W911S7-18-B-0014_18_June_18.pdf

0011143588

1. Repair/Replace Ashphalt Surfacces, Asphalt Requirements at Fort Leonard Wood, MO and Lake of the Ozarks Recreational Area, Linn Creek, MO.

2. This acquisition is a Total Small Business Set-Aside. The NAICS is 237310 w ith a size standard of $36.5M.

3. The magnitude of this effort is more than $10M.

4. Draw ings are available electronically and w ill be provided w ith the Solicitation. Requests for the hardcopy draw ings w ill not be considered.

5. No site visit w ill be conducted for this project.

6. Written questions shall be submitted to shamarian.n.plummer.civ@mail.mil no later than 2:00pm (local time) 26 June 2018.

7. Original bids w ill not be accepted by facsimile. Facsimile modifications or w ithdraw s w ill be not be permitted.

8. Contractor shall start physical perfomance of aw arded project in accordance w ith the specif ication and draw ings as incorporated not later than the close of business, 31 December 2018.

X

SHAMARIAN N. PLUMMER 573-596-1803

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

18-Jun-2018

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________ calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________18 Jul 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

MICC - FORT LEONARD WOOD

8112 NEBRASKA AVENUE

FORT LEONARD WOOD MO 65473

W911S7

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

5735960267FAX:TEL: 5735960266 TEL: FAX:

W911S718B0014 49

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W911S718B0014

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

CLIN 0001 - BASE PERIOD

FFP

CLIN 0001 - BASE PERIOD

FOB: Destination

PURCHASE REQUEST NUMBER: 0011143588

PSC CD: Z1LB

NET AMT

0002 1 Job CLIN 0002 - Option 1

FFP

CLIN 0001 - Option 1 FOB: Destination

0003 1 Job CLIN 0003 - Option 2

FFP

CLIN 0001 - Option 2 FOB: Destination

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 POP 18-SEP-2018 TO

17-SEP-2019

N/A DIRECTORATE OF PUBLIC WORKS - FLW

- MO

MATTHEW MCCRAY

1334 1ST STREET BLDG 2200

FORT LEONARD WOOD MO 65473-5000

573.596.2198 FOB: Destination

W90NM2

0002 POP 18-SEP-2019 TO

17-SEP-2020

N/A (SAME AS PREVIOUS LOCATION)

0003 POP 18-SEP-2020 TO

17-SEP-2021

N/A (SAME AS PREVIOUS LOCATION)

Section G - Contract Administration Data

CONTRACT ADMINISTRATION

CONTRACT ADMINISTRATION

RESPONSIBILITY FOR ADMINISTRATION OF CONTRACT

The MICC-Fort Leonard Wood, Contracting Office is responsible for the administration of this contract. The Contracting Officer alone is authorized to take action on behalf of the Government which results in chages in the terms of the contract, including deviations from specifications, details and delivery schedules.

CLAUSES INCORPORATED BY REFERENCE

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.246-7000 Material Inspection And Receiving Report MAR 2008

CLAUSES INCORPORATED BY FULL TEXT

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

CONSTRUCTION

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

GOVERNMENT

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC HQ0490 Issue By DoDAAC W911S7 Admin DoDAAC W911S7 Inspect By DoDAAC W90NM2

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

N/A

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

N/A

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

5152.233-4000 AMC-LEVEL PROTEST PROGRAM (Feb 2014) (LOCAL CLAUSE)

Prior to submitting an agency protest, it is preferable that you first attempt to resolve your concerns with the responsible contracting officer. However, you may also file a protest to the Headquarters (HQ), Army Materiel Command (AMC). The HQ AMC-Level Protest Program is intended to encourage interested parties to seek resolution of their concerns within AMC as an Alternative Dispute Resolution forum, rather than filing a protest with the Government Accountability Office (GAO) or other external forum. Contract award or performance is suspended during the protest to the same extent, and within the same time periods, as if filed at the GAO. The AMC protest decision goal is to resolve protests within 35 calendar days from filing. To be timely, protests must be filed within the periods specified in FAR 33.103. If you want to file a protest under the HQ AMC-Level Protest Program, the protest must request resolution under that program and be sent to the address below.

Headquarters U.S. Army Materiel Command Office of Command Counsel-Deputy Command Counsel 4400 Martin Road Rm: A6SE040.001 Redstone Arsenal, AL 35898-5000 Fax: (256) 450-8840 or email usarmy.redstone.usamc.mbx.protests@mail.mil

The AMC-Level Protest procedures are found at: http://www.amc.army.mil/amc/commandcounsel.html.

