120715 ENERGY ATTENUATOR CONCRETE PAD SQ FT 121

* JS121200 LOW PRESSURE EPOXY INJECTION FOOT 250

** JS121300 HIGH PRESSURE EPOXY INJECTION FOOT 4

** JS280050 SILT FENCE FOOT 1,555

** JS280051 RE-ERECT SILT FENCE FOOT 389

** JS280210

FILTER FABRIC INLET PROTECTION, BASKET

TYPE

EACH 8

* JS503160

DIAMOND GRINDING AND SURFACE

SMOOTHNESS FOR BRIDGE SECTIONS

SQ YD 2,978

** JS601325

PIPE UNDERDRAINS, FABRIC LINED TRENCH

8"

FOOT 613

** JS630002

GALVANIZED STEEL PLATE BEAM GUARDRAIL,

TYPE A 6 FOOT POSTS

FOOT 650

** JS631130 TRAFFIC BARRIER TERMINAL, TYPE T6 EACH 2

** JS631135 TRAFFIC BARRIER TERMINAL, TYPE T6B EACH 2

** JS670C00 FIELD OFFICE, TYPE C CAL MO 12

** JS671020 MOBILIZATION, TOLLWAY (MODIFIED) L SUM 1

* JS701010 MAINTENANCE OF TRAFFIC L SUM 1

* JS725000 TERMINAL MARKER - DIRECT APPLIED EACH 4

Addendum No. 4 P - 11 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

** JS780JA1

GROOVING FOR RECESSED PAVEMENT

MARKING LINES, 5" GROOVE

FOOT 15,343

** JS780JC1

GROOVING FOR RECESSED PAVEMENT

MARKING LINES, 7" GROOVE

FOOT 5,100

** JS780JE1

GROOVING FOR RECESSED PAVEMENT

MARKING LINES, 11" GROOVE

FOOT 3,114

* JS782014 GUARDRAIL BARRIER REFLECTORS, TYPE B EACH 27

** JS782022 BARRIER WALL REFLECTORS, TYPE C EACH 242

* JT130726 MAINTAIN ITS EQUIPMENT – RWIS EACH 1

* JT131153

REMOVE ROADWAY WEATHER INFORMATION

SYSTEM

EACH 1

* JT202009 NON-SPECIAL WASTE DISPOSAL, TYPE 1 CU YD 1,109

* JT211A11 SUBGRADE AGGREGATE 12 IN. CU YD 185

* JT250432

SEEDING, CLASS 2E SALT TOLERANT

ROADSIDE MIX (SPECIAL)

ACRE 0.75

* JT250442

SEEDING, CLASS 4F NATIVE GRASS LOW

PROFILE MIX (SPECIAL)

ACRE 1.00

* JT311050 CAPPING AGGREGATE CU YD 63

* JT501729 PROTECTIVE SHIELD SQ YD 934

* JT503010 DECK SLAB REPAIR (PARTIAL) SQ YD 5

* JT503040

STRUCTURAL REPAIR OF CONCRETE (DEPTH

EQUAL TO OR LESS THAN 5 IN.)

SQ FT 432

* JT503041

STRUCTURAL REPAIR OF CONCRETE (DEPTH

GREATER THAN 5 IN.)

SQ FT 6

* JT503100 FIBER WRAP REPAIR SQ FT 83

Addendum No. 4 P - 12 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

* JT503102 BEAM END ENCASEMENT EACH 15

* JT503401 FAST DECK SLAB REPAIR (PARTIAL) SQ YD 36

* JT524010 APPLY CONCRETE SEALANT SQ FT 2,937

* JT524015 BRIDGE DECK CONCRETE SEALER SQ FT 40,228

* JT525020

BRIDGE EXPANSION JOINTS, REPLACEMENT

AND RECONSTRUCTION, 3"

FOOT 90

* JT525025 ELASTOMERIC CONCRETE HEADINGS CU FT 2

* JT525130 BONDED PREFORMED JOINT SEAL, 3 IN. FOOT 202

* JT669030 EARTHWORK CONSTRUCTION PLAN L SUM 1

* JT669040 EARTHWORK FINAL CONSTRUCTION REPORT L SUM 1

* JT780300

MULTI-POLYMER PAVEMENT MARKING - LINE

4"

FOOT 15,343

* JT780310

MULTI-POLYMER PAVEMENT MARKING - LINE

6"

FOOT 5,100

* JT780320

MULTI-POLYMER PAVEMENT MARKING - LINE

10"

FOOT 3,114

* JT780325

MULTI-POLYMER PAVEMENT MARKING - LINE

12"

FOOT 479

* JT783005

WATERBLAST PAVEMENT MARKING REMOVAL

WITH VACUUM RECOVERY

SQ FT 10,739

* JT783007 RAISED PAVEMENT LANE MARKER REMOVAL EACH 26

* JT783009

RAISED PAVEMENT LANE MARKER,

REFLECTOR REMOVAL

EACH 182

* JT830051

GROUND MOUNTED LIGHT POLE,

GALVANIZED STEEL, 50 FT., WITHOUT MAST

ARM

EACH 1

Addendum No. 4 P - 13 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

TOTAL AMOUNT OF CORE WORK

* JT155001 CONTRACTOR'S QUALITY PROGRAM L SUM 1 $ 260,000.00 $ 260,000.00

* JT151500

CONTRACT ADJUSTMENT ALLOWANCE FOR

TEMPERATURE CONTROL OF CONCRETE

UNIT 25,000 $ 1.00 $ 25,000.00

* JT154002

DISPOSAL OF UNIDENTIFIED HAZARDOUS

WASTE

UNIT 10,000 $ 1.00 $ 10,000.00

* JT154008

UNFORESEEN ADDITIONAL MAINTENANCE OF

TRAFFIC

UNIT 10,000 $ 1.00 $ 10,000.00

* JT154023

CONTRACT ALLOWANCE FOR

EROSION/LANDSCAPE RESTORATION

UNIT 10,000 $ 1.00 $ 10,000.00

* JT154025

CONTRACT ALLOWANCE FOR ROADWAY

WEATHER INFORMATION SYSTEM SENSOR

REPLACEMENT

UNIT 2,000 $ 1.00 $ 2,000.00

* JT154049

CONTRACT ALLOWANCE FOR INCENTIVE

PAYMENT OF PAVEMENT SURFACE

SMOOTHNESS

UNIT 4,000 $ 1.00 $ 4,000.00

* JT154067

CONTRACT ALLOWANCE FOR

CONSTRUCTIONWORKS APPRENTICES

UNIT 100,000 $ 1.00 $ 100,000.00

* JT154079

CONTRACT ALLOWANCE FOR ILLINOIS STATE

POLICE SERVICES

UNIT 10,000 $ 1.00 $ 10,000.00

* JT154118 ALLOWANCE FOR UNFORESEEN CONDITIONS UNIT 25,000 $ 1.00 $ 25,000.00

* JT154193

ALLOWANCE FOR UNFORESEEN RELOCATION

OF FIBER OPTIC FACILITIES

UNIT 25,000 $ 1.00 $ 25,000.00

999NEG04

NON-COMPLIANCE WITH TOLLWAY

MAINTENANCE OF TRAFFIC PER TOLLWAY

SUPPL. SPEC. 701.08(a)

INC/DAY (2,500.00)$

999NEG05

FAILURE TO RESPOND TO RE-ESTABLISH

DEVICES PER TOLLWAY SUPPL. SPEC.

701.08(b)

OCCUR (2,500.00)$

999NEG06

FAILURE TO REPAIR IMPACT ATTENUATORS,

TEMPORARY PER TOLLWAY SUPPL. SPEC.

701.08(c)

OCCUR (2,500.00)$

999NEG07

LOSS OR DAMAGE TO TOLLWAY OWNED

DEVICES PER TOLLWAY SUPPL. SPEC.

701.08(d)

SQ FT (100.00)$

999NEG08

FAILURE TO OPEN TRAFFIC LANES TO

TRAFFIC PER TOLLWAY SUPPL. SPEC.

701.08(e)(a)

15 MINUTES (3,000.00)$

NEGATIVE

Addendum No. 4 P - 14 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

999NEG09

FAILURE TO OPEN TRAFFIC LANES TO

TRAFFIC PER TOLLWAY SUPPL. SPEC.

701.08(e)(b)

15 MINUTES (5,000.00)$

999NEG23

DAMAGES TO ILLINOIS TOLLWAY'S

OPERATIONAL FACILITIES PER S.P. 115.5 -

REAGAN MEMORIAL WEST

OCCUR (4,000.00)$

999NEG30

DAMAGES TO ILLINOIS TOLLWAY'S

OPERATIONAL FACILITIES PER S.P. 115.5 - ALL

ROADWAYS OFF-PEAK

OCCUR (2,000.00)$

999NEG31

DAMAGE TO ELECTRICAL FACILITIES PER

TOLLWAY SUPPL. SPEC. 107.30 (b)

INC/DAY (1,000.00)$

999NEG32

LIQUIDATED DAMAGES FOR DELAY IN

SUBMITTAL OF PROGRESS SCHEDULE PER

TOLLWAY SUPPL. SPEC. 108.02 (e)

DAY (300.00)$

999NEG33

NON-COMPLIANCE WITH EROSION AND

SEDIMENT CONTROL PER TOLLWAY SUPPL.

SPEC. 280.02 (2) (1)

INC/DAY (1,000.00)$

999NEG34

NON-COMPLIANCE WITH RESPONSIBILITY

FOR CONSTRUCTION HAULING EQUIPMENT

PER TOLLWAY SUPPL. SPEC. 105.15

DAY (1,000.00)$

999NEG36

FAILURE TO COMPLY WITH OCCUPANCY

DATE OR PROVIDE COMPLETE FACILITIES.

FIELD OFFICE OR LAB PER TOLLWAY SUPPL.

SPEC. 670.01 (b)

DAY (500.00)$

999NEG44

LIQUIDATED DAMAGES FOR NON-

COMPLETION PER S.P. 105.1.1

CAL DAY (6,000.00)$

999NEG45

LIQUIDATED DAMAGES FOR NON-

COMPLETION PER S.P. 105.1.2

CAL DAY (7,500.00)$

999NEG46

LIQUIDATED DAMAGES FOR NON-

COMPLETION PER S.P. 105.1.3

CAL DAY (7,500.00)$

999NEG47

LIQUIDATED DAMAGES FOR NON-

COMPLETION PER S.P. 105.1.4

CAL DAY (7,500.00)$

999NEG48

LIQUIDATED DAMAGES FOR NON-

COMPLETION PER S.P. 105.1.5

CAL DAY (7,500.00)$

999NEG49

DAMAGE TO FIBER OPTIC UTILITIES PER S.P.

