W912BV20Q0128 Tenkiller Fire Rings.pdf

SEE ADDENDUM

(No Collect Calls)

W912BV20Q0128 25-Jul-2020

b. TELEPHONE NUMBER

918.669.4916

8. OFFER DUE DATE/LOCAL TIME

02:00 PM 14 Aug 2020

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA X ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W912BV9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

LEROY R LEMARR

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

1 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.X

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

CONTRACTING DIV

US ARMY CORPS OF ENGINEERS, TULSA DISTRICT

2488 E. 81ST STREET

TULSA OK 74137-4290

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

918-669-7436FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

$8,000,000

NAICS:

713990

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF81

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W912BV20Q0128

Section A - Solicitation/Contract Form

INSTRUCTIONS TO OFFERS

Instructions to Offerors

MAIL, FAX, EMAIL or HAND DELIVER YOUR DOCUMENTS

Do not include excess information, to include audio-visual materials, electronic media, CD’s, thumbdrives, etc. or pages of the solicitation that do not contain information provided by the perspective offeror. NO cross outs or strike through marks. Submit a legible quote with no correction marks.

EMAIL

Emailed quotes must be received in a supported Adobe or Microsoft Office file format. These formats are the only acceptable methods of submitting a quote electronically. Cloud storage providers, google docs, web based drop boxes, OneNote/OneDrive, URLs, web-based format, or any other virtual/web-based memory service are NOT acceptable methods of submitting a quote electronically. All documents must be attached in one file. Reference the solicitation in the subject line. Send quotes to E-mail address CESWT‐CT‐SS‐Quotes@usace.army.mil and copy leroy.r.lemarr@USACE.Army.mil and Douglas.D.Buffington@USACE.Army.mil. Ensure your quote is received before the due date and time. In order for your quote to be considered responsive, all required materials must be received before the due date and time. If all required materials are not received your quote will not be considered.

FAX or MAIL

Include a cover sheet that references the Contract Specialist – LeRoy LeMarr and the solicitation number. When submitting through mail ensure you clearly mark the envelope to:

TULSA DISTRICT CORPS OF ENGINEERS

LeRoy LeMarr, CESWT-CTE 2488 E. 81st Street

TULSA, OK 74137-4290

Clearly mark the envelope in the lower left hand corner with the solicitation number. All pages should be numbered.

Use only 8 ½ by 11 inch paper for fax or mail submissions. Do not use fold-outs (e.g., 11” x 14” or 11” x 17” sheets). Do not use a font size smaller than 10, or condensed print for any submission. Time New Roman or Arial Font are the only acceptable fonts. All page margins must be at least 1 inch wide, but may include headers and footers. Illegible handwritten quotes will not be considered. Typed quotes are highly encouraged and the preferred method. Do not use spring clamps, staples, or exceed the recommended capacity of the fastener or binder. Do not use plastic multi-hole/spiral binding systems, heat binding systems, or other systems which do not facilitate the ready insertion of additional pages or removal of pages. DO NOT use tabbed dividers, flagged tabs, or any divider that extends beyond the paper size to separate sections. The pages must be able to be removed from their binding without ripping or tearing. Ensure to allow enough time to submit your quote before the due date and time.

HAND DELIVER

If your submission will be hand-carried, please provide notification to the Contract Specialist at least one working day in advance (918-669-4916) or leroy.r.lemarr@USACE.Army.mil, as unescorted visitors are not allowed in the Contracting Division offices. Please consider in your arrival that visitors must go through security checkpoints located on the 16th floor of the small tower. Offerors can only submit their documents to the Contract Specialist or a Contracting Officer of the Tulsa District Office. The address of the Tulsa District Office is below:

TULSA DISTRICT CORPS OF ENGINEERS

2488 E. 81st Street

TULSA, OK 74137-4290

This procurement is being conducted in accordance with Simplified Acquisition Procedures (SAP) of FAR Parts 12 and 13. Any reference to offers or bids or offerors or bidders should be substituted with quotations or quoters. All reference to discussions shall not be interpreted under FAR Part 15, but rather indicate that the Government may communicate with offerors/quoters as allowed under simplified acquisition procedures.

Please submit the following documents:

1) A signed copy of the 1st page of the solicitation and all amendments

2) Complete the pricing schedule provided in the solicitation at SECTION B

3) Offeror is requested to provide an estimated lead time, award is not based upon lead time, at SECTION F, FAR 52.211-8 and SECTION K FAR 52.225-18.

4) Offeror shall provide the country of origin.

INQUIRIES – OFFEROR’S QUESTIONS AND COMMENTS

USE OF BIDDER’S INQUIRY

Prospective offerors shall submit questions and inquiries related to this solicitation in accordance with the following (no other means of questions or inquiries will be answered except through Bidder Inquiry):

a. For information related to amendments, and the dates set for receipt of proposals, please check http://www.fedbizopps.gov

b. Contractual and Technical inquiries and questions relating to proposal procedures are to be submitted via Bidder Inquiry in ProjNet at https://www.projnet.org/projnet.

1. To submit and review bid inquiry items, offerors will need to be a current registered user or self‐register into the system. To self‐register go to the aforementioned web page and click on the BID tab. Select Bidder Inquiry, select agency USACE, and enter the Bidder Inquiry Key for this solicitation listed below, your e‐mail address, and then click login. Fill in all required information and click create user. Verify that information on next screen is correct and click continue.

2. From this page you may view all bidder inquiries or add an inquiry.

3. Bidders will receive an acknowledgement of their question via e‐mail, followed by an answer to their question after it has been processed.

