Solicitation_-_FA461019RA013.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

FA461019RA013

Section A - Solicitation/Contract Form

Section B - Supplies or Services and Prices/Cost

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

0001 XUMU181001B, Repair Fire Alarm Control Panel at VAFB (AETC/Bldg 8195) in accordance with the statement of work and all other attachments identified in section J Product Service Code: Z2JZ Firm Fixed Price

CIN: F4D3D88340A0010000AA

1.0 Job

Section C - Description/Specifications/Statement of Work

Requirements Replace Fire Alarm, B8195

Section D - Packaging and Marking

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. 1996-08 52.246-16 Responsibility for Supplies. 1984-04 0001 Inspection and Acceptance Location

Both Destination Instructions: N/A

DoDAAC: F4D3D8 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

30 CES CEND

1172 ICELAND AVE BLDG 11433

AF BPN NO MILSBILLS PROCESSES

VANDENBERG AFB, CA 93437 6011

United States

OfficeCode:

Barry Stringer Telephone: 805-276-2429 Email: barry.stringer@us.af.mil

Section F - Deliveries or Performance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.242-17 Government Delay of Work. 1984-04

FAR Clauses Incorporated by Full Text

52.211-10 Commencement, Prosecution, and Completion of Work. 1984-04 As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction. Commencement, Prosecution, and Completion of Work (Apr 1984) The Contractor shall be required to (a)commence work under this contract within __10__ [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b)prosecute the work diligently, and (c)complete the entire work ready for use not later than __365__.* The time stated for completion shall include final cleanup of the premises. * The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

DFARS Clauses Incorporated by Full Text

252.247-7023 Transportation of Supplies by Sea. 2019-02 Basic. As prescribed in 247.574(b) and (b)(1), use the following clause: TRANSPORTATION OF SUPPLIES BY SEABASIC (FEB 2019) (a) Definitions. As used in this clause Components means articles, materials, and supplies incorporated directly into end products at any level of manufacture, fabrication, or assembly by the Contractor or any subcontractor. Department of Defense (DoD) means the Army, Navy, Air Force, Marine Corps, and defense agencies. Foreign-flag vessel means any vessel that is not a U.S.-flag vessel. Ocean transportation means any transportation aboard a ship, vessel, boat, barge, or ferry through international waters. Subcontractor means a supplier, materialman, distributor, or vendor at any level below the prime contractor whose contractual obligation to perform results from, or is conditioned upon, award of the prime contract and who is performing any part of the work or other requirement of the prime contract. Supplies means all property, except land and interests in land, that is clearly identifiable for eventual use by or owned by the DoD at the time of transportation by sea.

(i) An item is clearly identifiable for eventual use by the DoD if, for example, the contract documentation contains a reference to a DoD contract number or a military destination. (ii) Supplies includes (but is not limited to) public works; buildings and facilities; ships; floating equipment and vessels of every character, type, and description, with parts, subassemblies, accessories, and equipment; machine tools; material; equipment; stores of all kinds; end items; construction materials;

