Solicitation_Amendment_1_(Conformed_Document).pdf

W912L1-17-B-0001-0001

F6S3CE6173A001

This w ill be a DESIGN-BID-BUILD project for services, non-personal, to provide all labor, materials, equipment and supervision necessary to complete the scope of w ork as described to repair HVAC Design Deficiencies in Building 1382.

a. Project Name: UAV Hangar HVAC Repairs

b. Project # FWJH069194A

c. Location: Ellington Field JRB, Houston, TX

d. NAICS code: 236220

e. Project Magnitude is betw een: $250,000.00 to $500,000.00

f. This project is a Total Small Business Set-Aside

X

JOSEPH R CEDERSTROM 512-782-5537

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

09-Jun-2017

(RFP)

(IFB)

CALL:

UAV Hangar HVAC Repairs at Ellington Field JRB, TX

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________270 calendar days after receiving aw ard, X notice to proceed. This performance period is mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________18 Jul 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All of fers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USPFO FOR TEXAS

CONTRACTING BRANCH

2200 WEST 35TH STREET

BLDG 66

AUSTIN TX 78703-1222

W912L1

PAGE OF PAGES

1 OF

CODE W912L1

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

USPFO FOR TX - PURCHASING & CONTRACTING

ATTN: JOSEPH CEDERSTROM

2200 WEST 35TH ST, BLDG 66

AUSTIN TX 78703-1222

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

FWJH069194A

8. ADDRESS OFFER TO (If Other Than Item 7)

512-782-5108FAX:TEL: 512-782-1151 TEL: 512-782-5537 FAX:

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specified below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912L1-17-B-0001

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job BASE BID FOR North Comm Room 214 Repairs

FFP

Non personal services: Provide all labor, materials, equipment and supervision necessary to complete the scope of work as described to repair HVAC Design Deficiencies in Building 1382, North Communication Room 214.

FOB: Destination

PURCHASE REQUEST NUMBER: F6S3CE6173A001

NET AMT

0002 1 Job BASE BID FOR South Comm Room 252 Repairs

FFP

Non personal services: Provide all labor, materials, equipment and supervision necessary to complete the scope of work as described to repair HVAC Design Deficiencies in Building 1382, South Communication Room 252

0003 1 Job BASE BID FOR Training Room Repairs

FFP

Non personal services: Provide all labor, materials, equipment and supervision necessary to complete the scope of work as described to repair HVAC Design Deficiencies in Building 1382, Training Room (FCU-2-2 and Supplemental Cooling Units)

0004 1 Job BASE BID FOR ECN#5 HVAC Revisions to AHU

FFP

Non personal services: Provide all labor, materials, equipment and supervision necessary to complete the scope of work as described to repair HVAC Design Deficiencies in Building 1382, ECN#5 HVAC Revisions to AHUs.

0005 1 Each Contractor Manpower Reporting

FFP

The awarded vendor will be required to comply with the Army’s policy for Contractor Manpower Reporting. The vendor is allowed a onetime fee for the administrative cost associated with providing the information online. See below for details:

“The Office of the Assistant Secretary of the Army (Manpower & Reserve Affairs) operates and maintains a secure Army data collection site where the contractor will report ALL contractor manpower (including subcontractor manpower) required for performance of this contract. The contractor is required to completely fill in all the information in the forma using the following web address: https://cmra.army.mil.

NOTES

TABLE OF CONTENTS

SOLICITATION, OFFER, AND AWARD SF 1442 and SF 1442 BACK

SECTION 00010 - BID SCHEDULE, NOTES

SECTION 00100 - INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

SECTION 00600 – REPRESENTATIONS & CERTIFICATIONS

SECTION 00700 - CONTRACT CLAUSES

SECTION 01000 - SPECIAL CONTRACT REQUIREMENTS

Attachment 1 - Technical Specifications Combined Attachment 2 - As Built- Mech Plumb Drawings Attachment 3 - As Built- Electrical Drawings Attachment 4 - ECN 5 Existing coil sketch Attachment 5 - ECN 5 Propsed coil sketch Attachment 6 - Elect drawings ECN-4 Attachment 7 - Mech drawings ECN-4 and ECN-5 Attachment 8 -Wage Determination

NOTES

1. All questions and requests for information regarding this Invitation For Bids (IFB) must be received NOT LATER THAN five (5) business days in order to minimize the need to extend the bid opening date. Questions shall be emailed to: joseph.r.cederstrom.mil@mail.mil@mail.mil .

2. Offeror’s attention is invited to the insurance requirement contained in this solicitation (Contract Clause FAR 52.228-5). Certification of the required coverage for the prime contractor shall be furnished prior to beginning work on this contract, and the Contracting Officer may request evidence of the required insurance at any time during the life the contract.

3. Reference Contract Clause 252.236-7008, CONTRACT PRICES – BIDDING SCHEDULES (DEC 1991).

The prices shown in the Bidding Schedule must reflect ALL costs involved in performing the work, as described in the plans and specifications.

4. The term “Bidding Schedule” shall also be construed to mean “Offer Schedule” or “Schedule”. The terms “bid” and “offer”, and “bidder” and “offeror” shall be construed as having the same meaning in this solicitation and resulting contract.

5. All information relating to this IFB, including pertinent changes/amendments and information will be posted on web site: http://www.fbo.gov.

6. Facsimile transmission of bid is not authorized.

7. Government reserves the right to include additive bid items taken at time of award in the Base CLIN to facilitate and simplify schedule and payment processing.

8. All information relating to this IFB, including pertinent changes/amendments and information will be posted on web site: http://www.fbo.gov. For security reasons, all potential offerors, plan rooms and printing companies are required to be registered in the GSA System for Award Management (SAM) database. Firms can register via the SAM internet site at https://www.sam.gov/portal/public/SAM/. Interested bidders are required to submit their representations and certifications at the same site.

9. A single award is contemplated. Prospective bidders must bid on all items to be considered for award. See explanation of how low bid will be determined in section 00100 of the solicitation.

10. A complete bid package must contain the following:

(a) Offer, Standard Form (SF) 1442 front and back signed

(b) Section 00010 Line Items- all items must be priced

(c) A valid Bid Bond. Standard Form 24.

(d) Section 00600, Representations and Certifications, completed and return only additional certifications found in this section In addition, the offeror must have entered current and complete data within the past year in Online Representations and Certifications at www.sam.gov.

(e) When completing the “Offeror” portion of the SF 1442 (Blocks 14 – 20), an official having the authority to contractually bind the company must sign the SF 1442 in accordance with FAR 4.102.

One copy of the SF1442 is required to have an original signature.

(f) All amendments to the solicitation must be acknowledged.

(g) Mark the front of the envelope with the following: “BID No. W912L1-17-B-0001”, and the Name and

Address of Bidder. See Block 13A of SF 1442 for required number of copies.

QUESTIONS AND ANSWERS

Questions and Answers for Solicitation Number: W912L1‐17‐B‐0001

1. As per item #0005 states that there will be a one-time administrative cost allowed. Please verify amounts.

Answer: The awarded vendor will be required to comply with the Army’s policy for Contractor Manpower Reporting. The vendor is allowed a onetime fee for the administrative cost associated with providing the information online. See below for details: “The Office of the Assistant Secretary of the Army (Manpower & Reserve Affairs) operates and maintains a secure Army data collection site where the contr manpower) required for perfor information in the forma using their estimated price associated labor hours and associated cos

2. Is there chases or block outs pr thru engine shop/tool room?

Answer: The refrigerant pipin room. The piping shall be rou piping shall be concealed insid partitions. Contractor will be r No fittings shall be installed in

3. Does the mini split ductless sy

Answer: No. Heat is provided supplemental cooling in these

4. On page 3 of 5 (statement of w out thru exterior wall near grad

Answer: A French Drain is no provided at the condensate dis

5. On page 3 of 5 (statement of w exterior wall to condensing un cover?

Answer: Penetrations through annual space shall be filled wi actor will report ALL contractor manpower (including su rmance of this contract. The contractor is required to com g the following web address: https://cmra.army.mil. The v d with inputting the required number of contractor employ st data in regards to this requirement.

