W911PT18R0021.docx

W911PT18R0021

Section SF 30 - BLOCK 14 CONTINUATION PAGE

MACHINE DELIVERY SCHEDULES

NOTICE:

The following is a tentative machine delivery schedule from soonest date to latest.

It should be noted the machine foundations will be required to be ready to have the machines installed (e.g. concrete formed and cured) by the stated below dates.

An additional 30 days for completion and fit up after the install of the machines is factored into the period of performance dates in Section E.

Liquidated damages will apply per FAR 52.211-12 per each seperate foundation not ready for machine installation and will be charged starting on dates provided below.

Location

Section A - Solicitation/Contract Form

CLAUSES INCORPORATED BY FULL TEXT

52.0000-4950 Disclosure of Unit Price Information (Jun 2004) (ACC-WRN (WVA))

This constitutes notification pursuant to Executive Order 12600, Pre-Disclosure Notification Procedures for Confidential Commercial Information (June 23, 1987), of our intention to release unit prices of the awardee in response to any request under the Freedom of Information Act, 5 USC 552. Unit price is defined as the contract price per unit or item purchased. We consider any objection to be waived unless the contracting officer is notified of your objection to such release prior to submission of initial proposals.

END OF CLAUSE

52.0000-4960 Contractor’s Representative (Jul 2007) (ACC-WRN (WVA))

Contractor’s Representative: A competent foreman or superintendent, with authority to act on behalf of the Contractor, must be present at the job site at all times that work is going on. The name of the foreman or superintendent will be furnished in writing to the Contracting Officer. If the foreman or superintendent is changed during the life of the contract, the Contracting Officer shall be notified accordingly.

(End of Provision)

Section B - Supplies or Services and Prices

7OD006 Install Foundation

FFP

7OD006 To cover the cost of labor, equipment and material to Install Foundation for 39' Hollow Spindle Lathe in B. 110 B- Bay Sections B32-37 FOB: Destination

PSC CD: Z2EC

NET AMT

7OD007 Install Foundation

7OD007 To cover the cost of labor, equipment and material to Install Foundation for 39' Double Carriage Lathe in B. 110 B- Bay Sections 40

NET AMT

7OD008 Install Foundation

7OD008 To cover the cost of labor, equipment and material to Install Foundation 26' Single Carriage Lathe in B. 35 C- Bay Sections C20-22W

NET AMT

7OD009 Install Foundation

7OD009 To cover the cost of labor, equipment and material to Install Foundation for 39' Single Carriage Lathe in B. 110 B- Bay Sections 38

NET AMT

7OD010 Install Foundations (2 each)

7OD010 To cover the cost of labor, equipment and material to Install Foundations (2 each) for 26' Double Carriage Lathes in Building 135 C Bay Sections 5-8E & Sections C9-11E

NET AMT

7OD011 Install Foundations (2 each)

7OD011 To cover the cost of labor, equipment and material to Install Foundations (2 each) for 26' Single Carriage Lathes in Building 35 Sections C20-22E & B. 35 Sections D 17-19W

NET AMT

7OD012 Install Foundations (2 each)

7OD012 To cover the cost of labor, equipment and material to Install Foundations (2 each) for 26' Dual Carriage Lathe in Building 135 Sections C12-14E & B. 135 Sections C2-4E

NET AMT

7OD013 Install Foundation

7OD013 To cover the cost of labor, equipment and material to Install Foundation for 39' Rifler in Building 110 Sections B42

NET AMT

52.0000-4200 NOTICE OF WATERVLIET ARSENAL INFORMATION/REQUIREMENTS (Dec 2014) (ACC-WRN(WVA)):

IMPORTANT DELIVERY/QUALITY REQUIREMENTS:

ALL OFFERORS MUST CAREFULLY REVIEW THE DELIVERY REQUIREMENT IN THE REQUEST FOR QUOTE OR SOLICITATION. WHEN SUBMITTING AN OFFER/BID, PLEASE ENSURE THAT YOU CAN MEET THE DELIVERY SCHEDULE.

ON TIME DELIVERY IS VERY CRITICAL. THEREFORE, YOU MUST ADHERE TO THE DELIVERY REQUIREMENTS INDICATED IN ANY RESULTANT AWARD. FAILURE TO COMPLY WITH THE CONTRACTUAL DELIVERY SCHEDULE, MAY RESULT IN TERMINATION OF THE ORDER OR REQUIRE CONSIDERATION IF THE GOVERNMENT ELECTS TO EXTEND DELIVERY. (NOTE: Non-availability of raw materials, subcontractor issues, scheduling conflicts, should be considered at the time you are submitting your offer/bid. They are not acceptable excuses for failing to meet the delivery after award).

PROVIDING QUALITY PRODUCTS THAT CONFORM TO THE CONTRACT ARE JUST AS IMPORTANT AS MEETING THE REQUIRED DELIVERY. DELIVERY OF NON-CONFORMING PRODUCTS RESULTS IN DELIVERY DELAYS AND INCREASED COSTS TO THE ARSENAL.

PAST PERFORMANCE FOR QUALITY AND DELIVERY MAY BE A MAJOR CONSIDERATION IN MAKING DETERMINATIONS FOR FUTURE CONTRACT AWARDS.