and components of the foregoing. U.S.-flag vessel means a vessel of the United States or belonging to the United States, including any vessel registered or having national status under the laws of the United States. (b)(1) The Contractor shall use U.S.-flag vessels when transporting any supplies by sea under this contract. (2) A subcontractor transporting supplies by sea under this contract shall use U.S.-flag vessels if (i) This contract is a construction contract; or (ii) The supplies being transported are (A) Noncommercial items; or (B) Commercial items that (1) The Contractor is reselling or distributing to the Government without adding value (generally, the Contractor does not add value to items that it subcontracts for f.o.b. destination shipment); (2) Are shipped in direct support of U.S. military contingency operations, exercises, or forces deployed in humanitarian or peacekeeping operations; or (3) Are commissary or exchange cargoes transported outside of the Defense Transportation System in accordance with 10 U.S.C. 2643. (c) The Contractor and its subcontractors may request that the Contracting Officer authorize shipment in foreign-flag vessels, or designate available U.S.-flag vessels, if the Contractor or a subcontractor believes that (1) U.S.-flag vessels are not available for timely shipment; (2) The freight charges are inordinately excessive or unreasonable; or (3) Freight charges are higher than charges to private persons for transportation of like goods. (d) The Contractor must submit any request for use of foreign-flag vessels in writing to the Contracting Officer at least 45 days prior to the sailing date necessary to meet its delivery schedules. The Contracting Officer will process requests submitted after such date(s) as expeditiously as possible, but the Contracting Officer's failure to grant approvals to meet the shipper's sailing date will not of itself constitute a compensable delay under this or any other clause of this contract. Requests shall contain at a minimum (1) Type, weight, and cube of cargo; (2) Required shipping date; (3) Special handling and discharge requirements; (4) Loading and discharge points; (5) Name of shipper and consignee; (6) Prime contract number; and (7) A documented description of efforts made to secure U.S.-flag vessels, including points of contact (with names and telephone numbers) with at least two U.S.-flag carriers contacted. Copies of telephone notes, telegraphic and facsimile message or letters will be sufficient for this purpose. (e) The Contractor shall, within 30 days after each shipment covered by this clause, provide the Contracting Officer and the Maritime Administration, Office of Cargo Preference, U.S. Department of Transportation, 400 Seventh Street SW, Washington, DC 20590, one copy of the rated on board vessel operating carrier's ocean bill of lading, which shall contain the following information: (1) Prime contract number; (2) Name of vessel; (3) Vessel flag of registry; (4) Date of loading; (5) Port of loading; (6) Port of final discharge;

(7) Description of commodity; (8) Gross weight in pounds and cubic feet if available; (9) Total ocean freight in U.S. dollars;

and (10) Name of steamship company. (f) If this contract exceeds the simplified acquisition threshold, the Contractor shall provide with its final invoice under this contract a representation that to the best of its knowledge and belief (1) No ocean transportation was used in the performance of this contract; (2) Ocean transportation was used and only U.S.-flag vessels were used for all ocean shipments under the contract; (3) Ocean transportation was used, and the Contractor had the written consent of the Contracting Officer for all foreign-flag ocean transportation; or (4) Ocean transportation was used and some or all of the shipments were made on foreign-flag vessels without the written consent of the Contracting Officer. The Contractor shall describe these shipments in the following format: | || ITEM DESCRIPTION || CONTRACT LINE ITEMS || QUANTITY || || ____ || ____ || ____ || TOTAL || ____ || ____ || ____ | (g) If this contract exceeds the simplified acquisition threshold and the final invoice does not include the required representation, the Government will reject and return it to the Contractor as an improper invoice for the purposes of the Prompt Payment clause of this contract. In the event there has been unauthorized use of foreign-flag vessels in the performance of this contract, the Contracting Officer is entitled to equitably adjust the contract, based on the unauthorized use. (h) If the Contractor indicated in response to the solicitation provision, Representation of Extent of Transportation by Sea, that it did not anticipate transporting by sea any supplies;

however, after the award of this contract, the Contractor learns that supplies will be transported by sea, the Contractor shall (1) Notify the Contracting Officer of that fact; and (2) Comply with all the terms and conditions of this clause. (i) In the award of subcontracts, for the types of supplies described in paragraph (b)(2) of this clause, including subcontracts for commercial items, the Contractor shall flow down the requirements of this clause as follows: (1) The Contractor shall insert the substance of this clause, including this paragraph (i), in subcontracts that exceed the simplified acquisition threshold in part 2 of the Federal Acquisition Regulation. (2) The Contractor shall insert the substance of paragraphs (a) through (e) of this clause, and this paragraph (i), in subcontracts that are at or below the simplified acquisition threshold in part 2 of the Federal Acquisition Regulation.