4. The Solicitation Number is: W912BV20Q0128

The Bidder Inquiry Key is: AVGZ65‐YJEZAX

c. The Bidder Inquiry System will be unavailable for new inquiries 2:00 PM CST, 07 AUG 2020 in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation, if necessary.

d. Offerors are requested to review the specification in its entirety, and review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

e. The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800‐428‐HELP.

f. Offers will NOT be publicly opened. Information concerning the status of the evaluation and/or award will NOT be available after receipt of proposals.

g. The point of contact for this solicitation is:

Contract Specialist: Leroy Lemarr Telephone: 918‐669‐4916 E‐MAIL: leroy.r.lemarr@USACE.Army.mil or

Contract Specialist: Douglas Buffington Telephone: 918‐669‐7078 E‐MAIL: Douglas.D.Buffington@USACE.Army.mil

PREPROPOSAL/SITE VISIT CONFERENCE

A pre-proposal conference is scheduled for August 04, 2020 at 10:00 am CST at the Tenkiller Lake Office 446977 E. 980 Rd. Gore, OK. 74435. Only one person per Contractor allowed, all personnel MUST provide their own masks and PPE. The Site Visit will allow prospective Contractors an opportunity to view the site conditions first hand. A question and answer period will not be conducted. Questions must be posed using Bidder s Inquiry as per the instructions above. .

ANTITERRORISM AND OPERATIONS SECURITY REQUIREMENTS

The Government will provide the successful offeror with the required Army iWatch Antiterrorism Briefing documentation within two (2) business days of Contract Award.

In accordance with AFARS 5132.702(a)(ii)(B): “Funds are not presently available for this acquisition. No contract award will be made until appropriated funds are made available.”

Section B - Supplies or Services and Prices

PRICE SCHEDULE

PRICE SCHEDULE

Grand Total: $__________________

CLIN ITEM QTY Unit Unit Price Amount

0001 Snake Creek Fire Rings 112 Each $ $ in accordance with SECTION C, 3.1.

Country of Origin: _____________________________________________________

0002 Snake Creek Campsite Grills 112 Each $ $ in accordance with SECTION C, 3.1.

Country of Origin: _____________________________________________________

0003 Snake Creek Large Group Grills 3 Each $ $ in accordance with SECTION C, 3.1.

Country of Origin: _____________________________________________________

0004 Elk Creek Fire Rings 41 Each $ $ in accordance with SECTION C, 3.1.

Country of Origin: _____________________________________________________

0005 Elk Creek Campsite Grills 41 Each $ $ in accordance with SECTION C, 3.1.

Country of Origin: _____________________________________________________

0006 Elk Creek Large Group Grills 2 Each $ $ in accordance with SECTION C, 3.1.

Country of Origin: _____________________________________________________

Section C - Descriptions and Specifications

WORK REQUIREMENT

Specifications of Work

Provide and Install Fire Rings, Campsite BBQ Grills and Large Group BBQ Grills at Snake and Elk Creek Campgrounds and Recreation Area

Tenkiller Lake, Oklahoma

PART 1 – GENERAL

1.1 Scope of Work. The contractor shall provide all labor, materials, tools, equipment, grills, fire rings and other items required to provide and install at Snake Creek Park 112 Fire Rings, 112 Campsite BBQ Grills and 3 Large Group BBQ Grills and Elk Creek will require 41 Fire Rings, 41 Campsite BBQ Grills and 2 Large Group BBQ Grills. The Contractor shall perform all tasks to the standards and specifications in this contract. The Tenkiller Lake Snake and Elk Creek are located in Cherokee County, Oklahoma.

1.1.2 Location of Work. Located at the Snake and Elk Creek Campground Facility in the Tenkiller Lake Area.

1.1.3 Site Conditions. A site visit by prospective bidders is encouraged to determine exact site conditions and work requirements. Work will be in a campground.

1.2.1 Pre-Proposal Conference. A pre-proposal conference is scheduled for 4 August 2020 at 10:00 AM CST at 446977 E. 980 Rd. Gore, OK. 74435.

1.2.2 The purpose of the site visit will be to familiarize prospective bidders with the extent and nature of the requirement and location of performance. Oral questions pertaining to this work will not be answered during the tour of the performance work areas. Any questions of any nature must be submitted to Bidders Inquiry Site.

1.2.3 These questions and answers will be posted on Bidder Inquiry Site and constitute the official Corps answer.

1.2.4 All prospective bidders are strongly urged to attend the pre-proposal conference and to satisfy themselves as to all general conditions that may affect the cost and schedule of performance of this contract.

1.3 References. All work will be accomplished in accordance with standard work practices.

1.4 Basis of Payment. The contractor may invoice for payment after all work has been completed, inspected and accepted by the Government. Invoice shall have as a minimum: Contractor's company name, contract number, invoice number, and date. Mail, email, fax, or hand deliver invoice and other required forms to: Corps of Engineers, Tenkiller Project Office, 446977 E. 980 Rd. Gore, OK 74435.

1.5 Work Hours. The contractor may work between the hours of 7:00 a.m. to 5:00 p.m., Monday through Friday, excluding federal holidays. Any proposed changes to the work hours must be approved by the Contracting Officer Representative (COR).

1.6 Completion Time. Work shall be completed within 90 calendar days. The Government understands there may be more lead time needed for the manufacturing and delivery of BBQ grills and fire rings.

