Solicitation_Oswego_W912P4B0016.pdf

The USACE Buffalo District is currently preparing a solicitation to aw ard a contract for an Osw ego Harbor Breakw ater Repair. Work w ill consist of the repair of the West Arrow head Breakw ater to be completed by installing a rubble mound overlayment of the existing breakw ater using bedding, underlayer, and armor stone.

The Government intends to aw ard on a Firm Fixed Price contract for the Osw ego West Breakw ater as a result of this solicitation. The contract w ill have a period of performance of 324 days on base w ork from issuance of Notice to Proceed. Please see Section 01 35 13 of the specif ication and FAR Clause 52.211-10 for more information.

In order to compete, offerors must be a Small Business as designated by FAR Clause 52.219-6. The applicable Wage Determination is IL 180018. The Wager Determination is attached in the solicitation.

The cost of this project is estimated at $5,000,000 to $10,000,000. The Buy American Act is applicable to this acquisition. A Bid Guarantee shall be submitted w ith the bid to be the considered responsive. The amount of the guarantee shall be 10% of bid amount or $1,600,000 w hichever is less, see FAR Clause 52.228-1.

X

KENNETH MACKAY 716.879.4173

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

21-Mar-2019

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________324 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________23 Apr 2019 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

U.S. ARMY ENGINEER DISTRICT, BUFFALO

1776 NIAGARA STREET

BUFFALO NY 14207-3199

W912P4

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 716.879.4173 TEL: FAX:

W912P419B0016 40

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

Section 00 10 00 - Solicitation

BIDS SCHEDULE/CLINS

SECTION 00 10 00

BIDDING SCHEDULE

Item Estimated Unit

No. Description Quantity Unit Price

Mobilization and Demobilization

JA

Record (As-built) Drawings

JA

(including surveys and photographs)

Breakwater Repair (Sta. 16+25 ~ 20+50) (includes tie-ins to existing breakwater at Sta. 20+50)

3 Armor Stone 15,000 TN $ $ -

4 Underlayer Stone 2,675 TN $ $ -

5 Bedding Stone 220 TN $ $ -

Tie-in (at south end) See the Notes and section 31 32 23.01 02.

6 Armor Stone

7 Underlayer Stone

8 Bedding Stone

1,114

TN $ $ -

Total Estimated Amount (Items 1 ~ 8) $ ‐

Option "A" - Sta. 15+00 ~ 16+25

9 Armor Stone

10 Underlayer Stone

11 Bedding Stone

4,840

1,010

Total Estimated Amount (Items 9 ~ 11) $ ‐

Option "B" - Sta. 13+75 ~ 15+00

12 Armor Stone 4,480 TN $ $ -

13 Underlayer Stone

14 Bedding Stone

1,205

Total Estimated Amount (Items 12 ~ 14) $ ‐

Total Estimated Amount (Items 1 ~ 14) $ ‐

Note 1: Bids must be complete as to all the items on the schedule. Failure to complete all items on the bid schedule will render the bid Non-responsive.

Note 2: The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

Note 3: The government may elect to excercise any combination of the options, or not exercise the options. If any option item is exercised, the Government reserves the right to limit the quantity of material up to the estimated quantity of the option item exercised. If an option is exercised, it will be exercised within 60 calendar days from Contract Award.

Note 4: The Option quantities do not include the tie-in. The location for the tie-in will be placed based upon what portion, if any portion of the option, may be exercised. See section 31 32 23 .

Note 5: The length of repair to be exercised for any option will determine the quantities executed.

EXAMPLE: Option "A" work is from Sta. 15+00 to 16+25. If 60% (75 feet) of this work will be completed, then the Government will calculate the quantities required to complete 75 feet of repair, and that quantity of the option will be exercised, which may not be the same percentage (60%) of length exercised.

Note 6: Option "B" may be exercised if the total quantity of stone to perform repairs for the total length (Sta. 15+00 ~ 16+25) of Option "A" is exercised.

Section 00 21 00 - Instructions

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.211-1 Availability of Specifications Listed in the GSA Index of

Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29

AUG 1998

52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996

CLAUSES INCORPORATED BY FULL TEXT

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (JUL 2016)

(a) Definition. As used in this provision--

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

(b) The Offeror shall enter its CAGE code in its offer with its name and address or otherwise include it prominently in its proposal. The CAGE code entered must be for that name and address. Enter ``CAGE'' before the number. The CAGE code is required prior to award.