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.204-7006 Billing Instructions. 2005-10 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2018-12 252.236-7000 Modification Proposals--Price Breakdown. 1991-12

FAR Clauses Incorporated by Full Text

52.236-22 Design Within Funding Limitations. 1984-04 As prescribed in 36.609-1(c), insert the following clause: Design Within Funding Limitations (Apr 1984) (a) The Contractor shall accomplish the design services required under this contract so as to permit the award of a contract, using standard Federal Acquisition Regulation procedures for the construction of the facilities designed at a price that does not exceed the estimated construction contract price as set forth in paragraph (c) of this clause. When bids or proposals for the construction contract are received that exceed the estimated price, the contractor shall perform such redesign and other services as are necessary to permit contract award within the funding limitation. These additional services shall be performed at no increase in the price of this contract. However, the Contractor shall not be required to perform such additional services at no cost to the Government if the unfavorable bids or proposals are the result of conditions beyond its reasonable control. (b) The Contractor will promptly advise the Contracting Officer if it finds that the project being designed will exceed or is likely to exceed the funding limitations and it is unable to design a usable facility within these limitations. Upon receipt of such information, the Contracting Officer will review the Contractor's revised estimate of construction cost. The Government may, if it determines that the estimated construction contract price set forth in this contract is so low that award of a construction contract not in excess of such estimate is improbable, authorize a change in scope or materials as required to reduce the estimated construction cost to an amount within the estimated construction contract price set forth in paragraph (c) of this clause, or the Government may adjust such estimated construction contract price. When bids or proposals are not solicited or are unreasonably delayed, the Government shall prepare an estimate of constructing the design submitted and such estimate shall be used in lieu of bids or proposals to determine compliance with the funding limitation. (c) The estimated construction contract price for the project described in this contract is $__100,000 and $250,000__. (End of clause)

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2018-12 As prescribed in 232.7004(b), use the following clause: WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause- Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization. Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF). Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system. Payment request and receiving report are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports. (b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports. (c) WAWF access. To access WAWF, the Contractor shall- (1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and (2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site. (d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the Web Based Training link on the WAWF home page at https://wawf.eb.mil/ (e) WAWF methods of document submission.

Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol. (f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order: (1) Document type. The Contractor shall submit payment requests using the following document type(s): (i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher. (ii) For fixed price line items (A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer. __Construction Invoice__ (Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.) (B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer. __F4D3D8__ (Contracting Officer: Insert either Invoice 2in1 or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request. (iv) For performance based payments, submit a performance based payment request. (v) For commercial item financing, submit a commercial item financing request. (2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract. (f) [Note: The Contractor may use a WAWF combo document type to create some combinations of invoice and receiving report in one step.] (3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system. Routing Data Table* | Field Name in WAWF || Data to be entered in WAWF || Pay Official DoDAAC || __F03000__ || Issue By DoDAAC || __FA4610__ || Admin DoDAAC || __FA4610__ || Inspect By DoDAAC || __FA4610 ext F4D3D8__ || Ship To Code || __FA4610__ || Ship From Code || __N/A__ || Mark For Code || __N/A__ || Service Approver (DoDAAC) || __FA4610 ext F4D3D8__ || Service Acceptor (DoDAAC) || __FA4610 ext F4D3D8__ || Accept at Other DoDAAC || __N/ A__ || LPO DoDAAC || __N/A__ || DCAA Auditor DoDAAC || __N/A__ || Other DoDAAC(s) || __N/A__ | (*Contracting Officer:

Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert See Schedule or Not applicable.)