1.7 Safety Requirements. The contractor shall comply with the Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, current edition, and all applicable Federal, State, and local safety codes and practices. Matters of interpretation of the standards shall be submitted to the Contracting Officer for resolution before starting work. Where the regulations conflict, the most stringent requirements shall apply. It is the contractor’s responsibility to insure public safety during the entire duration of the contract. Necessary signs, barriers, warning devices, etc. shall be operated and maintained by the contractor at contractor expense. Contractor employees shall comply with the minimum dress requirements as stated in Chapter 7 of EM 385-1-1.

1.7.1 The following sections of the manual are particularly applicable to the work under these specifications.

Section 14 – Material Handling, Storage, and Disposal; Section 18 - Vehicles, Machinery, and Equipment. Workers shall be required to comply with the minimum clothing requirements for field work which includes short sleeve shirt, long pants, leather or protective work boots, hard hat, and proper ear, hand, and eye protection as necessary.

Persons exposed to vehicular traffic shall wear reflective vests or high visibility apparel. Traffic warning signs will be required when equipment is parked on the roadway and a flagman present to direct traffic anytime equipment and personnel are working from or on the roadway. The work plan shall include procedures to follow in case of injury accidents. The Contractor shall review the safety requirements with all workers prior to any work under this Contract.

1.8 Equipment. All equipment used to perform work under this contract shall be in good operating and mechanical condition and shall comply with Section 18 of EM 385-1-1 (30 NOV 2014). Equipment shall be inspected by the contractor and the inspection reports shall be submitted to the Contracting Officer prior to utilization of such equipment to accomplish work on this contract.

1.9 Environmental Cleanup. The contractor shall maintain a clean work area at all times. The contractor shall be responsible for the protection of the environment and will be required to restore all damages subject to the approval of the contracting officer. The contractor shall remove and dispose of all debris off Government property in a state approved disposal site unless specified otherwise. The contractor will be required to comply with Federal and State environmental requirements.

1.9.1 Quality Control. The contractor is responsible for all actions necessary to allow for successful completion of this contract. Plumbing work shall comply with the National Plumbing Code. Electrical work shall comply with the National Electrical Code. Concrete work shall comply with American Concrete Institute.

1.9.2 Warranties. The contractor shall warranty all work for one year from the date of acceptance.

1.10 Weather Delays. TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 1989) (ER 415-1- 15).

1.10.1 This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the contract clause entitled “Default: (Fixed Price Construction)”. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

1.10.2 The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The contractor’s progress schedule must reflect these anticipated adverse weather delays in all-weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

4 4 4 5 5 4 4 4 4 3 4 4

1.10.3 Upon award and continuing throughout the contract, the contractor will record on the daily Contractor Quality Control (CQC) report, the occurrence of adverse weather and resultant impact to normally scheduled work.

Actual adverse weather delay days must prevent work on critical activities for 50 percent of more of the contractor’s scheduled work day. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph 1.10.2, above, the contracting officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work day, and issue a modification in accordance with the contract clause entitled “Default (Fixed Price Construction)”.

1.11 Submittals. The contractor may be required to furnish certain submittals. These submittals may be certifications of materials, safety plans, drawings, training certifications, work plans, etc. These will be specifically listed and the mandatory pre-work meeting and shall be furnished to the COR. Submittals requiring Government approval shall be formally prepared and approval granted prior to proceeding with work involving these submittals.

FIO (For Information Only) submittals do not require Government approval.

1.11.1 Work Plan. If requested, the contractor’s work plan shall be submitted to the Contracting Officer’s Representative (COR) for approval prior to the beginning of work. The work plan shall provide detailed procedures defining the Contractor’s provisions for utility and equipment installation activities.

1.11.2 Safety Plan. If requested, a safety plan for work procedures and safety and health protection shall be approved prior to beginning work. This plan shall include the procedures for equipment operation, chainsaw operation, public safety precautions, and traffic control if applicable. The safety plan shall include procedures to follow in case of injury accidents. The Contractor shall review the safety requirements with all workers prior to any work. Contractor Job Hazard Analysis shall be provided for each type of work.

1.11.3 Government Furnished Items. None

1.11.4 Other submittals shall include but not limited to 1) safety meeting records and 2) monthly exposure reports.

1.12 Pre-Work Conference. A mandatory pre-work conference will be held with the Contracting Officer or the Contracting Officer’s Representative and contractor prior to the commencement of any work at Tenkiller Lake. The contractor’s responsible person and necessary administrative staff will be required to attend this meeting.

Procedures for proper invoicing and payment, schedule, etc., shall be covered at this time.

1.13 Coordination of Work. The Contractor will be required to complete the work, within the recommended time frame without impacting the day to day operations. The Technical Point of Contract (POC) and Contracting Officer’s Representative (COR) will be provided at award.

1.14 Antiterrorism and Operations Security Requirements. The Contractor shall be responsible for ensuring all personnel, to include sub-contractor personnel, comply with the training requirements and procedures identified on the document titled “Antiterrorism/Operations Security Requirements” in Section H, Special Contract Requirements. When items for which training is identified, the Contractor shall ensure that all personnel complete acknowledgement for the specified training; the Contractor is responsible for ensuring all training acknowledgments, when applicable, are submitted to the COR or Contracting Officer within 10 calendar days of contract award. In no event shall any contractor or sub-contractor personnel be onsite prior to completion of any applicable training and submission of training verification. Training materials and verification forms will be provided by the Contracting Officer upon written request.