115.3

OCCUR (10,000.00)$

999NEG53

NON-COMPLIANCE WITH CONTRACTOR

QUALITY PROGRAM SPECIAL PROVISION

OCCUR (1,000.00)$

999NEG54

DAMAGE TO TOLLWAY MULTI-MODE CABLE,

DMS SIGNS, CAMERAS,

TELECOMMUNICATION, CABLE, ELECTRICAL,

WATER AND SEWER PER S.P. 115.4

OCCUR (1,000.00)$

999ADJ45

CONSTRUCTIONWORKS APPRENTICES WAGE

RATE PAYMENT

HOUR $ 15.00

999ADJ46 ARROW BOARD EACH $ 13.32

ADJUSTMENTS

Addendum No. 4 P - 15 February 5, 2026RR

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

999ADJ47 ARROW BOARD (WINTER RATE) EACH $ 19.98

999ADJ48 TYPE I OR TYPE II BARRICADE EACH $ 1.00

999ADJ49 TYPE I OR TYPE II BARRICADE (WINTER RATE) EACH $ 1.50

999ADJ50 TYPE III BARRICADE EACH $ 2.35

999ADJ51 TYPE III BARRICADE (WINTER RATE) EACH $ 3.53

999ADJ52 PLASTIC DRUM EACH $ 1.25

999ADJ53 PLASTIC DRUM (WINTER RATE) EACH $ 2.34

999ADJ54 FLASHER LIGHT EACH $ 0.20

999ADJ55 FLASHER LIGHT (WINTER RATE) EACH $ 0.30

999ADJ56 STEADY BURN LIGHT EACH $ 0.30

999ADJ57 STEADY BURN LIGHT (WINTER RATE) EACH $ 0.45

999ADJ58 HI-INTENSITY LIGHT, SIGN MOUNTED EACH $ 1.70

999ADJ59

HI-INTENSITY LIGHT, SIGN MOUNTED

(WINTER RATE)

EACH $ 2.55

999ADJ60 CMS, SOLAR POWERED EACH $ 45.70

999ADJ61 CMS, SOLAR POWERED (WINTER RATE) EACH $ 68.55

999ADJ62 SIGNS, WORK ZONE EACH $ 2.00

999ADJ63 SIGNS, WORK ZONE (WINTER RATE) EACH $ 3.00

Addendum No. 4 P - 16 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

999ADJ64

TEMPORARY MODULAR GLARE SCREEN (12.5

FT. SECTION)

UNIT $ 0.60

999ADJ65

TEMPORARY CONCRETE BARRIER (12.5 FT.

SECTION)

UNIT $ 0.83

999ADJ66

TEMPORARY CONCRETE BARRIER (10.0 FT.

SECTION)

UNIT $ 0.50

999ADJ67

TEMPORARY CONCRETE BARRIER, CROSS

BOLT CONNECTION (12.5 FT. SECTION)

UNIT $ 1.47

999ADJ68 TEMPORARY SAND MODULE ATTENUATOR EACH $ 18.33

999ADJ69

IMPACT ATTENUATOR, TEMPORARY (SEVERE

USE, NARROW), TEST LEVEL 3

EACH $ 18.33

999ADJ70

IMPACT ATTENUATOR, TEMPORARY (SEVERE

USE, WIDE), TEST LEVEL 3

EACH $ 18.33

999ADJ71

TEMPORARY INFORMATION SIGNING-

GROUND MOUNTED, 24 SQ FT IN AREA OR

LESS

SQ FT $ 0.25

999ADJ72

TEMPORARY INFORMATION SIGNING-

GROUND MOUNTED, GREATER THAN 24 SQ

FT IN AREA

SQ FT $ 0.25

999ADJ73

TEMPORARY INFORMATION SIGNING-

OVERHEAD, 24 SQ FT IN AREA OR LESS

SQ FT $ 0.25

999ADJ74

TEMPORARY INFORMATION SIGNING-

OVERHEAD, GREATER THAN 24 SQ FT IN

AREA

SQ FT $ 0.25

TOTAL AMOUNT OF CONTINGENCY WORK + CONTRACTOR'S QUALITY PROGRAM (CQP) $ 481,000.00

BID CREDIT

AWARD CRITERIA

TOTAL AMOUNT OF CORE WORK + TOTAL AMOUNT OF CONTINGENCY WORK +

CONTRACTOR'S QUALITY PROGRAM = TOTAL AMOUNT OF BASE BID

Addendum No. 4 P - 17 February 5, 2026

NO.

DESIGNATION UNIT QUANTITY

UNIT PRICE

DOLLAR

AMOUNT

DOLLAR

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY

CONTRACT RR-25-2022

MILE POST 53.9 TO MILE POST 74.3

SCHEDULE OF PRICES

BRIDGE REHABILITATION

REAGAN MEMORIAL TOLLWAY (I-88)

IL RTE 26 TO STEWARD CREEK

S.P. COLUMN LEGEND

INDICATES SPECIAL PROVISION (PROJECT SPECIFIC OR TOLLWAY STANDARD) *

INDICATES TOLLWAY SUPPLEMENTAL SPECIFICATIONS **

INDICATES IDOT SUPPLEMENTAL SPECIFICATIONS AND RECURRING SPECIAL PROVISIONS ***

INDICATES IDOT BDE SPECIAL PROVISION BDE

INDICATES IDOT GBSP SPECIAL PROVISION GBSP

INDICATES DISTRICT 1 SPECIAL PROVISION D1

Note 1: The Contractor should leave the unit price value blank. The unit price will be entered by the Tollway after receipt of bids.

Addendum No. 4 P - 18 February 5, 2026

Contract RR-25-2022 J-4R February 5, 2026

701101-05 OFF-ROAD OPERATIONS, MULTILANE, 15' (4.5 M) TO 24" (600 MM)

FROM PAVEMENT EDGE

701106-02 OFF-ROAD OPERATIONS, MULTILANE, MORE THAN 15' (4.5 M)

AWAY

701201-05 LANE CLOSURE, 2L, 2W, DAY ONLY, FOR SPEEDS ≥ 45 MPH

701206-05 LANE CLOSURE, 2L, 2W, NIGHT ONLY, FOR SPEEDS ≥ 45 MPH

701301-04 LANE CLOSURE, MULTILANE, INTERMITTENT OR MOVING OPER.,

FOR SPEED ≥ 45 MPH

701421-08 LANE CLOSURE, MULTILANE, DAY OPERATIONS ONLY FOR

SPEEDS ≥ 45 MPH TO 55 MPH

701501-06 URBAN LANE CLOSURES, 2L, 2W, UNDIVIDED

701901-10 TRAFFIC CONTROL DEVICES

S.P. 104 NOTICE TO PROCEED/COMMENCEMENT OF ON-SITE WORK

In accordance with Article 103.08 of the Illinois Tollway Supplemental Specifications, it is anticipated the Notice to Proceed will be issued after the Contract is approved by all parties; including a work commencement date no earlier than May 18, 2026. The Illinois Tollway will not issue the Notice to Proceed until all documents required by the Contract, including bonding and insurance requirements, are submitted by the Contractor, and approved by the

S.P. 103 CONTRACT COMPLETION DATE, SUBSTANTIAL AND INTERIM

COMPLETION DATE

S.P. 103.1 CONTRACT COMPLETION DATE

The Contractor shall complete all work under this Agreement for the performance of Contract RR-25-2022 on or before 11:59 p.m. on October 8, 2027, and as specified in Article 108.05 of the Illinois Tollway Supplemental Specifications.

S.P. 103.2 SUBSTANTIAL COMPLETION DATE

The Contractor shall have completed all roadway and bridge work, shoulder work, installation of permanent pavement markings, and establishment of the traffic lanes to the final proposed traffic lane configuration such that permanent lane closures are no longer required under this this Agreement for the performance of Contract RR-25-2022 on or before 11:59 p.m. on September 8, 2027.

S.P. 103.3 INTERIM COMPLETION DATE

The I-88 Westbound entrance ramp at IL 26 closure shall not exceed 72 hours in Stage 1. The ramp may be opened between operations on BN 1238, if required, so long as the cumulative closure duration does not exceed 72 hours in Stage 1.

S.P. 103.4 INTERIM COMPLETION DATE

The I-88 Westbound entrance ramp at IL 26 closure shall not exceed 72 hours in Stage 2. The ramp may be opened between operations on BN 1238, if required, so long as the cumulative closure duration does not exceed 72 hours in Stage 2.

S.P. 104 NOTICE TO PROCEED/COMMENCEMENT OF ON-SITE WORK

S.P. 103.5 INTERIM COMPLETION DATE

All work on bridges other than the US-52 bridges (BN 1233 and (BN 1234) shall be completed by October 12, 2026.

