18-T-0010_SF1442_(Released)_Solicitation.pdf

W41G26734001E4

FURNISH ALL LABOR, EQUIPMENT, MATERIALS, AND TRANSPORTATION TO PROVIDE HIGH VOLTAGE OVERHEAD POWER TO BUILDINGS 81-100, 81-200, 81-300, AND 81-400 IN ACCORDANCE WITH THE ATTACHED STATEMENT OF WORK.

All contractors submitting a proposal must be registered & current in System for Aw ard Management (SAM)

NAICS CODE: 238210- $15.0 MIL

Acquisition is a (100%) Small Business Set-Aside

A Site Visit is recommended

PBA Site Visit is scheduled for March 15, 2018 at 1:00 pm CST - Plainview Complex, Building 17-120. Please send an email to jeffrey.l.allred.civ@mail.mil or the COR at clayton.d.ferrell.civ@mail.mil The magnitude for this construction project is betw een 250,000 and 500,000.

Do not submit your proposal or pricing electionically

Wage Decision Number AR180036 - 01/05/2018 AR36 is applicalbe and attached

JEFFREY L. ALLRED 870-540-4130

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

06-Mar-2018

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________120 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________05 Apr 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

ARMY CONTRACTING COMMAND - ROCK ISLAND

PINE BLUFF ARSENAL CONTRACTING OFFICE

10-020 KABRICH CIRCLE, BLDG 17-120

ATTN: CCRC-AEP

PINE BLUFF AR 71602-9500

W911RP

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

(870) 540-4090FAX:TEL: (870) 540-3020 TEL: FAX:

W911RP18T0010 38

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W911RP18T0010

Section 00010 - Solicitation Contract Form

STATEMENT OF WORK

GENERAL STATEMENT OF WORK

Provide 277/480V 600 Amp service with neutral to buildings 81-100, 81-200, 81-300 and 81-400.

DETAILED SCOPE OF WORK

Provide power to buildings 81-100, 81-200, 81-300 and 81-400

1. Provide labor and materials needed to run overhead primary to buildings 81-100, 81-200, 81-300 and 81-400.

a. Provide poles, cross arms, wire and hardware to establish power to all 4 buildings

b. Install pole mounted transformers.

c. Provide cut outs at earliest entry point for new line.

2. Install 277/480V 600 Amp service with neutral and fusible disconnects to all buildings.

a. Each building service will have ground rod with ground wire per NEC for 600 amp service. Ran in ¾ rigid.

Pipe will strapped to building min of 2 times.

b. Install 600 Amp/480v surface mount panels w/main breaker with all trim and ground kits in all buildings.

c. All 400 amp 480v/277 panels will be 42 circuit.

3. Install Dry cell transformer to provide all buildings with a 208/120V service w/ neutral.

a. Transformer will need 3 point grounding provided.

b. Transformers will need to be placed on housekeeping pad provided by contractor. Min 4” thick between 408v panel and 208v panels.

c. Install 200 Amp surface mount panels with main breaker and all trim and ground kits to all buildings.

d. All 200 amp panels 208v/120v will be 42 circuit w/main

4. Provide option for underground service from primary lines to buildings.

5. Install smart metering system in each building that is compatible with the Pine Bluff Arsenal tracer summit power monitoring program.

6. Contactor will need to be experienced in high voltage overhead power line distribution work and will need to provide proof of work done within the last 3 years with a magnitude of at least $50K per awarded contracts.

Environmental 0Requirements:

1. Compliance with Environmental Laws and Regulations: Contractor shall comply with all applicable federal, state, and local environmental laws, statutes, regulations, executive orders, permits, Army regulations (with supplements), as well as Major Subordinate Command (MSC) and installation regulation, policy, Host Tenant Agreement, Interagency Service Support Agreement, or Status-of-Forces Agreement. Contractor shall immediately report any conflicts between applicable federal, state, local environmental laws, statutes, executive orders, and provisions of Army Regulation 200-1, and any specifications within this contract to the Contracting Officer Representative (COR).

2. Compliance with Green Procurement Requirements: Contractor shall follow Federal EPA Comprehensive Procurement guidelines (www.epa.gov/cpg) and Army Contracting Command Quick Guide (https://acc.aep.army.mil/accapps/ACCMAP/Documents/Quick-Guide-for-Sustainable-Procurement.docx) for acquisition of building materials and products and select materials that have a long life cycle; the least toxic materials;

recyclable materials; materials that are resource-efficient; materials with the maximum recycled content; materials harvested on a sustained yield basis; and products causing the least pollution during their manufacture, use, and reuse.

3. Compliance with License and Certification Requirements: Contractor shall obtain all license and certification required by Federal, State, and Local environmental laws and regulations necessary to adhere to the specifications of this contract. The Contractor shall submit all plans, notifications, reports, submittal documents, and fees required by Federal, State, and Local environmental laws and regulations to the appropriate Federal, State, and Local authority and/or agency as necessary to adhere to the specification of this contract. All required licenses and certifications required by Federal, State, and Local environmental laws and/or regulations shall be considered a contract deliverable upon award.

4. Notification of Federal and State Regulators: Contractor shall immediately notify the Designated Government Representative (DGR) and COR of the arrival on site of any Federal, State, and/or DoD environmental regulator or enforcement agent and/or the receipt of any correspondence from a Federal or State environmental agency.

5. Inspections of Work Sites: Contractor shall submit to potential Federal, State, Army and installation work site environmental regulatory inspections and/or investigations into noncompliance, and fully cooperate with such inspections/investigations by providing the appropriate records and documentation. Environmental regulatory agencies are authorized by law to inspect any work site for environmental compliance with regulatory requirements. If an inspection is conducted, it will not stop or disrupt ongoing contract activities. The inspection will only require the work site environmental officer, or supervisor/manager to answer questions and/or escort the inspector to specific work site areas with the potential to affect environmental quality.

6. Reporting Noncompliance: Contractor shall immediately report any nonconformance and/or noncompliance with applicable Federal, State or Local environmental laws, Army and installation environmental regulations or policies to the COR and DGR.

7. Verification of National Environmental Policy Act Documents: Contractor shall obtain from the COR or DGR, a copy of AMC's National Environmental Policy Act Policy and 32 CFR 651 which addresses actions to be taken by contractor. These documents include but is not limited to the analysis-associated decision document of an Environmental Impact Statement and Record of Decision; Environmental Assessment and Finding of No Significant Impact or Notice to Proceed; or Record of Environmental Consideration on the proposed contract actions prior to commencement of such actions.

8. Conformance with Environmental Management System: Contractor shall take the necessary actions to identify, monitor, and control those contract operations and activities that pose risk of contamination, or can negatively impact the natural and/or human environment.

9. Assignment of Environmental Compliance Designee (ECD): Contractor shall appoint an ECD for all contract work periods exceeding 180 consecutive days. Contractor shall appoint a primary and alternate ECD for each production, shop or work area that uses and/or stores hazardous materials and/or generates hazardous wastes.

Contractor ECDs shall monitor implementation of all environmental regulatory requirements, report all environmental noncompliance to the work site supervisor, correct all environmental noncompliance, and verify implementation of directed actions to correct identified environmental noncompliance. Contractor shall have at least one ECD on duty at all times at each shop or work area. Contractor shall require all personnel designated as ECDs to complete the initial ECD training through the installation or Major Subordinate Command (MSC) environmental compliance point of contact within 15 days of the start of contract performance. Contractor personnel appointed as ECDs may perform other duties provided they do not prevent the performance of ECD duties. Contractors may request a waiver of this requirement through the COR and DGR, if using and/or storing very small quantities of hazardous materials.

10. Competency Training for Contractor Personnel: Contractor shall not allow personnel to perform any activities and/or tasks on AMC installations without proper and adequate qualifications or job competency training. In the event of any identified noncompliance, the Contractor shall, if requested, provide proof of contract personnel training or qualification (individual name, training/qualification type, training/qualification certificate, and date of training/qualification) to perform those contract activities associated with the identified noncompliance.

11. Generation of Solid Waste: Contractor shall remove from the installation and dispose of all solid waste generated, which cannot be recycled to an approved and permitted off-post disposal facility.

11.1 Contractor shall make every effort to divert construction, demolition debris, and all other solid waste to comply with the Army Integrated Solid Waste Management Policy.