1.15 Discrepancies. The contractor shall notify the government of any discrepancies discovered in prior work or in work under contract that are not readily explainable and in such time that they may be resolved prior to completion of the work. If, at the discretion of the contracting officer, work is found to be in error after the assignment is completed, the contractor shall be liable for all costs in connection with correcting the work.

PART 2 – PRODUCTS

2.1 Materials. The Contractor shall furnish all materials and supplies required to complete this task.

2.5 Delivery and Storage. Materials shall be delivered to the site undamaged and stored in an area approved by the COR. Materials that are damaged during the delivery shall be replaced at no cost to the Government.

PART 3 - EXECUTION

3.0 Execution. The contractor shall furnish all labor, fuel, tools, materials, supplies and equipment to complete the tasks listed below. Construction area shall be flagged or caution taped around the entire worksite at the end of each day's work and at the final completion of each project. All work shall be accomplished in a safe manner and in accordance with standard industry practices.

3.1 Description of Work.

Fire Ring and Grill Specifications For Snake and Elk Creek Parks

SNAKE CREEK

Item 1 – Provide and place 112 Fire Rings of following type – 31” diameter X 9” high adjustable ring with single flange, black powder coat finish, with spade anchors. These items will be placed in Snake Creek PUA at Tenkiller Lake in specific locations which will be flagged by U.S. Army Corps of Engineers employees. Fire rings will be placed flat and level with ground and concreted in place to manufactures specifications. Markers used for location identification will be red/orange flagging.

Item 2 – Provide and place 112 Campsite Grills of the following type – Standard park grill with stainless steel back and bottom and 3 ½” outside diameter post, adjustable cooking grate, black powder coat finish, with in ground mounting. These items will be placed in Snake Creek PUA at Tenkiller Lake in specific locations which will be flagged by U.S. Army Corps of Engineers employees. Grills will be installed level and concreted in place to manufactures specifications. Markers used for location identification will be blue/green flagging.

Item 3 – Provide and place 3 Large Group Grills of the following type – 36 1/8” wide X 31 ¾ “ deep X 10 1/8” high, adjustable cooking grate, black powder coat finish, with pad mount. These items will be placed in Snake Creek PUA at Tenkiller Lake near group shelters in specific locations which will be flagged by U.S. Army Corps of Engineers employees. 2 (two) Concrete pads will need to be constructed in two locations and will be 3’ X 3’ and no less that 4” thick. Excavation will need to take place in order to assure top of pad is flush with ground. Wire mesh will be used to assure no cracking of concrete pad. Markers used for location identification will be yellow flagging.

ELK CREEK

Item 4 – Provide and place 41 Fire Rings of following type – 31” diameter X 9” high adjustable ring with single flange, black powder coat finish, with spade anchors. These items will be placed in Elk Creek PUA at Tenkiller Lake in specific locations which will be flagged by U.S. Army Corps of Engineers employees. Fire rings will be placed flat and level with ground and concreted in place to manufactures specifications. Markers used for location identification will be red/orange flagging.

Item 5 – Provide and place 41 Campsite Grills of the following type – Standard park grill with stainless steel back and bottom and 3 ½” outside diameter post, adjustable cooking grate, black powder coat finish, with in ground mounting. These items will be placed in Elk Creek PUA at Tenkiller Lake in specific locations which will be flagged by U.S. Army Corps of Engineers employees. Grills will be installed level and concreted in place to manufactures specifications. Markers used for location identification will be blue/green flagging.

Item 6 – Provide and place 2 Large Group Grills of the following type – 36 1/8” wide X 31 ¾ “ deep X 10 1/8” high, adjustable cooking grate, black powder coat finish, with pad mount. These items will be placed in Elk Creek PUA at Tenkiller Lake near group shelters in specific locations which will be flagged by U.S. Army Corps of Engineers employees. 2 (two) Concrete pads will need to be constructed in these two locations and will be 3’ X 3’ and no less that 4” thick. Excavation will need to take place in order to assure top of pad is flush with ground. Wire mesh will be used to assure no cracking of concrete pad. Markers used for location identification will be yellow flagging.

Section E - Inspection and Acceptance

CLAUSES INCORPORATED BY REFERENCE

52.246-1 Contractor Inspection Requirements APR 1984

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

52.211-17 Delivery of Excess Quantities SEP 1989 52.242-15 Stop-Work Order AUG 1989 52.247-34 F.O.B. Destination NOV 1991

CLAUSES INCORPORATED BY FULL TEXT

52.211-8 TIME OF DELIVERY (JUN 1997)

(a) The Government requires delivery to be made according to the following schedule:

REQUIRED DELIVERY SCHEDULE

Within 90 Calendar Days

The Government will evaluate equally, as regards time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above. Offers that propose delivery that will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an offeror offers an earlier delivery schedule than required above. If the offeror proposes no other delivery schedule, the required delivery schedule above will apply.

OFFEROR'S PROPOSED DELIVERY SCHEDULE

Within Days

After Date

Item No. Quantity of Contract

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor's date of receipt of the contract or notice of award by adding (1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term "working day" excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected.