If internet access is not available, contact the contracting officer or HQ, AMC to obtain the HQ AMC-Level Protest Procedures.

(End of Clause)

Section H - Special Contract Requirements

LOCAL INSTRUCTIONS

LOCAL INSTRUCTIONS

INSTRUCTIONS TO OFFERORS

H-1 USE OF TOBACCO PRODUCTS ON FORT LEONARD WOOD

The Contractor and its employees shall be familiar with and shall comply with the provisions of Executive Order 13058, Protecting Federal Employees and the Public From Exposure to Tobacco Smoke in the Federal Workplace, and Title 41 CFR Part 102-74.315 [73 Federal Register 77518, Dec. 19, 2008].

H-2 FIRE PREVENTION

a. The current Post Fire Regulations, Chapter 25, AR 420-1, Fire Prevention and Protection, and FLW Supplements to FLW Reg. 420-2 are by this reference made a part of this solicitation and resultant contract. The Contractor’s operations shall conform to all applicable portions of those documents. All personnel entering on duty as Contractor’s employees shall be instructed in the fire prevention program of the Post and shall be advised of the requirement of the Post Fire Regulations as they pertain to this particular contract.

b. The Contractor shall obtain a written “Hot Work Permit” (DA Form 5383-R) prior to commencing all hot work outside an approved shop area. Permits will be issued by the Fort Leonard Wood Fire Department, (573) 596-0883, after all necessary precautions have been taken, such as wetting down the area, protection of combustible material, and positioning of first aid fire extinguishers of proper type and class. Permits must be obtained in advance for use of open flame devices, such as blow torches, portable furnaces, tar kettles, or gas and electric welding and cutting equipment. Preparation and protection for such areas are the responsibility of the Contractor accomplishing the work. An inspection conducted by the Fire Department prior to commencing work may be required; however, the Contractor shall conduct an inspection of the area at least 30 minutes after completion of all work. The Contractor shall be liable for any fire loss to Government property attributable to negligence on the part of the Contractor, including failure to comply with fire prevention measures prescribed by terms of this contract.

c. The Fire Prevention-Protection Division is responsible for monitoring the Contractor in the area of fire prevention and advising the Contracting Officer of all deficiencies. The Contracting Officer will alert the Contractor if a violation is a fire hazard or fire protection deficiency.

d. The provision in no way authorizes anyone other than the Contracting Officer to commit the Government to changes in the terms of the contract.

H-3 NORMAL WORKING HOURS

a. The Contractor shall schedule his working hours to coincide with the working hours of the military reservation. Normal working hours of the reservation are 7:30 a.m. to 4:00 p.m., Monday thru Friday, Legal Public Holidays excepted. The Contractor shall not perform work on the reservation beyond the aforementioned working hours without the written approval of the Contracting Officer.

For informational purposes, the Government observes the following holidays:

New Year’s Day, 1 January Martin Luther King, Jr.’s Birthday, the third Monday in January Presidents’ Day, the third Monday in February Memorial Day, the last Monday in May Independence Day, 4 July Labor Day, the first Monday in September Columbus Day, the second Monday in October Veterans Day, 11 November Thanksgiving Day, the fourth Thursday in November Christmas Day, 25 December When such holidays fall on a Saturday, the preceding Friday will be considered a holiday. When such holidays fall on a Sunday, the succeeding Monday will be considered a holiday. (Applicable to Government personnel only.)

b. If the Contractor for his convenience desires to perform work during other than normal working hours or on other than normal workdays, he shall notify the Contracting Officer in writing at least 72 hours in advance. The Contractor shall not perform work beyond the normal working hours or normal workdays without the Contracting Officer’s written approval.

H-4 UTILIZATION OF HEAVY TRACKED OR WHEELED EQUIPMENT

All projects that require the use of any heavy tracked or wheeled equipment on the streets will require prior approval by the Directorate of Public Works.

H-5 PREVENTION OF TRAINEE ABUSE

The Contractor and its employees shall be familiar with and shall comply with the provisions of Fort Leonard Wood (FLW) Regulation 350-6, Initial Entry Training Policy and Administration, as presently written and as subsequently amended. The Contractor, upon its request, shall be furnished with a copy of FLW Regulation 350-6. However, failure to request a copy of the regulation will not relieve the Contractor from complying with the requirements of this paragraph.

H-6 ACCIDENT PREVENTION AND SAFETY REQUIREMENTS

a. In order to provide safety controls for protection to the life and health of employees and other persons, for prevention of damage to property, materials, supplies and equipment, and for avoidance of work interruption in the performance of this contract, the Contractor shall comply with all pertinent provisions of the Occupational Safety and Health Act of 1970, Public Law 91-

596. The Contractor shall also take or cause to be taken such additional measures as the Contracting Officer may determine to be reasonable and necessary for the purpose.

b. The Contractor shall maintain an accurate record of, and shall report to the Contracting Officer in the manner and on the forms prescribed by the Contracting Officer, exposure data and all accidents resulting in death, traumatic injury, occupational disease and damage to property, materials, supplies, and equipment incident to work performed under this contract.

c. The Contracting Officer will notify the Contractor of any non-compliance with the foregoing provisions and the action to be taken. The Contractor shall, after receipt of such notice, immediately take corrective action. Such notice, when delivered to the Contractor or his representative at the site of the work, shall be deemed sufficient for the purpose. If the Contractor fails or refuses to comply promptly, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to any such stop orders shall be made the subject of claim for extension of time or for excess costs or damages by the Contractor.

d. Compliance with the provisions of this clause by subcontractors shall be the responsibility of the Contractor.

H-7 CONTRACTOR CORRESPONDENCE REQUIREMENTS

All Contractor and subcontractor originated correspondence under this contract shall be on the originating firm’s letterhead, except in the case where pre-printed Government forms are used, shall be typed or handwritten in a legible manner, and shall be submitted in the signed original, with supporting copies as required by the Contracting Officer.

H-8 BID GUARANTEE AND BOND REQUIREMENTS

a. BID GUARANTEE. The offeror (bidder) shall furnish a bid guarantee in the form of a firm commitment, such as a bid bond, postal money order, certified check, cashier’s check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States in accordance with FAR Clause 52.228-1, Bid Guarantee, stated elsewhere in the solicitation. The bid guarantee shall be twenty percent (20%) of the bid price or $3,000,000 whichever is lesser. The penal sum may be expressed in terms of a percentage of the bid price or may be expressed in dollars and cents. A bid guarantee is not required for bids of $150,000 or less. For contracts with option years the bid guarantee shall be twenty percent (20%) of the bid price for the base period of performance or $3,000,000 whichever is less.

b. PERFORMANCE AND PAYMENT BONDS. The Contractor shall furnish a Performance Bond (Standard Form 25) and a Payment Bond (Standard Form 25-A), each with good and sufficient surety or sureties acceptable to the Government within ten (10) days after contract award date.

c. On requirements-type contracts, performance and payment bonds will be required on the first delivery order issued under the contract. Thereafter as additional delivery orders (DD Form 1155) are issued the contractor shall cause the penal amount of each bond to be increased to equal the total contract price as of the date of the most current delivery order. The contractor shall utilize a Standard Form 1415, (Consent of Surety and Increase of Penalty) to increase the penal sum. The initial performance bond (SF 25) and payment bond (SF 25-A) shall be submitted within seven (7) days after the date of the initial order (Block 3 of DD Form 1155).

Thereafter a SF 1415 shall be submitted within seven (7) after the execution of each additional delivery order. The contractor may not proceed with the work on any delivery order until the penal sum of the performance and payment bonds has been adjusted to reflect the total contract price.

d. The penal amount of the performance bond shall equal—

(1) Performance Bond: The penal amount of the performance bond shall equal one hundred percent (100%) of the contract/delivery order price.

(2) Payment Bond: The penal amount of payment bonds shall equal one hundred percent (100%) of the contract/delivery order price.

e. Should a contractor performing a Requirements Contract determine during contract performance that it wishes to utilize a different Surety for future delivery orders; the contractor shall obtain a Consent of Surety (SF 1414) from the existing Surety prior to submitting any bonds from an alternative Surety to the Contracting Officer.

H-9 REQUIRED INSURANCE

a. The Contractor shall, at its own expense, procure and maintain during the entire period of his performance under this contract the following minimum insurance:

TYPE AMOUNT

(1) Workmen’s Compensation Workmen’s Compensation Insurance shall comply with applicable Federal and State Workers’ compensation and occupational disease statutes and shall extend to cover employee’s liability for accidental bodily injury or death and for occupational disease with a minimum liability of the greater of: $100,000.00 or the State minimum

Requirements

(2) Comprehensive General Liability with minimum limits of:

Per accident or occurrence for bodily injury $500,000.00

(3) Comprehensive Automobile Liability with minimum limits of:

Per Person $200,000.00 Per Accident for Bodily Injury $500,000.00 Per Accident for Property Damage $ 20,000.00

b. Prior to commencement of work hereunder, the Contractor shall furnish to the Contracting Officer, a certificate or written statement of the above required insurance. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change in the policies adversely affecting the interests of the Government in such insurance shall not be effective for such periods as may be prescribed by the laws of the State in which this contract is to be performed and in no event less than thirty (30) days after written notice thereof to the Contracting Officer.

c. The Contractor shall insert the substance of this clause, including this paragraph c, in subcontracts under this contract that require work on a Government installation and shall require subcontractors to provide and maintain the insurance required in the Schedule, or elsewhere in the contract. At least five (5) days before entry of each such subcontractor’s personnel on the government installation, the contractor shall furnish (or ensure that there has been furnished) to the Contracting Officer a current certificate of insurance, meeting the requirements of paragraph b above, for each such subcontractor.

H-10 TAXES

The Missouri Department of Revenue agrees that contractors, subcontractors and material suppliers may claim an exemption from Missouri sales and use tax with respect to tangible personal property and materials purchased or used for the purpose of constructing, repairing or remodeling facilities for the United States of America, its agencies and instrumentalities (“the United States”). Therefore, the Contracting Officer shall provide a project exemption certificate to the successful contractor awarded this project. The Contractor shall further provide the project exemption to all subcontractors purchasing construction materials for this project.

NOTE: THE PROJECT EXEMPTION CERTIFICATE DOES NOT ALLOW CONTRACTORS

TO PURCHASE MACHINERY, EQUIPMENT, OR TOOLS USED IN FULFILLING THIS

CONTRACT, TAX EXEMPT.

H-11 POSTAWARD ORIENTATION

A Post-award Orientation will be scheduled by the Contracting Officer after contract award and prior to commencement of work. The Contracting Officer will notify the Contractor of the time and date set for the meeting that will be held at Fort Leonard Wood, MO. At this meeting, the Contractor will be oriented with respect to Government procedures and line of authority, as well as contractual, administrative, and construction matters. The Contractor is required to furnish a current Certificate of Insurance and a letter appointing a construction superintendent at the meeting. The Contractor is responsible for costs associated with any scheduled conference.

H-12 UTILITIES

At work sites where Government utilities are currently available, the Government will provide necessary utilities for the completion of the work at no charge to the Contractor. The Contractor must satisfy himself as to the extent of Government utility services available at each site and include any costs associated with the providing of necessary utilities, not available from the Government, in the prices bid for the applicable bid item.

H-13 EXCAVATION PERMIT REQUEST

If this project requires an excavation permit, the following procedures will apply:

a. The Contractor is required to process an Excavation Permit, FLW Form 364, prior to any digging of six inches (6”) or deeper, including installing posts or planting trees. Coordination with other Contractors and Army Agencies is required to properly locate all underground utilities. Utilities identified in the immediate area of the excavation site shall be located and marked prior to the Contractor proceeding with the excavation.

b. The Contractor shall make contact with the following contractors and Army Agencies at least two working days, but not more than ten working days, from the day excavations are expected to begin. An on-site meeting shall be held in advance to specifically point out the excavation location and to provide time for these persons to locate and mark underground utilities. A signature is required from each point of contact in order for DPW to approve the excavation permit. The completed excavation permit shall be furnished to the DPW Work Management office, Building 2200 for approval. A copy of the approved permit shall be furnished to the DPW Inspection Branch, Building 2202.

c. POINTS OF CONTACT:

1. To locate telephone lines owned by United Telephone System:

POC: Missouri One Call, Phone: 1-800-DIG-RITE Information you will need: (a) Name, address and phone number of your company; (b) excavation location to include township, range, section and quarter section or street name and address/building number; (c) type of work and depth to be excavated.

You will be given a serial number for your project. KEEP FOR YOUR RECORDS. Note the time and date of your call. Once you have the serial number you need to contact Sam Spade,

(573) 336-4242 or

(573) 336-4300, to arrange a meeting time.

2. To locate cable television lines (48 hour notice required):

POC: Cable America Dispatch, Phone: (573) 336-5284

3. To locate U.S. Army telephone lines:

POC: NEC, phone (573) 596-0680

4. To locate J-SIIDS lines, security alarm systems (located only at the Ammo supply Point):

POC: DOL, Phone: (573) 596-0874

5. To locate natural gas pipelines:

POC: Omega Pipeline Company (on FLW), Phone: (800) 282-4916 Missouri Gas Company (Railroad ROW) Phone :( 800) DIG-RITE

6. To locate underground primary (12.47/7.2 KV) electrical lines and area lighting circuits:

POC: Ext. Primary Electric, Phone: (573) 596-0068

7. To locate water, sanitary sewer, LLPG, fuel oil, steam, and EMCS (Energy Monitoring and Control System) lines, secondary Electrical line, chilled water, high temperature and cathodic Protection lines: POC: Base Maintenance, Phone: (573) 596-0074

d. If any utilities are cut or damaged during excavations, the Contractor shall immediately notify the DPW Inspection Office, 573-596-0907

e. Only one approved permit is required per project. If a project entails a large scope of excavations, the utilities should be located in increments of work not exceeding one week’s worth of digging operations. This will ensure that markings and flags used to locate underground utilities are not disturbed before digging can begin. If the Contractor elects to have the utilities located in increments, the Contractor shall conduct an on-site meeting for each increment documenting the times, dates, and POCs in case of discrepancies.

f. A blank excavation permit can be obtained at the publications Office, Building 2314, or in the Work Management Office, DPW, Building 2200.

g. The Contractor is required to furnish the Contracting Officer with a drawing identifying any utility or other item permanently installed below the ground surface. If utilities, abandoned lines, or other items are uncovered during excavations which were not identified by excavation permit coordinators, these shall also be identified to the government. This is important in order to update basic information maps. The DPW Inspection Branch is at 573-596-0907, Building 2202, or contact your Government inspector.

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.211-13 Time Extensions SEP 2000 52.211-13 Time Extensions SEP 2000 52.214-26 Audit and Records--Sealed Bidding OCT 2010 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data -

Modifications - Sealed Bidding

AUG 2011

52.214-28 Subcontracting Certified Cost Or Pricing Data-- Modifications--Sealed Bidding

OCT 2010

52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-14 Limitations On Subcontracting JAN 2017 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation

MAY 2014

52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014

52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-32 Construction Wage Rate Requirements--Price Adjustment (Actual Method)

JAN 2017

52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.233-3 Protest After Award AUG 1996 52.233-3 Protest After Award AUG 1996 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-16 Quantity Surveys APR 1984 52.236-17 Layout of Work APR 1984 52.236-26 Preconstruction Conference FEB 1995 52.239-1 Privacy or Security Safeguards AUG 1996 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007

52.244-6 Subcontracts for Commercial Items NOV 2017 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2015 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7006 Billing Instructions OCT 2005 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7002 Qualifying Country Sources As Subcontractors DEC 2017 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea APR 2014 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237310.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $62.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.216-19 ORDER LIMITATIONS (OCT 1995)

(a) Minimum order. When the Government requires supplies or services covered by this contract in an amount of less than 500.00, the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those supplies or services under the contract.

(b) Maximum order. The Contractor is not obligated to honor -

(1) Any order for a single item in excess of $500,000.00

(2) Any order for a combination of items in excess of $750,000 or

(3) A series of orders from the same ordering office within 3 days that together call for quantities exceeding the limitation in paragraph (b) (1) or (2) of this section.

(c) If this is a requirements contract (i.e., includes the Requirements clause at subsection 52.216-21 of the Federal Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) of this section.

(d) Notwithstanding paragraphs (b) and (c) of this section, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within 5 days after issuance, with written notice stating the Contractor's intent not to ship the item (or items) called for and the reasons. Upon receiving this notice, the Government may acquire the supplies or services from another source.

52.216-21 REQUIREMENTS (OCT 1995)

(a) This is a requirements contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies or services specified in the Schedule are estimates only and are not purchased by this contract. Except as this contract may otherwise provide, if the Government's requirements do not result in orders in the quantities described as "estimated'' or "maximum" in the Schedule, that fact shall not constitute the basis for an equitable price adjustment.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. Subject to any limitations in the Order Limitations clause or elsewhere in this contract, the Contractor shall furnish to the Government all supplies or services specified in the Schedule and called for by orders issued in accordance with the Ordering clause. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(c) Except as this contract otherwise provides, the Government shall order from the Contractor all the supplies or services specified in the Schedule that are required to be purchased by the Government activity or activities specified in the Schedule.

(d) The Government is not required to purchase from the Contractor requirements in excess of any limit on total orders under this contract.

(e) If the Government urgently requires delivery of any quantity of an item before the earliest date that delivery may be specified under this contract, and if the Contractor will not accept an order providing for the accelerated delivery, the Government may acquire the urgently required goods or services from another source.

(f) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period; provided, that the Contractor shall not be required to make any deliveries under this contract after 30 September 2020

52.217-9 OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000)

(a) The Government may extend the term of this contract by written notice to the…