W912QR23Q0069.pdf

W22W9K30964031

1. Caesar Creek Hydraulic Line Replacement. 4020 N. Clarksville Rd. Waynesville, Ohio.

2. Estimated Construction Cost: Betw een $100,000 and $250,000

3. NAICS code 237110. Size determination: $45,000,000.00. Please note that business size in SAM is determined by the NAICS code. If the vendor size is not listed correctly for a particular NAICS code in SAM the business w ill be considered other than a small business

4. This project is set-aside 100% for Small Business.

5. Contractors must register and complete the representation and certif ication requirements in the System for Aw ard Management (SAM) database, available at https://sam.gov. PLEASE ensure your annual SAM registration is current. Offerors must comply w ith the requirements of 52.204-7, 52.204-8, 52.232-33, and any other representation and certif ication requirements in this solicitation through SAM. PLEASE NOTE:

SAM is completely f ree of charge for both registrants and users.

6. Bonds required for this project w ill be dependent upon the total aw ard amount of the Purchase Order aw arded from this Request for Quote.

(See Special Instructions for additional details)

RYAN R FERRELL 502.315.6545

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

11-May-2023

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______14 calendar days and complete it w ithin ________90 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________22 May 2023 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

U. S. ARMY ENGINEER DISTRICT, LOUISVILLE

600 DR. MARTIN LUTHER KING, JR. PLACE

ROOM 821

LOUISVILLE KY 40202-2239

W912QR

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 502.315.7494 TEL: FAX:

W912QR23Q0069 83

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912QR23Q0069

Section SF 30 - Block 14 Continuation Page (SF 30)

SPECIAL INSTRUCTIONS

The contractor shall provide material, labor and equipment necessary to complete Caesar Creek Hydraulic Line Replacement. 4020 N. Clarksville Rd. Waynesville, Ohio. Prices should include mobilization & de-mobilization, fuel, labor, material and equipment. The contractor’s work and responsibility shall include all planning, programming, administration, management, supervision, communications and inspection necessary to assure that all work is conducted in accordance with the contract requirements and all applicable Federal, State and Local laws and regulations. All work shall be performed in strict compliance with the attached specifications and all other terms and conditions incorporated herein. Work will begin within 14 calendar days of the Notice to Proceed (NTP) and will conclude 90 calendar days after the NTP.

One award will be made from this solicitation. The contract award will be based on Low Price. Method of payment under this contract will be Electronic Funds Transfer (EFT) to a commercial bank account specified by the Contractor. Quotes will not be accepted for quantities less than the quantities specified in the price breakout schedule. Failure to submit a unit price for all items listed will be considered as a material deviation from the requirements and the Quote will be rejected.

BONDS: Bonds required for this project will be dependent upon the total award amount of the Purchase Order awarded from this Request for Quote:

For a Purchase Order equal to or less than $150,000 - In lieu of both performance and payments bonds, per 52.228-13 Alternate Payment Protections (2000) and FAR 28.102-1(b), only a Payment Bond, or Irrevocable Letter of Credit is required. A Performance Bond is not required.

For a Purchase Order more than $150,000 – Both Performance and Payment Bonds will be required.

Questions for this RFQ shall be emailed to Ryan Ferrell at Ryan.R.Ferrell@usace.army.mil NLT 18 May 2023 at 3:00 PM Eastern Time. Questions received and answers to those questions will be posted in the description section of the SAM.gov contract opportunity.

Note: A site visit is HIGHLY ENCOURAGED for the contractor to review the complexities of the work site, verify existing conditions, and exact measurements. The Contractor may request a site visit with the Project Manager James Oboyle, (513) 429-8000, and/or TPOC, Graham Smith (502) 315-6603.

Central Contractor Registration, EPLS, ORCA, and FedReg are now available through the System for Award Management (SAM), available at www.sam.gov . Offerors must comply with the requirements of 52.204-6, 52.204- 7, 52.204-8, 52.232-33, 252.204-7004, and any other CCR/ORCA requirements in this solicitation through SAM.

Training tools are available on the SAM website to help you get familiar with SAM. Start by going to www.sam.gov , and then click on the SAM HELP tab. Under User Help you will find the full User Guide as well as Quick Start Guides and Helpful Hints that will help you create and account, migrate your roles, perform updates, and search for the information you need. These guides can also be viewed on http://www.acquisition.gov .