(End of clause)

Section G - Contract Administration Data

252.201-7000 Contracting Officer's Representative DEC 1991 252.204-7006 Billing Instructions OCT 2005 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

Section H - Special Contract Requirements

WAGE DETERMINATIONS

"REGISTER OF WAGE DETERMINATIONS UNDER | U.S. DEPARTMENT OF LABOR

THE SERVICE CONTRACT ACT | EMPLOYMENT STANDARDS ADMINISTRATION

By direction of the Secretary of Labor | WAGE AND HOUR DIVISION

| WASHINGTON D.C. 20210

| Wage Determination No.: 2015-5319 Daniel W. Simms Division of | Revision No.: 11 Director Wage Determinations| Date Of Last Revision: 06/30/2020 Note: Under Executive Order (EO) 13658 an hourly minimum wage of $10.80 for calendar year 2020 applies to all contracts subject to the Service Contract Act for which the contract is awarded (and any solicitation was issued) on or after January 1 2015. If this contract is covered by the EO the contractor must pay all workers in any classification listed on this wage determination at least $10.80 per hour (or the applicable wage rate listed on this wage determination if it is higher) for all hours spent performing on the contract in calendar year 2020. The EO minimum wage rate will be adjusted annually. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

State: Oklahoma

Area: Oklahoma Counties of Adair Cherokee Craig Delaware Mayes McIntosh Muskogee Nowata Okfuskee Ottawa Washington

**Fringe Benefits Required Follow the Occupational Listing**

OCCUPATION CODE - TITLE FOOTNOTE RATE

01000 - Administrative Support And Clerical Occupations 01011 - Accounting Clerk I 12.85 01012 - Accounting Clerk II 15.33 01013 - Accounting Clerk III 17.78 01020 - Administrative Assistant 19.04 01035 - Court Reporter 19.66 01041 - Customer Service Representative I 10.84 01042 - Customer Service Representative II 12.19 01043 - Customer Service Representative III 13.30 01051 - Data Entry Operator I 12.52 01052 - Data Entry Operator II 13.66 01060 - Dispatcher Motor Vehicle 17.99 01070 - Document Preparation Clerk 12.66 01090 - Duplicating Machine Operator 12.66 01111 - General Clerk I 11.48 01112 - General Clerk II 12.83 01113 - General Clerk III 16.83 01120 - Housing Referral Assistant 16.40 01141 - Messenger Courier 14.18 01191 - Order Clerk I 11.92 01192 - Order Clerk II 13.79 01261 - Personnel Assistant (Employment) I 15.19 01262 - Personnel Assistant (Employment) II 17.00 01263 - Personnel Assistant (Employment) III 18.94 01270 - Production Control Clerk 22.66 01290 - Rental Clerk 13.33 01300 - Scheduler Maintenance 13.15 01311 - Secretary I 13.15

01312 - Secretary II 14.71 01313 - Secretary III 16.40 01320 - Service Order Dispatcher 14.95 01410 - Supply Technician 19.04 01420 - Survey Worker 13.80 01460 - Switchboard Operator/Receptionist 12.54 01531 - Travel Clerk I 13.55 01532 - Travel Clerk II 14.45 01533 - Travel Clerk III 15.15 01611 - Word Processor I 11.77 01612 - Word Processor II 13.35 01613 - Word Processor III 14.97 05000 - Automotive Service Occupations 05005 - Automobile Body Repairer Fiberglass 19.15 05010 - Automotive Electrician 18.19 05040 - Automotive Glass Installer 17.24 05070 - Automotive Worker 17.24 05110 - Mobile Equipment Servicer 15.14 05130 - Motor Equipment Metal Mechanic 19.15 05160 - Motor Equipment Metal Worker 17.24 05190 - Motor Vehicle Mechanic 17.91 05220 - Motor Vehicle Mechanic Helper 13.98 05250 - Motor Vehicle Upholstery Worker 16.08 05280 - Motor Vehicle Wrecker 17.19 05310 - Painter Automotive 18.22 05340 - Radiator Repair Specialist 17.24 05370 - Tire Repairer 13.29 05400 - Transmission Repair Specialist 19.15 07000 - Food Preparation And Service Occupations 07010 - Baker 11.11 07041 - Cook I 10.47 07042 - Cook II 12.32 07070 - Dishwasher 9.03 07130 - Food Service Worker 9.33 07210 - Meat Cutter 12.17 07260 - Waiter/Waitress 9.49 09000 - Furniture Maintenance And Repair Occupations 09010 - Electrostatic Spray Painter 16.54 09040 - Furniture Handler 11.67 09080 - Furniture Refinisher 16.54 09090 - Furniture Refinisher Helper 13.06 09110 - Furniture Repairer Minor 14.73 09130 - Upholsterer 16.54 11000 - General Services And Support Occupations 11030 - Cleaner Vehicles 13.28 11060 - Elevator Operator 11.16 11090 - Gardener 16.25 11122 - Housekeeping Aide 11.16 11150 - Janitor 11.16 11210 - Laborer Grounds Maintenance 11.82 11240 - Maid or Houseman 9.75 11260 - Pruner 10.38 11270 - Tractor Operator 14.79 11330 - Trail Maintenance Worker 11.82 11360 - Window Cleaner 12.71 12000 - Health Occupations 12010 - Ambulance Driver 14.77 12011 - Breath Alcohol Technician 17.89 12012 - Certified Occupational Therapist Assistant 31.28 12015 - Certified Physical Therapist Assistant 34.98 12020 - Dental Assistant 17.06 12025 - Dental Hygienist 43.24 12030 - EKG Technician 25.05 12035 - Electroneurodiagnostic Technologist 25.05 12040 - Emergency Medical Technician 14.77 12071 - Licensed Practical Nurse I 15.98 12072 - Licensed Practical Nurse II 17.89 12073 - Licensed Practical Nurse III 19.94