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).) (4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable. (5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. (g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activitys WAWF point of contact. __damian.perez.1@us.af.mil__ (Contracting Officer: Insert applicable information or Not applicable.) (2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed. (End of clause)

Section H - Special Contract Requirements

DFARS Clauses Incorporated by Full Text

252.211-7003 Item Unique Identification and Valuation. 2016-03 As prescribed in 211.274-6(a)(1), use the following clause: ITEM UNIQUE IDENTIFICATION AND VALUATION (MAR 2016)

(a) Definitions. As used in this clause Automatic identification device means a device, such as a reader or interrogator, used to retrieve data encoded on machine-readable media. Concatenated unique item identifier means (1) For items that are serialized within the enterprise identifier, the linking together of the unique identifier data elements in order of the issuing agency code, enterprise identifier, and unique serial number within the enterprise identifier; or (2) For items that are serialized within the original part, lot, or batch number, the linking together of the unique identifier data elements in order of the issuing agency code; enterprise identifier; original part, lot, or batch number; and serial number within the original part, lot, or batch number. Data matrix means a two-dimensional matrix symbology, which is made up of square or, in some cases, round modules arranged within a perimeter finder pattern and uses the Error Checking and Correction 200 (ECC200) specification found within International Standards Organization (ISO)/International Electrotechnical Commission (IEC) 16022. Data qualifier means a specified character (or string of characters) that immediately precedes a data field that defines the general category or intended use of the data that follows. DoD recognized unique identification equivalent means a unique identification method that is in commercial use and has been recognized by DoD. All DoD recognized unique identification equivalents are listed at http://www.acq.osd.mil/dpap/pdi/uid/iuid_equivalents.html. DoD item unique identification means a system of marking items delivered to DoD with unique item identifiers that have machine-readable data elements to distinguish an item from all other like and unlike items. For items that are serialized within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier and a unique serial number.

For items that are serialized within the part, lot, or batch number within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier; the original part, lot, or batch number; and the serial number.

Enterprise means the entity (e.g., a manufacturer or vendor) responsible for assigning unique item identifiers to items.

Enterprise identifier means a code that is uniquely assigned to an enterprise by an issuing agency. Governments unit acquisition cost means (1) For fixed-price type line, subline, or exhibit line items, the unit price identified in the contract at the time of delivery; (2) For cost-type or undefinitized line, subline, or exhibit line items, the Contractors estimated fully burdened unit cost to the Government at the time of delivery; and (3) For items produced under a time-and-materials contract, the Contractors estimated fully burdened unit cost to the Government at the time of delivery. Issuing agency means an organization responsible for assigning a globally unique identifier to an enterprise, as indicated in the Register of Issuing Agency Codes for ISO/IEC 15459, located at http://www.aimglobal.org/?Reg_Authority15459. Issuing agency code means a code that designates the registration (or controlling) authority for the enterprise identifier. Item means a single hardware article or a single unit formed by a grouping of subassemblies, components, or constituent parts. Lot or batch number means an identifying number assigned by the enterprise to a designated group of items, usually referred to as either a lot or a batch, all of which were manufactured under identical conditions. Machine-readable means an automatic identification technology media, such as bar codes, contact memory buttons, radio frequency identification, or optical memory cards.

Original part number means a combination of numbers or letters assigned by the enterprise at item creation to a class of items with the same form, fit, function, and interface. Parent item means the item assembly, intermediate component, or subassembly that has an embedded item with a unique item identifier or DoD recognized unique identification equivalent.