11.2 Prior to removing any waste from the installation for disposal, the Contractor shall coordinate with the installation Qualified Recycling Program (QRP) Manager, DGR, and COR to arrange for recyclable materials to be removed and diverted from the waste stream.

11.1 Submit in writing the quantities of waste removed and recycled to the DGR and/or COR on a monthly basis.

The submittal shall include the date of disposal/recycling, the disposal/recycling facility, the types of material disposed/recycled and the quantities of materials disposed/recycled by weight.

11.4 The Contractor shall establish a program to promote cost-effective waste reduction in all operations and facilities covered by the contract. This includes collection, separation, and processing products or other materials recovered from solid waste streams for use in the form of raw materials.

11.5 The Contractor shall make maximum effort to reduce and prevent waste.

12. Generation of Hazardous Waste: Contractor shall assign all hazardous waste management responsibilities to the appointed ECD. Contractor shall contact the DGR and/or COR to obtain technical assistance from the Environmental Office for assisting the ECD with achieving and maintaining compliance with hazardous waste storage and disposal requirements. Contractor shall properly profile all waste generated as part of this contract to determine if any waste is hazardous waste as defined by 40 CFR. Contractor shall accumulate hazardous waste prior to disposal shipment in a satellite accumulation point at or near the point of generation or in a less-than-90-day site, in accordance with Federal, State, Army, and installation regulation, policy, Host Tenant Agreement, Interagency Service Support Agreement or Status-of-Forces Agreement. The Contractor shall properly package the hazardous waste and complete the hazardous waste manifest, then take the manifest to DGR for approval and signature prior to removing any hazardous waste from the installation. Contractor shall contact DGR to obtain the installation’s hazardous waste EPA ID number for the hazardous waste manifest. The Contractor shall notify the DGR 24 hours prior to removing any hazardous waste from the installation. The contractor shall remove and dispose of manifested hazardous waste generated by contract activities from the installation, to an approved off-post permitted hazardous waste disposal facility. The DGR shall assist contractors with profiling their waste upon request.

13. Use of Hazardous Materials: Contractor shall assign all hazardous materials management responsibilities to the appointed ECD. Contractor shall contact the DGR or COR to obtain technical assistance from Environmental Office for assisting the ECD with achieving and maintaining compliance with hazardous material storage, issue, use, and disposal requirements. Contractor shall submit to the COR and/or DGR a hazardous material inventory. The hazardous material inventory will be submitted 30 days prior to commencement of work for contracts that exceed 180 consecutive days. The inventory list will contain the hazardous material type and maximum quantities of materials anticipated to be stored on-site. The hazardous material shall be properly identified and include any applicable identification number, such as National Stock Number or Special Item Number. The Contractor shall maintain copies of Safety Data Sheets for all hazardous materials used and stored on-site during performance of the contract.

Contractor shall not supply or deliver any hazardous materials or chemicals to an installation that are listed on EPA toxic chemical list without prior written approval from DGR and/or COR.

14. Prevention of Storm Water Pollution: The Contractor shall perform, track, participate, implement, and comply with storm water pollution prevention minimum control measures, protocols, and best management practices (BMP) and ensure that water quality standards are not violated in accordance with all regulations and policies as applicable to the Pollutant Discharge Elimination System general permit requirements. Applicable permits include:

1. The installation’s Small Municipal Separate Storm Sewer System (MS4) Permit;

2. The Multi-Sector General Permit for Storm Water Discharges Associated with Industrial Activities (MSGP); and,

3. All Construction Activity Storm Water permits minimum control measures include, but not limited to:

Public Education and Outreach on Storm Water Impacts Public Involvement and Participation Illicit Discharge Detection and Elimination Construction Site Storm Water Run-off Control Post Construction Storm Water Management in New Development and Redevelopment

Pollution Prevention/Good Housekeeping for Municipal Operations Contractors will comply with the MSGP permit when the activity is identified as a permitted industrial activity. BMPs include, but are not limited to:

Practicing spill prevention and good housekeeping.

Installing and managing erosion and sediment control.

Meeting the requirements of the MS4 permit.