PLEASE NOTE: SAM is completely free of charge for both registrants and users.

ALERT: You must submit a notarized letter appointing the authorized Entity Administrator before your registration will be activated. This requirement now applies to both new and existing entities. Effective 29 April 2018, the notarized letter process is now mandatory on all CURRENT registrants at SAM who have a requirement to update data on their SAM record. The notarized letter is mandatory and is required before the GSA Federal Service Desk (FSD) will activate the entity's registration. Effective 29 June 2018, vendors creating or updating their registration can have their registration activated prior to the approval of the required notarized letter. However, the signed copy of the notarized letter must be sent to the GSA Federal Service Desk (FSD) with 30 days of activation or the vendor risks no longer being active in SAM. PLEASE NOTE: SAM is completely free of charge for both registrants and users.

PRICE BREAKOUT SCHEDULE

Item Description Quantity Unit Price Per Unit Price Replace Directional Control Valves with a max psi of 3,000

4 Each

Replace Directional Control Valves with a max psi of 4,500

2 Each

Replace Counter Balance Valve with a max psi of 2,000

6 Each

Replace all check valves, drain valves, or any other valves encountered during the replacement of all lines and directional valves

1 Job

Replace tube lines with new tube lines rated for pressures equal to or greater than existing lines

24 Each

REPRESENTATIONS AND CERTIFICATIONS

COMPANY NAME AND ADDRESS: _________________________________________

PHONE NUMBER: _________________________________________

EMAIL ADDRESS: _________________________________________

BUSINESS SIZE (select one or more as applicable):

Large Business ____ Small Business ____ HUBZone ____ 8(a) ____ Women-Owned Small Business ____ Economically Disadvantaged Women-Owned Small Business ____ Service-Disabled Veteran-Owned ____

CURRENTLY REGISTERED WITH SYSTEM FOR AWARD MANAGEMENT (SAM): YES ____ NO ____

(Note: See FAR 52.204-7)

TAX IDENTIFICATION NUMBER (TIN): ____________

UNIQUE ENTITY IDENTIFIER: ____________

(Note: See FAR 52.204-7. The Unique Entity Identifier is a 12 character alphanumeric code.)

CAGE CODE: ________

(Note: See FAR 52.204-7)

SCOPE OF WORK

Caesar Creek Hydraulic Line Replacement

Project Location:

Caesar Creek Lake

4020 N. Clarksville Rd.

Waynesville, Ohio 45068

General Requirements The contractor shall replace all control valves, check valves, flow control valves, and tube lines within the existing hydraulic system on elevation 854 of the control tower. The entire clamping system will also be replaced. Tube lines will be replaced with new stainless steel tube lines. The existing hydraulic system is rated for a maximum pressure of 1,875 psi in the Caesar Creek Lake Control Tower, Waynesville, Ohio.

Current information is provided below. All replacement valves will be approved by Technical Point of Contact (TPOC) prior to installation.

The valves listed below are not listed for in-kind replacement, but are for your reference as to their individual ratings.

Anything used to replace these valves must have equal to or greater ratings than what is currently in place.

1. Replace two (2) Directional Control Valves. Current Valves are Vickers Model DG17V4-0133N-10 with a max psi of 4,500.

2. Replace four (4) Directional Control Valves. Current Valves are Vickers Model DG17S4-033C-50 with a max psi of 3,000.

3. Replace six (6) Counter Balance Control Valve. Current valve model is a Double A Products Co. Model OSA4-165 with a max psi of 2,000.

4. Replace all check valves, drain valves, or any other valves encountered during the replacement of all lines and directional valves with equipment approved by Technical POC.

• All Directional Control Valves (DCV), Pressure Control Valves, Pressure Relief Valves, Check Valves, Drain Valves or any other Valves encountered in this project will be updated and upgraded to modern technology. A complete re-design of the valve stand will be allowed.

(For example, Stack type Valves.) ALLDCV can be replaced with push button technology. Any DCVs replaced with push button operation will be discarded; there will be no blank openings left in the control unit from DCV removal. The contractor must provide details on any proposed re-design prior to the pre-work meeting for review/acceptance by the Technical POC.

