Amendment_1_Blasting_Booth.pdf

SECTION 01 00 00.00 44 Page 1

Corpus Christi Army Depot

SECTION 01 00 00.00 44

CONSTRUCTION SCHEDULE

PART 1 GENERAL

1.1 SCHEDULE

Commence, prosecute, and complete the work under this contract in accordance with the following schedule and Section 00 73 00 CONTRACT CLAUSES COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK and LIQUIDATED

DAMAGES:

Item of Work Commencement of Work

(Calendar days)

Completion of Work

(Calendar days)

Liquidated Damages per calendar days

(1) All work, including warranties and operation manuals

90 days N/A

NOTE: All work on this project shall be completed within the number of calender days stated in Item of Work (1) above, inclusive of all review periods and Government phasing requirements specified. If the Government accepts a proposal for a completion period of lesser duration, and such proposal alters the time periods for review and phasing, the Contract shall be read to include the original periods for review and phasing. If a completion period of lesser duration is proposed and accepted by the Government, the accepted completion period will replace the original construction schedule listed above in the Schedule. If an alternate completion period is proposed, the Bid Schedule must reflect pricing information for the alternate proposed completion period. The liquidated damages stated above will be applied for each calendar day the Contractor exceeds the Contract scheduled duration.

1 c. Liquidated damages will not be assessed.

d. Not Used.

SECTION 01 00 00.00 44 Page 2

** Operation and Maintenance Manuals: Required.

*** Record Drawings: Not Required

1.1.1 Testing of Installed Equipment

The times stated for completion of the contract includes all required testing specified to accept equipment.

1.2 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 1989)

(ER 415-1-15)(52.0001-4038 1/96)

a. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the contract clause FAR 52.249-10 entitled "DEFAULT: (FIXED PRICE CONSTRUCTION)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays due to precipitation and temperature is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations.

The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities. Wind is not considered in the Monthly Anticipated Adverse Weather Calendar Day Schedule.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

3 2 1 2 4 4 2 3 4 2 2 2

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record the occurrence of adverse weather and resultant impact to normally scheduled work.

Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day.

SECTION 01 00 00.00 44 Page 3

d. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph "b", above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled "Default (Fixed Price Construction)."

1.3 CONSTRUCTION PHASING

1.4 WORK RESTRICTIONS

1.4.1 Working Hours

Normal working hours will be identified as 0730 to 1600, Monday through Friday. Requests to work at times other than the stated working hours, including scheduled utility outages discussed below, shall be submitted to the Contracting Officer for approval. Contractor shall not work outside of the above stated working hours without prior written approval of the Contracting Officer.

1.4.2 Security Requirements

1.4.2.1 Installation Entrance Requirements

Entrance requirements to the Installation are specified in Section 01 35

23.00 44 SPECIAL PROJECT PROCEDURES FOR CORPUS CHRISTI ARMY DEPOT.

For the duration of this Contract, access to CORPUS CHRISTI ARMY DEPOT will be delayed between 5 minutes to 30 minutes or more due to increased security precautions, including the checking of vehicle occupants' IDs, vehicle manifests, and the searching of all vehicles. Any general or specific threat to the safety of those working or living at the Installation could result in longer waiting times at the access points to the Installation.

The following are the minimum requirements for contractor employees entering CORPUS CHRISTI ARMY DEPOT:

a. One form of picture ID.

b. A memo from the construction company on their letterhead stating the reason for entry, contract number, and the location at CORPUS CHRISTI ARMY DEPOT where the jobsite is located.

c. All delivery trucks must have a bill of lading and delivery truck drivers must have a picture ID.

1.4.3 Identification of Employees

The Contractor shall be responsible for furnishing to each employee, and for requiring each employee engaged on the work to display, identification as approved and directed by the Contracting Officer. Prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon release of any employee. When required, the Contractor shall obtain and provide fingerprints of persons employed on the project. Contractor and subcontractor personnel shall wear identifying markings on hard hats clearly identifying the company for whom the employee works.