Contract RR-25-2022 J-5R February 5, 2026

S.P. 106 COOPERATION WITH UTILITIES AND OTHERS

NOT USED

S.P. 105.2 COMPLETION INCENTIVE PAYMENT PLAN(S)

In accordance with the provisions of Article 108.09 of the Illinois Tollway Supplemental Specifications, the Contractor shall pay to the Illinois Tollway the sum of $7,500.00 per day, as liquidated damages for each and every calendar day beyond the Substantial Completion Date stipulated in S.P. 103.2 that the work, or any part thereof, remains incomplete.

sum of $7,500.00 per day, as liquidated damages for each and every calendar day beyond the Interim Completion Date stipulated in S.P. 103.5 that the work, or any part thereof, remains incomplete.

S.P. 105.1.5 Liquidated Damages for Non-Completion Per S.P. 103.5 sum of $7,500.00 per day, as liquidated damages for each and every calendar day beyond the Interim Completion Date stipulated in S.P. 103.4 that the work, or any

S.P. 105.1.4 Liquidated Damages for Non-Completion Per S.P. 103.4 sum of $7,500.00 per day, as liquidated damages for each and every calendar day beyond the Interim Completion Date stipulated in S.P. 103.3 that the work, or any

S.P. 105.1.3 Liquidated Damages for Non-Completion Per S.P. 103.3

S.P. 105.1.1 Liquidated Damages for Non-Completion Per S.P. 103.1 sum of $6,000.00 per day, as liquidated damages for each and every calendar day beyond the Completion Date stipulated in S.P. 103.1 that the work, or any part thereof, remains incomplete.

S.P. 105 LIQUIDATED DAMAGES FOR DELAY(S) AND INCENTIVE PLAN(S)

S.P. 105.1 LIQUIDATED DAMAGES

Work, Maintenance of Traffic, and/or detours cannot begin prior to April 15, 2027 at I-88 bridges (BN 1233 and BN 1234) over US-52.

Illinois Tollway. A Time Extension Request shall not be considered should the Notice to Proceed be delayed due to the failure of the Contractor to submit contract documents in compliance with the specified requirements. There shall be no damages or additional compensation due the Contractor for delays, if any, in issuing the Notice to Proceed.

S.P. 104.1 WORK RESTRICTIONS

S.P. 105.1.2 Liquidated Damages for Non-Completion Per S.P. 103.2

Contract RR-25-2022 J-7R February 5, 2026

The Contractor shall notify the Engineer 14 calendar days prior to commencement of any work on or affecting a State highway, so as to provide the opportunity to alert the motoring public of possible delays. The Engineer or Corridor Construction Manager will notify IDOT of the start of work.

The Contractor shall indemnify and hold harmless IDOT in accordance with the indemnification provided to IDOT in Article 107.26 of IDOT’s Standard Specifications for Road and Bridge Construction in effect at the time of construction. Such indemnity shall not be limited to amounts recoverable in the Court of Claims or by any insurance or bonds to be provided by said Contractor. A highway permit is required to be secured from IDOT for access to IDOT right of way for the purposes of completing the work. The contractor will not be allowed access to IDOT right of way prior to receiving the Highway Permit from IDOT. The contractor shall include the date of anticipated IDOT Permit approval on the Baseline Progress Schedule and on the Revised Baseline Schedule submitted as required by Article 108.02 of the Tollway Supplemental Specifications. The IDOT Highway Permit is anticipated to be secured no earlier than July 1, 2026. The Contractor will not be allowed access to IDOT right-of-way prior July 1, 2026 and will not be due additional compensation now will an extension of time be granted should access to IDOT right-of-way not be allowed prior to July 1, 2026.

For purposes of obtaining the IDOT Highway Permit, the Contractor shall submit the following to the Engineer upon request:

1. IDOT Highway Permit Form OPER 1045 executed by the Contractor in triplicate.

2. IDOT Individual Highway Permit Bond Form OPER 1046 executed by the Contractor in triplicate. The bond amount required for the contract is $10,000.