(c) CAGE codes may be obtained via--

(1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision).

(2) The DLA Commercial and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the offeror does not otherwise register in SAM, an offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil.

(3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity's country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity's country is not a member of NATO or a sponsored nation. Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm.

(d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil.

(e) When a CAGE Code is required for the immediate owner and/or the highest-level owner by 52.204-17 or 52.212-3(p), the Offeror shall obtain the respective CAGE Code from that entity to supply the CAGE Code to the Government.

(f) Do not delay submission of the offer pending receipt of a CAGE code.

(End of Provision)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

Section 00 21 13 - Instructions to Bidders

INSTRUCTIONS TO BIDDERS

Questions concerning this solicitation shall be submitted via electronic mail (e-mail) no later then 8 April 2019, 2:00 P.M. EST to Walter.Kamad@USACE.Army.mil

All bids shall be submitted via sealed envelope by hand or mail. Bids shall not be submitted via electronic mail or FAX. Sealed bids shall be delivered to USACE Buffalo District, Attn:Walter Kamad, 1776 Niagara Street, Buffalo, New York 14207-3199.

Bids will be opened publically at 1776 Niagara Street, Buffalo, NY 14207, Conference Room C at the date and time specified in the solicitation.

All times specified are Eastern Standard Time.

23 April 2019 2:00 P.M. EST to Walter.Kamad@USACE.Army.mil

A completed bid includes:

- Fully executed Form 1442-with amendments acknowledged

- Bid Bond

- Fully completed Bid Schedule

- Completed Reps and Certs from @SAM.GOV

For bid evlauation purposes, the total bid will be based upon the lowest price total of the base bid items and the option items listed on Bid Schedule.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

7.7% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Oswego Breakwater, Oswego, New York.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $1,600,000, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Walter Kamad, U.S. Army Corps of Engineers, 1776 Niagara Street, NY 14207.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for—

Monday, April 1st at 1pm

(c) Participants will meet via a teleconference—

Call-in information: TBD

Dial (877) 336-1828 Access Code: 3234778 Security Code: 1234

Webinar information:

https://www.teleconference.att.com/servlet/AWMlogin Meeting number: 8773361828 Code: 3234778 Email: Your own Name: Your own

Contractors are encouraged to attend the site visit via teleconference, but are not required in order to submit bids for this solicitation.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/

Section 00 22 13 - Supplementary Instructions to Bidders

52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.236-7008 Contract Prices-Bidding Schedules DEC 1991

Section 00 45 00 - Representations and Certifications

52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 237990- assigned to contract number TBD.

(Contractor to sign and date and insert authorized signer's name and title).

(End of clause)

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (DEC 2018)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services--Representations.

Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

Section 00 70 00 - Conditions of the Contract

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

APR 2014

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018 52.204-22 Alternative Line Item Proposal JAN 2017 52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

JUL 2018

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-13 Time Extensions SEP 2000 52.211-18 Variation in Estimated Quantity APR 1984 52.214-26 Audit and Records--Sealed Bidding OCT 2010 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data -

Modifications - Sealed Bidding

AUG 2011

52.214-28 Subcontracting Certified Cost Or Pricing Data-- Modifications--Sealed Bidding

OCT 2010

52.217-5 Evaluation Of Options JUL 1990 52.219-6 (Dev) Notice of Total Small Business Set-Aside (DEVIATION

2019-O0003).

DEC 2018

52.219-8 Utilization of Small Business Concerns OCT 2018 52.219-14 Limitations On Subcontracting JAN 2017 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records AUG 2018 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014

52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-31 Construction Wage Rate Requirements--Price Adjustment (Percentage Method)

AUG 2018

52.222-32 Construction Wage Rate Requirements--Price Adjustment (Actual Method)

AUG 2018

52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets AUG 2018 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.244-6 Subcontracts for Commercial Items OCT 2018 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Alt I Value Engineering-Construction (Oct 2015) - Alternate I APR 1984 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7002 Payment For Subline Items Not Separately Priced DEC 1991 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.215-7013 Supplies and Services Provided by Nontraditional Defense Contractors.

JAN 2018

252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7048 Export-Controlled Items JUN 2013 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7002 Obstruction of Navigable Waterways DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea APR 2014

52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS (JUN 2016)

Covered contractor information system means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

Federal contract information means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or…