SECTION 01 00 00.00 44 Page 4

Contractor personnel shall wear visible Contractor-furnished employee identification badges while physically on the Installation. Each badge shall include, as a minimum, the company name, employee name, photograph, Contract Title, Contract Number, and the expiration date of the badge.

1.5 PAPERLESS CONTRACT SUBMISSION

a. GENERAL INFORMATION ON PAPERLESS CONTRACT SUBMISSION

The goal is to reduce waste, decrease time, decrease associated costs, and to streamline most file transmission procedures.

b. METHODS OF DIGITAL SUBMISSION

This contract shall use digital submission methods to the greatest extent practicable. Acceptable methods are as follows, in order of precedence:

1. RMS – Not used.

2. Secure, Password Protected Web-Based System Access must be allowed and approved by the Government Representative. Access must be allowed and approved by the Government Representative. This method shall not be used for security sensitive documents.

3. E-mail – Items not submitted via RMS, as discussed above, shall be submitted via e-mail, if possible. E-mail limitations for file size must be considered prior to submission. Under current conditions, 5 megabytes is the limitation for any single file/e-mail.

4. CD/DVD – Will be accepted if no other method is possible and upon prior approval.

c. ITEMS TO BE SUBMITTED VIA HARDCOPY

Product information and any other item not feasible to submit digitally, shall be submitted hard copy. The Government reserves the right to request hard copy submission on any item, if deemed necessary. Contractor shall be prepared to provide requested hard copy at any time.

1.6 Veterans Employment Emphasis for U.S. Army Corps of Engineers Contracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

SECTION 01 00 00.00 44 Page 5

Federal Veteran employment information at http://www.fedshirevets.gov/index.aspx Department of Labor Veterans Employment Assistance http://www.dol.gov/vets/ Department of Veteran Affairs - VOW to Hire Heroes Act http://benefits.va.gov/vow Army Wounded Warrior Program -http://wtc.army.mil/modules/employers/index.html U.S. Chamber of Commerce Foundation - Hiring Our Heroes http://www.hiringourheroes.org/ Guide to Hiring Veterans - Reference Material -http://whitehouse.gov/sites/default/files/docs/white_house_business_ council

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section --http://www.fedshirevets.gov/index.aspx http://www.dol.gov/vets/ http://benefits.va.gov/vow http://wtc.army.mil/modules/employers/index.html http://www.hiringourheroes.org/

SECTION 01 10 00.30 44 Page 6

<AMD 1>

SECTION 01 10 00.30 44

STATEMENT OF WORK

COMPOSITE SHOP PHASE 1 EQUIPMENT INSTALL

Corpus Christi, Texas

PART 1 GENERAL

1.1 STATEMENT OF WORK

The Contractor shall provide all work, materials, supplies, parts (to include system components), plant, supervision, labor, transportation, and equipment (except when specified as Government Furnished), for maintenance, repair, upgrade and construction of real property facilities at Corpus Christi Army Depot (CCAD) in Texas and the related services as specified in strict accordance with all the terms, conditions, special contract requirements, specifications, drawings, attachments, and exhibits contained in the contract or incorporated by reference as follows.

The Contractor's work and responsibility shall include all Contractor planning, programming, administration, and management necessary to provide all facets of work for this effort and related services specified. The work shall be conducted by the Contractor in strict accordance with the contract and all applicable Federal, States of Texas, and local laws, regulations, codes or directives. The Contractor shall ensure that all work provided meets, or exceeds the critical reliability rates or tolerances specified or included in the applicable documents. The Contractor shall provide related services such as preparing and submitting required reports, performing administrative work, and submitting necessary information as specified under this contract.

1.2 PERIOD OF PERFORMANCE

Period of performance is 90 days.

1.3 GENERAL INFORMATION

All work shall comply with State, local and Federal laws and regulations, industry and construction codes and standards, manufacturer’s specifications and recommendations, and all contract special provisions, terms and conditions. All work shall comply with International Building Code, 2009 Edition, Life Safety Code, National Standards Plumbing Code and manufacturer’s recommended practices. All electric work shall comply with NFPA 70, National Electric Code and NFPA 13 and 101, Life Safety Code and manufacturer’s recommendations. The Contractor shall be responsible for obtaining all required licenses and permits to perform construction work on a Federal installation, be properly bonded and insured in accordance with FAR requirements.