5. Replace 24 tube lines with new tube lines rated for pressures equal to or greater than existing lines. The entire clamping system will be replaced, brackets in kind and using stainless clamps. The following footages are for estimation purposes only.

a. 400 feet of 3/4” line

All fluids released during replacement shall be captured by either containment or absorbents and discarded offsite at proper disposal site. The contractor must provide and have at the job site sufficient containment and/or absorbent materials for the quantity of hydraulic fluids present. The Contractor must supply the Technical Point of Contact (TPOC) with an inventory of these containment/absorbent materials, along with spill control/response procedures at the pre-work conference.

6. Refill hydraulic reservoir to proper operational levels with new hydraulic oil, there will be no oil reused. The current hydraulic oil is T-32 and it will be replaced in kind. The work must be completed while allowing partial use of system for flood control operation and system must be capable of being put back in operation within 6 hours in case of emergency. If possible, contractors will remove one system at a time and replace in whole that system before continuing to the next. All work must be performed during normal working hours (0730AM-0330PM, M-F) and system shall be operational at the end of each shift.

All work will be coordinated with Corps personnel and may be interrupted in event of heavy rains or conditions requiring full operation of facility.

After installation is completed, a functionality test will be performed by Corps personnel to assure of proper operation of all functions in facility. The Contractor must be present for this functionality test; date and time of the test will be coordinated with the Contractor. If for any reason the system fails to operate properly, the repairs made will come at no cost to the Government.

Following work, the contractor is responsible for removing all excess supplies, materials, equipment, trash, etc. within 1 workday of acceptance.

Caesar Creek Hydraulic Line Replacement

TABLE OF CONTENTS

SPECIFICATIONS/DESCRIPTION

1. Project Information

2. Performance Work Statement

3. Technical Point of Contact (TPOC)

4. Pre-Work Conference

5. Working Hours

6. Contract Start and Completion Dates

7. Contractor Submittals

8. Permits and Licenses

9. Identification of Contract Employees and Vehicles

10. Safety Requirements

11. Required Security Training and Planning

12. Accident Reporting

13. Damage Reports

14. Contractor Employees’ Conduct and Competency

15. Damage or Loss of Contractor’s Supplies and Property

16. Supervision

17. Environmental Program

18. Contract Discrepancy Report (CDR)

19. Meetings

20. Quality Control

21. Quality Assurance

22. Deficiencies

23. Interruptions to Systems

24. Government Furnished Materials and Equipment

25. Contractor Furnished Items

26. Safeguarding Government Property

27. Minimum Manpower Requirements

28. Minimum Personnel Qualifications

29. Cooperation with other Contractors, Lessees, and Volunteers

30. Reports

31. Applicable Publications

32. Warranty

33. Wage Rates

34. Definitions

35. Index of Exhibits

SPECIFICATIONS/DESCRIPTION

1. Project Information.

The project point of contact (POC):

Jim O’Boyle Caesar Creek Lake 4020 N. Clarksville Rd.

Waynesville, Ohio 45068 513-897-1050

2. Performance Work Statement.

The contractor shall furnish all personnel, equipment, supplies and materials necessary to replace all control valves, check valves, flow control valves, and tube lines within the existing hydraulic system on elevation 854 of the control tower at Caesar Creek Lake, Waynesville, Ohio. Prices should include mobilization & de-mobilization, fuel, labor, material and equipment. The contractor’s work and responsibility shall include all planning, programming, administration, management, supervision, communications and inspection necessary to assure that all work is conducted in accordance with the contract requirements and all applicable Federal, State and Local laws and regulations. All work shall be performed in strict compliance with the attached specifications and all other terms and conditions incorporated herein.

3. Technical Point of Contact (TPOC):

Graham Smith U.S. Army Corps of Engineers 600 Dr Martin Luther King Jr Pl Louisville, KY 40202 502-315-6603

4. Pre-Work Conference:

The contractor will be required to attend a pre-work conference prior to beginning work during which the Contractor’s plan of work, safety procedures, start date and other items in this contract will be discussed.

5. Working Hours.

a. Normal working hours, except as otherwise specified herein, shall be Monday through Friday, 7:00 a.m. to 3:30 p.m. Eastern Time. Work inside Government buildings or other secured areas shall be performed during the above referenced work hours. Work that interferes with other ongoing functions at the project shall be scheduled around normal working hours, as specified by the Project Manager.

