191BWC19B0002_001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE RATING

2. AMENDMENT/MODIFICATION NO.

3. EFFECTIVE DATE

08/19/2019

4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

IBWC_CODE

International Boundary and Water Commission

(IBWC)

USIBWC - ACQUISITIONS DIV

4191 NORTH MESA ST

EL PASO, TX 79902-1441

Philip Johnson

NAME

TEL.

johnsonpk@state.gov

EMAIL

6. ISSUED BY IBWC_CODE

International Boundary and Water Commission (IBWC)

USIBWC - ACQUISITIONS DIV

4191 NORTH MESA ST

EL PASO, TX 79902-1441

7. ADMINISTERED BY (If other than Item 6)

9A. AMENDMENT OF SOLICITATION NO.

191BWC19B0002

CONTACT DUNS

CODE FACILITY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, country, state and ZIP Code) (X)

X 9B. DATED (SEE ITEM 11)

08/19/2019

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X XThe above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended, Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing items 8 and 15, and returning __2__copies of the amendment;(b)By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.X

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

The purpose of this Amendment 001 is to correct the line item quantities and make minor changes to the terms and conditions.

CLIN 002 change from 5,000 LF to 2,340 SY CLIN 003 change from 2,500 LF to 3,260 SY

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

Philip Johnson

(Signature of person authorized to sign)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED

By (Signature of Contracting Officer)

16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

NSN 7540-01-152-8070

Previous edition unusable

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

191BWC19B0002

Table of Contents

Section Description Page Number

F Deliveries or Performance 52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984)

H Special Contract Requirements H.08 Construction Safety Requirements (DEC 2015) H.08 Construction Safety Requirements (DEC 2015) H.13 Time Extensions for Unusually Severe Weather (DEC 2015) H.13 Time Extensions for Unusually Severe Weather (DEC 2015)

I Contract Clauses

52.236-21 Alt II Specifications and Drawings for Construction (Feb 1997) DELETED

Section F- Deliveries or Performance

52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor re-ceives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 180.* The time stated for completion shall include final cleanup of the premises.

(End of clause)

* 180 calendar days for construction; 240 calendar days for re-vegetation; 420 calendar days for total contract performance.

Section H- Special Contract Requirements

Clause H.08 Construction Safety Requirements (DEC 2015) was deleted or updated.

H.08 Construction Safety Requirements (DEC 2015)

(a) Offerors shall obtain and review the current Construction Industry "OSHA Safety and Health Standards (29 CFR 1926)" and the U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, dated November 30, 2014 (see Technical Spe-cifications, Division 01- General Requirements, Specification 01.35.23-Safety), prior to submitting offers and preparing required safety program. Offerors shall utilize these standards in preparing required safety programs.

(b) The Contractor shall comply with all pertinent provisions of the U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, dated November 30, 2014. This manual is available from:

http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf

(c) In the event there is a conflict between the requirements contained in OSHA Safety and Health Standards (29 CFR 1926), U.S.

Army Corps of Engineers Safety and Health Requirements Manual (EM 385-1-1), specifications paragraphs, Contractor's approved safety program, or referenced safety and health standards, the more stringent requirement will prevail.

[End of Clause]

H.13 Time Extensions for Unusually Severe Weather (DEC 2015)

(a) This provision specifies the procedures for the determination of time extensions for unusually severe weather in accordance with the Contract Clause, 52.249-10, Default (Fixed-Price Construction). The listing below defines the monthly anticipated adverse weath-er for the contract period and is based on NOAA or similar data for the geographical location of the project. The weather conditions for this contract is based upon the weather station at New Mexico State University 290131.

Monthly Anticipated Adverse Weather Calendar Days Jan Feb Mar Apr May Jun Jul Aug Sep Oct Nov Dec Annual

1 1 1 1 1 1 4 4 3 2 1 2 22

(b) Determination:

(1) The above schedule of anticipated adverse weather will constitute the base line for monthly (or portion thereof) weather time evaluations. Upon acknowledgment of the Notice to Proceed and continuing throughout the contract on a monthly basis, actual ad-verse weather days will be recorded on a calendar day basis (including weekends and holidays) and compared to the monthly anticip-ated weather in subparagraph (a) above. For purposes of subparagraph (b), the term actual adverse weather days shall include days impacted by actual adverse weather days.

(2) The number of actual adverse weather days shall be calculated chronologically from the first to the last day in each month.

Once the number of actual adverse weather days anticipated in subparagraph (a) above have been incurred, the Contracting Officer will examine any subsequently occurring adverse weather days to determine whether a Contractor is entitled to a time extension.

These subsequently occurring adverse weather days must prevent work for 50 percent or more of the Contractor's work day and delay work critical to the timely completion of the project. These subsequently occurring adverse weather days must fall on a scheduled work day to count towards the entitled time extension. The Contracting Officer will convert any delays to meeting the above require-ments to calendar days and issue a modification in accordance with the Contract Clause, 52.249-10, Default (Fixed-Price Construc-tion).

(3) The Contractor shall not request a modification to the contract to add the adverse weather delay days more frequently than every fourth month after the start of mobilization.

(c) The Contractor's progress schedule must reflect the above anticipated adverse weather delays on all weather dependent activities.

[End of Clause]

Clause H.13 Time Extensions for Unusually Severe Weather (DEC 2015) was deleted or updated.