12100 - Medical Assistant 13.46 12130 - Medical Laboratory Technician 21.40 12160 - Medical Record Clerk 14.60 12190 - Medical Record Technician 16.34 12195 - Medical Transcriptionist 15.98 12210 - Nuclear Medicine Technologist 39.30 12221 - Nursing Assistant I 11.80 12222 - Nursing Assistant II 13.27 12223 - Nursing Assistant III 14.47 12224 - Nursing Assistant IV 16.24 12235 - Optical Dispenser 14.54 12236 - Optical Technician 15.98 12250 - Pharmacy Technician 14.68 12280 - Phlebotomist 13.68 12305 - Radiologic Technologist 24.31 12311 - Registered Nurse I 23.55 12312 - Registered Nurse II 28.82 12313 - Registered Nurse II Specialist 28.82 12314 - Registered Nurse III 34.86 12315 - Registered Nurse III Anesthetist 34.86 12316 - Registered Nurse IV 41.79 12317 - Scheduler (Drug and Alcohol Testing) 22.15 12320 - Substance Abuse Treatment Counselor 21.47 13000 - Information And Arts Occupations 13011 - Exhibits Specialist I 18.95 13012 - Exhibits Specialist II 22.25 13013 - Exhibits Specialist III 27.23 13041 - Illustrator I 18.95 13042 - Illustrator II 22.25 13043 - Illustrator III 27.23 13047 - Librarian 20.72 13050 - Library Aide/Clerk 10.30 13054 - Library Information Technology Systems 19.12 Administrator 13058 - Library Technician 13.71 13061 - Media Specialist I 13.50 13062 - Media Specialist II 15.11 13063 - Media Specialist III 16.84 13071 - Photographer I 15.06 13072 - Photographer II 17.50 13073 - Photographer III 20.54 13074 - Photographer IV 25.14 13075 - Photographer V 30.42 13090 - Technical Order Library Clerk 15.74 13110 - Video Teleconference Technician 15.24 14000 - Information Technology Occupations 14041 - Computer Operator I 15.21 14042 - Computer Operator II 17.02 14043 - Computer Operator III 21.59 14044 - Computer Operator IV 25.11 14045 - Computer Operator V 27.62 14071 - Computer Programmer I (see 1) 22.27 14072 - Computer Programmer II (see 1) 14073 - Computer Programmer III (see 1) 14074 - Computer Programmer IV (see 1) 14101 - Computer Systems Analyst I (see 1) 14102 - Computer Systems Analyst II (see 1) 14103 - Computer Systems Analyst III (see 1) 14150 - Peripheral Equipment Operator 15.21 14160 - Personal Computer Support Technician 28.80 14170 - System Support Specialist 25.20 15000 - Instructional Occupations 15010 - Aircrew Training Devices Instructor (Non-Rated) 28.14 15020 - Aircrew Training Devices Instructor (Rated) 34.04 15030 - Air Crew Training Devices Instructor (Pilot) 40.79 15050 - Computer Based Training Specialist / Instructor 28.14 15060 - Educational Technologist 26.15 15070 - Flight Instructor (Pilot) 40.79

15080 - Graphic Artist 19.06 15085 - Maintenance Test Pilot Fixed Jet/Prop 40.79 15086 - Maintenance Test Pilot Rotary Wing 40.79 15088 - Non-Maintenance Test/Co-Pilot 40.79 15090 - Technical Instructor 19.11 15095 - Technical Instructor/Course Developer 23.38 15110 - Test Proctor 15.43 15120 - Tutor 15.43 16000 - Laundry Dry-Cleaning Pressing And Related Occupations 16010 - Assembler 9.61 16030 - Counter Attendant 9.61 16040 - Dry Cleaner 12.25 16070 - Finisher Flatwork Machine 9.61 16090 - Presser Hand 9.61 16110 - Presser Machine Drycleaning 9.61 16130 - Presser Machine Shirts 9.61 16160 - Presser Machine Wearing Apparel Laundry 9.61 16190 - Sewing Machine Operator 13.13 16220 - Tailor 14.01 16250 - Washer Machine 10.52 19000 - Machine Tool Operation And Repair Occupations 19010 - Machine-Tool Operator (Tool Room) 20.71 19040 - Tool And Die Maker 26.21 21000 - Materials Handling And Packing Occupations 21020 - Forklift Operator 14.78 21030 - Material Coordinator 22.66 21040 - Material Expediter 22.66 21050 - Material Handling Laborer 11.36 21071 - Order Filler 11.99 21080 - Production Line Worker (Food Processing) 14.78 21110 - Shipping Packer 15.07 21130 - Shipping/Receiving Clerk 15.07 21140 - Store Worker I 12.19 21150 - Stock Clerk 16.90 21210 - Tools And Parts Attendant 14.78 21410 - Warehouse Specialist 14.78 23000 - Mechanics And Maintenance And Repair Occupations 23010 - Aerospace Structural Welder 23.56 23019 - Aircraft Logs and Records Technician 17.80 23021 - Aircraft Mechanic I 22.18 23022 - Aircraft Mechanic II 23.56 23023 - Aircraft Mechanic III 24.99 23040 - Aircraft Mechanic Helper 14.89 23050 - Aircraft Painter 20.71 23060 - Aircraft Servicer 17.80 23070 - Aircraft Survival Flight Equipment Technician 20.71 23080 - Aircraft Worker 19.25 23091 - Aircrew Life Support Equipment (ALSE) Mechanic 19.25 I 23092 - Aircrew Life Support Equipment (ALSE) Mechanic 22.18