Holiday Work. The eleven Federal holidays observed are:

New Year's Day (January 1st) Martin Luther King Day (3rd Monday in January) President's Day (3rd Monday in February) Memorial Day (Last Monday in May) Juneteenth Day (June 19th) Independence Day (July 4th) Labor Day (1st Monday in September) Columbus Day (2nd Monday in October) Veterans Day (November 11th) Thanksgiving Day (4th Thursday in November) Christmas Day (December 25th)

When one of the above designated holidays falls on a Sunday, the following Monday is observed as a legal holiday. When a legal holiday falls on a Saturday, the preceding Friday is observed as a holiday. Work shall be scheduled around the above listed Federal holidays except as specified herein or as approved by the

TPOC.

b. Inclement Weather Work.

The Contractor shall maintain the schedule of services regardless of inclement weather. Exceptions may be approved by the TPOC when severe conditions make it impractical or dangerous to perform the work.

6. Contract Start and Completion Dates.

Work under this contract will begin within 14 calendar days of Notice to Proceed (NTP) and complete within 90 calendar days after receiving the NTP.

7. Contractor Submittals.

Unless otherwise specified, the Contractor will submit the following information to the TPOC prior to the pre-work conference for this contract:

a. Contractor Representatives. List of names of Contractor Representatives.

b. Accident Prevention Plan (APP). A suggested outline for the Contractor’s Accident Prevention Plan Appendix A of EM 385-1-1 See Section C-1.9 for APP requirements. Exhibit D.

c. Emergency Contacts. A prioritized list, including phone numbers, of those persons (normally Contractor Representatives) to call in case of emergencies.

d. Operators. A list of names of qualified equipment/vehicle operators, including experience, training and qualification to operate specific equipment.

e. Certificate of Insurance.

f. Performance Bond. (where applicable)

g. Security Requirements.

8. Permits and Licenses.

The Contractor will obtain, at own expense, any required licenses, permits or certifications necessary to perform the specified services. Required licenses, permits and certifications will be kept current during the period the work is performed. The Contractor is also responsible for any and all costs associated with the training of Contractor personnel to acquire and maintain valid licenses, permits or certifications necessary to perform the contract services specified herein. The Contractor, Contractor personnel and any persons acting on behalf of the Contractor will comply with all applicable Federal, State and local laws and regulations; including any subsequent changes to these laws and regulations.

Minimum Personnel and Training Requirements. The Contractor will provide an adequate number of fully trained and qualified personnel to perform the work specified herein. Contractor personnel will be properly trained to perform their assigned work in a safe and effective manner. Training will include, but is not limited to instruction on the proper and safe use and operation of Contractor equipment and any Contractor provided tools, supplies and materials required to perform the specified services. Only properly trained and qualified employees will be used in the performance of services specified herein.

The Contractor will also assume responsibility for training or Orienting Contractor personnel to perform the services specified in the contract. In the event the Contracting Officer or his/her Authorized Representative determines that the Contractor does not have a qualified employee performing the specified work, the Contractor will be required to provide qualified personnel, or subcontract the work to a person or persons who are trained and qualified to perform the work. The Contractor acknowledges that the employment of undocumented migrant workers to perform services under this contract will not be permitted.

9. Identification of Contract Employees and Vehicles.

All Contractor employees will be in good appearance while performing services. Employees must wear long pants, shirt with no vulgar or obscene graphics with at least sleeves equivalent of a t-shirt, and durable work type shoes. Vehicles and any motorized equipment utilized for transportation will be in good operating condition with no display of obscene or vulgar material such as stickers, flags, or etc. Vehicles will be maintained in accordance with federal, state, and local laws.

10. Safety Requirements.

a. General. Performance of all services will assure complete safety to public visitors, Contractor employees, and all other persons in the area. The Contractor will comply with any pertinent requirements contained in the Corps of Engineers Safety Manual (EM 385-1-1), current at the time of award and any subsequent revisions to that document. Furthermore, the Contractor will comply with pertinent occupational safety and health standards for general industry (29 CFR Part 1910) as required by the Occupational Safety and Health Administration (OSHA). If the Contractor fails or refuses to promptly comply with safety and security requirements as specified herein, the TPOC or any other project employee may stop all or part of the work until satisfactory corrective action has been taken.

No part of the time lost due to any such work stoppage will be made subject to any claims for extension of time or for excess costs or damages sustained by the Contractor. Also, the Contractor will not be paid for work not performed as a result of the stop order.

b. The Contractor will comply with the Occupational Safety and Health Act (OSHA), the Corps of Engineers Manual, EM 385-1-1, https://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf or latest version and as otherwise stated herein. Special attention will be given to the requirements https://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf for safety meetings.