3. Certificate of Liability Insurance listing IDOT as an additional insured; See S.P.

107 for other agencies required to be included as additional insureds.

4. Expressway Flow Sheet providing contact information.

5. Traffic Control Authorization BSE 725 form providing contact information.

Where State highways will be affected by the construction of the Toll Highway, the Contractor shall have responsibility for the installation, maintenance, relocation and removal of temporary and permanent traffic control devices along the State highways in accordance with IDOT Standards and Specifications.

The Contractor shall be required to meet regularly with IDOT and Illinois Tollway representatives to keep them abreast of traffic phase changes and shall provide a minimum 24-hour notice of said changes. The Contractor shall be required to comply with all IDOT traffic control requirements, including the specifications for lane closures contained in the final plans and specifications. Such lane closures must be reviewed and approved by IDOT prior to implementation. The Contractor will be required to request written authorization through the Traffic Control Supervisor a minimum of two (2) weeks prior to any traffic pattern changes or lane closures and provide detailed description of the traffic pattern revisions and respective durations in his/her authorization request. Upon receipt of the permit and authorization, the Contractor shall submit a copy to the Engineer for recording.

The IDOT Traffic Control Supervisor may be contacted at:

RR-25-2022

I L L I N O I S 6 0 5 1 5

D O W N E R S G R O V E, 2 7 0 0 O G D E N A V E N U E

DRAWING NO.

OF

DESCRIPTIONDATENO.

DESIGNED BY: DATE:

DATE:

CHECKED BY: DATE:

DRAWN BY:

THE ILLINOIS STATE TOLL HIGHWAY AUTHORITY CONTRACT NO.

U

S E

R N

A M

E

P L O

T D

A T E

P L O

T T E

D B

Y p w ie i-p w .b e n tl e y .c o m :i e i-p w -0

D o c u m e n ts P ro je c ts P -2

-4

-0

P

S B -1 C o n tr a c t4

I -8

B ri d g e R e h a b D

G N C

A D

D S h e e ts -S

H T -S

C H -0

-I

E I.

d g n

F

IL

E N

A M

E

M O

D E L N

A M

E

D e fa u l t

P L O

T D

R

IV

E R

P L T

D R

V L

P E

N T

A B

L E

P E

N T

B L L

P L O

T T

IM

E

:3

:4

A

M

PAGE SIZE:PLOT SCALE: 50.0000 ' / in. $SHEETSIZE$

REVISIONS

SUGGESTED PROGRESS SCHEDULE

1.

2.

TO MEET THE REQUIREMENTS OF THE CONTRACT DOCUMENTS.

IT IS THE CONTRACTOR'S RESPONSIBILITY TO PROVIDE MANPOWER AND EQUIPMENT

SPECIFICATIONS, SPECIAL PROVISIONS OR OTHER CONTRACT DRAWINGS SHALL GOVERN.

THE SPECIFICATIONS, SPECIAL PROVISIONS OR OTHER CONTRACT DRAWINGS, THE

IF ANY DISCREPANCIES EXIST BETWEEN THIS SUGGESTED PROGRESS SCHEDULE AND

THE SUGGESTED SCHEDULE DURATION.

SCHEDULE IS TO ILLUSTRATE THE WORK CAN REASONABLY BE PREFORMED WITHIN

SPECIFICATIONS ARTICLE 108.02. THE INTENT OF THIS SUGGESTED PROGRESS

THE CONTRACTOR'S BASELINE SCHEDULE AS REQUIRED IN TOLLWAY SUPPLEMENTAL

THIS IS ONLY A SUGGESTED PROJECT SCHEDULE AND IS NOT TO BE CONSIDERED

3.

NOTES

SPS-1

SUGGESTED PROGRESS SCHEDULE

KK

KK

RB 07/08/2025

07/08/2025

07/08/2025

4 ADDENDUM NO. 4

2/5/2026