W9124D-18-T-0003-0002_Solicitation_Amendment.pdf

W9124D-18-T-0003

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been modified:

Firm Fixed Price Requirements Type Contract (RTC) for portable power chargers with custom logo for Army

Marketing Research Group (AMRG), Fort Knox, Kentucky for a base period and two (2) one-year option periods.

This requirement is 100% Small Business Set-Aside, all items offered shall be manufactured in the United States by a small business.

NOTICE PERTAINING TO THE BUY AMERICAN ACT AND SMALL BUSINESS SET-ASIDES

THE GOVERNMENT IS AGGRESSIVELY PURSUING THE ENFORCEMENT OF THE BUY AMERICAN

ACT AND THE REGULATIONS PERTAINING TO SMALL BUSINESS SET-ASIDES. AS A RESULT,

PRODUCTS ARE BEING MORE CLOSELY SCRUTINIZED PRIOR TO AWARD AND UPON DELIVERY TO

ENSURE THAT WHEN A DOMESTIC PRODUCT IS REQUIRED BY REGULATION, A DOMESTIC

PRODUCT IS BEING DELIVERED. CONTRACTORS WHO FALSELY VERIFY PRODUCTS AND THEN

EITHER NOTIFY BEFORE DELIVERY OF THE “ERROR” OR DELIVER NON-COMPLIANT PRODUCT

ARE BEING TERMINATED FOR CAUSE/DEFAULT AND CRIMINAL FRAUD CHARGES FILED. AS A

RESULT OF THE ABOVE ACTIONS, CONTRACTORS ARE DEBARRED AND EXCLUDED FROM FUTURE

COMPETITION FOR GOVERNMENT CONTRACTS.

OFFERORS ARE ADVISED THAT FAILURE TO COMPLETE THE BUY AMERICAN—BALANCE OF

PAYMENTS PROGRAM CERTIFICATE AND PROVIDE THE COUNTRY OF ORIGIN FOR THE

REQUIREMENT ITEMS, WILL RESULT IN SUBMITTED BID/QUOTE BEING CONSIDERED NON-

RESPONSIVE AND NOT ELIGIBLE FOR AWARD.

If requested, a contractor shall provide confirmation of compliance with all applicable manufacturing requirements within 24 hours of notifications of award.

QUOTERS SHALL PROVIDE THE FOLLOWING INFORMATION:

DUNS NUMBER: ________________________________

FED TAX ID#: ________________________________

CAGE CODE: ________________________________

POINT OF CONTACT: ________________________________

PHONE NO: ________________________________

FAX NO: ________________________________

E-MAIL ADDRESS: ________________________________

Offerors Please Note:

1. All offerors shall be registered in the System for Award Management (SAM) to be eligible for award of a contract. Offerors shall ensure SAM registration is active and shall not assume that CCR information automatically migrated to the SAM system. The official SAM website is https://www.sam.gov/portal/public/SAM/. Contractors are encouraged to complete SAM registration as soon as possible The government may not delay award for the purpose of allowing a contractor time to register in SAM.

2. Offeror must submit any questions regarding this solicitation in writing to the contracting officer. Questions must

W9124D-18-T-0003 be received by the contracting officer no later than close of business on December 6, 2018 to allow a written response prior to the quote due date. No remarks or written responses to questions by government personnel shall change or qualify any of the terms or conditions of this Request for Quote (RFQ). The solicitation can only be changed by a formal written amendment issued by Mission and Installation Contracting Command (MICC) -Fort

Knox, Kentucky.

Questions concerning this RFQ shall emailed to Valerie.d.perry.civ@mail.mil

3. All offers /quotes shall include descriptive literature and photo image of the actual portable power charger being offered. The image does not need to have the custom logos imprinted.

4. All offers/quotes shall be submitted in writing to Valerie Perry via email to Valerie.d.perry.civ@mail.mil. Quote shall be submitted no later than the date and time specified for receipt (see Block 8 on the SF 1449 or the latest issued amendment).

5. BASIS OF AWARD. Award will be made to the lowest priced responsive quote submitted by a responsible offeror.

A. Offers/quotes submitted on a basis other than F.O.B. destination will be rejected as nonresponsive.

B. Offerors shall submit all unit prices to the whole penny; any fractions will be rounded to the next higher whole penny per unit for evaluation and award purposes.

C. Failure to submit a quote on all items may render the quote non-responsive.

D. Failure to disclose country of origin will render the quote non-responsive.

6. All times stated reflects Fort Knox, KY Local/Eastern Time.

Provide your quote below:

Item Number Description Quantity Unit Unit Price Amount

0001 Base: Portable

Power Charger

375,000 Each $ $

1001 Option one:

Portable Power

Charger

375,000 Each $ $

2001 Option two:

Portable Power

Charger

375,000 Each $ $

TOTAL: $

(End of Summary of Changes) mailto:Valerie.d.perry.civ@mail.mil