The Contractor will inform the TPOC a minimum of 7 calendar days prior to a Contractor monthly safety meeting, to permit a Government representative to attend.

c. Accident Prevention Plan (APP). The Contractor will prepare an Accident Prevention Plan to assure that requirements of the safety program are provided as specified. This plan must be accepted by the Contracting Officer prior to commencement of any work. One copy of the Accident Prevention Plan will be provided to the Contracting Officer and the TPOC one week prior to the pre-work conference.

The Accident Prevention Plan must be in the outline and form prescribed in Appendix A of EM 385-1- 1.

d. Activity Hazard Analysis (AHA). The Contractor will use Activity Hazard Analyses (AHA’s) as one of many tools to insure safe performance of work. It is the Contractor’s responsibility to prepare the AHA. Sample AHA’s may be available at the project office for review and use by the Contractor to assist in the development of site specific Activity Hazard Analyses prior to the Contractor performing the job. The Contractor is encouraged to revise or add to these sample AHA’s as necessary to address changing conditions. Prior to performing jobs with inherent hazards, the Contractor will review, at a “Tool Box” safety meeting, the approved AHA’s with those employees who will perform that work each time the work is ordered. The Government may request advanced notification of the time and date of the above AHA “Tool Box” safety meeting for Contractor employees so that the Government may attend such reviews.

The Government will require the Contractor to prepare an AHA for any jobs for which an adequate AHA does not already exist. A copy of this AHA will be submitted to the TPOC and must be accepted before the Contractor starts the job. This copy of the AHA will become the property of the Government. Guidance is included, which will be used by the Contractor as a guide for the preparation of required AHA's.

A copy of the approved AHA’s will be available at all times to workers at each associated job site and a copy will be provided to the Government.

e. Public Safety. The Contractor will ensure that reasonable precautions are taken to protect the public at all times where work is being performed. The Contractor will immediately report to the TPOC any potential hazards found by his employees on the project. The Accident Prevention Plan will include procedures to be taken to provide for public safety. Additionally, the Contractor will not allow any persons, except employees, into work areas that are not otherwise open to the public; nor will the Contractor transport in Contractor work vehicles any persons, except employees, during times the Contractor is on the project performing work under a contract.

f. Personal Protective Apparel and Equipment. Protective apparel and equipment, as identified in the AHA, will be provided to eliminate or minimize hazards to personnel. As a minimum, each employee will wear a short-sleeved shirt, long trousers, and appropriate footwear during all contract work. Face shields, spectacles with side-shields, or goggles, and hearing protection will be worn by employees when required by safety manual. Fire extinguisher(s) and first aid kit(s) meeting the Safety Manual standards will also be provided and easily accessible to all employees.

g. Contractor Employees Certified in First Aid & CPR. The Contractor will schedule employees so the appropriate numbers of certified personnel are on duty to administer First Aid and CPR as required by the Safety Manual.

Copies of their certification will be provided in accordance with regulations. Two people per crew will be trained in First Aid and CPR. Individuals working alone will be trained in First Aid.

h. Hazard Communication Program. The Contractor will be responsible for implementing a hazard communication program for Contractor employees, as required by the Safety Manual. The Contractor will provide Material Safety Data Sheets (MSDS) and/or Safety Data Sheets (SDS) for review by the TPOC prior to use of any hazardous substance on the project and provide a plan for the proper handling, transportation, storage and usage of hazardous substances on the project.

11. Required Security Training and Planning.

A. General security requirements and guidance: The security requirements described below apply to all contract personnel (including employees of the prime Contractor (“Contractor”) and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations, facilities and activities, and security awareness training contributes to those efforts. The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations. Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as “RAMs”), and Health Protection Condition (HPCON) measures. The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures --this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel.

The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

B. Physical security and access control requirements: All contract personnel requiring physical access to a federal installation or facility shall comply with the access control procedures of that location. Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as “NCIC-III”) and Terrorist Screening Database (commonly referred to as “TSDB”). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USACE facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the RA.