Serial number within the enterprise identifier means a combination of numbers, letters, or symbols assigned by the enterprise to an item that provides for the differentiation of that item from any other like and unlike item and is never used again within the enterprise. Serial number within the part, lot, or batch number means a combination of numbers or letters assigned by the enterprise to an item that provides for the differentiation of that item from any other like item within a part, lot, or batch number assignment. Serialization within the enterprise identifier means each item produced is assigned a serial number that is unique among all the tangible items produced by the enterprise and is never used again. The enterprise is responsible for ensuring unique serialization within the enterprise identifier. Serialization within the part, lot, or batch number means each item of a particular part, lot, or batch number is assigned a unique serial number within that part, lot, or batch number assignment. The enterprise is responsible for ensuring unique serialization within the part, lot, or batch number within the enterprise identifier. Type designation means a combination of letters and numerals assigned by the Government to a major end item, assembly or subassembly, as appropriate, to provide a convenient means of differentiating between items having the same basic name and to indicate modifications and changes thereto. Unique item identifier means a set of data elements marked on items that is globally unique and unambiguous. The term includes a concatenated unique item identifier or a DoD recognized unique identification equivalent. Unique item identifier type means a designator to indicate which method of uniquely identifying a part has been used. The current list of accepted unique item identifier types is maintained at http:// www.acq.osd.mil/dpap/pdi/uid/uii_types.html. (b) The Contractor shall deliver all items under a contract line, subline, or exhibit line item. (c) Unique item identifier. (1) The Contractor shall provide a unique item identifier for the following: (i) Delivered items for which the Governments unit acquisition cost is $5,000 or more, except for the following line items: Contract Line, Subline, or Exhibit Line Item Number Item Description ____ ____ ____ (ii) Items for which the Governments unit acquisition cost is less than $5,000 that are identified in the Schedule or the following table: Contract Line, Subline, or Exhibit Line Item Number Item Description ____ ____ ____ (If items are identified in the Schedule, insert See Schedule in this table.)

(iii) Subassemblies, components, and parts embedded within delivered items, items with warranty requirements, DoD serially managed reparables and DoD serially managed nonreparables as specified in Attachment Number ____. (iv) Any item of special tooling or special test equipment as defined in FAR 2.101 that have been designated for preservation and storage for a Major Defense Acquisition Program as specified in Attachment Number ____. (v) Any item not included in (i), (ii), (iii), or (iv) for which the contractor creates and marks a unique item identifier for traceability. (2) The unique item identifier assignment and its component data element combination shall not be duplicated on any other item marked or registered in the DoD Item Unique Identification Registry by the contractor. (3) The unique item identifier component data elements shall be marked on an item using two dimensional data matrix symbology that complies with ISO/IEC International Standard 16022, Information technology International symbology specification Data matrix; ECC200 data matrix specification.

(4) Data syntax and semantics of unique item identifiers. The Contractor shall ensure that (i) The data elements (except issuing agency code) of the unique item identifier are encoded within the data matrix symbol that is marked on the item using one of the following three types of data qualifiers, as determined by the Contractor: (A) Application Identifiers (AIs) (Format Indicator 05 of ISO/IEC International Standard 15434), in accordance with ISO/IEC International Standard 15418, Information Technology EAN/UCC Application Identifiers and Fact Data Identifiers and Maintenance and ANSI MH 10.8.2 Data Identifier and Application Identifier Standard. (B) Data Identifiers (DIs) (Format Indicator 06 of ISO/IEC International Standard 15434), in accordance with ISO/IEC International Standard 15418, Information Technology EAN/UCC Application Identifiers and Fact Data Identifiers and Maintenance and ANSI MH 10.8.2 Data Identifier and Application Identifier Standard.