Contractors will obtain permit coverage for construction activities disturbing over one acre of land (total acreage is cumulative across all portions of the project). BMPs include, but are not limited to:

Preparing and implementing a site-specific Storm Water Pollution Prevention Plan (SWPPP) as outlined in the permit and prior to any soil disturbance.

Installing and managing erosion and sediment control.

Make available, upon request, permit associated documentation.

Practicing spill prevention and good housekeeping.

Meeting the requirements of the MS4 permit.

Schedule inspections and provide corrective actions for noted deficiencies.

15. Storm Water Management Low Impact Design/Development (LID): The Contractor shall perform, track, participate, implement, and comply with Section 438 of the Energy Independence and Security Act; Executive Order 13514; and the DOA memorandum (2010) for full implementation of low impact design/development (LID) techniques to restore predevelopment hydrology to the maximum extent technically feasible for both new and renovation construction projects regardless of size. In support of LID, Contractors will adhere to installation landscape codes and the guidance found in the Installation Design Guide concerning Low Impact Design/Development for storm water management. The following LID practices include, but are not limited to:

Restoring predevelopment hydrology to the maximum extent technically feasible Promoting natural removal of pollutants such as nutrients, oil and grease, and sediments from storm water Managing rainfall at the point where it falls Meeting the requirements of the MS4 permit Important Note: Utilization of permanent retention/detention ponds is prohibited without authorization from the Installation Planning Division.

16. Use of Pesticides: Contractor shall submit the type and quantity of regulated pesticides to be applied, the application purpose, and location to the DGR and COR for approval 10 working days prior to the initial application.

The Contractor shall submit the actual quantities applied (DD1532 or equivalent) to the DGR and COR within 2 working days (48 hours) after each approved application. The Contractor shall utilize Integrated Pest Management (IPM) technology and procedures in strict compliance with all applicable Federal, State, Army, and installation regulations, to include the installation's integrated pest management plan. Pesticide applicators shall be certified and licensed in accordance with the State where work is being performed and/or Department of Defense regulations. The Contractor shall provide evidence of personnel licenses and certifications to the Contracting Officer and the DGR prior to the initial application of pesticides. Only those pesticides registered with the US Environmental Protection Agency (EPA) and approved by Army Materiel Command Pest Management Consultant shall be utilized and then only in strict accordance with product labeling. The installation reserves the right to prohibit and limit the amount and type of pesticides used.

17. Protection of Work Site Resources: Contractor shall confine all activities to areas defined by the drawings and specifications. Prior to the beginning of any work, the Contractor shall identify any land resources to be preserved within the work area. Except in areas indicated on the drawings or specified to be cleared, the Contractor shall not remove, cut, deface, injure, or destroy land resources including trees, shrubs, vines, grasses, topsoil, and landforms.

The Contractor shall provide effective protection for land and vegetative resources at all times. Prior to site clearing and grubbing, the Contractor shall coordinate harvesting of saleable timber with the DGR and/or COR. Contractor shall notify the DGR and/or COR if any trees are required to be disposed or removed. The Contractor is not authorized to remove or dispose of any tree greater than 6 inches in diameter unless permission has been granted in writing by the DGR or COR.

18. Prevention of Spills: Contractor shall adopt the installation's Spill Prevention Control and Countermeasures Plan (SPCC) if transporting, processing, storing, or in any way managing hazardous waste, hazardous material, petroleum-oils-lubricants, or other restricted items. In case of a spill, the person in control of the spill site or their designated representative shall take appropriate action to protect workers and bystanders; contain the spill (if it can be done safely); secure the spill site; restrict ignition sources; and immediately contact the installation Fire and Emergency Services (Fire Department).

19. Protection of Sensitive Areas: Contractor shall comply with all installation designated sensitive and/or off-limit area restrictions. Sensitive areas are generally demarked indicating what activities (e.g., driving, digging, foot traffic) are prohibited. The Contractor shall also adhere to the following installation sensitive areas requirements:

19.1. Cultural Resources Sites: Do not excavate, remove, damage, or otherwise deface any archeological resource located on public lands.

19.2 Endangered Species Habitats: Do not initiate any action that may disturb, endanger, or damage to any degree the habitat of a threaten and endangered species.

19.3 Wetlands: Do not excavate or take any action that could fill or damage any wetland unless working under a project specific Corps of Engineers 404 permit. Wetlands include streams, riparian areas, bogs, marshes, and swamps.

20. Corrective Action for Noncompliance: Contractor shall when given a verbal and/or written notice of environmental noncompliance or nonconformance by the COR, take immediate corrective action. Failure or refusal to comply promptly may be grounds for the Contracting Officer to invoke the appropriate contractual remedies. This may cause all or part of the work to be stopped immediately until satisfactory corrective action has been taken.

21. Noise: Make the maximum use of low-noise emission products, as certified by the EPA. Blasting or use of explosives will not be permitted without written permission from the Contracting Officer, and then only during the designated times. Pile-driving operations shall be coordinated through the DGR and COR.

22. Mercury: Mercury is prohibited, unless specified otherwise, and with the exception of mercury vapor lamps and fluorescent lamps. Dumping of mercury-containing materials and devices such as mercury vapor lamps, fluorescent lamps, and mercury switches, in rubbish containers is prohibited. Remove without breaking, pack to prevent breakage, and transport out of the activity in an unbroken condition for disposal as directed. Immediately report to the DGR and COR instances of breakage or mercury spillage. Clean mercury spill area to the satisfaction of the Contracting Officer.

Cleanup of a mercury spill shall not be recycled and shall be managed as a hazardous waste for disposal.

23. Universal Waste / e-Waste Management: Universal waste including but not limited to some mercury containing building products such florescent lamps, mercury vapor lamps, high pressure sodium lamps, CRTs, batteries, aerosol paint containers, electrical equipment containing PCBs, and consumed electronic devices, shall be managed in accordance with applicable environmental law and installation instructions.

24. Pollution Prevention / Hazardous Waste Minimization: Minimize the use of hazardous materials and the generation of hazardous waste. Consult with the Environmental Office for suggestions and to obtain a copy of the installation's pollution prevention/hazardous waste minimization plan for supporting waste minimization goals.

CONDITIONS:

a. The contractor shall provide all materials, equipment, tools and labor for the execution of this contract. Contractor shall be responsible for loading and unloading of equipment, to include forklift or other equipment, operator and labor.

b. Changes or deviations will be submitted in writing to the contracting officer for approval or rejection.

c. Any alteration to the building or any other equipment in the building shall be approved by the Contracting Officer prior to execution and at the expense of the contractor.

d. Design engineering drawings, software’s and any other documents including editable copy in original file format developed and submitted to the government as part of this contract become the property of the U.S. Government.

The government will have the right to reproduce and subsequently edit any of these documents and will reserve the right to procure parts, components or the entire system from any source capable of producing it.

LOCATION OF WORK: The local work covered by this specification is to be performed at Pine Bluff Arsenal.

Postal address is Pine Bluff, Arkansas 71602-9500. Carload freight address is Baldwin, Arkansas on either the Union Pacific R.R. or the St. Louis Southwestern R.R. The Arsenal is located off Highway 65, Exit 32, about 12 miles northwest of Pine Bluff and 35 miles southeast of Little Rock. The job site is Area 8, Section 1, Buildings 81- 100, 81-200, 81-300, and 81-400.

ORDER AND SCHEDULING OF WORK: When performing work on Pine Bluff Arsenal the Contractor shall adhere to the normal duty hours of the Arsenal which are 6:30 AM to 4:00 P.M., Monday thru Thursday and 6:30 AM to 3:00 PM every other Friday. However, contractor shall coordinate Friday work with the Contracting Officer or the COR, to ensure which Friday is the workday. No work will be permitted on Government holidays, days that are observed in lieu of Government holidays and days that are declared non-work days by the Commanding Officer of Pine Bluff Arsenal or officials of higher headquarters. Deviations from the above must be approved in writing by the Contracting Officer at least two working days prior to the proposed deviation.

DISPOSAL OF EXCESS REMOVED MATERIALS: All salvaged rubble, material, and equipment will remain the property of the Government.

a. Uncontaminated rubble, materials, and equipment, will be delivered to an erosion control area as directed by the Contracting Officer. Materials and equipment will be placed in "like material" stacks when delivered to the Property Disposal Yard.

b. Contaminated rubble, materials, and equipment will be placed in containers and delivered to a materials holding area as directed by the Contracting Officer.

