W912BU19B0013-Specs.pdf

IFB W912BU-19-B-0013

US Army Corps of Engineers

Philadelphia District

Beachfill Nourishment

Rehoboth Beach and Dewey Beach Delaware

Construction Solicitation and Specifications

07 August 2019

This page was intentionally left blank for duplex printing.

07 August 2019

INVITATION NO. W912BU-19-B-0013

PHILADELPHIA DISTRICT

CORPS OF ENGINEERS

INVITATION FOR BIDS

FOR

BEACH NOURISHMENT

REHOBOTH BEACH AND DEWEY BEACH, DELAWARE

I. NOTE THE AFFIRMATIVE ACTION REQUIREMENT OF THE EQUAL OPPORTUNITY CLAUSE

WHICH MAY APPLY TO THE CONTRACT RESULTING FROM THIS SOLICITATION.

II. BIDDERS ARE REQUIRED TO COMPLETE THE REPRESENTATION AND CERTIFICATIONS

PORTION OF SECTION 00 45 00 OF THIS SOLICITATION AND SUBMIT THIS WITH THEIR

BID.

III. THERE WILL NOT BE A GOVERNMENT CONDUCTED SITE VISIT FOR THIS PROJECT.

THE PROSPECTIVE BIDDERS ARE ENCOURAGED TO VISIT THE SITE OF THE WORK AT THEIR

CONVENIENCE IN ORDER TO ACQUAINT THEMSELVES WITH THE SITE CONDITIONS AND ANY

PROBLEMS INCIDENT TO THE PROSECUTION OF THE WORK.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

W912BU19B0013

2. TYPE OF SOLICITATION

X SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED

07-August-2019

PAGE OF PAGES

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

7. ISSUED BY CODE W912BU 8. ADDRESS OFFER TO (If Other Than Item 7) CODE

CONTR DIV-CONTRACTS BR

USACE, PHILA DISTRICT

WANAMAKER BUILDING

100 PENN SQUARE EAST

PHILADELPHIA PA 19107-3390

TEL: FAX:

See Item 7

TEL: FAX:

9. FOR INFORMATION

CALL:

A. NAME

CHELEY AUGUSTE

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

215-656-6771

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

(Title, identifying no., date): 10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

INVITATION FOR BID: W912BU-19-B-0013

PROJECT TITLE: ROHOBOTH BEACH/DEWEY NOURISHMENT

ISSUE DATE: 07 AUGUST 2019

BID OPENING DATE: 10 SEPTEMBER 2019 AT 11:00 A.M. EST.

THIS PROCUREMENT IS UNRESTRICTED

11. The Contractor shall begin performance w ithin 1_0 calendar days and complete it w ithin 160 aw ard, X notice to proceed. This performance period is mandatory, negotiable. (See calendar days after receiving

52.211-10.)

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and 1 copies to perform the w ork required are due at the place specified in Item 8 by 1_1_:_0_0_A_M (hour) local time 1_0 Sep 2019 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than 9_0 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

OF ER (M ust be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

See Item 14

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specified below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAMEAND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY: CODE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to f urnish and deliv er all items or perf orm all work, requisitions identif ied on this f orm and any continuation sheets f or the consideration stated in this contract. The rights and obligations of the parties to this contract shall be gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.)

Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-summates the contract, which consists of (a) the Gov ernment solicitation and y our of f er, and (b) this contract award. No f urther contractual document is necessary .

30A. NAMEAND TITLE OF CONTRACTOR OR PERSON AUTHORIZED

TO SIGN (Type or print)

31A. NAME OF CONTRACTING OFFICER (Type or print)

TEL: EMAIL: 30B. SIGNATURE 30C. DATE

31B. UNITED STATES OF AMERICA

BY

31C. AWARD DATE

NSN 7540-01-155-3212 STANDARD FORM 1442 BACK (REV. 4-85)

00 10 00-3

BIDDING SCHEDULE

(To be attached to SF 1442)

Item Estimated Unit Estimated No. Description Quantity Unit Price Amount

BASE BID:

1. Mobilization and Demobilization 1 JOB LS $____________

Rehoboth Beach (Sta. 20+69 to 58+05)

2. Structures Monitoring 1 JOB LS $____________

3. Beachfill 190,000 CY $______ $____________

4. Repair Vehicular Dune Crossover 760 SF $______ $____________

5. Replacement of ADA Grab Rails 270 LF $______ $____________

6. Sand Fence 370 LF $______ $____________

7. Dune Grass 560 SY $______ $____________

8. MEC Modifications and Monitoring 1 JOB LS $____________

Dewey Beach (Sta. 128+94 to 169+23)

9. Structures Monitoring 1 JOB LS $____________

10. Beachfill 219,000 CY $______ $____________

11. MEC Modifications and Monitoring 1 JOB LS $____________

TOTAL ESTIMATED BASE BID AMOUNT $_________________

00 10 00-4

OPTIONS:

Rehoboth Beach

12. Option 1 Beachfill (Sta. 20+69 to 58+05) 25,000 CY $______ $____________

13. Option 2 – Beachfill (Sta. 20+69 to 58+05) 25,000 CY $______ $____________

Dewey Beach

14. Option 3 – Beachfill (Sta. 128+94 to 169+23) 25,000 CY $______ $____________

15. Option 4 – Beachfill (Sta. 128+94 to 169+23) 25,000 CY $______ $____________

TOTAL ESTIMATED OPTION AMOUNT $___________

TOTAL ESTIMATED BASE BID AND OPTIONS AMOUNT $_________________

NOTES:

1. Bidders must bid on all items.

W912BU-19-B-0013 Section 00 21 00 Page 1 of

Section 00 21 00 - Bidding Schedule/Instructions to Bidders

CLAUSES INCORPORATED BY REFERENCE

52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.214-5000 Apparent Clerical Mistakes MAR 2000 52.216-1 Type Of Contract APR 1984 52.217-5 Evaluation Of Options JUL 1990 52.219-2 Equal Low Bids OCT 1995 52.222-5 Construction Wage Rate Requirements--Secondary Site of the MAY 2014

Work 52.222-23 Notice of Requirement for Affirmative Action to Ensure FEB 1999

Equal Employment Opportunity for Construction 52.225-12 Notice of Buy American Requirement - Construction MAY 2014

Materials Under Trade Agreements 52.232-38 Submission of Electronic Funds Transfer Information with JUL 2013

Offer

52.233-2 Service Of Protest SEP 2006 252.236-7008 Contract Prices-Bidding Schedules DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (JUL 2016)

(a) Definition. As used in this provision—

“Commercial and Government Entity (CAGE) code means--

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity; or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

(b) The Offeror shall enter its CAGE code in its offer with its name and address or otherwise include it prominently in its proposal. The CAGE code entered must be for that name and address. Enter “CAGE” before the number. The CAGE code is required prior to award.

(c) CAGE codes may be obtained via –

(1) Registration in the system for Award management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision).

(2) The DLA Commercial and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the offeror does not otherwise register in SAM, an offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil.

(3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity’s country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity’s country is not a member of NATO or a sponsored nation. Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm.

(d) Additional guidance for establishing and maintaining CAGE codes is available at https://www.cage.dla.mil.

(e) When a CAGE Code is required for the immediate owner and/or the highest-level owner by 52.204-17 or 52.212- 3(p), the Offeror shall obtain the respective CAGE Code from that entity to supply the CAGE Code to the Government.

(f) Do not delay submission of the offer pending receipt of a CAGE code.

(End of Provision)

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (JUL 2016)

(a) Definition. As used in this clause--

Commercial and Government Entity (CAGE) code means--

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or W912BU-19-B-0013 Section 00 21 00 Pag e 2 of http://www.sam.gov/ https://cage.dla.mil/ https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx http://www.nato.int/structur/AC/135/main/links/contacts.htm https://www.cage.dla.mil/

W912BU-19-B-0013 Section 00 21 00 Page 3 of

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

(b) Contractors shall ensure that the CAGE code is maintained throughout the life of the contract. For contractors registered in the System for Award Management (SAM), the DLA Commercial and Government Entity (CAGE) Branch shall only modify data received from SAM in the CAGE master file if the contractor initiates those changes via update of its SAM registration. Contractors undergoing a novation or change-of-name agreement shall notify the contracting officer in accordance with subpart 42.12. The contractor shall communicate any change to the CAGE code to the contracting officer within 30 days after the change, so that a modification can be issued to update the CAGE code on the contract.

(c) Contractors located in the United States or its outlying areas that are not registered in SAM shall submit written change requests to the DLA Commercial and Government Entity (CAGE) Branch. Requests for changes shall be provided at https://cage.dla.mil. Change requests to the CAGE master file are accepted from the entity identified by the code.

(d) Contractors located outside the United States and its outlying areas that are not registered in SAM shall contact the appropriate National Codification Bureau (points of contact available at http://www.nato.int/structur/AC/135/main/links/contacts.htm) or NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx to request CAGE changes.

(e) Additional guidance for maintaining CAGE codes is available at https://cage.dla.mil.

(End of Clause)

52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS (DEC 2016)

(a) If this solicitation is amended, then all terms and conditions which are not modified remain unchanged.

(b) (1) Bidders shall acknowledge receipt of any amendment to this solicitation--

(i) By signing and returning the amendment;

(ii) By identifying the amendment number and date in space provided for this purpose on the form for submitting a bid;

(iii) By letter;

(iv) By facsimile, if facsimile bids are authorized in the solicitation; or http://www.nato.int/structur/AC/135/main/links/contacts.htm) http://www.nato.int/structur/AC/135/main/links/contacts.htm)

W912BU-19-B-0013 Section 00 21 00 Page 4 of

(v) By email, if email bids are authorized in the solicitation.

(2) The Government must receive the acknowledgement by the time and at the place specified for receipt of bids.

(End of provision)

52.214-4 FALSE STATEMENTS IN BIDS (APR 1984)

Bidders must provide full, accurate, and complete information as required by this solicitation and its attachments.

The penalty for making false statements in bids is prescribed in 18 U.S.C. 1001.

(End of provision)

52.214-5 SUBMISSION OF BIDS (DEC 2016)

(a) Bids and bid modifications shall be submitted in sealed envelopes or packages (unless submitted by electronic means) (1) addressed to the office specified in the solicitation, and (2) showing the time and date specified for receipt, the solicitation number, and the name and address of the bidder.

(b) Bidders using commercial carrier services shall ensure that the bid is addressed and marked on the outermost envelope or wrapper as prescribed in subparagraphs (a)(1) and (2) of this provision when delivered to the office specified in the solicitation.

(c) Facsimile bids, modifications, or withdrawals, will not be considered unless authorized by the solicitation.

(d) Bids submitted by electronic commerce shall be considered only if the electronic commerce method was specifically stipulated or permitted by the solicitation.

(End of provision)

52.214-6 EXPLANATION TO PROSPECTIVE BIDDERS (APR 1984)

Any prospective bidder desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must request it in writing soon enough to allow a reply to reach all prospective bidders before the submission of their bids. Oral explanations or instructions given before the award of a contract will not be binding. Any information given a prospective bidder concerning a solicitation will be furnished promptly to all other prospective bidders as an amendment to the solicitation, if that information is necessary in submitting bids or if the lack of it would be prejudicial to other prospective bidders.

(End of provision)

52.214-7 LATE SUBMISSIONS, MODIFICATIONS, AND WITHDRAWALS OF BIDS (NOV 1999)

(a) Bidders are responsible for submitting bids, and any modifications or withdrawals, so as to reach the Government office designated in the invitation for bids (IFB) by the time specified in the IFB. If no time is specified in the IFB, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that bids are due.

W912BU-19-B-0013 Section 00 21 00 Page 5 of

(b)(1) Any bid, modification, or withdrawal received at the Government office designated in the IFB after the exact time specified for receipt of bids is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late bid would not unduly delay the acquisition; and--

(i) If it was transmitted through an electronic commerce method authorized by the IFB, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of bids; or

(ii) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of bids and was under the Government's control prior to the time set for receipt of bids.

(2) However, a late modification of an otherwise successful bid that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(c) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the bid wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(d) If an emergency or unanticipated event interrupts normal Government processes so that bids cannot be received at the Government office designated for receipt of bids by the exact time specified in the IFB and urgent Government requirements preclude amendment of the IFB, the time specified for receipt of bids will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(e) Bids may be withdrawn by written notice received at any time before the exact time set for receipt of bids. If the IFB authorizes facsimile bids, bids may be withdrawn via facsimile received at any time before the exact time set for receipt of bids, subject to the conditions specified in the provision at 52.214-31, Facsimile Bids. A bid may be withdrawn in person by a bidder or its authorized representative if, before the exact time set for receipt of bids, the identity of the person requesting withdrawal is established and the person signs a receipt for the bid.

(End of provision)

52.214-15 PERIOD FOR ACCEPTANCE OF BIDS (APR 1984)

In compliance with the solicitation, the bidder agrees, if this bid is accepted within 60 calendar days from the date specified in the solicitation for receipt of bids, to furnish any or all items upon which prices are bid at the price set opposite each item, delivered at the designated point(s), within the time specified in the Schedule.

(End of clause)

52.214-18 PREPARATION OF BIDS--CONSTRUCTION (APR 1984)

(a) Bids must be (1) submitted on the forms furnished by the Government or on copies of those forms, and (2) manually signed. The person signing a bid must initial each erasure or change appearing on any bid form.

(b) The bid form may require bidders to submit bid prices for one or more items on various bases, including--

(1) Lump sum bidding;

(2) Alternate prices;

(3) Units of construction; or

W912BU-19-B-0013 Section 00 21 00 Page 6 of

(4) Any combination of subparagraphs (1) through (3) above.

(c) If the solicitation requires bidding on all items, failure to do so will disqualify the bid. If bidding on all items is not required, bidders should insert the words "no bid" in the space provided for any item on which no price is submitted.

(d) Alternate bids will not be considered unless this solicitation authorizes their submission.

(End of provision)

52.214-19 CONTRACT AWARD--SEALED BIDDING--CONSTRUCTION (AUG 1996)

(a) The Government will evaluate bids in response to this solicitation without discussions and will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the Government, considering only price and the price-related factors specified elsewhere in the solicitation.

(b) The Government may reject any or all bids, and waive informalities or minor irregularities in bids received.

(c) The Government may accept any item or combination of items, unless doing so is precluded by a restrictive limitation in the solicitation or the bid.

(d) The Government may reject a bid as nonresponsive if the prices bid are materially unbalanced between line items or subline items. A bid is materially unbalanced when it is based on prices significantly less than cost for some work and prices which are significantly overstated in relation to cost for other work, and if there is a reasonable doubt that the bid will result in the lowest overall cost to the Government even though it may be the low evaluated bid, or if it is so unbalanced as to be tantamount to allowing an advance payment.

(End of provison)

52.214-34 SUBMISSION OF OFFERS IN THE ENGLISH LANGUAGE (APR 1991)

Offers submitted in response to this solicitation shall be in the English language. Offers received in other than English shall be rejected.

(End of provision)

52.214-35 SUBMISSION OF OFFERS IN U.S. CURRENCY (APR 1991)

Offers submitted in response to this solicitation shall be in terms of U.S. dollars. Offers received in other than U.S.

dollars shall be rejected.

(End of provision)

52.214-5000 APPARENT CLERICAL MISTAKES (MAR 1995)--EFARS

(a) For the purpose of initial evaluations of bids, the following will be utilized in the resolving arithmetic discrepancies found on the face of bidding schedule as submitted by the bidder:

(1) Obviously misplaced decimal points will be corrected;

W912BU-19-B-0013 Section 00 21 00 Page 7 of

(2) Discrepancy between unit price and extended price, the unit price will govern;

(3) Apparent errors in extension of unit prices will be corrected;

(4) Apparent errors in addition of lump-sum and extended prices will be corrected.

(b) For the purpose of bid evaluation, the government will proceed on the assumption that the bidder intends his bid to be evaluated on basis of the unit prices, the totals arrived at by resolution of arithmetic discrepancies as provided above and the bid will be so reflected on the abstract of bids.

(c) These correction procedures shall not be used to resolve any ambiguity concerning which bid is low.

(End of statement)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed-Price contract resulting from this solicitation.

(End of provision)

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of provision)

52.219-2 EQUAL LOW BIDS. (OCT 1995)

(a) This provision applies to small business concerns only.

(b) The bidder's status as a labor surplus area (LSA) concern may affect entitlement to award in case of tie bids. If the bidder wishes to be considered for this priority, the bidder must identify, in the following space, the LSA in which the costs to be incurred on account of manufacturing or production (by the bidder or the first-tier subcontractors) amount to more than 50 percent of the contract price.

(c) Failure to identify the labor surplus area as specified in paragraph (b) of this provision will preclude the bidder from receiving priority consideration. If the bidder is awarded a contract as a result of receiving priority consideration under this provision and would not have otherwise received award, the bidder shall perform the contract or cause the contract to be performed in accordance with the obligations of an LSA concern.

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

W912BU-19-B-0013 Section 00 21 00 Page 8 of

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of provision)

52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999)

The offeror represents that --

(a) ( ) It has, ( ) has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation;

(b) ( ) It has, ( ) has not, filed all required compliance reports; and

(c) Representations indicating submission of required compliance reports, signed by proposed subcontractors, will be obtained before subcontract awards.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

10% 5%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with

W912BU-19-B-0013 Section 00 21 00 Page 9 of the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is

Rehoboth Beach, DE.

(End of provision)

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-- CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “designated country construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American -- Construction Materials Under Trade Agreements” (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers. (1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11

W912BU-19-B-0013 Section 00 21 00 Page 10 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested-- (i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of provision)

52.232-38 SUBMISSION OF ELECTRONIC FUNDS TRANSFER INFORMATION WITH OFFER (JULY

2013)

The offeror shall provide, with its offer, the following information that is required to make payment by electronic funds transfer (EFT) under any contract that results from this solicitation. This submission satisfies the requirement to provide EFT information under paragraphs (b)(1) and (j) of the clause at 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management.

(1) The solicitation number (or other procurement identification number).

(2) The offeror's name and remittance address, as stated in the offer.

(3) The signature (manual or electronic, as appropriate), title, and telephone number of the offeror's official authorized to provide this information.

(4) The name, address, and 9-digit Routing Transit Number of the offeror's financial agent.

(5) The offeror's account number and the type of account (checking, savings, or lockbox).

(6) If applicable, the Fedwire Transfer System telegraphic abbreviation of the offeror's financial agent.

(7) If applicable, the offeror shall also provide the name, address, telegraphic abbreviation, and 9-digit Routing Transit Number of the correspondent financial institution receiving the wire transfer payment if the offeror's financial agent is not directly on-line to the Fedwire and, therefore, not the receiver of the wire transfer payment.

(End of provision)

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Contracting Officer, U.S. Army Corps of Engineers, Philadelphia District, Wannamaker Building, 6th Floor, 100 East Penn Square, Philadelphia, PA 19107.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

W912BU-19-B-0013 Section 00 21 00 Page 10 of 10

252.236-7008 CONTRACT PRICES - BIDDING SCHEDULES. (DEC 1991)

(a) The Government's payment for the items listed in the Bidding Schedule shall constitute full compensation to the Contractor for --

(1) Furnishing all plant, labor, equipment, appliances, and materials; and

(2) Performing all operations required to complete the work in conformity with the drawings and specifications.

(b) The Contractor shall include in the prices for the items listed in the Bidding Schedule all costs for work in the specifications, whether or not specifically listed in the Bidding Schedule.

W912BU-19-B-0013 INDEX 00 45 00 - i

Section 004500 - Representations & Certifications

CLAUSES INCORPORATED BY REFERENCE

52.204-3 Taxpayer Identification OCT 1998 52.204-5 Women-Owned Business (Other Than Small Business) OCT 2014 52.204-7 System for Award Management OCT 2016 52.204-8 Annual Representations and Certifications JAN 2017 52.209-2 Prohibition on Contracting with Inverted Domestic

Corporations--Representation

NOV 2015

52.209-5 Certification Regarding Responsibility Matters OCT 2015 52.209-7 Information Regarding Responsibility Matters JUL 2013 52.219-1 Alt I Small Business Program Representations (Sept 2015)

Alternate I

SEP 2015

52.219-2 Equal Low Bids OCT 1995 52.219-4 Notice of Price Evaluation Preference for HUBZone

Small Business Concerns

OCT 2014

52.222-22 Previous Contracts And Compliance Reports FEB 1999 52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.225-18 Place of Manufacture MAR 2015 52.225-25 Prohibition on Contracting with Entities Engaging in

Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015 252.209-7993 (Dev)

Representation by Corporations Regarding an Unpaid Delinquent Tax Liability or a Felony Conviction under any Federal Law -- Fiscal Year 2014 Appropriations (Deviation)

FEB 2014

SECTION 00 50 05

PRE-AWARD SURVEY SUBMITTAL REQUIREMENTS

PART 1 GENERAL

1.1 DEFINITIVE RESPONSIBILITY CRITERIA

Award of this Contract will be made as a whole to the lowest responsive and responsible Bidder whose bid conforms to all requirements of the specifications. Subsequent to the bid opening, the apparent low Bidder shall submit Pre-Award Survey Information that demonstrates compliance with the requirements set forth in this section as a precondition to receiving award.

1.2 GENERAL PRE-AWARD SURVEY INFORMATION

Complete the pre-award survey information sheets attached to this section, and submit to the Contracting Officer within 5 calendar days after bid opening.

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

-- End of Section --

Section 00 50 05 Page 1

US ARMY CORPS OF ENGINEERS

PHILADELPHIA DISTRICT

PRE-AWARD SURVEY

A. GENERAL INFORMATION

1) Name of Firm: ___________________________________________________________________

Address: __________________________________________________________________________

Phone: _____________________________________ Fax:__________________________________

Email: ____________________________________________________________________________

CAGE CODE:

If your company has more than one CAGE Code, please list all that apply.

2) Location where accounts are kept (if different than item 1 above): ____________________________

3) Type of Firm (Please check one):

Sole Proprietorship [ ] Partnership [ ] Corporation [ ] Joint Venture [ ] Other

Date Organized: ____________________________________

Date Incorporated: __________________________________

State of Incorporation: _______________________________

4) Attach list of Name of Officers.

Please check "Yes" or "No" for each of the following:

Have current officers of your firm ever been indicted? Yes [ ] No [ ]

Are any of your officers currently under indictment? Yes [ ] No [ ]

If you have answered "Yes" to either of the above, please attach an explanation.

5) Has your firm been terminated for default on any contracts in the past six years? Yes [ ] No [ ] (If yes, please attach an explanation)

00 50 05 Page 2

B. PROPOSED SCHEDULE

Submit a preliminary schedule depicting your project plan from start to final completion. The schedule you submit will be used to determine your ability to successfully perform the project within the time frame stated in the specifications.

IAW FAR 52.236-15, Schedules for Construction Contracts, you will be required to submit a fully loaded schedule within five days after work commences on the awarded contract.

C. PERFORMANCE AND PAYMENT BOND INFORMATION

1) Performance & Payment Bonds will be furnished by:

Name of Company: _______________________________________________________________

Phone No: _____________________________________________________________________

2) Firm's bonding capacity as authorized by your Insurance Company:

Single Project: ___________________________________________________________________

Aggregate Basis: _________________________________________________________________

D. BANKING INFORMATION

Name of Bank: ___________________________________________________________________

Address: ________________________________________________________________________

Account Representative: ____________________________________________________________

Phone No: ________________________________ E-mail: _______________________________

Authorized Credit Line: ________________________________________________

If additional banks are utilized, please provide this information for each.

E. INSURANCE INFORMATION

Name of Insurance Company: ______________________________________________________

Type of Insurance Provided: _______________________________________________________

Insurance Agency: _______________________________________________________________

Address: _______________________________________________________________________

Agent: _________________________________________________________________________

Phone No: ______________________________ Email: _________________________________

If more than one insurance company is utilized, please provide this formation for each.

00 50 05 Page 3

F. FINANCIAL DATA

Please provide the last two certified public accountant's financial statements.

G. SAFETYDATA

Please check "Yes" or "No" for each of the following:

1. Does your firm have a Standard Operating Procedure for Safety?

Yes [ ] No [ ] If yes, please provide a copy.

Does your firm have a Policy Letter dealing with Safety?

Yes [ ] No [ ] If yes, please provide a copy.

2. What was your accident rate for last year? _____________________

3. What is your accident rate to date for this year? ____________________

H. QUALITY CONTROL DATA

Please check "Yes" or "No" for each of the following:

1. Does your firm have a Standard Operating Procedure for Quality Control?

Yes [ ] No [ ] If yes, please provide a copy.

2. Does your firm have a Policy Letter dealing with Quality Control?

Yes [ ] No [ ] If yes, please provide a copy.

I. EQUIPMENT DATA

Please provide the following data for each piece of construction equipment (including equipment you will rent or lease), intended to be used on the project. Do not include consumables.

Make Year Mfg.

Description Purchase Price (if equipment is owned) Size Book Value (if equipment is owned) Model Number Unpaid Balance (if equipment is owned)

J. EXPERIENCE DATA

1. Please provide the following data for all major projects in progress or completed with the past three years.

Also, provide the same data for Corps of Engineer projects completed within the last five years. Those projects containing work similar in nature to that involved under this solicitation are to marked with an asterisk (*).

Name and Address of Owner Point of Contact and Telephone Number Project Location Type of Work performed by your firm Indicate whether you performed as a prime or subcontractor Name of Architect/Engineer in charge for Owner Address of Architect/Engineer Contract or Subcontract Amount Approximate date completed or, if not completed provide percent complete

00 50 05 Page 4

Were time extensions necessary? Were penalties imposed? Were liens, claims or stop work orders filed?

2. How many years have you been in business as a contractor? ________________________________

3. How many years experience in the type of work involved in the subject solicitation do you have

a) as prime contractor? ___________________________________

b) as a subcontractor? ___________________________________

K. KEY PROJECT PERSONNEL

Please provide resumes for each of the following key personnel to be assigned to this project:

Project Engineer, Superintendent, Quality Control Manager/Technician, Safety Technician, Office Engineer

(Signature of Person Supplying Data)

(Print or Type Name and Title of Person Supplying Data)

(Phone No.)

(Email Address)

00 50 05 Page 5

W912BU-19-B-0013 Section 00-70-00

Section 00 70 00 - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper MAY 2014

Activity

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal Transactions OCT 2010 52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform APR 2014

Employees of Whistleblower Rights

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper MAY 2011 52.204-7 System of Award Management OCT 2016 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards OCT 2016 52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-17 Ownership or Control of Offeror JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and Certifications. DEC 2014 52.204-20 Predecessor of Offeror JUL 2016 52.209-2 Prohibition on Contracting with Inverted Domestic Corporations-- NOV 2015

Representation

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors OCT 2015 Debarred, Suspended, or Proposed for Debarment

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters JUL 2013 52.209-10 Prohibition on Contracting With Inverted Domestic Corporations NOV 2015 52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a FEB 2016

Felony Conviction under and Federal Law

52.211-10 Commencement, Prosecution, and Completion of Work APR 1984 52.211-12 Liquidated Damages--Construction SEP 2000 52.211-13 Time Extensions SEP 2000 52.211-18 Variation in Estimated Quantity APR 1984 52.214-26 Audit and Records--Sealed Bidding OCT 2010 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data - Modifications -AUG 2011

Sealed Bidding 52.214-28 Subcontracting Certified Cost Or Pricing Data--Modifications--Sealed OCT 2010

Bidding

52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business OCT 2014

Concerns

52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-9 Alt I Small Business Subcontracting Plan (JAN 2017) Alternate I NOV 2016 52.219-16 Liquidated Damages-Subcontracting Plan JAN 1999 52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards- Overtime Compensation MAY 2014 52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 MAY 2014

52.222-12 MAY 2014

52.222-13 MAY 2014

52.222-14 FEB 1988

52.222-15 MAY 2014

52.222-21 APR 2015

52.222-1 FEB 1997

52.222-26 SEP 2016

52.222-27 APR 2015

52.222-30 MAY 2014

52.222-35 OCT 2015

52.222-36 JUL 2014

52.222-37 FEB 2016

52.222-40 DEC 2010

52.222-50 MAR 2015

52.222-54 OCT 2015

52.222-55 DEC 2015

52.222-62 JAN 2017

52.223-6 MAY 2001

52.223-18 AUG 2011

52.225-11 OCT 2016

52.225-12 MAY 2014

52.225-13

Subcontracts (Labor Standards) Contract Termination-Debarment Compliance With Construction Wage Rate Requirements and Related Regulations Disputes Concerning Labor Standards Certification of Eligibility Prohibition Of Segregated Facilities Notice to the Government of Labor Disputes Equal Opportunity Affirmative Action Compliance Requirements for Construction Construction Wage Rate Requirements--Price Adjustment (None or Separately Specified Method) Equal Opportunity for Veterans Equal Opportunity for Workers with Disabilities Employment Reports on Veterans Notification of Employee Rights Under the National Labor Relations Act Combating Trafficking in Persons Employment Eligibility Verification Minimum Wages Under Executive Order 13658 Paid Sick Leave Under Executive Order 13706 Drug-Free Workplace Encouraging Contractor Policies To Ban Text Messaging While Driving Buy American-Construction Materials Under Trade Agreements Notice of Buy American Requirement-Construction Materials Under T A Restrictions on Certain Foreign Purchases JUN 2008

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or OCT 2015 Transactions Relating to Iran-- Representation and Certifications.

52.226-1 Utilization Of Indian Organizations And Indian-Owned Economic JUN 2000 Enterprises

52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright Infringement DEC 2007 52.228-1 Bid Guarantee SEP 1996 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award Management JUL 2013 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors DEC 2013 52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-1 Performance of Work by the Contractor APR 1984 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures,…