(C) Text Element Identifiers (TEIs) (Format Indicator 12 of ISO/IEC International Standard 15434), in accordance with the Air Transport Association Common Support Data Dictionary; and (ii) The encoded data elements of the unique item identifier conform to the transfer structure, syntax, and coding of messages and data formats specified for Format Indicators 05, 06, and 12 in ISO/IEC International Standard 15434, Information Technology Transfer Syntax for High Capacity Automatic Data Capture Media. (5) Unique item identifier. (i) The Contractor shall (A) Determine whether to (1) Serialize within the enterprise identifier; (2) Serialize within the part, lot, or batch number; or (3) Use a DoD recognized unique identification equivalent (e.g. Vehicle Identification Number); and (B) Place the data elements of the unique item identifier (enterprise identifier; serial number; DoD recognized unique identification equivalent; and for serialization within the part, lot, or batch number only: original part, lot, or batch number) on items requiring marking by paragraph (c)(1) of this clause, based on the criteria provided in MIL-STD-130, Identification Marking of U.S. Military Property, latest version; (C) Label shipments, storage containers and packages that contain uniquely identified items in accordance with the requirements of MIL-STD-129, Military Marking for Shipment and Storage, latest version; and (D) Verify that the marks on items and labels on shipments, storage containers, and packages are machine readable and conform to the applicable standards. The contractor shall use an automatic identification technology device for this verification that has been programmed to the requirements of Appendix A, MIL-STD-130, latest version. (ii) The issuing agency code (A) Shall not be placed on the item; and (B) Shall be derived from the data qualifier for the enterprise identifier. (d) For each item that requires item unique identification under paragraph (c)(1)(i), (ii), or (iv) of this clause or when item unique identification is provided under paragraph (c)(1)(v), in addition to the information provided as part of the Material Inspection and Receiving Report specified elsewhere in this contract, the Contractor shall report at the time of delivery, as part of the Material Inspection and Receiving Report, the following information: (1) Unique item identifier. (2) Unique item identifier type. (3) Issuing agency code (if concatenated unique item identifier is used). (4) Enterprise identifier (if concatenated unique item identifier is used). (5) Original part number (if there is serialization within the original part number). (6) Lot or batch number (if there is serialization within the lot or batch number). (7) Current part number (optional and only if not the same as the original part number). (8) Current part number effective date (optional and only if current part number is used). (9) Serial number (if concatenated unique item identifier is used). (10) Governments unit acquisition cost. (11) Unit of measure. (12) Type designation of the item as specified in the contract schedule, if any. (13) Whether the item is an item of Special Tooling or Special Test Equipment. (14) Whether the item is covered by a warranty. (e) For embedded subassemblies, components, and parts that require DoD item unique identification under paragraph (c)(1)(iii) of this clause or when item unique identification is provided under paragraph (c)(1) (v), the Contractor shall report as part of the Material Inspection and Receiving Report specified elsewhere in this contract, the following information: (1) Unique item identifier of the parent item under paragraph (c)(1) of this clause that contains the embedded subassembly, component, or part. (2) Unique item identifier of the embedded subassembly, component, or part.

(3) Unique item identifier type.** (4) Issuing agency code (if concatenated unique item identifier is used).** (5) Enterprise identifier (if concatenated unique item identifier is used).** (6) Original part number (if there is serialization within the original part number).** (7) Lot or batch number (if there is serialization within the lot or batch number).** (8) Current part number (optional and only if not the same as the original part number).** (9) Current part number effective date (optional and only if current part number is used).** (10) Serial number (if concatenated unique item identifier is used).** (11) Description. ** Once per item. (f) The Contractor shall submit the information required by paragraphs (d) and (e) of this clause as follows: (1) End items shall be reported using the receiving report capability in Wide Area WorkFlow (WAWF) in accordance with the clause at 252.232-7003. If WAWF is not required by this contract, and the contractor is not using WAWF, follow the procedures at http://dodprocurementtoolbox.com/site/uidregistry/. (2) Embedded items shall be reported by one of the following methods

(i) Use of the embedded items capability in WAWF; (ii) Direct data submission to the IUID Registry following the procedures and formats at http://dodprocurementtoolbox.com/site/uidregistry/; or (iii) Via WAWF as a deliverable attachment for exhibit line item number (fill in) ____, Unique Item Identifier Report for Embedded Items, Contract Data Requirements List, DD Form 1423. (g) Subcontracts. If the Contractor acquires by subcontract, any item(s) for which item unique identification is required in accordance with paragraph (c)(1) of this clause, the Contractor shall include this clause, including this paragraph (g), in the applicable subcontract(s), including subcontracts for commercial items. (End of clause)

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. 2010-10 52.203-18 Prohibition on Contracting with Entities that Require Certain Internal

Confidentiality Agreements or Statements-Representation.

2017-01

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

2017-01

52.204-9 Personal Identity Verification of Contractor Personnel. 2011-01 52.204-13 System for Award Management Maintenance. 2018-10 52.204-18 Commercial and Government Entity Code Maintenance. 2016-07 52.204-19 Incorporation by Reference of Representations and Certifications. 2014-12 52.204-22 Alternative Line Item Proposal. 2017-01 52.204-23 Prohibition on Contracting for Hardware, Software, and Services

Developed or Provided by Kaspersky Lab and Other Covered Entities.

2018-07

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. 2015-11 52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a

Felony Conviction under any Federal Law.

2016-02

52.211-5 Material Requirements. 2000-08 52.219-6 Deviation 2019- O0003

Notice of Total Small Business Set-Aside (DEVIATION 2019-O0003) 2011-11

52.219-13 Notice of Set-Aside of Orders. 2011-11 52.219-14 Limitations on Subcontracting. 2017-01 52.222-6 Construction Wage Rate Requirements. 2018-08 52.222-7 Withholding of Funds. 2014-05 52.222-8 Payrolls and Basic Records. 2018-08 52.222-9 Apprentices and Trainees. 2005-07 52.222-10 Compliance with Copeland Act Requirements. 1988-02 52.222-11 Subcontracts (Labor Standards). 2014-05 52.222-12 Contract Termination-Debarment. 2014-05 52.222-13 Compliance with Construction Wage Rate Requirements and Related

Regulations.

2014-05

52.222-14 Disputes Concerning Labor Standards. 1988-02 52.222-15 Certification of Eligibility. 2014-05 52.222-62 Paid Sick Leave Under Executive Order 13706. 2017-01 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. 2011-08 52.223-19 Compliance with Environmental Management Systems. 2011-05 52.223-21 Foams. 2016-06 52.224-3 Privacy Training. 2017-01 52.227-1 Authorization and Consent. 2007-12 52.227-1 Alternate I Authorization and Consent. - (Alternate I) 2007-12 52.232-23 Assignment of Claims. 2014-05 52.233-3 Protest after Award. 1996-08 52.236-2 Differing Site Conditions. 1984-04 52.236-3 Site Investigation and Conditions Affecting the Work. 1984-04 52.236-5 Material and Workmanship. 1984-04 52.236-6 Superintendence by the Contractor. 1984-04 52.236-7 Permits and Responsibilities. 1991-11 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and

Improvements.

1984-04

52.236-10 Operations and Storage Areas. 1984-04 52.236-11 Use and Possession Prior to Completion. 1984-04 52.236-12 Cleaning Up. 1984-04 52.236-13 Accident Prevention. 1991-11 52.236-15 Schedules for Construction Contracts. 1984-04 52.236-17 Layout of Work. 1984-04 52.236-23 Responsibility of the Architect-Engineer Contractor. 1984-04

52.236-24 Work Oversight in Architect-Engineer Contracts. 1984-04 52.236-25 Requirements for Registration of Designers. 2003-06 52.242-14 Suspension of Work. 1984-04 52.243-1 Changes-Fixed-Price. 1987-08 52.243-1 Alternate II Changes-Fixed-Price. - (Alternate II) 1987-08 52.243-5 Changes and Changed Conditions. 1984-04 52.247-5 Familiarization with Conditions. 1984-04 52.247-15 Contractor Responsibility for Loading and Unloading. 1984-04 52.247-68 Report of Shipment (REPSHIP). 2006-02 52.249-4 Termination for Convenience of the Government (Services) (Short

Form).

1984-04

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials 2011-09 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. 2013-09 252.204-7000 Disclosure of Information. 2016-10 252.204-7003 Control of Government Personnel Work Product. 1992-04 252.204-7004 Antiterrorism Awareness Training for Contractors. 2019-02 252.204-7008 Compliance with Safeguarding Covered Defense Information Controls. 2016-10 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident

Reporting.

2016-10

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. 2016-05 252.209-7004 Subcontracting with Firms that are Owned or Controlled by the

Government of a Country that is a State Sponsor of Terrorism.

2015-10

252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials.