rovided that can be used to route the drains and or refrige ng and condensate piping will be exposed to view in the en uted neatly along the wall through this space. In the Train de the metal-stud walls that form the door pockets for the responsible to restore the wall to its original state after ins nside the wall. The wall is shown in the image below.

ystems for training rooms 224,225 and 226 requires heatin d by existing FCU 2-2. The mini-split systems are to be in spaces, but are not required to provide supplemental heat work) line item 6.b.iv. states to run condensate

de. Does it require having a French drain?

ot required. The discharge should be above grade and A s scharge.

work) line item 6.b.iv. states to route insulated refrigerant nits. Does it require having sleeves thru exterior wall and a h the wall should be sealed water tight. Sleeves are not req th joint sealant and back-up material.

W912L1-17-B-0001 ubcontractor mpletely fill in all the vendor must provide yees using direct rant line sets down ngine shop / tool ning rooms, the accordion wall stalling the piping.

ng?

nstalled to provide ting.

splash block shall be line sets thru a metal shroud quired, but the

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0001 270 dys. ADC 1 F9CESC - 147 CES/DE

CAMPBELL, CHRISTIAN

14657 SNEIDER STREET

BLDG #1256

ELLINGTON FIELD

HOUSTON TX 77034-5586

281-929-2702

F9CESC

0002 270 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0003 270 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0004 270 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0005 28-SEP-2017 1 F6S3CE

CHRISTIAN CAMPBELL

147 CES

14657 SNEIDER STREET

HOUSTON TX 77034-5586

281-929-2702

F6S3CE

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 Attachment 1- Technical

Specifications Combined

Attachment 2 Attachment 2- As Built- Mech Plumb Drawings

Attachment 3 Attachment 3- As Built- Electrical Drawings

Attachment 4 Attachment 4- ECN 5 Existing coil sketch

Attachment 5 Attachment 5- ECN 5 Propsed coil sketch

Attachment 6 Attachment 6- Elect drawings ECN-4

Attachment 7 Attachment 7- Mech drawings ECN-4 and

ECN-5

Attachment 8 Wage Determination

Section 00100 - Bidding Schedule/Instructions to Bidders

INSTRUCTIONS

SECTION 00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

1. SCOPE:

1.1. You are invited to submit a bid in response to our Invitation for Bids (IFB) entitled) W912L1-17-B-0001 entitled UAV Hangar HVAC Repairs, Project Number FWJH069194A, at Ellington Field JRB in Houston, Texas.

1.2. As a result of this solicitation, the Government intends to award a Firm Fixed Price (FFP) contract resulting from this solicitation to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantageous to the Government, considering only price.

1.3. This solicitation is set-aside 100% for small businesses.

2. NOTICE OF PRE-BID CONFERENCE AND SITE VISIT:

2.1 A pre-bid conference will be conducted on 05 July 2017, 1:00PM local time for the purposes of briefing on the bid requirements and answering questions regarding this solicitation. This conference will be held at Ellington Field JRB in Houston, Texas. Interested Contractors are highly encouraged to attend the pre-bid conference. The site visit will be held following the conference.

2.2 Due to security conditions, all offerors must register to attend this conference and site visit. Email the attached form completely filled out (147 SFS Form 3) for all attendees to Linda Janak at the following address joseph.r.cederstrom.mil@mail.mil . Be sure to include in the subject line of your email “Pre-Bid Conference/Site Visit” or your request might be overlooked.

2.3 This information must be provided in advance, 3 business days prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. Even if you have access to the base you must register to ensure adequate seating. The furnishing of the above information is voluntary; however, your failure to furnish all or part of the requested information may result in the Government’s denial of your access to the pre-proposal conference. This information will be provided to the Base Security Forces who will authorize your entrance to the site.