C. Suspicious Activity Reporting training (e.g. iWATCH, CorpsWatch, or See Something, Say Something): All contract personnel shall receive initial and annual refresher training from the RA representative on the local suspicious activity reporting program. This locally developed training provides contract personnel with general information on suspicious behavior, and guidance on reporting suspicious activity to the project manager, security representative or law enforcement entity.

D. Pre-screen candidates using E-Verify Program: Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at (https://www.e-verify.gov/) (website subject to change) to meet the contract employment eligibility requirements. Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1(i). An initial list of verified/eligible candidates shall be provided to the COR no later than three business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, and submit it to the Contracting Officer to become part of the official contract file.

E. Supplemental Security Requirements: All Contractors and subcontractor employee(s) working on this contract who require access to any Louisville District Lake Projects and Lock and Dam Projects shall receive authorization to be on site at these facilities based upon a favorable background investigation in accordance with “Homeland Security Presidential Directive 12: Policy for a Common Identification Standard for Federal Employees and Contractors” (HSPD 12). The Louisville District Security Management Office shall submit contractor(s) personal information to complete the basic background investigation in order to make a recommendation to the Contracting Office of an employee’s suitability for work on Government property. The Procuring Contracting Officer (PCO) has the right to deny any contractor or subcontractor employee from working on the contract based upon the results of the background investigation provided by the Louisville District Security Office. The Government, Contractor, and subcontractors shall not permit any employee(s) access to drawings, blueprints, records, photos, sites, or projects until the Louisville District Security Management Office has completed an Operations Security (OPSEC) review of such items and determined they can be released.

F. For All Louisville District Contracts: Contractors shall submit a complete investigation packet for each contractor and subcontractor employee to the Louisville District Security Management office within 10 working days after award of any contract, or prior to the individual being permitted access to Louisville District facilities.

The Contractor must also provide the following: (1) Name of the Contract Specialist with whom he/she is working,

(2) Project Name, (3) Contract Number (4) Task Order Number when applicable, and (5) US Citizens Security Access Form or Pre-Bid/Site Visit Form; each employee working on site must have a background investigation form submitted directly to the Louisville District Security Office.

The Contractor must provide a full legal name, complete SSN#, Date of Birth, Place of Birth (City and State) and Driver’s license number if available. It is the Contractor’s responsibility to ensure the above information is accurate and legible, otherwise delays may occur.

Contractors shall have background checks completed for their employees annually in the case of Contracts with an initial period of performance (POP) greater than 1 year and those Contracts with Options or Modifications Which Extend the POP beyond 1 year. For instance, if the employee was cleared in May of 2022, they shall be cleared again in May of 2023. It is the Contractor’s responsibility to ensure that each employee’s security is up to date. Failure to comply may lead to possible removal from the project/jobsite.

The Contractor must ensure if new employees are brought in to work on an existing Contract with the U.S. Army Corps of Engineers (USACE), they must process the employee through the Louisville District USACE Security Office for background purposes.

G. For Contractors Requiring DoD Common Access Cards (CAC): The documents listed below are required:

SF 85, Questionnaire for Non-Sensitive Positions (see http://www.opm.gov/forms/ to print form).

Fingerprints are captured electronically at the closest Army Recruiting Station to the contractor’s home of record or at the USACE, Louisville District Security Office.

Contractor shall report any changes in personnel, or at any time conditions change at least 5 working days prior to individual(s) need to have access to the site. The Contractor shall provide the same information as listed above for all new employees.

Following submission of paperwork, the Louisville District Security Office will conduct an initial criminal check based upon the information provided. If there are no issues, the Louisville District Security Office will make recommendations to the PCO or their Designated Representative. The Louisville District Security Office cannot give approval due to unfavorable report(s). The Louisville District Security Office shall coordinate with Office of Counsel and will jointly make recommendations to the PCO and/or the Designated Representative should a background investigation come back with http://www.opm.gov/forms/ derogatory information. The PCO will make the determination whether to allow the Contractor personnel to work on the site based on Security and Office of Counsel recommendations, and the PCO will advise the Contractor of the decision.

H. Foreign Nationals: The Contractor shall provide the package listed above, as well as additional materials noted below for all Foreign Nationals. The Contractor is to expect additional time in the approval process for all Foreign Nationals due to the level of review and elevation of the review to Headquarters staff to complete. All Foreign Nationals must comply with the following paragraph:

In accordance with Engineering Regulation 380-1-18, “Technology Transfer, Disclosure of Information and Contacts with Foreign Representatives” dated 1 August 1996, Section 4, all foreign nationals who work on Corps of Engineers’ contracts shall be approved by the Headquarters US Army Corps of Engineers (HQ USACE) Foreign Disclosure Officer before beginning work on this contract; this regulation includes subcontractor employees. The Contractor shall submit to the Security Management Office, the names of all foreign nationals proposed for performance under this contract, along with documentation to verify legal admittance into the United States. Such documentation shall include at least one of the following: a U.S. passport, Certificate of U.S.

Citizenship (INS Form N-560 or N-561), Certificate of Naturalization (INS Form N-550 or N-570), Alien Registration Card with photograph (INS Form I-151 or I-551), Employment Authorization Card (INS Form I-688A), etc.

In order to assure forms are properly completed, and to minimize time delays, the Contractor is encouraged to work closely with the Louisville District Security Office. The Government will return for correction incomplete forms, illegible forms, etc. which will delay the contractor / subcontractor from beginning work.

Security requirements are subject to change in accordance with HSPD-12, Office of Personnel Management, regulation or policy changes, etc. The Government shall add any changes to security requirements by modification to the contract.

The Contractor shall contact the Louisville District Security Office by phone, letter, or email at the following numbers/addresses:

CELRL-SC

600 Martin Luther King Jr. Pl Louisville, KY 40202

Charles R. Tanner, phone (502) 315-6929; email Charles.R.Tanner@usace.army.mil James R. Milner, phone (502) 315-6916; email James.R.Milner@usace.army.mil Jason Almodovar, phone (502) 315-6754; email Jason.Almodovar@usace.army.mil

12. Accident Reporting.

The Contractor is responsible for reporting all accidents to the Project Manager immediately. Prompt action will be taken to ensure immediate and appropriate medical treatment. The Contractor will maintain an accurate record of any accidents in the manner and on the forms prescribed by the Project Manager. For property damage accidents of $2,000 or more, the Contractor will complete and submit to the Project Manager a copy of ENG Form 3394. The Contractor will maintain an OSHA 300 Log of On

– The – Job injuries and first aid treatments.

The Contractor will also provide a monthly record of all exposure and accident experience incidental to the performance of services under the contract. This reporting requirement includes exposure and accident experience of both the Prime Contractor and any subcontractor(s). A Monthly Record of Work-Related Injuries/Illnesses & Exposure form will be available from the Project Manager. The Monthly Record of mailto:Charles.R.Tanner@usace.army.mil mailto:James.R.Milner@usace.army.mil mailto:Jason.Almodovar@usace.army.mil

Work-Related Injuries/Illnesses & Exposure report will be provided to the Project Manager by the 5th working day of the month for the previous month. Emergency Contacts. A prioritized list, including phone numbers, of those persons (normally Contractor Representatives) to call in case of emergencies.

The contractor will supply the Technical Point of Contact (TPOC) with an Accident Prevention Plan (APP), Scaffolding Plan, Control of Hazardous Energy Plan (LO/TO), and an Activity Hazard Analysis (AHA) prior to site work in accordance with EM 385-1-1.

13. Damage Reports.

All instances where Government materials, supplies, property, and/or equipment are damaged will be reported immediately to the Project Manager. When the damage was caused by contract employees, a written report of the incident and extent of such damage will be submitted to the Project Manager, within 2 work days (less weekends and holidays) of occurrence. For property damage accidents of $2,000 or more the Contractor will complete and submit to the Project Manager a copy of ENG 3394.

14. Contractor Employees’ Conduct and Competency.

All contract employees will conduct themselves in a proper and courteous manner at all times. Since the majority of work is performed in the presence of the general public, the conduct of all employees is critical and will be closely monitored. Contract employees will comply with all provisions of Title 36, Chapter III, Part 327, CFR and obey all posted signs and regulations in the performance of the work under this contract. Being under the influence of or consuming alcoholic beverages or controlled substances by the Contractor or employees while on duty is prohibited.

a. Employee Dismissal. The Contractor expressly agrees to dismiss any employee or subcontractor employee whose continued employment is deemed by the Project Manager to be inconsistent with the best interests of the public or the U.S. Army Corps of Engineers. The KO or the Project Manager may require the Contractor to immediately remove from the work site any employee or subcontractor who is incompetent, endangers persons or property, or whose physical or mental condition would impair their ability to satisfactorily perform the work. Notification to the Contractor will be promptly made in writing if time and circumstances permit. Otherwise, notification will be verbal and confirmed in writing as soon as possible. No removal will reduce the Contractor's obligation to perform all work required under this contract nor be the basis for time extension. Immediate replacement of the employee will be made.