2014-09

252.223-7008 Prohibition of Hexavalent Chromium. 2013-06 252.225-7001 Buy American and Balance of Payments Program. 2017-12 252.225-7002 Qualifying Country Sources as Subcontractors. 2017-12 252.225-7016 Restriction on Acquisition of Ball and Roller Bearings. 2011-06 252.225-7048 Export-Controlled Items. 2013-06 252.227-7000 Non-Estoppel. 1966-10 252.227-7022 Government Rights (Unlimited). 1979-03 252.227-7033 Rights in Shop Drawings. 1966-04 252.232-7010 Levies on Contract Payments. 2006-12 252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. 2013-06 252.243-7001 Pricing of Contract Modifications. 1991-12 252.244-7000 Subcontracts for Commercial Items 2013-06 252.246-7008 Sources of Electronic Parts. 2018-05

FAR Clauses Incorporated by Full Text

52.204-1 Approval of Contract. 1989-12 As prescribed in 4.103 , insert the following clause: Approval of Contract (Dec 1989) This contract is subject to the written approval of ____[identify title of designated agency official here] and shall not be binding until so approved. (End of clause)

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. 2000-09 As prescribed in 11.503(a), insert the following clause in solicitations and contracts: Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000) (a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $__637.95__ per calendar day of delay [Contracting Officer insert amount]. (b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract. (End of clause)

52.211-12 Liquidated Damages-Construction. 2000-09 As prescribed in 11.503(b), insert the following clause in solicitations and contracts: Liquidated Damages-Construction (Sept 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of __$637.95__ [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted. (b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (End of clause)

52.213-4 Terms and Conditions-Simplified Acquisitions (Other Than Commercial Items). 2019-01 As prescribed in 13.302-5(d), insert the following clause: Terms and Conditions-Simplified Acquisitions (Other Than Commercial Items) (Jan 2019) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference: (1) The clauses listed below implement provisions of law or Executive order: (i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91). (iii) 52.222-3, Convict Labor (Jun 2003) (E.O.11755). (iv) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). (v) 52.222-26, Equal Opportunity (Sept 2016) (E.O.11246). (vi) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). (vii) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C.3553). (viii) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Pub.L.108-77, 108-78 (19 U.S.C. 3805 note)). (2) Listed below are additional clauses that apply: (i) 52.232-1, Payments (Apr 1984). (ii) 52.232-8, Discounts for Prompt Payment (Feb 2002). (iii) 52.232-11, Extras (Apr 1984). (iv) 52.232-25, Prompt Payment (Jan 2017). (v) 52.232-39, Unenforceability of Unauthorized Obligations (Jun 2013). (vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Dec2013) (vii) 52.233-1, Disputes (May2014). (viii) 52.244-6, Subcontracts for Commercial Items (Jan 2019). (ix) 52.253-1, Computer Generated Forms (Jan 1991). (b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply: (1) The clauses listed below implement provisions of law or Executive order: (i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018)(Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more). (ii) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan2018) (E.O.13126) (Applies to contracts for supplies exceeding the micro-purchase threshold.) (iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (May 2014) (41 U.S.C.chapter

65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands). (iv) 52.222-35, Equal Opportunity for Veterans (Oct2015) (38 U.S.C.4212) (applies to contracts of $150,000 or more). (v) 52.222-36, Equal Employment for Workers with Disabilities (Jul 2014) (29 U.S.C.793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States.) (For purposes of this clause, United States includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.) (vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C.4212) (Applies to contracts of $150,000 or more). (vii) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C.chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf). (viii) (A) 52.222-50, Combating Trafficking in Persons (Jan 2019) (22U.S.C. chapter 78 and E.O 13627) (Applies to all solicitations and contracts).

(B) Alternate I (Mar 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies). (ix) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)). (x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.)) (xi) 52.223-5, Pollution Prevention and Right-to-Know Information (May2011) (E.O.

13423) (Applies to services performed on Federal facilities). (xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)). (xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR?