W9127N-16-R-0011-0003_Final.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

PROJECT NAME: THE DALLES FISH UNIT BREAKER REPLACEMENT

LOCATION: KLICKITAT COUNTY, WASHINGTON

1. The purpose of this amendment is to extend the response date of the solicitation.

2. Add CLIN 0010 Asbestos Abatement Work

3. Correct the specification section listed in the continuation sheet.

4. All other terms and conditions of the solickitation remain the same.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 18-Nov-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W9127N-16-R-0011

X 9B. DATED (SEE ITEM 11)

17-Oct-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

18-Nov-2016

CODE

USACE PORTLAND DISTRICT

333 SW 1ST AVE

PORTLAND OR 97204-3440

W9127N 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9127N-16-R-0011

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

SECTION 00100 - BIDDING SCHEDULE / INSTRUCTIONS TO BIDDERS

AMENDMENT 0003

The following is a list of the changes to the technical sections for The Dalles Fish Unit Breakers Replacement.

Division 01 ‐ General Requirements:

‐ Section 01 10 00.00 25, Subpart 1.7 has been updated.

‐ Section 01 10 10.00 25, Subpart 1.29 has been updated.

‐ Section 01 22 00.00 26, Subpart 1.3.7 has been updated.

‐ Section 01 22 00.00 26, Subpart 1.3.10 has been added.

‐ Section 01 57 20.00 25 has been deleted.

‐ Section 01 57 19.00 25 has been added.

Division 02 ‐ Existing Conditions:

‐ Section 02 83 13.00 25, Subpart 1.4 has been updated.

‐ Section 02 83 13.00 25, Subpart 3.3.1 has been updated.

‐ Section 02 83 13.00 25, Subpart 3.5.3 has been updated.

‐ Section 02 82 14.00 25, Subpart 1.2 has been updated.

‐ Section 02 82 14.00 25, Subpart 1.4 has been updated.

‐ Section 02 82 14.00 25, Subpart 3.3 has been updated.

Division 26 ‐ Electrical:

‐ Section 26 08 01.00 26, Subpart 3.3.1 has been updated.

‐ Section 26 13 13.00 26, Subpart 1.3 has been updated.

‐ Section 26 25 00.00 26, Subpart 1.3 has been updated.

SUMMARY OF CHANGES

SECTION 00010 - SOLICITATION CONTRACT FORM

The required response date/time has changed from 28-Nov-2016 12:00 AM to 30-Nov-2016 02:00 PM.

SECTION 00100 - BIDDING SCHEDULE / INSTRUCTIONS TO BIDDERS

CLIN 0010 is added as follows:

W9127N-16-R-0011

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0010 1 Job Asbestos Abatement Work

FFP

Asbestos Abatement Work FOB: Destination

NET AMT

The following Acceptance/Inspection Schedule was added for CLIN 0010:

INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

N/A N/A N/A Government

(End of Summary of Changes)

The Dalles Fish Unit Breakers Replacement

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 10 00.00 25 CONTRACT ADMINISTRATION DATA

01 10 10.00 25 CONTRACTOR'S OPERATIONS AND REQUIREMENTS

01 11 00.00 26 SUMMARY OF WORK

01 22 00.00 26 MEASUREMENT AND PAYMENT

01 30 70.00 26 AS-CONSTRUCTED DRAWINGS

01 32 01.00 25 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26.00 25 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 25 QUALITY CONTROL

01 45 00.10 25 QUALITY CONTROL SYSTEM (QCS)

01 57 19.00 25 TEMPORARY ENVIRONMENTAL CONTROLS

01 78 23.00 25 OPERATION AND MAINTENANCE DATA

01 78 39.00 25 PROJECT RECORD DOCUMENTS

DIVISION 02 - EXISTING CONDITIONS

02 82 14.00 25 ASBESTOS ABATEMENT WORK

02 83 13.00 25 LEAD IN CONSTRUCTION

DIVISION 03 - CONCRETE

03 30 53.00 26 MISCELLANEOUS CAST-IN-PLACE CONCRETE

03 30 70.00 26 CONCRETE FOR MINOR STRUCTURES

03 60 00.00 26 CONCRETE DEMOLITION AND REPAIR

DIVISION 05 - METALS

05 50 03.00 26 METALWORK FABRICATION, MACHINE WORK, AND MISCELLANEOUS

PROVISIONS

05 50 13.00 26 MISCELLANEOUS METAL FABRICATIONS

DIVISION 13 - SPECIAL CONSTRUCTION

13 48 00.00 26 SEISMIC RESTRAINT FOR MECHANICAL AND ELECTRICAL EQUIPMENT

DIVISION 26 - ELECTRICAL

26 05 00.00 26 BASIC ELECTRICAL MATERIALS AND METHODS

26 05 13.00 26 MEDIUM-VOLTAGE CABLE

26 05 19.00 26 INSULATED WIRE AND CABLE

26 05 26.00 26 GROUNDING

26 05 33.00 26 RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS

26 05 36.00 26 CABLE TRAY FOR ELECTRICAL SYSTEMS

26 08 01.00 26 SYSTEMS COMMISSIONING

26 11 15.00 26 HIGH RESISTANCE GROUNDING SYSTEM (HRG)-MEDIUM VOLTAGE

26 13 13.00 26 METAL-CLAD SWITCHGEAR

26 25 00.00 26 BUS STRUCTURES, DISCONNECT SWITCH AND CURRENT LIMITING

REACTORS

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 31 13.00 40 FIRE DETECTION AND ALARM CONTROL, GUI, AND LOGIC SYSTEMS

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 10 00.00 25

CONTRACT ADMINISTRATION DATA

PART 1 GENERAL

1.1 REFERENCES

1.2 MEANING OF TERMS

1.3 CONTRACT ADMINISTRATION

1.4 CONTRACTING OFFICER

1.5 SERIAL LETTER CORRESPONDENCE

1.5.1 Numbering

1.5.2 Subcontractors

1.5.3 Transmittals

1.6 EM 385-1-1 SAFETY AND HEALTH REQUIREMENTS MANUAL

1.7 PROJECT-SPECIFIC MANAGEMENT PLAN

1.8 LETTERS OF AUTHORITY

1.9 CONTRACTOR PERFORMANCE EVALUATIONS

1.10 LABOR STANDARDS

1.10.1 Coverage

1.10.2 Wages

1.10.3 Overtime

1.10.4 Deductions

1.10.5 Apprentices

1.10.6 Equal Opportunity

1.10.7 Reporting

1.10.8 Subcontracts

1.10.9 Payrolls

1.10.10 Records

1.10.11 Job Interviews

1.10.12 Work Stoppage

1.10.13 Other

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

-- End of Section Table of Contents --

SECTION 01 10 00.00 25 Page 1

97014. Letters must be signed by the Project Manager or by assistants designated to act for the Project Manager; furnish a list of personnel so designated.

1.5.1 Numbering

All letter correspondence must be independently numbered serially with no numbers missing or duplicated, and in sequence, commencing with number one (1). Each letter must show the Contract number, description, and subject matter. Only one subject must be covered in the same letter.

1.5.2 Subcontractors

Subcontractors must not correspond with either the Resident or District offices; the Prime Contractor must handle all correspondence.

1.5.3 Transmittals

Transmittals of signed pay estimates, payrolls, submittals, and other similar correspondence will not require a Serial Letter; use of a commercial transmittal form or speed letter is encouraged.

1.6 EM 385-1-1 SAFETY AND HEALTH REQUIREMENTS MANUAL

The latest version in effect on the date of the Solicitation for this Contract (in accordance with EM 385-1-1 Paragraph 4 General, subparagraphs b.(1) and c.) will be contractually binding as part of this Contract. The latest version, including all errata and changes, must be used for this Contract and is obtainable at http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals /EM_385-1-1.pdf.

1.7 PROJECT-SPECIFIC MANAGEMENT PLAN

Submit SD-01, Preconstruction Submittals (listed on the preliminary submittal register, Attachment A1, and defined in Section 01 33 00, SUBMITTAL PROCEDURES). The Project-Specific Management Plan must be submitted as a single document and address job-specific accident prevention program, environmental protection plan, construction quality control program, and project work plan. Acceptance of the Preconstruction Submittals are required prior to commencement of work.

The PSMP must include:

a. Section I - Accident Prevention Program.

(1) Accident prevention plan (EM 385-1-1 and Section 01 35 26.00 25, GOVERNMENTAL SAFETY REQUIREMENTS).

(2) Drug-free workplace policy.

(3) Global Harmonization program (EM 385-1-1). Note: Replaces hazard communication program.

(4) Activity hazard analysis (EM 385-1-1).

(5) Equipment certification.

b. Section II - Environmental Protection Plan (Section 01 57 19.00 25, SECTION 01 10 00.00 25 Page 3

TEMPORARY ENVIRONMENTAL CONTROLS).

c. Section III - Construction Quality Control System (Section 01 45 00.00 25, QUALITY CONTROL).

(1) Contractor's quality control (CQC) plan.

(2) CQC Daily Report form.

d. Project Work Plan. The following are examples:

(1) Roadway Access Agreement.

(2) Temporary electrical systems.

(3) Welder qualifications.

(4) Welding procedures.

(5) Bolt pre-tensioning procedure.

e. Schedule for Construction.

f. Submittal Register.

1.8 LETTERS OF AUTHORITY

a. To authenticate actions required under terms of this Contract, furnish a letter of authority to the CO and Resident Engineer that indicates the names of individual or individuals who are authorized to perform the following functions on behalf of the company:

(1) Sign progress payment estimates.

(2) Sign final payment estimate.

(3) Accept Government-furnished property (if applicable).

(4) Sign Contract modifications, supplemental agreements and consent of surety.

(5) Monitor and report on the environmental protection plan, management plan, quality control plan, and safety plan.

(6) Supervise the field activities

(7) Sign Release of Claims

(8) Sign Correspondence.

b. This letter of authority must bear the typewritten names and the handwritten signatures of each individual and be signed by the person whose signature appears on the final Contract.

1.9 CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with the provisions of Federal Acquisition Regulation (FAR) Subpart 36.201, Evaluation of Contractor Performance, construction Contractor’s performance will be evaluated throughout the performance of

SECTION 01 10 00.00 25 Page 4

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 10 10.00 25

CONTRACTOR'S OPERATIONS AND REQUIREMENTS

PART 1 GENERAL

1.1 DESCRIPTION OF WORK

1.2 REFERENCES

1.3 SUBMITTALS

1.4 SCHEDULE FOR CONSTRUCTION

1.5 INTERIM CONSTRUCTION COMPLETION DATES

1.6 PERMITS AND RESPONSIBILITIES

1.7 INCLEMENT WEATHER CONSTRUCTION

1.8 IN-WATER WORK

1.8.1 In-Water Work (IWW) Periods

1.8.2 In-Water Work Activities

1.9 NOTIFICATION OF EQUIPMENT OUTAGE

1.10 WORK BY THE GOVERNMENT CONCURRENT WITH CONTRACTOR WORK

1.11 WEEKLY COORDINATION MEETINGS

1.12 PARTNERING

1.13 CONTRACTOR EMPLOYEES

1.14 PAGERS

1.15 ACCESS AGREEMENTS AND WORK AREAS

1.15.1 Access Agreements

1.15.2 Work Areas

1.15.3 Employee Access and Parking

1.16 SECURITY PROCEDURES

1.16.1 Project Security

1.16.2 Contractor's General Personnel

1.16.3 Identification of Employees

1.16.4 Foreign Born Employees

1.16.5 Identification of Contractor Vehicles

1.16.6 Use of Private Vehicles

1.17 SUPPLEMENTAL SECURITY REQUIREMENTS

1.17.1 Personnel Risk Assessment

1.17.2 Authorized Unescorted Access Requirements

1.17.3 Security Programs

1.17.3.1 Quarterly Security Awareness Program

1.17.3.2 Annual NERC Mandated Cyber Infrastructure Protection

Training Program

1.18 ANNUAL ANTITERRORISM AND OPERATIONS SECURITY TRAINING

1.19 DECK ACCESS RESTRICTIONS

1.20 CONSTRUCTION PROJECT IDENTIFICATION SIGN

1.21 UTILITIES

1.21.1 Sanitary Facilities

1.21.2 Electrical Power

1.21.2.1 General

1.21.2.2 Temporary Electrical Wiring

1.21.3 Telephone

1.21.4 Water

1.22 CONTRACTOR'S EQUIPMENT

1.22.1 Contractor's Planned Equipment Methods

SECTION 01 10 10.00 25 Page 1

1.22.2 Plant and Equipment List

1.22.3 Movement of Equipment by the Contractor

1.23 CONTRACTOR USE OF GOVERNMENT CRANES

1.24 CRANES AND HEAVY EQUIPMENT

1.24.1 Contractor Crane Safety

1.24.2 Contractor Crane Testing

1.24.3 Contractor's Cranes and Heavy Equipment

1.25 DAMAGED EQUIPMENT OR ABNORMAL CONDITIONS

1.26 GAS, VAPOR, FUME, DUST, AND MIST CONTROL IN POWERHOUSE

1.26.1 General

1.26.2 Additional Provisions

1.27 NOISE CONTROL

1.27.1 General

1.27.2 Nighttime Noise Limitations

1.28 USE OF EXPLOSIVES

1.29 DISPOSITION OF MATERIALS

1.29.1 Daily Cleanup and Disposal

1.29.2 Disposal of Equipment and Miscellaneous Materials

1.30 LEAD BASED PAINT

1.31 PRESERVATION OF HISTORICAL, ARCHEOLOGICAL, AND CULTURAL RESOURCES

1.32 PROTECTION OF MATERIAL AND WORK

1.33 PROTECTION OF EXISTING UTILITIES

1.34 PROTECTION AND RESTORATION OF EXISTING FACILITIES

1.35 RESTORATION OF PROJECT ROADS

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

SECTION 01 10 10.00 25 Page 2

1.29 DISPOSITION OF MATERIALS

Submit the location of the Contractor's offsite disposal area and a plan for safe disposal of material in the Disposal Plan. Dispose of all demolished material and miscellaneous materials off-site in conjunction with Section 01 57 19.00 25, TEMPORARY ENVIRONMENTAL CONTROLS, and in accordance with all local, state, and federal rules and regulations.

1.29.1 Daily Cleanup and Disposal

Keep all work areas reasonably neat on a daily basis. Collect, remove, and dispose of all debris resulting from the work, such as waste metalwork, packing cases, scrap lumber, and other debris off-site at least once per week. Do not use the Government's trash cans, dump boxes, and other containers. Do not dispose of liquid waste in Project drains. All costs of removing debris must be incidental to the work, and therefore, no separate payment will be made.

1.29.2 Disposal of Equipment and Miscellaneous Materials

Title to all materials and equipment to be disposed of will be vested in the Contractor when beginning disassembly work or when such materials and equipment are designated as scrap. The Government will not be responsible for the condition, loss, or damage to such property after title transfer.

The Contractor may retain these items in usable form and take possession of them providing that there is no subsequent cost or inconvenience to the Government. The Government does not guarantee that these items are complete or in working order and the Contractor must assume responsibility for any damages caused by their use immediately upon taking possession of them.

1.30 LEAD BASED PAINT

Lead paint is suspected to be present on the site. Any lead paint removed from site must be completed with a chemical paint stripping compound and contained for proper disposal. Take care to minimize the amount of hazardous waste generated. Only local areas subject to drilling must have the lead based paint removed prior to drilling. Paint strippers must not be allowed to be used below the water surface or come in contact with water. Rags used to remove paint may be disposed with the Project's hazardous waste stream. Place generated waste into approved DOT drums (1A1/1A2). Notify the Project Environmental Compliance Coordinator when drums are full and ready for disposal. The Contractor must be responsible for following all EPA, OSHA, and EM 385-1-1 standards, as well as 29 CFR 1926.62, all state, and local ordinances pertaining to the proper removal, handling, and disposal of hazardous waste. Chemical paint strippers must not contain methylene chloride. Removal, handling, and disposal of LBP must be considered incidental to the work and no separate payment will be made therefore.

1.31 PRESERVATION OF HISTORICAL, ARCHEOLOGICAL, AND CULTURAL

RESOURCES

If during construction activities items are observed that might have historical or archaeological value, such observations must be reported immediately so that the appropriate authorities may be notified and a determination can be made as to their significance and what, if any, special disposition of the finds should be made. Cease all activities that

SECTION 01 10 10.00 25 Page 18

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 22 00.00 26

MEASUREMENT AND PAYMENT

PART 1 GENERAL

1.1 GENERAL INFORMATION

1.2 MEASUREMENT

1.3 PAYMENT

1.3.1 CLIN 0001 Mobilization and Demobilization

1.3.2 CLIN 0002 Remove Existing 15 kV Bus and Circuit Breakers, Complete with Conduits and Feeders

1.3.3 CLIN 0003 Remove Existing Fish Unit Generator Neutral

Grounding, Neutral Circuit Breaker and Surge Gear, Complete with Conduits and Wire

1.3.4 CLIN 0004 Furnish & Install New 13.8 kV Switchgear FSJ1 and FSJ 2, Complete with Wiring, Conduits and Feeders

1.3.5 CLIN 0005 Furnish & Install New 15kV Bus, CLR's, and

Disconnect Switches, Complete with Wiring, Relays, Meters, Controls, Control Board, Autosynchronizers, 15kV Bus Duct Modifications, and Conduits and Feeders to interconnect the T1 and T3 bus with FSJ1 and FSJ2.

1.3.6 CLIN 0006 Furnish & Install New Fish Unit Generator, High Resistance Grounding System

1.3.7 CLIN 0007 Furnish Operations and Maintenance Manuals

1.3.8 CLIN 0008 Furnish As-Constructed Drawings

1.3.9 CLIN 0009 Contractor-Furnished Training of Government Personnel

1.3.10 CLIN 0010 Asbestos Abatement Work

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

SECTION 01 22 00.00 26 Page 1

1.3.3 CLIN 0003 Remove Existing Fish Unit Generator Neutral Grounding, Neutral Circuit Breaker and Surge Gear, Complete with Conduits and Wire

Payment for Remove Existing Fish Unit Generator Neutral Grounding and Surge Gear, Complete with Conduits and Wires, will be paid under CLIN 0003.

Price and payment will constitute full compensation to remove and dispose of the generator neutral grounding equipment, Surge Gear, PT Cubicles, and Control Wiring to the first existing points of termination.

1.3.4 CLIN 0004 Furnish & Install New 13.8 kV Switchgear FSJ1 and FSJ 2, Complete with Wiring, Conduits and Feeders

Payment for Furnish & Install New 13.8 kV Switchgear FSJ1 and FSJ 2, Complete with Wiring, Conduits and Feeders, will be paid under CLIN 0004.

Price and payment will constitute full compensation to furnish and install the new switchgear, interconnecting bus, controls, wire and cable, and all necessary appurtenances.

1.3.5 CLIN 0005 Furnish & Install New 15kV Bus, CLR's, and Disconnect Switches, Complete with Wiring, Relays, Meters, Controls, Control Board, Autosynchronizers, 15kV Bus Duct Modifications, and Conduits and Feeders to interconnect the T1 and T3 bus with FSJ1 and FSJ2.

Payment for Furnish & Install New 15kV Bus, CLR's, and Disconnect Switches, Complete with Wiring, Relays, Meters, Controls, Control Boards, 15kV Bus Duct Modifications, and Conduits and Feeders to SQ will be paid under CLIN 0005. Price and payment will constitute full compensation for the furnishing of all material, labor and equipment to fabricate and install the new isolated phase bus taps, disconnect switches, CLR's, and bus interconnection to FSJ1 and FSJ2.

1.3.6 CLIN 0006 Furnish & Install New Fish Unit Generator, High Resistance Grounding System

Payment for Furnish & Install New Fish Unit Generator, High Resistance Grounding System will be paid under CLIN 0006. Price and payment will constitute full compensation for the furnishing of all material, labor and equipment to fabricate and install the generator grounding system, including new surge arrestors and PT cubicles.

1.3.7 CLIN 0007 Furnish Operations and Maintenance Manuals

Payment for Furnish Operations and Maintenance Manuals will be paid under CLIN 0007. Price and payment will constitute full compensation for the furnishing of all material and labor to provide separate Operation and Maintenance Manuals complete with as-constructed shop drawings for the FSJ1 and FSJ2 switchgear with vacuum breakers, disconnect switches, high resistance ground units, and the associated relays, meters, and autosynchronizers. Submit three hardbound copies and an electronic copy of each.

1.3.8 CLIN 0008 Furnish As-Constructed Drawings

Payment for Furnish As-Constructed Drawings will be paid under CLIN 0008.

Price and payment will constitute full compensation for the furnishing of all material and labor to maintain red-lined copies of the contract drawings throughout construction and incorporating as-constructed information into electronic copies of the contract drawings. Electronic

SECTION 01 22 00.00 26 Page 3 copies of the contract drawings as awarded will be furnished by the Government.

1.3.9 CLIN 0009 Contractor-Furnished Training of Government Personnel

Payment for Contractor-Furnished Training of Government Personnel will be paid under CLIN 0009. Price and payment will constitute full compensation for the furnishing of all material, labor and equipment to perform two types of training. Operator training will be offered over 3 sessions, the training will be at least 4 hours long and will cover the theory and operation of the equipment. The maintenance electrician training will be offered for at least one session and will be one full day of training for about eight Government personnel on the theory, operation, and maintenance of the SJ vacuum circuit breakers including the disconnect switches, non-segregated bus, current limiting reactors, current transformers, potential transformers, relays and controls. The operator training sessions must be scheduled at times to accommodate alternate shifts of Government personnel.

1.3.10 CLIN 0010 Asbestos Abatement Work

a. Measurement will be made as a job item for all cost associated with asbestos abatement work. This includes all materials, labor, submittals, up to 50 samples, and equipment for abatement and disposal.

b. Payment: Payment will be made at the Contract amount under CLIN 0010, "Asbestos Abatement Work".

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

-- End of Section --

SECTION 01 22 00.00 26 Page 4

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 57 19.00 25

TEMPORARY ENVIRONMENTAL CONTROLS

PART 1 GENERAL

1.1 REFERENCES

1.2 DEFINITIONS

1.2.1 Class I and II Ozone Depleting Substance (ODS)

1.2.2 Contractor Generated Hazardous Waste

1.2.3 Electronics Waste

1.2.4 Environmental Pollution and Damage

1.2.5 Environmental Protection

1.2.6 Hazardous Debris

1.2.7 Hazardous Materials

1.2.8 Hazardous Waste

1.2.9 Land Application

1.2.10 National Pollutant Discharge Elimination System (NPDES)

1.2.11 Oily Waste

1.2.12 Petroleum, Oil, Lubricant (POL)

1.2.13 Regulated Waste

1.2.14 Sediment

1.2.15 Solid Waste

1.2.15.1 Debris

1.2.15.2 Green Waste

1.2.15.3 Material not regulated as solid waste

1.2.15.4 Non-Hazardous Waste

1.2.15.5 Recyclables

1.2.15.6 Surplus Soil

1.2.15.7 Scrap Metal

1.2.15.8 Wood

1.2.16 Surface Discharge

1.2.17 Wastewater

1.2.17.1 Stormwater

1.2.18 Waters of the United States

1.2.19 Wetlands

1.2.20 Universal Waste

1.3 SUBMITTALS

1.4 ENVIRONMENTAL PROTECTION REQUIREMENTS

1.5 QUALITY ASSURANCE

1.5.1 Preconstruction Survey and Protection of Features

1.5.2 Environmental Preparatory Meeting

1.5.3 Environmental Manager

1.5.4 Employee Training Records

1.5.5 Non-Compliance Notifications

1.6 ENVIRONMENTAL PROTECTION PLAN

1.6.1 Regulatory Notification and Permits

1.6.2 General Overview and Purpose

1.6.2.1 Procedures

1.6.2.2 Communications

SECTION 01 57 19.00 25 Page 1

SECTION ADDED

AMD# 0002

1.6.3 General Site Information

1.6.3.1 Drawings

1.6.3.2 Work Area

1.6.4 Documentation of Environmental Conditions

1.6.5 Protection of the Environment from Waste Derived from

Contractor Operations

1.6.6 Spill Control Plan

1.6.7 Clean Air Act Compliance

1.6.7.1 Dirt and Dust Control Plan

1.6.7.2 Pollution Generating Equipment

1.6.7.3 Refrigerants

1.6.7.4 Air Pollution-engineering Processes

1.6.7.5 Compliant Materials

1.7 ENVIRONMENTAL RECORDS BINDER

1.8 SOLID WASTE MANAGEMENT PERMIT

1.8.1 Solid Waste Management Report

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 ENVIRONMENTAL PERMITS AND COMMITMENTS

3.2 STORMWATER

3.2.1 Work Area Limits

3.2.2 Contractor Facilities and Work Areas

3.3 CULTURAL RESOURCES

3.3.1 Archaeological Resources

3.4 AIR RESOURCES

3.4.1 Burning

3.4.2 Dust Control

3.4.3 Particulates

3.4.4 Odors

3.5 WASTE MINIMIZATION

3.5.1 Salvage, Reuse and Recycle

3.5.2 Nonhazardous Solid Waste Diversion Report

3.6 WASTE MANAGEMENT AND DISPOSAL

3.6.1 Waste Determination Documentation

3.6.2 Solid Waste Management

3.6.2.1 Solid Waste Management Report

3.6.2.2 Control and Management of Solid Wastes

3.6.3 Control and Management of Hazardous Waste

3.6.3.1 Hazardous Waste/Debris Management

3.6.3.2 Hazardous Waste Disposal

3.6.3.3 Universal Waste Management

3.6.3.4 Electronics End-of-Life Management

3.6.4 Releases/Spills of Oil and Hazardous Substances

3.6.5 Mercury Materials

3.6.6 Wastewater

3.6.6.1 Treatment

3.7 HAZARDOUS MATERIAL MANAGEMENT

3.8 PREVIOUSLY USED EQUIPMENT

3.9 PETROLEUM, OIL, LUBRICANT (POL) STORAGE AND FUELING

3.9.1 Used Oil Management

3.9.2 Oil Storage Including Fuel Tanks

3.10 SOUND INTRUSION

3.11 POST CONSTRUCTION CLEANUP

SECTION 01 57 19.00 25 Page 2

SECTION 01 57 19.00 25

TEMPORARY ENVIRONMENTAL CONTROLS

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910.120 Hazardous Waste Operations and Emergency Response

40 CFR 112 Oil Pollution Prevention

40 CFR 241 Guidelines for Disposal of Solid Waste

40 CFR 243 Guidelines for the Storage and Collection of Residential, Commercial, and Institutional Solid Waste

40 CFR 258 Subtitle D Landfill Requirements

40 CFR 260 Hazardous Waste Management System: General

40 CFR 261 Identification and Listing of Hazardous Waste

40 CFR 261.7 Residues of Hazardous Waste in Empty Containers

40 CFR 262 Standards Applicable to Generators of Hazardous Waste

40 CFR 263 Standards Applicable to Transporters of Hazardous Waste

40 CFR 264 Standards for Owners and Operators of Hazardous Waste Treatment, Storage, and Disposal Facilities

40 CFR 265 Interim Status Standards for Owners and Operators of Hazardous Waste Treatment, Storage, and Disposal Facilities

40 CFR 266 Standards for the Management of Specific Hazardous Wastes and Specific Types of Hazardous Waste Management Facilities

40 CFR 268 Land Disposal Restrictions

SECTION 01 57 19.00 25 Page 4

40 CFR 273 Standards For Universal Waste Management

40 CFR 273.2 Standards for Universal Waste Management - Batteries

40 CFR 273.4 Standards for Universal Waste Management - Mercury Containing Equipment

40 CFR 273.5 Standards for Universal Waste Management - Lamps

40 CFR 279 Standards for the Management of Used Oil

40 CFR 300 National Oil and Hazardous Substances Pollution Contingency Plan

40 CFR 355 Emergency Planning and Notification

40 CFR 50 National Primary and Secondary Ambient Air Quality Standards

40 CFR 64 Compliance Assurance Monitoring

40 CFR 82 Protection of Stratospheric Ozone

49 CFR 171-178 Hazardous Materials Regulations

49 CFR 171 General Information, Regulations, and Definitions

49 CFR 172 Hazardous Materials Table, Special Provisions, Hazardous Materials Communications, Emergency Response Information, and Training Requirements

49 CFR 173 Shippers - General Requirements for Shipments and Packagings

49 CFR 178 Specifications for Packagings

1.2 DEFINITIONS

1.2.1 Class I and II Ozone Depleting Substance (ODS)

a. Class I ODS is defined in Section 602(a) of The Clean Air Act. A list of Class I ODS can be found on the EPA website at the following weblink. http://www.epa.gov/ozone/science/ods/classone.html.

b. Class II ODS is defined in Section 602(s) of The Clean Air Act. A list of Class II ODS can be found on the EPA website at the following weblink. http://www.epa.gov/ozone/science/ods/classtwo.html.