II

23110 - Appliance Mechanic 20.71 23120 - Bicycle Repairer 16.36 23125 - Cable Splicer 25.63 23130 - Carpenter Maintenance 16.61 23140 - Carpet Layer 19.25 23160 - Electrician Maintenance 23.92 23181 - Electronics Technician Maintenance I 24.44 23182 - Electronics Technician Maintenance II 26.29 23183 - Electronics Technician Maintenance III 28.16 23260 - Fabric Worker 17.80 23290 - Fire Alarm System Mechanic 17.96 23310 - Fire Extinguisher Repairer 16.36 23311 - Fuel Distribution System Mechanic 23.78 23312 - Fuel Distribution System Operator 17.61 23370 - General Maintenance Worker 16.08 23380 - Ground Support Equipment Mechanic 22.18 23381 - Ground Support Equipment Servicer 17.80

23382 - Ground Support Equipment Worker 19.25 23391 - Gunsmith I 16.36 23392 - Gunsmith II 19.25 23393 - Gunsmith III 22.18 23410 - Heating Ventilation And Air-Conditioning 19.43 Mechanic 23411 - Heating Ventilation And Air Contidioning 20.63 Mechanic (Research Facility) 23430 - Heavy Equipment Mechanic 20.88 23440 - Heavy Equipment Operator 18.18 23460 - Instrument Mechanic 22.18 23465 - Laboratory/Shelter Mechanic 20.71 23470 - Laborer 11.36 23510 - Locksmith 20.71 23530 - Machinery Maintenance Mechanic 29.11 23550 - Machinist Maintenance 21.11 23580 - Maintenance Trades Helper 13.06 23591 - Metrology Technician I 22.18 23592 - Metrology Technician II 23.56 23593 - Metrology Technician III 24.99 23640 - Millwright 26.77 23710 - Office Appliance Repairer 20.71 23760 - Painter Maintenance 16.48 23790 - Pipefitter Maintenance 24.77 23810 - Plumber Maintenance 23.16 23820 - Pneudraulic Systems Mechanic 22.18 23850 - Rigger 22.18 23870 - Scale Mechanic 19.25 23890 - Sheet-Metal Worker Maintenance 21.07 23910 - Small Engine Mechanic 17.24 23931 - Telecommunications Mechanic I 25.74 23932 - Telecommunications Mechanic II 27.10 23950 - Telephone Lineman 33.22 23960 - Welder Combination Maintenance 17.78 23965 - Well Driller 21.49 23970 - Woodcraft Worker 22.18 23980 - Woodworker 16.36 24000 - Personal Needs Occupations 24550 - Case Manager 14.50 24570 - Child Care Attendant 10.22 24580 - Child Care Center Clerk 13.07 24610 - Chore Aide 9.04 24620 - Family Readiness And Support Services 14.50 Coordinator 24630 - Homemaker 16.29 25000 - Plant And System Operations Occupations 25010 - Boiler Tender 26.36 25040 - Sewage Plant Operator 16.74 25070 - Stationary Engineer 26.36 25190 - Ventilation Equipment Tender 17.88 25210 - Water Treatment Plant Operator 16.74 27000 - Protective Service Occupations 27004 - Alarm Monitor 13.51 27007 - Baggage Inspector 12.55 27008 - Corrections Officer 15.14 27010 - Court Security Officer 16.43 27030 - Detection Dog Handler 14.04 27040 - Detention Officer 15.14 27070 - Firefighter 19.43 27101 - Guard I 12.55 27102 - Guard II 14.04 27131 - Police Officer I 18.67 27132 - Police Officer II 20.74 28000 - Recreation Occupations 28041 - Carnival Equipment Operator 12.99 28042 - Carnival Equipment Repairer 14.28 28043 - Carnival Worker 9.12 28210 - Gate Attendant/Gate Tender 15.40

28310 - Lifeguard 12.63 28350 - Park Attendant (Aide) 17.23 28510 - Recreation Aide/Health Facility Attendant 12.58 28515 - Recreation Specialist 20.57 28630 - Sports Official 13.72 28690 - Swimming Pool Operator 16.79 29000 - Stevedoring/Longshoremen Occupational Services 29010 - Blocker And Bracer 19.25 29020 - Hatch Tender 19.25 29030 - Line Handler 19.25 29041 - Stevedore I 17.80 29042 - Stevedore II 20.71 30000 - Technical Occupations 30010 - Air Traffic Control Specialist Center (HFO) (see 2) 39.89 30011 - Air Traffic Control Specialist Station (HFO) (see 2) 27.50 30012 - Air Traffic Control Specialist Terminal (HFO) (see 2) 30.29 30021 - Archeological Technician I 17.97 30022 - Archeological Technician II 20.87 30023 - Archeological Technician III 25.85 30030 - Cartographic Technician 25.85 30040 - Civil Engineering Technician 24.53 30051 - Cryogenic Technician I 27.38 30052 - Cryogenic Technician II 30.24 30061 - Drafter/CAD Operator I 17.97 30062 - Drafter/CAD Operator II 20.87 30063 - Drafter/CAD Operator III 23.28 30064 - Drafter/CAD Operator IV 28.64 30081 - Engineering Technician I 17.13 30082 - Engineering Technician II 19.23 30083 - Engineering Technician III 21.51 30084 - Engineering Technician IV 26.65 30085 - Engineering Technician V 32.59 30086 - Engineering Technician VI 39.44 30090 - Environmental Technician 24.72 30095 - Evidence Control Specialist 24.72 30210 - Laboratory Technician 25.61 30221 - Latent Fingerprint Technician I 27.38 30222 - Latent Fingerprint Technician II 30.24 30240 - Mathematical Technician 25.85 30361 - Paralegal/Legal Assistant I 18.55 30362 - Paralegal/Legal Assistant II 22.97 30363 - Paralegal/Legal Assistant III 26.94 30364 - Paralegal/Legal Assistant IV 34.00 30375 - Petroleum Supply Specialist 30.24 30390 - Photo-Optics Technician 25.85 30395 - Radiation Control Technician 30.24 30461 - Technical Writer I 24.72 30462 - Technical Writer II 30.24 30463 - Technical Writer III 36.58 30491 - Unexploded Ordnance (UXO) Technician I 25.35 30492 - Unexploded Ordnance (UXO) Technician II 30.67 30493 - Unexploded Ordnance (UXO) Technician III 36.76 30494 - Unexploded (UXO) Safety Escort 25.35 30495 - Unexploded (UXO) Sweep Personnel 25.35 30501 - Weather Forecaster I 28.64 30502 - Weather Forecaster II 34.83 30620 - Weather Observer Combined Upper Air Or (see 2) 23.28 Surface Programs 30621 - Weather Observer Senior (see 2) 25.85 31000 - Transportation/Mobile Equipment Operation Occupations 31010 - Airplane Pilot 30.67 31020 - Bus Aide 11.74 31030 - Bus Driver 15.84 31043 - Driver Courier 13.24 31260 - Parking and Lot Attendant 10.03 31290 - Shuttle Bus Driver 14.55 31310 - Taxi Driver 11.27 31361 - Truckdriver Light 14.55

31362 - Truckdriver Medium 15.82 31363 - Truckdriver Heavy 21.49 31364 - Truckdriver Tractor-Trailer 21.49 99000 - Miscellaneous Occupations 99020 - Cabin Safety Specialist 14.95 99030 - Cashier 9.26 99050 - Desk Clerk 10.22 99095 - Embalmer 25.01 99130 - Flight Follower 25.35 99251 - Laboratory Animal Caretaker I 12.72 99252 - Laboratory Animal Caretaker II 13.52 99260 - Marketing Analyst 22.29 99310 - Mortician 25.01 99410 - Pest Controller 14.80 99510 - Photofinishing Worker 13.32 99710 - Recycling Laborer 16.20 99711 - Recycling Specialist 20.03 99730 - Refuse Collector 14.23 99810 - Sales Clerk 12.10 99820 - School Crossing Guard 12.85 99830 - Survey Party Chief 22.23 99831 - Surveying Aide 13.20 99832 - Surveying Technician 20.88 99840 - Vending Machine Attendant 12.74 99841 - Vending Machine Repairer 15.68 99842 - Vending Machine Repairer Helper 12.74

Note: Executive Order (EO) 13706 Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Service Contract Act for which the contract is awarded (and any solicitation was issued) on or after January 1 2017. If this contract is covered by the EO the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness injury or other health-related needs including preventive care; to assist a family member (or person who is like family to the employee) who is ill injured or has other health-related needs including preventive care; or for reasons resulting from or to assist a family member (or person who is like family to the employee) who is the victim of domestic violence sexual assault or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

ALL OCCUPATIONS LISTED ABOVE RECEIVE THE FOLLOWING BENEFITS:

HEALTH & WELFARE: $4.54 per hour up to 40 hours per week or $181.60 per week or $786.93 per month

HEALTH & WELFARE EO 13706: $4.22 per hour up to 40 hours per week or $168.80 per week or $731.47 per month*

*This rate is to be used only when compensating employees for performance on an SCA-covered contract also covered by EO 13706 Establishing Paid Sick Leave for Federal Contractors. A contractor may not receive credit toward its SCA obligations for any paid sick leave provided pursuant to EO 13706.

VACATION: 2 weeks paid vacation after 1 year of service with a contractor or successor 3 weeks after 5 years and 4 weeks after 15 years. Length of service includes the whole span of continuous service with the present contractor or successor wherever employed and with the predecessor contractors in the performance of similar work at the same Federal facility. (Reg. 29 CFR 4.173)

HOLIDAYS: A minimum of ten paid holidays per year: New Year's Day Martin Luther King Jr.'s Birthday Washington's Birthday Memorial Day Independence Day Labor Day Columbus Day Veterans' Day Thanksgiving Day and Christmas Day. (A contractor may substitute for any of the named holidays another day off with pay in accordance with a plan communicated to the employees involved.) (See 29 CFR 4.174)

THE OCCUPATIONS WHICH HAVE NUMBERED FOOTNOTES IN PARENTHESES RECEIVE THE FOLLOWING:

1) COMPUTER EMPLOYEES: Under the SCA at section 8(b) this wage determination does not apply to any employee who individually qualifies as a bona fide executive administrative or professional employee as defined in 29 C.F.R. Part 541. Because most Computer System Analysts and Computer Programmers who are compensated at a rate not less than $27.63 (or on a salary or fee basis at a rate not less than $455 per week) an hour would likely qualify as exempt computer professionals (29 C.F.R. 541.

400) wage rates may not be listed on this wage determination for all occupations within those job families. In addition because this wage determination may not list a wage rate for some or all occupations within those job families if the survey data indicates that the prevailing wage rate for the occupation equals or exceeds $27.63 per hour conformances may be necessary for certain nonexempt employees.