15. Damage or Loss of Contractor’s Supplies and Property.

The Contractor is responsible for taking the action necessary to protect Contractor supplies, materials and equipment, and the personal property of Contractor employees from loss, damage or theft. The Government assumes no responsibility for theft, damage, etc., of the above. The Government is not responsible for providing storage areas or facilities for the storage of Contractor supplies, materials and equipment. With prior approval, the Project Manager may provide a location for the temporary storage of large equipment to prevent the transportation of such equipment to/from the work site while a particular service is being performed. However, the Government assumes no liability for the loss or destruction of Contractor equipment while it is stored on Government property.

16. Supervision.

The Contractor is responsible for providing on-site supervision and quality control inspections of work performed under the contract. The level of supervision and inspections will be sufficient to assure that services are performed in accordance with contractual requirements and all applicable Federal, state and local laws and regulations. The Contractor or a Contractor Representative will personally supervise the work, or be readily available by phone or other means of communication to respond to any contract issue that may arise when work is in progress. The Contractor Representative(s) will conduct overall management coordination and be the central point of contact with the Government for performance of all work under the contract.

Contractor Representative will have full authority to contractually commit the Contractor for prompt action on all matters pertaining to administration of this contract, and will be the on-site Contractor employee who is responsible for safety.

The names and telephone numbers of all individuals authorized to act on behalf of the Contractor as Contractor Representatives will be submitted in writing to the TPOC before work is performed.

The Contractor will maintain copies of contract work requirements, specifications, Activity Hazard Analysis, etc., at each work site which relate to each person's work responsibilities, and will review them to insure employees comprehension of a job prior to initiating work.

17. Environmental Program.

The Contractor will comply with Federal, State, and local laws, regulations and standards regarding environmental protection. All environmental protection matters will be coordinated with the TPOC. Any of the facilities operated by the Contractor may be inspected by the TPOC, or other Federal, State and local officials without advance notice. Access for inspection will be granted upon request.

Citations against Government facilities operated by the Contractor for non-compliance with environmental standards are a matter for resolution between the Government and the issuing office.

The Contractor will conduct all operations and maintenance activities in a manner to prevent contamination of Government land and property. The Contractor will ensure all lubricants, petroleum products, paints, cleaning materials, or any other hazardous substances are not spilled, leaked or disposed of on Government property and are disposed of in accordance with environmental regulations. If spills or contamination occur, the Contractor will be responsible for cleanup and any associated costs in accordance with Federal, State and Local Law. Such spills will be reported to the TPOC immediately.

18. Contract Discrepancy Report (CDR).

A CDR is a formal document used by the Government to process defects in services. As initially issued to the Contractor, the CDR describes the discrepancy or problem. The CDR will be discussed with the Contractor or his representative when it is issued. The Contractor will provide his written response on the CDR form within 24 hours of issuance. The Contractor's response must:

Identify the cause and corrective action taken, and Identify Contractor action to prevent recurrence.

Upon finalization of the CDR, the Contractor and the TPOC must sign the form. The Contractor will be given a copy of the completed form. Should the Contractor not concur with any decision, etc., the Contractor may so state, in writing, and request a final decision by the Contracting Officer. The Contracting Officer monitors all CDR's issued, and CDR's are the principle evidence used by the Contracting Officer in determining Government contract actions such as termination or decision not to exercise options.

19. Meetings.

The Contractor is required to attend a pre-work meeting to be scheduled by the TPOC. The Contractor or his authorized representative will report each Month with the schedule and location determined by the TPOC to discuss contract work items. Specific topics of discussion at the Monthly meetings may include issuing inspections, quality control, and upcoming work. If a CDR is issued, mutual effort will be made to resolve any and all problems identified to preclude their recurrence. The TPOC may alter this reporting schedule, or change the reporting method, time, or place if mutually agreeable between the TPOC and the Contractor. A tour of the work site will be conducted following the discussions. It is recommended that the Contractor’s on-site representative or superintendent also attend this meeting. During the pre-work conference, the Contractor will also provide any required submittals not previously submitted.

20. Quality…