1.2.2 Contractor Generated Hazardous Waste

Contractor generated hazardous waste is materials that, if abandoned or disposed of, may meet the definition of a hazardous waste. These waste streams would typically consist of material brought on site by the Contractor to execute work, but are not fully consumed during the course of construction. Examples include, but are not limited to, excess paint

SECTION 01 57 19.00 25 Page 5 thinners (i.e. methyl ethyl ketone, toluene), waste thinners, excess paints, excess solvents, waste solvents, excess pesticides, and contaminated pesticide equipment rinse water.

1.2.3 Electronics Waste

Electronics waste is discarded electronic devices intended for salvage, recycling, or disposal.

1.2.4 Environmental Pollution and Damage

Environmental pollution and damage is the presence of chemical, physical, or biological elements or agents which adversely affect human health or welfare; unfavorably alter ecological balances of importance to human life;

affect other species of importance to humankind; or degrade the environment aesthetically, culturally or historically.

1.2.5 Environmental Protection

Environmental protection is the prevention/control of pollution and habitat disruption that may occur to the environment during construction. The control of environmental pollution and damage requires consideration of land, water, and air; biological and cultural resources; and includes management of visual aesthetics; noise; solid, chemical, gaseous, and liquid waste; radiant energy and radioactive material as well as other pollutants.

1.2.6 Hazardous Debris

As defined in paragraph SOLID WASTE, debris that contains listed hazardous waste (either on the debris surface, or in its interstices, such as pore structure) in accordance with 40 CFR 261. Hazardous debris also includes debris that exhibits a characteristic of hazardous waste in accordance with

40 CFR 261.

1.2.7 Hazardous Materials

a. Hazardous materials as defined in 49 CFR 171 and listed in 49 CFR 172.

b. Hazardous material is any material that: Is regulated as a hazardous material in accordance with 49 CFR 173; or requires a Safety Data Sheet (SDS) in accordance with 29 CFR 1910.120; or during end use, treatment, handling, packaging, storage, transportation, or disposal meets or has components that meet or have potential to meet the definition of a hazardous waste as defined by 40 CFR 261 Subparts A, B, C, or D. Designation of a material by this definition, when separately regulated or controlled by other sections or directives, does not eliminate the need for adherence to that hazard-specific guidance which takes precedence over this section for "control" purposes. Such material includes ammunition, weapons, explosive actuated devices, propellants, pyrotechnics, chemical and biological warfare materials, medical and pharmaceutical supplies, medical waste and infectious materials, bulk fuels, radioactive materials, and other materials such as asbestos, mercury, and polychlorinated biphenyls (PCBs).

1.2.8 Hazardous Waste

Hazardous Waste is any material that meets the definition of a solid waste and exhibit a hazardous characteristic (ignitability, corrosivity, SECTION 01 57 19.00 25 Page 6 reactivity, or toxicity) as specified in 40 CFR 261, Subpart C, or contains a listed hazardous waste as identified in 40 CFR 261, Subpart D.

1.2.9 Land Application

Land Application means spreading or spraying discharge water at a rate that allows the water to percolate into the soil. No sheeting action, soil erosion, discharge into storm sewers, discharge into defined drainage areas, or discharge into the "waters of the United States" must occur.

Comply with federal, state, and local laws and regulations.

1.2.10 National Pollutant Discharge Elimination System (NPDES)

The NPDES permit program controls water pollution by regulating point sources that discharge pollutants into waters of the United States.

1.2.11 Oily Waste

a. Oily waste are those materials that are, or were, mixed with Petroleum, Oils, and Lubricants (POLs) and have become separated from that POLs. Oily wastes also means materials, including wastewaters, centrifuge solids, filter residues or sludges, bottom sediments, tank bottoms, and sorbents which have come into contact with and have been contaminated by, POLs and may be appropriately tested and discarded in a manner which is in compliance with other state and local requirements.

b. This definition includes materials such as oily rags, "kitty litter" sorbent clay and organic sorbent material. These materials may be land filled provided that: It is not prohibited in other state regulations or local ordinances; the amount generated is "de minimus" (a small amount); it is the result of minor leaks or spills resulting from normal process operations; and free-flowing oil has been removed to the practicable extent possible. Large quantities of this material, generated as a result of a major spill or in lieu of proper maintenance of the processing equipment, are a solid waste. As a solid waste, perform a hazardous waste determination prior to disposal. As this can be an expensive process, it is recommended that this type of waste be minimized through good housekeeping practices and employee education.

1.2.12 Petroleum, Oil, Lubricant (POL)

POL products include flammable or combustible liquids, such as gasoline, diesel, lubricating oil, used engine oil, hydraulic oil, mineral oil, and cooking oil.

1.2.13 Regulated Waste

Regulated waste are solid wastes that have specific additional federal, state, or local controls for handling, storage, or disposal.

1.2.14 Sediment

Sediment is soil and other debris that have eroded and have been transported by runoff water or wind.

1.2.15 Solid Waste

Solid waste is a solid, liquid, semi-solid or contained gaseous waste. A solid waste can be a hazardous waste, non-hazardous waste, or non-Resource

SECTION 01 57 19.00 25 Page 7

Conservation and Recovery Act (RCRA) regulated waste. Types of solid waste typically generated at construction sites may include:

1.2.15.1 Debris

Debris is non-hazardous solid material generated during the construction, demolition, or renovation of a structure that exceeds 2.5-inch particle size that is: a manufactured object; plant or animal matter; or natural geologic material (for example, cobbles and boulders), broken or removed concrete, masonry, and rock asphalt paving; ceramics; roofing paper and shingles. Inert materials may be reinforced with or contain ferrous wire, rods, accessories and weldments. A mixture of debris and other material such as soil or sludge is also subject to regulation as debris if the mixture is comprised primarily of debris by volume, based on visual inspection.