SECTION 01 10 00.30 44 Page 7

Changes Clause: The Contractor shall not deviate from the written scope of work unless a change has been submitted and approved by the Contracting/Ordering Officer in writing. Do not act on direction, suggestions or instructions from any Government representative, customer, or other Contractors unless approved by the Contracting/Ordering Officer in writing.

Differing Site Conditions Clause: All changes concerning differing site conditions discovered during the course of construction shall be presented to the Ordering Officer/COR immediately upon discovery by Contractor personnel. Notify the Ordering Officer/COR if a work stoppage or schedule impact will occur if direction is not received promptly.

Request for Information: If Clarification is required for issues that arise during the course of construction, the Contractor shall submit in writing a Request for Information (RFI) to the Ordering Officer/COR. The RFI shall be identified by numerical sequence and project name, number and any other data that pertains to the request. The RFI may be submitted to the Ordering Officer/COR by email format for expediency. If field verification is required for installation of equipment or devices not identified or discussed at the pre-construction conference and a decision is required to proceed with the work an RFI shall be requested to receive direction from the Ordering Officer/COR in writing.

Request for information shall be submitted to receive direction in determining choices in color, quantity, type, location of equipment or device installation and any other issues, which require direction from the Government.

Only a warranted Contracting Officer acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

1.4 Location of work

Project site is within Building 8, Composite Shop Phase I. See referenced location map.

1.5 Description of Work

Purchase and Install:

• Two (2) 12 foot wide sanding booth and

• Two (2) 24 foot wide sanding booths in the Composite shop Phase 1 area.

SECTION 01 10 00.30 44 Page 8

Features:

1) two (2) New booths that have a nominal working area inside the booth of 12 foot wide X 8 foot high X 8 Foot deep (11.25 Minimum X 7.5 Minimum X 7.5 Minimum). The booths will operate on 460V <AMD 1> 480V <AMD 1>/60Hertz/3 Phase power. The booth will be compatible with sanding Fiberglass and composite materials. The Face Velocity will be a minimum of 125 FPM. The primary filter will be a minimum of 12 MERV Cartridge style with a built in self-cleaning method. Typical self-cleaning method is by using reverse air pulses, but other method are acceptable. Booths will have secondary HEPA rated filtration. The booths will include pressure gages to determine when filters need replacement. The walls and ceiling of the booths will be solid with sound insulation installed. Booths are to include lighting fixtures. Contractor will provide rigid EMT style conduit from booth to electrical disconnect. Contractor shall provide connection and air drops. <AMD 1> Government will be responsible for relocating the compressed air drops (from current location) and will need cut sheets on booths to determine location of drops. Offeror will match existing color of airdrops. <AMD 1>

2) Two (2) New booths that have a nominal working area inside the booth of 24 foot wide X 8 foot high X 8 Foot deep (23 Minimum X 7.5 Minimum X7.5 Minimum ) The booths will operate on 460V<AMD 1> 480V <AMD 1> /60Hertz/3 Phase power. The booth will be compatible with sanding Fiberglass and composite materials. The Face Velocity will be a minimum of 125 FPM. The primary filter media will be a minimum of 12 MERV Cartridge style with a built in self-cleaning method. Typical self-cleaning method is by using reverse air pulses, but other method are acceptable. Booths will have secondary HEPA rated filtration. The booths will include pressure gages to determine when filters need replacement. The walls and ceiling of the booths will be solid with sound insulation installed. Booths are to include lighting fixtures. Contractor will connect booth to electrical disconnect and air drops.

3) Contractor shall procure and install the Quantity four (4) sanding booths:

Two (2) twelve (12) foot nominal width and two (2) twenty-four (24) nominal width.

The contractor shall provide all the labor and material to complete the job.

Contractor shall provide EMT conduit run and all wiring from the Disconnect to the control panel on the booth.

Contractor shall complete the airline connections to the Sanding Booths.

Contractor shall provide four (4) air tool connection points inside the booth, two (2) on each side.

Contractor shall start-up and operate the equipment to demonstrate that installation is complete.

Contractor shall demonstrate that FPM meets OEM specification sheets.

SECTION 01 10 00.30 44 Page 9

4) Depending on the electrical requirements of each manufacturer product, the selected

Offeror would have to make some upgrades. There are two (2) existing 60A electrical disconnects are in place for 2 of the booths. In this case, two 60A branch circuits would have to be removed and replaced with two increased branch circuits (depending on product requirements). The disconnect switches, conduit, conductors, and circuit breakers in the branch circuit panel would have to be upgraded. <AMD 1>

Install Government Furnished Equipment, Program, Start-up, and Testing:

CCAD Production team will deliver workstations to the Composite Shop for installation.

<AMD 1> Contractor shall relocate (from a building approximately 1 mile away) all 7

Benchtron Systems to the Composite Shop. They will need to collect and pack all workstations, transport, unpack, install, connect to power, and dispose of packaging material and debris. The systems will clear all opening leading to the new work area.

<AMD 1>

4) Install seven (7) existing Filter 1 Benchtron Model BFS-12-8-10-H-CVS-SC Downdraft/Backdraft Workstations. Reconfigure the Workstations to operate on 460V /<AMD1> 480V <AMD 1>/60HZ/3 Phase power. The workstations are currently configured to operate on 230V/60Hz/3 phase. Serial numbers of the units to be installed are 12-38-750, 12-38-751, 12-38-752, 12-38-755, 12-38-756, 12-38-757, 13-04-771.

Modifications to workstations will include programing, start-up and testing.

Contractor shall Install (government furnished) seven (7) existing Filter 1 Benchtron Model BFS-12-8-10-H-CVS-SC Downdraft/Backdraft Workstations.

Contractor shall provide all the labor and material to complete the job.

Contractor shall Reconfigure/reprogram the Workstations to operate on 460V<AMD 1> 480V <AMD 1>/60HZ/3Phase power. The workstations are currently configured to operate on 230V/60Hz/3 phase.

<AMD 1> Installation/operation manual to Benchtron systems are included as Attachment 3 <AMD 1>

Serial numbers of the units to be installed are 12-38-750, 12-38-751, 12-38-752, 12-38- 755, 12-38-756, 12-38-757, 13-04-771.

Contractor shall provide the EMT conduit and run and all wiring from the disconnect to the control panel.

Contractor shall complete the airline connections to the Workstations.

Contractor shall replace and reprogram all components needed to convert the workstation to operate on 460V <AMD 1> 480V <AMD 1>/60hz/3phase from the current 230V/60hz/3 phase.

Contractor shall start-up and operate the equipment to demonstrate that installation is complete.

SECTION 01 10 00.30 44 Page 10

1.6 Additional Information:

Contractor shall provide a work schedule within 14 calendar days of NTP.

Schedule shall breakdown all definable features of work with anticipated start and end dates.

USACE/CCAD will verify that the correct equipment specified has been delivered before installation.

If Required, Contractor shall notify USACE of any planned utility outages for coordination with the CCAD Facilities Engineering Management and with individual customers.

Contractor shall provide a safe project site. Contractor shall ensure that safety signs and barriers are placed to protect the work crews and pedestrians during on and off work hours. Contractor shall meet the requirements per the Safety and Health Requirements Manual, United States Army Corps of Engineers EM385-1-1, dated November 2014 or most recent edition and safety requirements of the CCAD Safety Office.

Contractor shall field verify existing site conditions prior to execution of work.

Prior to start of work, coordination meetings will be held with USACE and CCAD personnel to agree on the methods and procedures to be used for the installation and connection of equipment and associated work. Discussion will include safety and environmental precautions to the work.

Prior to start of work, contractor shall attend a preconstruction meeting to discuss project requirements and CCAD requirements for working on the installation.

Utility Outages – The following guidelines for utility outages are provided where required. Utility outage permits are required. The contractor is responsible for coordination and submitting all forms and sketches required for any outage. Utility, road and railroad closures require a minimum 15 working days advance written notice and will be subject to CCAD approval.

Equipment and Installation Construction Phasing – Contractor will Interface with others (USACE, CCAD). Government will maintain use of the surrounding facility during construction activities.

Contractor shall protect existing buildings, utilities and equipment during construction. The contractor will be provided with reasonable access and storage areas during construction.

Contractor will be responsible for maintaining the construction area and storage facilities and repairing damage caused during construction activities prior to substantial completion and final payment.

Power outages- Where power is not available for contractor use, contractor will be responsible for providing their own power source during the duration of construction activities or during necessary power outages. Where critical utilities, alarm or IT services are required to remain powered. The Contractor shall provide alternate power source during any planned outages.

Contractor shall provide all necessary safety equipment and first aid kits during construction activities for the duration of the project.

SECTION 01 10 00.30 44 Page 11

The equipment shall be installed in accordance with industry standard criteria, materials and efficient practices. Work Package shall also meet the requirements as stated in the Statement of Work and the contractual specifications manual.

The contractor shall be responsible for the professional quality, code compliance, technical accuracy and coordination of all packages, drawings, specifications and other documents or publications upon which the equipment installation is based.

Contractor shall perform all work according to current industry standards. Contractor shall report to the USACE representative any unforeseen damage or issues that cause or may cause additional work not covered in this scope of work. Contractor shall maintain EM 385-1-1 / OSHA / CCAD safety standards throughout the duration of the project.

Contractor shall use caution and keep work area organized and clear during the work day.

Contractor shall implement a plan to cordon off the site to prevent unintended access to the construction area.

SPECIFICATIONS: At a minimum, the following specifications from the Fort Worth District shall apply to this contract, but are not limited to:

GENERAL REQUIREMENTS

Special Project Procedures for CCAD (spec section 00 73 00) Government Safety Requirements - Follow EM 385-1-1

Work Package Documents: The contractor will be held responsible for the purchase and installation of the equipment per work package. Contractor is responsible for verifying the existing field conditions to complete work per the statement of work, work package and contract documents.

REQUIREMENTS

Contractor shall submit work package construction plans prior to beginning work. Plans will be reviewed for compliance with the SOW and referenced documents.

Contractor shall submit milestone and construction schedules (Gantt chart) within 14 calendar days of NTP.

Contractor, vendors and subcontractors shall attend a preconstruction meeting prior to start of work.

Prior to the start of work, the Contractor shall conduct a preparatory meeting with the USACE and CCAD project team. Recommended for attendance (i.e. Project Engineer / Quality Assurance Representative).

SECTION 01 10 00.30 44 Page 12

Contractor shall provide daily progress reports and schedule updates.

Hours of Operation: The contractor shall coordinate with USACE, CCAD and building owner for access and schedule. Any hours other than allowed are to be requested, in writing, through the USACE and CCAD team members.

Debris and Cleanup: Upon completion of the workday the contractor shall leave the work area in a clean manner. All project generated debris and waste shall be removed from site and disposed of at an appropriate location off post, daily.

Toilet Facilities: Are not available.

TECHNICAL REQUIREMENTS

SUBMITTALS All listed documents shall be submittal as “Government Approved” (GA) and shall be submitted digitally to the USACE and CCAD project team, with an ENG FORM 4025- E.

Title Submittal Date Date Approved

Activity Hazard Analysis Competent Person Documentation (As Required)

Material Safety Data Sheets Contractor General Warranty Letter Equipment

THIS SCOPE OF WORK INCLUDES THE FOLLOWING ATTACHMENTS:

a. Attachments 1: Project Site Map.

b. Attachments 2 : Site visit required approximately one week after solicitation.

c. <AMD 1> Attachment 3: Installation and operation manual for Benchtron systems.

CONTRACT MANAGEMENT

The Contractor shall implement schedule monitoring procedures adequate to provide performance reporting and timely identification and resolution of all problems that effect proper completion of this effort.

PERFORMANCE PERIOD

The contract performance period is 90 calendar days from contract award.

Corpus Christi, Texas