SAFETY REQUIREMENTS:

a. General: Limited emergency first aid, to prevent loss of life or limb, is available for contractor personnel at the U.S. Army Health Clinic for injuries sustained in the performance of their duties. This service is normally available from 7:30 A.M. to 4:00 P.M., Monday through Friday. For life threatening emergencies after duty hours, contractor personnel will notify the Medical Officer of the day. For any other injury, contractor personnel should go to Jefferson Regional Medical Center or see their private physician. Use of this Health Clinic constitutes compliance with the First Aid Requirements of the Corps of Engineers Manual EM 385-1 as referenced in, FAR 52.236-13 "Accident Prevention". The requirements of Department of Labor, Occupational Safety and Health Administration (OSHA) Standard 29 CFR 1910 or EM 385-1, General Safety Requirements, whichever is the most stringent, will be followed

b. The regulations and supplements listed below will be adhered to by all contractor and sub-contractor personnel.

PBAR 190-5 PBA antiterrorism/force protection background check PBAR 190-47 Privately Owned Firearms Registration PBAR 385-10 Smoking Designated Area Approval PBAR 385-7 Hazardous Work Permit PBAR 385-6 Energized Electrical work Permit

c. No fire or flame producing device will be used on the Arsenal without prior approval of the Contracting Officer.

The Contractor shall also be required to obtain a burn permit from the Fire Department. This includes all forms of welding.

d. Smoking will not be permitted in the production area, except in designated areas.

e. Equipment will be maintained in a safe operating condition and a fire safe condition at all times. It shall be stored in a designated area, approved by the Contracting Officer.

f. Hoists, cranes, derricks, or similar equipment shall not be operated where it is possible to bring any part of the machine, suspended load, or lines closer than ten feet to power lines unless the lines have been de-energized and grounded.

g. Work will be performed in a manner which will allow the passage of traffic, especially emergency vehicles, at all times. Where only one lane is open to traffic, adequate warning signs and flagmen will be used.

h. All personnel working at Pine Bluff Arsenal must have a safety briefing given by Safety personnel prior to beginning work.

i. Contractor shall provide the names and personnel data on all employees scheduled for this contract work at PBA, to the Contracting Officer at least one week prior to actual work. This is necessary for proper identification and issue of security pass to each employee for access to PBA job site.

- End SOW -

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot

POWER TO 81 SERIES BUILDINGS

FFP

FURNISH ALL LABOR, EQUIPMENT, MATERIALS, AND

TRANSPORTATION TO PROVIDE HIGH VOLTAGE OVERHEAD POWER

TO BUILDINGS 81-100, 81-200, 81-300, AND 81-400 IN ACCORDANCE

WITH THE ATTACHED STATEMENT OF WORK.

FOB: Destination

PURCHASE REQUEST NUMBER: W41G26734001E4

PSC CD: Y1NZ

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

DD 1423

FFP

NSP: NOT SEPARATELY PRICED:

CONTRACT DATA REQUIREMENTS LIST - CONTRACTOR SHALL

PREPARE AND DELIVER ALL TECHNICAL DATA IN ACCORDANCE

WITH THE CONTRACT DATA REQUIREMENTS LIST, DD FORM 1423.

NET AMT

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 N/A N/A N/A N/A

Section 00100 - Bidding Schedule/Instructions to Bidders

WAGE DETERMINATION

General Decision Number: AR180036 01/05/2018 AR36

Superseded General Decision Number: AR20170036

State: Arkansas

Construction Type: Building BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Counties: Cleveland, Jefferson and Lincoln Counties in Arkansas.

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.35 for calendar year 2018 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015.

If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.35 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2018. The EO minimum wage rate will be adjusted annually.

Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/05/2018

BOIL0069-002 01/01/2017

Rates Fringes

BOILERMAKER......................$ 28.97 21.38

CARP0216-003 01/01/2017

Rates Fringes

MILLWRIGHT.......................$ 24.45 9.28

ELEC0295-009 01/01/2017

Rates Fringes

ELECTRICIAN......................$ 24.55 12.23

PAIN0424-009 07/01/2017

Rates Fringes

PAINTER (Brush, Roller and Spray)...........................$ 17.00 7.92

* PLUM0155-015 08/14/2017

Rates Fringes

PIPEFITTER.......................$ 22.65 9.61

SHEE0036-034 06/01/2015

Rates Fringes

SHEET METAL WORKER (Includes HVAC Duct Installation)..........$ 22.64 13.35

SUAR2015-033 01/09/2017

Rates Fringes

BRICKLAYER.......................$ 19.39 0.00

CARPENTER........................$ 15.73 0.55

CEMENT MASON/CONCRETE FINISHER...$ 17.03 0.00

INSULATOR - MECHANICAL

(Duct, Pipe & Mechanical System Insulation)...............$ 17.16 4.76

IRONWORKER, REINFORCING..........$ 14.00 0.00

IRONWORKER, STRUCTURAL...........$ 19.39 0.00

LABORER: Common or General......$ 10.80 0.00

LABORER: Mason Tender - Brick...$ 12.04 0.00

LABORER: Pipelayer..............$ 14.02 0.00

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 23.17 0.00

OPERATOR: Bulldozer.............$ 16.74 0.00

OPERATOR: Crane.................$ 17.52 0.00

OPERATOR: Grader/Blade..........$ 14.66 0.00

OPERATOR: Paver (Asphalt, Aggregate, and Concrete).........$ 17.79 0.00

OPERATOR: Roller................$ 14.34 0.00

PLUMBER..........................$ 22.95 6.86

ROOFER...........................$ 15.39 0.00

TRUCK DRIVER: Dump Truck........$ 13.80 0.71

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

IMPORTANT LOCAL INFORMATION

IMPORTANT LOCAL INFORMATION

SECURITY VETTING REQUIREMENTS

The Pine Bluff Arsenal (PBA) Vetting Program is being changed to comply with installation access requirements identified in AR 190-13, HSPD-12 and DTM 09-012. Access policy requires all unescorted persons entering DOD installations to have a valid purpose to enter, have their identity verified and vetted to determine the fitness of the individual requesting and/or requiring access to the installation, and be issued or in possession of an authorized and valid access credential. They also require local passes only be issued to non-DOD cardholder personnel who have successfully passed an NCIC check.

The Directorate of Law Enforcement and Security (D/LE&S) requires background checks to be conducted on all individuals 16 years of age or older who do not possess a valid DOD Identification (ID) credential (i.e. CAC, Military Id) prior to being granted access onto PBA. This change includes 100% of contractors, vendors, commercial carriers, visitors, Natural Resources customers, MWR customers and CYS customers.

The following criteria will prevent access to PBA: Violent Offense Conviction within the last ten (10) years, Felony or Misdemeanor Class A Conviction within the last five (5) years, Current Pending Charges, Active Warrant or Convicted Sex Offender. Habitual Offenders with three (3) or more criminal convictions may also be denied access at the mutual discretion of two Certified ACIC/NCIC Operators. In addition, the following criteria will prevent hunting on PBA: Felony Conviction, Domestic Violence Conviction, DUI/DWI Conviction within the last five (5) years or Active Order of Protection.

AMC-LEVEL PROTEST PROGRAM

If you have complaints about this procurement, it is preferable that you first attempt to resolve those concerns with the responsible contracting officer. However, you can also protest to Headquarters, AMC. The HQ, AMC-Level Protest Program is intended to encourage interested parties to seek resolution of their concerns within AMC as an Alternative Dispute Resolution forum, rather than filing a protest with the General Accounting Office or other external forum. Contract award or performance is suspended during the protest to the same extent, and within the same time periods, as if filed at the GAO. The AMC protest decision goal is to resolve protests within 20 working days from filing. To be timely, protests must be filed within the periods specified in FAR 33.103. If you want to file a protest under the AMC-Level Protest Program, the protest must request resolution under that program and be sent to the address below. All other agency-level protests should be sent to the contracting officer for resolution.

Headquarters U.S. Army Materiel Command Office of Command Counsel-Deputy Command Counsel 4400 Martin Road

RM: A6SE040.001

Redstone Arsenal, AL 35898-5000

Fax: (256) 450-8840 or e-mail: usarmy.redstone.usamc.mbx.protests@mail.mil Packages sent by FedEx or UPS should be addressed to:

Headquarters U.S. Army Materiel Command Office of Command Counsel-Deputy Command Counsel 4400 Martin Road

RM: A6SE040.001

Redstone Arsenal, AL 35898-5000 Fax: (256) 450-8840 or e-mail: usarmy.redstone.usamc.mbx.protests@mail.mil AMC-Level Protest Procedures are located on the Internet. If Internet access is not available, contact the contracting officer or HQ, AMC to obtain the AMC-Level Protest Procedures.

http://www.amc.army.mil/pa/COMMANDCOUNSEL.asp

OSHA STANDARDS

Contractor must comply with all applicable OSHA standards.

INSPECTION AND ACCEPTANCE

a. The work will be conducted under the general direction of the Contracting Officer and is subject to inspection by his appointed inspectors to insure strict compliance with the terms of the contract. No inspector is authorized to change any provision of the specifications without written authorization of the Contracting Officer, nor shall the presence or absence of an inspector relieve the contractor from any requirements of the contract.

b. The Contracting Officer shall designate individuals to act as the Contracting Officer’s Representative (COR) under any resultant contract. Such representative will be designated in writing by the Contracting Officer with a copy of designation to the contractor. The COR will represent the Contracting Officer in the technical phases of the work, but will not be authorized to change any of the terms and conditions of the contract.

c. The COR will act in a liaison capacity to coordinate activities between the contractor and the Government as required in the performance of work under the contract.

INSURANCE RQUIREMENTS

The following insurance is required as a minimum in accordance with the Federal Acquisition Regulation and the appropriate clause in Section I:

a. Legally Required Insurance: When certain laws apply, such as state laws governing workman's compensation and employer's liability coverage, etc., the contractor, prior to commencement of work, shall furnish the Contracting Officer a written statement that such laws have been complied with and that compliance will continue throughout the period of contract performance. Minimum coverage of $100,000.00 is required.

b. Comprehensive General Liability and Automobile Liability:

Per Property Each Person Occurrence Damage

Comprehensive None $500,000 None General Liability

Automobile Liability $200,000 $500,000 $20,000

DELIVERY OF MATERIALS

It is the responsibility of the contractor or subcontractor to inform their vendors or truck drivers of the prime contractor's name, contract number and work site. Pine Bluff Arsenal is a controlled access installation therefore, subcontractors, vendors, or delivery persons who do not possess the above information and other proper identification as required by the Security Office may be denied access to Pine Bluff Arsenal. Any delay caused by such denial will be at the contractor's expense and no time extensions for such delays will be allowed. Contractors will provide escorts for suppliers' trucks from the perimeter gates to job site when required.

NOTICE OF POSSIBLE DELAYS

During the time a contractor is working on the Arsenal he may, from time to time, be working in an area where munition test exercises are conducted. While it is not the Arsenal's policy to interfere with a contractor during these test exercises, delay may occur. These delays may involve contractor personnel being withdrawn from an area or being denied access for a period of time. The length of time and frequency of these delays will be held to a minimum. No claim shall be submitted for less than five (5) man-hours per month. Claims may be submitted under the Changes Clause of the contract.

BURIED CABLES AND LINES

The contractor shall submit a Pine Bluff Arsenal Request to Mark Utility Lines and submits the same to the Contracting Officer's Representative (COR) three (3) working days prior to commencing any digging on the Pine Bluff Arsenal. Blank forms will be issued at the Post Award Meeting. If the Contractor fails to provide notification, the Contractor shall be liable for any damages to any buried telephone cables or utility lines regardless of care exercised or drawings followed.

The Government shall not grant time extensions nor pay additional costs incurred because of delays, unless the Contractor has properly notified the Government one working day in advance of the desired digging date.

DISMISSALS

The Contracting Officer may require the contractor to suspend or dismiss from work any employee or employees whose retention is deemed to be not in the public interest, because of the misconduct of the employee or for reasons of security, subject, however, to appeal under the provisions of Articles entitled "Disputes" for reinstatement of such employees.

SUBMITTALS

Should…