2.4 You will be required to present the following information upon arrival: (1) Vehicle Registration, (2) Valid Drivers License, (3) Proof of Insurance for Vehicle, (4) Safety Inspection and Car Rental agreement if applicable. Any of the above information furnished by you is protected under the Privacy Act and shall not be released unless permitted by law and/or you have consented to such.

2.5 Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitation is amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

2.6 A record of the conference shall be made and furnished to all prospective bidders via posting at http://www.fbo.gov. The record will include minutes of the meeting, including questions (on a non-attribution basis) and answers.

3. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS:

3.1 Submit all questions in the format shown below by email to the contracting office at the addresses show below. Do NOT contact Engineering personnel directly. Doing so will only delay your answer. All questions must come through the Contracting Office.

Subject Line: Reference No. SOLICITATION W912L1-17-B-0001 Email: joseph.r.cederstrom.mil@mail.mil

PRE-BID INQUIRY FORMAT

Date of Bid Inquiry: _______________

From: ______________________________ Company Name: ________________________________

Address:_____________________________________________________________________________

Phone Number: _____________________________ Fax Number:______________________________

Email address: ________________________________________________________________________

Bid Inquiry: (Please clearly state your question) (If sent via an attachment word docs are preferred to facilitate posting of answers to the master Q&A document.)

3.2 Any explanation desired by an offeror regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach bidders before the submission of their bid.

3.3 All questions and requests for information (RFI) must be received NOT LATER THAN close of business on 09 July 2017. OFFERORS ARE STRONGLY ENCOURAGED TO SUBMIT QUESTIONS EARLY IN

THIS PROCESS.

3.4 Any changes to the drawings, specifications, etc. will be issued in the form of an amendment. However, any answers that clarify or provide an interpretation to the drawings, specifications, etc. will NOT be posted via amendment but rather as a response to the RFI on FBO at http://www.fbo.gov

3.5 Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of bids.

3.6 For security reasons, all technical and engineering data related to this solicitation will be distributed using the Federal Business Opportunities (FedBizOpps.gov or fbo.gov) system. FedBizOpps is a web-based dissemination tool designed to safeguard acquisition-related information for all Federal agencies. Interested bidders/offerors must register with FedBizOpps before accessing the system. FedBizOpps registration requires the following information:

3.6.1 Amendments, if/when issued will be posted to https://www.fbo.gov/ for electronic downloading.

This will normally be the only method of distributing amendments prior to closing; therefore, it is the offerors responsibility to check the website periodically for any amendments to the solicitation. Websites are occasionally inaccessible due to various reasons.

4. AMENDMENTS PRIOR TO DATE SET FOR OPENING OF BIDS: The right is reserved, as the interest of the Government may require, to revise or amend the solicitation, specifications and/or drawings, prior to the date set for opening of bids, as necessary. Such changes, if any, will be announced by an amendment or amendments to this Invitation for Bids. All information relating to this IFB, including pertinent changes/amendments and other information applicable prior to the date set for receipt of bids will be posted at: http://www.fbo.gov. Offerors are strongly cautioned to check this site frequently and to “refresh” their web page to ensure they have the latest information.

5. BID REPOSITORY AND BID OPENING:

5.1 A bid repository is provided for hand carried bids and is located at:

USPFO FOR TEXAS

ATTN: CONTRACTING (CEDERSTROM)

2200 W. 35TH STREET

CAMP MABRY, BUILDING #66

AUSTIN, TEXAS 78703

Hand carried bids must be deposited in the repository prior to the time established for opening of bids. Bidders are cautioned that they will be required to sign-in and obtain a visitor’s pass to enter the facility and should allow time to accomplish this. Offerors are cautioned that Camp Mabry does have a security guard at the entrance and a proof of identity is required to enter. Word will be provided to security the day the proposal is due and they will be expecting your arrival. Have the Contracting Officer’s name, building number and phone number available. Delays are probable at the entry point and should be accounted for. Late receipt of proposals due to base entry delays may not be deemed excusable and the Contracting Officer may declare the proposal late and remove it from consideration. Late receipt of bids due to entry delays may not be deemed excusable and the Contracting Officer may declare the bid “late” in accordance with FAR 14.304.

5.2 The bid opening will occur at the time and date specified in Block 13 of the SF1442 AT:

2200 W. 35TH STREET

CAMP MABRY, BUILDING #66

AUSTIN, TEXAS 78703

5.3 All interested offerors and their major subcontractors are encouraged to attend the bid opening.

6. WAGE DETERMINATION: Davis Bacon Wage Rates are applicable to this project. Current prevailing wage determination(s) at time of issuance of solicitation are. General Decision Number TX170303 04/21/2017 TX303, Harris County. Applicable wage rates can be found at Applicable wage rates can be found at http://www.wdol.gov/wdol/scafiles/davisbacon/tx.html

7. BID PREPARATION EXPENSES AND PRE-CONTRACT COSTS: This IFB does not commit the Government to pay costs incurred in preparation and submission of bids or for other costs incurred prior to award of a formal contract.

8. INFORMATION REGARDING AVAILABILITY OF UTILITY SERVICES: Reference information found at Section 00700 FAR Provision/Clause 52.236-14, Availability and Use of Utility Services consideration when computing its offer.

9. CLAUSES:

9.1 Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

9.2 Clauses and provisions in this document may not appear in consecutive order.

10. REMOVAL OF SECTIONS AT TIME OF AWARD: Sections 00100 and 00600 will be physically removed as a result of an award, but will be deemed to be incorporated by reference in that award.

11. DISPOSITION OF UNSUCCESSFUL BIDS:

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful bids. The Government will destroy extra copies of unsuccessful bids. No destruction certificate will be provided.

12. OFFERORS QUALIFICATIONS:

To establish its responsibility, the apparent low bidder may be requested by the Government prior to award, to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial and bonding resources and plant available to be used in performing the work. This action may be requested to determine if the contractor is responsible.

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-22 Alternative Line Item Proposal JAN 2017 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.225-10 Notice of Buy American Requirement--Construction Materials

MAY 2014

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

27.3% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Houston, Texas Harris County

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

Protest to the independent review authority shall be filed with either the Office of the Chief Council or the Contracting Officer:

Office of Chief Counsel

ATTN: NGB Protest Decision Authority 1411 Jefferson Davis Highway Jefferson Plaza 1; Suite 11300 Arlington, Virginia 22202-3231 FAX (703) 607-3684 or 3682

OR

Protest to the Contracting Officer shall be filed at:

USPFO FOR TEXAS

ATTN: Contracting (Koenig) 2200 W. 35th Street Camp Mabry, Building #66 Austin, Texas 78703-1222

ONLY WRITTEN PROTESTS WILL BE CONSIDERED. NO PROTESTS MAY BE FILED BY ELECTRONIC MAIL.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: MAJ Christian Campbell Address: 11210 Blume Avenue, Houston, Texas 77034 Telephone: 281-929-2702 or cell 281-743-0137

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.arnet.gov/far http://farsite.hill.af.mil http://www.acq.osd.mil/dpap

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

None.

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Deviation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00600 - Representations & Certifications

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2017)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding elinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

X (i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

252.203-7005 REPRESENTATION RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (NOV 2011)

(a) Definition. Covered DoD official is defined in the clause at 252.203-7000, Requirements Relating to Compensation of Former DoD Officials.

(b) By submission of this offer, the offeror represents, to the best of its knowledge and belief, that all covered DoD officials employed by or otherwise receiving compensation from the offeror, and who are expected to undertake activities on behalf of the offeror for any resulting contract, are presently in compliance with all post-employment restrictions covered by 18 U.S.C. 207, 41 U.S.C. 2101-2107, and 5 CFR parts 2637 and 2641, including Federal Acquisition Regulation 3.104-2.

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2015)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Commercial Satellite Services from Certain Foreign Entities-- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

Section 00700 - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreeements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-21 Basic Safeguarding of Covered Contractor Information Systems

JUN 2016

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-14 Limitations On Subcontracting JAN 2017 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015

52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.223-4 Recovered Material Certification MAY 2008 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-1 Bid Guarantee SEP 1996 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And…