18-Q-0015_Am0001_CONFORMED.pdf

SEE ADDENDUM

(No Collect Calls)

W912CN-18-Q-0015 12-Mar-2018

b. TELEPHONE NUMBER

808.656.0976

8. OFFER DUE DATE/LOCAL TIME

02:00 PM 26 Apr 2018

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W912CN9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

ANTHONY G. REYES

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

EXPEDITIONARY CONTRACTING COMMAND

413TH CSB, RCO-HAWAII,

742 SANTOS DUMONT AVENUE

BLDG 108, 3RD FLOOR (WAAF)

SCHOFIELD BARRACKS HI 96857-5026

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE WX3JN3 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

US ARMY GARRISON HI DIR OF PUB WKS DPW

DALE KANEHISA-LAM

BLDG 104 947 WRIGHT AVE WAAF SCB DIV

SCHOFIELD BARRACKS HI 96857-5000

TEL: 808-656-5411 FAX: 8086567771

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

$38,500,000

NAICS:

562111

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF95

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W912CN-18-Q-0015

Section SF 30 - BLOCK 14 CONTINUATION PAGE

ATTACHMENT 1

GENERAL INFORMATION

1. The Contractor shall be responsible for provide recycling services for the USAG-HI, including recyclable material collection, delivery, segregation, offsite transport of recycling commodities, and operational management of the USAG-HI Recycling Center. Recyclable items consist of aluminum cans, paper (white, color, all shreds), mixed paper, newspaper, cardboard, scrap metal (ferrous and non-ferrous), glass bottles, green waste, plastic bottles, plastic containers (recycling resin code numbers 1 through 5), magazines, pallets, phone books, toner/ink cartridges, oil filters (drained), oil cans (drained, tops cut off), wood waste (unpainted, untreated), bulky items, and any other material deemed by the Government to be candidates for recycling. The contractor shall provide a detailed accounting of all recyclable items recycled (type and weight) to the Contracting Officer Representative (COR) monthly. The Contractor would retain proceeds generated from the sales of recycled commodities.

2. This is a Firm Fixed Price Requirements contract. All quantities shown are estimated and provided for informational purposes only. The actual quantities ordered may be more or less than the estimated quantities. (See clause 52.216-21 entitled “Requirements”). As a prerequisite of the Government hereunder, there must be (i) adequate and sufficient funds available to cover the order, and (ii) an administrative determination by the Government that the requirement exists.

3. The Period of Performance is anticipated to be:

Base Period: 1 Aug 2018 – 31 Dec 2018 Option Period: 1 Jan 2019 – 30 Jun 2019

4. This solicitation contains the following Attachments:

Attachment 1 – General Information Attachment 2- Addendum to FAR 52.212-1 Attachment 3- Addendum to FAR 52.212-2 Attachment 4- Performance Work Statement (PWS) Attachment 5- Work Experience Information Sheet Attachment 6- U.S. Department of Labor Wage Determination No. 2015-5689, Revision 6 Dated 10 January 2018.

5. Contract Award. This procurement is a total Small Business set-aside. The Government reserves the right to cancel this solicitation, either before or after the closing date. Such action shall not constitute grounds or basis for any claims for quote preparation costs from contactors responding to the solicitation. Selection of awardee will be based on FAR Subpart 12.6 and FAR Subpart 13.5. Award will be made in accordance with Addendum to FAR 52.212-2.

6. Quotes shall be submitted through Federal Business Opportunities (fbo.gov). Please see Addendum to FAR 52.212-1. If unable to submit quotation in fbo.gov, please contact Contract Specialist, Anthony Reyes; anthony.g.reyes1.civ@mail.mil or Contracting Officer, Susan Shafii;

susan.shafii.civ@mail.mil.

7. Questions must be submitted in writing to Contract Specialist, Anthony Reyes;

anthony.g.reyes1.civ@mail.mil or Contracting Officer, Susan Shafii;

susan.shafii.civ@mail.mil in accordance with Addendum to FAR 52.212-1. A response to questions submitted will appear as an Amendment on the Federal Business Opportunities website: https://www.fbo.gov. The deadline for submission of questions is no later than ten business days after issuance of solicitation. Questions received after 4:00 p.m., HST on the tenth business day may not be answered.

8. The closing date and time of this solicitation is reflected in Block 8 of the Standard Form (SF) 1449.

9. Site Visit:

a . The site visit is scheduled for 20 March 2018. All interested offerors are required to register attendance no later than 16 March 2018. Interested offerors shall contact Anthony Reyes, phone (808) 656-0976, email: anthony.g.reyes1.civ@mail.mil for registration. Attendees that are not registered may not be permitted to participate in the site visit. All costs associated with attendance are at the expense of the offeror.

b. Due to security reasons, photography and filming of any type are prohibited. Interested firms are requested to limit attendance to three (3) representatives. In addition, offerors will have the opportunity to submit written questions concerning requirements of this Request for Quotation.

c. The Government cannot guarantee that technical personnel will be available at any other time. Any discussions, remarks, and explanations that may be made by Government representatives during this event will not change the terms of the solicitation, unless the solicitation is amended in writing.

Site visit is scheduled:

Date: 20 March 2018 Time: 10:00 a.m. (HST) Location: Army Recycling Center (ARC) Building 1087 McMahon Rd Schofield Barracks, HI 96857 Access To Army Installations:

All vehicle operators must obtain visitor pass prior scheduled site visit, prepared to provide a valid driver’s license, vehicle registration, certificate of insurance and current safety inspection to the security guard prior to entry to the Installation. Offerors should anticipate a delay in entering the Installation and allow sufficient time when attending a site visit or hand delivering an offer at:

Visitor pass may obtain at:

Lyman Gate Lyman Road, Schofield Barracks, Wahiawa, HI 96787 Point Of Contact: Anthony Reyes, Work Telephone Number: (808) 656-0976

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES ESTIMATED

QUANTITY

UNIT UNIT PRICE ESTIMATED AMOUNT

0001 475 Net Ton (2,000

LB).

PSC S205 Recyclable Material Collection

FFP

Provide recyclable material collection services in accordance with the Performance Work Statement (PWS) paragraphs 2.1. & 2.2.

FOB: Destination

PSC CD: S205

ESTIMATED

NET AMT

UNIT UNIT PRICE ESTIMATED AMOUNT

0002 1 Each PSC S205 eCMRA Annual Reporting

FFP

Enterprise Contractor Manpower Reporting Application (eCMRA) annual reporting in accordance with Performance Work Statement (PWS) paragraph 7.

QUANTITY

UNIT UNIT PRICE ESTIMATED AMOUNT

1001 570 Net Ton (2,000

LB).

OPTION PSC S205 Recyclable Material Collection

FFP

Provide recyclable material collection services in accordance with the Performance Work Statement (PWS) paragraphs 2.1. & 2.2.

UNIT UNIT PRICE ESTIMATED AMOUNT

1002 1 Each OPTION PSC S205 eCMRA Annual Reporting

FFP

Enterprise Contractor Manpower Reporting Application (eCMRA) annual reporting in accordance with Performance Work Statement (PWS) paragraph 7.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government 1001 Destination Government Destination Government 1002 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 POP 01-AUG-2018 TO

31-DEC-2018

N/A US ARMY GARRISON HI DIR OF PUB

WKS DPW

DALE KANEHISA-LAM

BLDG 104 947 WRIGHT AVE WAAF

SCB DIV

SCHOFIELD BARRACKS HI 96857-5000

808-656-5411

WX3JN3

0002 POP 01-AUG-2018 TO

31-DEC-2018

N/A (SAME AS PREVIOUS LOCATION)

1001 POP 01-JAN-2019 TO

30-JUN-2019

N/A (SAME AS PREVIOUS LOCATION)

1002 POP 01-JAN-2019 TO

30-JUN-2019

N/A (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-10 Waste Reduction Program MAY 2011

52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.228-5 Insurance - Work On A Government Installation JAN 1997 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.237-2 Protection Of Government Buildings, Equipment, And Vegetation

APR 1984

52.242-15 Stop-Work Order AUG 1989 52.252-6 Authorized Deviations In Clauses APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.223-7001 Hazard Warning Labels DEC 1991 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.225-7012 Preference For Certain Domestic Commodities DEC 2016 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7006 Wide Area WorkFlow Payment Instructions MAY 2013 252.232-7010 Levies on Contract Payments DEC 2006 252.237-7010 Prohibition on Interrogation of Detainees by Contractor

Personnel

JUN 2013

252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.245-7004 Reporting, Reutilization, and Disposal SEP 2016

CLAUSES INCORPORATED BY FULL TEXT

52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (JAN 2017)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF 1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees.

See Addendum to FAR 52.212-1.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show--

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation), or alternative commercial items for satisfying the requirements of this solicitation.

Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers:

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers.

Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA Federal Supply Service Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC 20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision.

Additional copies will be issued for a fee.

(2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(i) ASSIST (https://assist.dla.mil/online/start/).

(ii) Quick Search (http://quicksearch.dla.mil/).

(iii) ASSISTdocs.com (http://assistdocs.com).

(3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by--

(i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone

(215) 697-2667/2179, Facsimile (215) 697-1462.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM) database.) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) System for Award Management. Unless exempted by an addendum to this solicitation, by submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed through https://www.acquisition.gov.

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

52.212-2 EVALUATION--COMMERCIAL ITEMS (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

See Addendum to FAR 52.212-2.

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the options.

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision --

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means—

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) Concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

"Forced or indentured child labor" means all work or service-

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except--

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate--

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology--

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically--

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

"Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern”, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned--

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name.

The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Veteran-owned small business concern” means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

"Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

"Women-owned small business concern" means a small business concern--

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; or

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)”, means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted electronically on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212- 3, Offeror Representations and Certifications--Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ___ .

[Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any.) These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a small business concern.

(2) Veteran-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. (Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, ( ___ ) is not a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, ( ___ ) is not a women-owned small business concern.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that--

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___ .] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that--

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ___ -.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(8) Women-owned business concern (other than small business concern). (Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

(10) HUBZone small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ___ .] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Certifications and representations required to implement provisions of Executive Order 11246--

(1) Previous Contracts and Compliance. The offeror represents that--

(i) It ( ___ ) has, ( ___ ) has not, participated in a previous contract or subcontract subject either to the Equal Opportunity clause of this solicitation, the and

(ii) It ( ___ ) has, ( ___ ) has not, filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that--

(i) It ( ___ ) has developed and has on file, ( ___ ) has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR Subparts 60-1 and 60-2), or

(ii) It ( ___ ) has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract.