Amend 0001 W912HY20B0031.pdf

W45VAK00771438

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is show n on the follow ing pages: See page 2

THE BID OPENING DATE REMAINS ON 13 JUL 2020 AT 2:00 P.M. LOCAL TIME.

NO OTHER CHANGES.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912HY20B0031

X 9B. DATED (SEE ITEM 11)

11-Jun-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO.

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

23-Jun-2020

CODE

CONTRACTING DIVISION

US ARMY CORPS OF ENGINEERS

2000 FT. POINT RD.

GALVESTON TX 77550

W912HY 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912HY20B0031

A0001-2

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

THE SPECIFICATIONS FOR SOLICITATION NO. W912HY19B0031, HOUSTON SHIP

CHANNEL, TEXAS LOST LAKE PLACEMENT AREA IN HARRIS COUNTY, TEXAS

PROJECT MANUAL FOR IMPROVEMENTS, ARE HEREBY AMENDED AS FOLLOWS:

a) Changes by narrative.

(1) SECTION 00 73 00.00 45, SPECIAL CONTRACT REQUIREMENTS, STANDARD –

(a) Paragraph 1.1: COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK (APR 1984) (FAR 52.211-10)

The Contractor shall be required to:

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the Notice to Proceed. Issuance of Notice to Proceed may be delayed up to 120 calendar days after contract award.

(2) SECTION 01 50 00.00 45, TEMPORARY CONSTRUCTION FACILITIES AND

CONTROLS –

(a) Paragraph 1.5 OTHER CONTRACTORS IN THE WORK AREA

At the time of advertise, a contractor working for a non-federal entity is placing dredged material at the project site. The Government may delay issuance of Notice to Proceed in order to give the site some time to drain and dry out, but the site will not be restored to a pre-dredge condition prior to commencement of work. The Contractor should therefore expect very wet and soft conditions when Notice to Proceed is issued.

(b) Paragraph 2.2.1.1 (DELETED)

(c) Paragraph 3.5.4 (DELETED)

b) Specifications.

(1) No Attachments.

c) Drawings.

(1) No Changes to Drawings

2. This amendment shall be attached to and become a part of the solicitation.

0 Encls: