This is a design-build multiple award construction contract (DB-MACC) project intended to repair building 905. The work includes painting of interior and exterior walls, painting of ceiling, repair…

Ended Awarded

Contract number
0047
Awardee
Awarding agency
Obligated
$129,947

Award facts

Opportunity
  • N4019209R2700 Solicitation number
Contract value 100% obligated
$129,947.39 Current and potential, with all options
Completion date 100% complete
Current and potential, with all options
Funding agency
Navy Installations Command Department of the Navy, Department of Defense
NAICS code
236220 Commercial and Institutional Building Construction
PSC
Z1GA Maintenance Of Ammunition Storage Buildings
Set-aside
HUBZone
Competition
Full and Open Competition after exclusion of sources · 8 offers Multiple Award, Fair Opportunity
Pricing
Firm Fixed Price
Place of performance
Sånta Rita-Sumai, Guam

Award details come from SAM.gov/FPDS.

Description

As the agency reported it.

This is a design-build multiple award construction contract (DB-MACC) project intended to repair building 905. The work includes painting of interior and exterior walls, painting of ceiling, repair and repainting of existing sliding steel access doors and repainting of existing loading dock. A. The contractor shall provide all labor, material, equipment, permit and clearances, engineering design/approach services and other incidental work required for the project in accordance with statements of work for WR#5525246 dated 07 october 2011 and serrano construction development corporation s proposal dated 25 june 2012. B. The performance period is 120 calendar days commencing on the date of award up to and including 26 october 2012. C. Liquidated damages in the amount of $200.00 shall be assessed for each calendar day of delay until the work is completed and accepted. D. The site safety and health officer (ssho) for the above DB basic scope of work shall meet the requirements of level II. E. The assigned team for this project will be provided by the contracting officer prior to the start of work. F. The requirements of dfars 252.247-7023, transportation of supplies by sea, apply to this contract. Within 30 days of each shipment, the contractor is required to provide an electronic copy of the carrier's bill of lading to the contracting officer and to marad via e-mail. Marad

Quick answers

Who was awarded contract 0047?

0047 was awarded to Serrano Construction And Development Corp. by Naval Facilities Engineering Command (Department of the Navy) on June 28, 2012.

How much is contract 0047 worth?

The government has obligated $129,947 on 0047.

Which agency awarded contract 0047?

Naval Facilities Engineering Command (Department of the Navy) awarded 0047, with funding from Navy Installations Command (Department of the Navy).

Is contract 0047 an order under another contract?

Yes. 0047 is a delivery order under N4019209D2708, an indefinite delivery contract.

Was contract 0047 competed?

The extent of competition for 0047 was full and open competition after exclusion of sources. The government received 8 offers. It was set aside: HUBZone.

On GovTribe

See this award's full record

  • Every transaction and funding action
  • The awardee's other awards and teaming partners
  • Similar awards and recompete opportunities
  • Ask GovTribe AI about this award
Try for free Login