1.2.15.2 Green Waste

Green waste is the vegetative matter from landscaping, land clearing and grubbing, including, but not limited to, grass, bushes, scrubs, small trees and saplings, tree stumps and plant roots. Marketable trees, grasses and plants that are indicated to remain, be re-located, or be re-used are not included.

1.2.15.3 Material not regulated as solid waste

Material not regulated as solid waste is nuclear source or byproduct materials regulated under the Federal Atomic Energy Act of 1954 as amended;

suspended or dissolved materials in domestic sewage effluent or irrigation return flows, or other regulated point source discharges; regulated air emissions; and fluids or wastes associated with natural gas or crude oil exploration or production.

1.2.15.4 Non-Hazardous Waste

Non-hazardous waste is waste that is excluded from, or does not meet, hazardous waste criteria in accordance with 40 CFR 263.

1.2.15.5 Recyclables

Recyclables are materials, equipment and assemblies such as doors, windows, door and window frames, plumbing fixtures, glazing and mirrors that are recovered and sold as recyclable, wiring, insulated/non-insulated copper wire cable, wire rope, and structural components. It also includes commercial-grade refrigeration equipment with Freon removed, household appliances where the basic material content is metal, clean polyethylene terephthalate bottles, cooking oil, used fuel oil, textiles, high-grade paper products and corrugated cardboard, stackable pallets in good condition, clean crating material, and clean rubber/vehicle tires. Metal meeting the definition of lead contaminated or lead based paint contaminated may be included as recyclable if sold to a scrap metal company. Paint cans that meet the definition of empty containers in accordance with 40 CFR 261.7 may be included as recyclable if sold to a scrap metal company.

1.2.15.6 Surplus Soil

Surplus soil is existing soil that is in excess of what is required for this work, including aggregates intended, but not used, for on-site mixing

SECTION 01 57 19.00 25 Page 8 of concrete, mortars, and paving. Contaminated soil meeting the definition of hazardous material or hazardous waste is not included and must be managed in accordance with paragraph HAZARDOUS MATERIAL MANAGEMENT.

1.2.15.7 Scrap Metal

This includes scrap and excess ferrous and non-ferrous metals such as reinforcing steel, structural shapes, pipe, and wire that are recovered or collected and disposed of as scrap. Scrap metal meeting the definition of hazardous material or hazardous waste is not included.

1.2.15.8 Wood

Wood is dimension and non-dimension lumber, plywood, chipboard, hardboard.

Treated or painted wood that meets the definition of lead contaminated or lead based contaminated paint is not included. Treated wood includes, but is not limited to, lumber, utility poles, crossties, and other wood products with chemical treatment.

1.2.16 Surface Discharge

Surface discharge means discharge of water into drainage ditches, storm sewers, creeks or "waters of the United States". Surface discharges are discrete, identifiable sources and require a permit from the governing agency. Comply with federal, state, and local laws and regulations.

1.2.17 Wastewater

Wastewater is the used water and solids from a community that flow to a treatment plant.

1.2.17.1 Stormwater

Stormwater is any precipitation in an urban or suburban area that does not evaporate or soak into the ground, but instead collects and flows into storm drains, rivers, and streams.

1.2.18 Waters of the United States

Waters of the United States means Federally jurisdictional waters, including wetlands, that are subject to regulation under Section 404 of the Clean Water Act or navigable waters, as defined under the Rivers and Harbors Act.

1.2.19 Wetlands

Wetlands are those areas that are inundated or saturated by surface or groundwater at a frequency and duration sufficient to support, and that under normal circumstances do support, a prevalence of vegetation typically adapted for life in saturated soil conditions.

1.2.20 Universal Waste

The universal waste regulations streamline collection requirements for certain hazardous wastes in the following categories: batteries, pesticides, mercury-containing equipment (for example, thermostats), and lamps (for example, fluorescent bulbs). The rule is designed to reduce hazardous waste in the municipal solid waste (MSW) stream by making it easier for universal waste handlers to collect these items and send them

SECTION 01 57 19.00 25 Page 9 for recycling or proper disposal. These regulations can be found at

40 CFR 273.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Preconstruction Survey

Environmental Manager Qualifications; G

Employee Training Records; G

Environmental Protection Plan; G ECDG

SD-06 Test Reports

Solid Waste Management Report; G

SD-07 Certificates

Solid Waste Management Permit; G

SD-11 Closeout Submittals

Environmental Records Binder; G

Solid Waste Management Report; G

Nonhazardous Solid Waste Diversion Report

Waste Determination Documentation; G ECDG

Sales Documentation; G

Contractor Certification

Hazardous Waste/Debris Management; G

1.4 ENVIRONMENTAL PROTECTION REQUIREMENTS

a. Provide and maintain, during the life of the contract, environmental protection as defined. Plan for and provide environmental protective measures to control pollution that develops during construction practice. Plan for and provide environmental protective measures required to correct conditions that develop during the construction of permanent or temporary environmental features associated with the project. Protect the environmental resources within the project boundaries and those affected outside the limits of permanent work during the entire duration of this Contract. Comply with federal, state, and local regulations pertaining to the environment, including water, air, solid waste, hazardous waste and substances, oily substances, and noise pollution.

SECTION 01 57 19.00 25 Page 10

b. Tests and procedures assessing whether construction operations comply with Applicable Environmental Laws may be required. Analytical work must be performed by qualified laboratories; and where required by law, the laboratories must be certified.

1.5 QUALITY ASSURANCE

1.5.1 Preconstruction Survey and Protection of Features

This paragraph supplements the Contract Clause PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS. Prior to start of any onsite construction activities, perform a Preconstruction Survey of the project site with the Contracting Officer, and take photographs showing existing environmental conditions in and adjacent to the site as described in Paragraph titled Documentation of Environmental Conditions. Submit a report for the record. Include in the report a plan describing the features requiring protection under the provisions of the Contract Clauses, which are not specifically identified on the drawings as environmental features requiring protection along with the condition of trees, shrubs and grassed areas immediately adjacent to the site of work and adjacent to the Contractor's assigned storage area and access route(s), as applicable. The Contractor and the Contracting Officer will sign this survey report upon mutual agreement regarding its accuracy and completeness. Protect those environmental features included in the survey report and any indicated on the drawings, regardless of interference that their preservation may cause to the work under the Contract.

1.5.2 Environmental Preparatory Meeting

a. Prior to initiating any work on site, meet with the Contracting Officer to discuss the proposed Environmental Protection Plan (EPP).

Develop a mutual understanding relative to the details of environmental protection, including measures for protecting natural and cultural resources, required reports, required permits, permit requirements (such as mitigation measures), and other measures to be taken.

b. Provide the following information: types, quantities, and use of hazardous materials that will be brought onto the project site; and types and quantities of wastes/wastewater that may be generated during the Contract. Discuss the results of the Preconstruction Survey at this time.

1.5.3 Environmental Manager

a. Submit a letter signed by an officer of the firm appointing the Environmental Manager and stating that person is responsible for managing and implementing the Environmental Program as described in this contract. Include in this letter the Environmental Manager's authority to direct the removal and replacement of non-conforming work and emergency contact information (office phone number, cell phone number, and e-mail address). The Environmental Manager is directly responsible for coordinating contractor compliance with federal, state, and local requirements. The Environmental Manager must

(1) Ensure compliance with Hazardous Waste Program requirements (including hazardous waste handling, storage, manifesting, and disposal)

SECTION 01 57 19.00 25 Page 11

(2) Implement the EPP and ensure its compliance

(3) Ensure environmental permits are obtained, maintained, and closed out

(4) Ensure compliance with Stormwater Program requirements

(5) Ensure compliance with Hazardous Materials (storage, handling, and reporting) requirements; and coordinate any remediation of regulated substances (lead, asbestos, PCB transformers).

(6) Be responsible for spill cleanup and training personnel on spill response procedures

(7) Be responsible for manifesting hazardous waste to be removed from the site (if applicable)

(8) Be responsible for training the Contractor's environmental protection personnel

b. This can be a collateral position; however, the person in this position must be trained to adequately accomplish the following duties:

ensure waste segregation and storage compatibility requirements are met; ensure only authorized personnel add wastes to containers; ensure Contractor personnel are trained in 40 CFR requirements in accordance with their position requirements; coordinate removal of waste containers; and maintain the Environmental Records binder and required documentation, including environmental permits compliance and close-out. Submit Environmental Manager Qualifications to the Contracting Officer of relavent environmental training and experience.

1.5.4 Employee Training Records

a. Prepare and maintain Employee Training Records throughout the term of the contract meeting applicable 40 CFR requirements. Keep Employee Training Records in the Environmental Records Binder. Ensure every employee completes a program of classroom instruction or on-the-job training that teaches them to perform their duties in a way that ensures compliance with federal, state and local regulatory requirements.

b. Train personnel to meet regulatory requirements for environmental, biological and cultural resources. Conduct environmental protection/pollution control meetings for personnel prior to commencing construction activities. Conduct additional meetings for new personnel and when site conditions change. Include in the training and meeting agenda the following:

(1) the methods of detecting and avoiding pollution;

(2) familiarization with statutory and contractual pollution standards;

(3) installation and care of devices, vegetative covers, and instruments required for monitoring purposes to ensure adequate and continuous environmental protection/pollution control;

(4) anticipated hazardous or toxic chemicals or wastes, and other

SECTION 01 57 19.00 25 Page 12 regulated contaminants;

1.5.5 Non-Compliance Notifications

The Contracting Officer will notify the Contractor in writing of any observed noncompliance with federal, state or local environmental laws or regulations, permits, and other elements of the Contractor's EPP. After receipt of such notice, inform the Contracting Officer of the proposed corrective action and take such action when approved by the Contracting Officer. The Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No time extensions will be granted or equitable adjustments allowed for any such suspensions. This is in addition to any other actions the Contracting Officer may take under the contract, or in accordance with the Federal Acquisition Regulation or Federal Law.

1.6 ENVIRONMENTAL PROTECTION PLAN

a. The purpose of the EPP is to present an overview of known or potential environmental issues that must be considered and addressed during construction. Submit the EPP within 15 days before the Environmental Preparatory meeting. Revise the EPP throughout the project to include any reporting requirements, changes in site conditions, or contract modifications that change the project scope of work in a way that could have an environmental impact. No requirement in this section will relieve the Contractor of any applicable federal, state, and local environmental protection laws and regulations. During Construction, identify, implement, and submit for approval any Additional Environmental Protection Plan Requirements to be included in the EPP. Maintain the current version onsite.

b. The EPP includes, but is not limited to, the following elements:

1.6.1 Regulatory Notification and Permits

List what notifications and permit applications must be made. Some permits require up to 180 days to obtain. Demonstrate that those permits have been obtained or applied for by including copies of applicable environmental permits. The EPP will not be approved until the permits have been obtained.

1.6.2 General Overview and Purpose

A brief description of each specific plan required by environmental permit or elsewhere in this Contract such as stormwater pollution prevention plan, spill control plan, solid waste management plan, wastewater management plan, air pollution control plan, contaminant prevention plan, a historical, archaeological, cultural resources, biological resources and wetlands plan, traffic control plan, Hazardous, Toxic and Radioactive Waste (HTRW) Plan, Non-Hazardous Solid Waste Disposal Plan,…