NOTICE: Throughout this document we may use the terms “we” and “you”, the term “we” means the government of the United States of America, and the term “you” means the contractor.

WATERVLIET ARSENAL INFORMATION FOR CONTRACTORS:

“Watervliet Arsenal Information for Contractors” document is incorporated by reference in all solicitations and contracts. The full text version of the instructions is available at Internet address: http://www.wva.army.mil/Documents/Contracting/WAIC.pdf Upon request, the contracting officer will make its full text available.”

POC - CONTRACT SPECIALIST/BUYER: Connie Turner

TELEPHONE NUMBER: 518-266-4631

E-MAIL ADDRESS: connie.j.turner.civ@mail.mil

CONTRACTOR DUNS NUMBER/CAGE CODE/FAX NUMBER:

Please provide the following information for your company.

VENDOR NAME: _________________________

VENDOR POC: __________________________

POC PHONE: ____________________________

E-MAIL ADDRESS (see note below): __________________________

DUNS NUMBER _______________________

CAGE CODE (if known) __________________

TAX ID NUMBER ________________________

VENDOR FAX NUMBER ________________

NOTE: Your e-mail address is required so that in the event you receive the resultant award, we can e-mail it to you. If we experience difficulties with e-mail, it will be datafaxed.

AWCF BULK FUND ____ DOES __X__ DOES NOT APPLY

POSTERS:

Walsh-Healey Act/Service Contract Act. Orders subject to these Acts require contractors to post WH Publication 1313, “Employee Rights on Government Contracts”.

Construction Orders. Orders for construction require contractors to post WH Publication 1321, “Employee Rights under the Davis Bacon Act” and the Office of Federal Contract Compliance poster on “Equal Employment Opportunity is the Law.”

These posters can be accessed electronically at http://www.dol.gov .

Hard copies of the posters will be made available upon request to the contracting officer.

PAYMENTS:

Any vendor that receives an award (except those paid by credit card or accommodation check) can view invoice payments made by DFAS at https://wawf.eb.mil/ using the “my invoice” system. You will be required to register in order to view payments. Payment information is maintained for 120 days from invoice payment. Vendors can find out when invoices have been paid by Electronic Funds Transfer (EFT), etc. This website can save valuable time and frustration over billing questions and it is a free service.

RELEASE OF INFORMATION:

The contractor shall not release or authorize release of DoD specifications; acceptance test results; information involving critical military technology; or any other information in which the DoD maintains proprietary rights, or is otherwise confidential or classified. This restriction includes any endorsement by the Department of Army of a contractor. Release of information under the circumstances referenced above requires the prior written approval of the Contracting Officer responsible for this contract. It is the contractor’s responsibility to be familiar with, and comply with the requirements of Chapter 5, page 22, paragraph 5-48, of AR 360-1 may be found at http://www.apd.army.mil/pdffiles/r360_1.pdf

(END OF CLAUSE)

52.0000-4201 SERVICES/CONSTRUCTION REQUIREMENTS (Jan 2017) (ACC-WRN(WVA)):

SCHEDULE UNIT OF MEASURE NOTE: When "LOT" is stated as a unit of measure it is the equivalent to "JOB".

WORK PERFORMED ON-SITE AT WATERVLIET ARSENAL:

The contractor agrees that each employee working at Watervliet Arsenal will sign the “Contractor Personnel Agreement on Non-Disclosure of Watervliet Arsenal Technology below. Signatures must be received by the Contract Administrator before work may begin and any resultant delay won’t be considered an excusable delay to contract performance as defined in the contract clause “Default”. Additional copies of this Non-Disclosure Statement can be found on the Internet at http://www.wva.army.mil/Documents/Contracting/nondis.pdf

CONTRACTOR PERSONNEL AGREEMENT ON NON-DISCLOSURE

OF WATERVLIET ARSENAL TECHNOLOGY

1. The Undersigned, as an employee of _________________________ (Name of Firm) agrees to the following terms and conditions.

2. Any knowledge gained, as a result of my being permitted on Watervliet Arsenal’s premises, concerning cannon production technology (as defined below) or other technology on any defense item being manufactured or developed at Watervliet Arsenal, will not be released outside of _________________________ (Name of firm) and/or the United States of America (this prohibition includes, but is not limited to, the company’s domestic and foreign subsidiaries, affiliates, etc.), nor will such technology be used to manufacture or assist another in the manufacture of cannon (as described below) or other defense items being manufactured or developed at Watervliet Arsenal, without the written prior approval of Watervliet Arsenal.

3. Definitions:

a. CANNON: is defined as any and all components/parts of a complete assembly consisting of a tube, breech mechanism, tube attachments, muzzle appendages, firing mechanisms, and all integral components. It may also be a component of a weapons system of 40mm Bore or over such as tank guns, towed and self-propelled howitzers, naval guns, mortars and recoilless guns.

b. CANNON PRODUCTION TECHNOLOGY: is defined as the technical data package and manufacturing technology.

(1) TECHNICAL DATA PACKAGE: cannon engineering drawings, specifications and standards.

(2) MANUFACTURING TECHNOLOGY: technical knowledge, documentation, assistance and equipment and machines used an/or useful in the manufacturing of cannon.

(a) TECHNICAL KNOWLEDGE: the know how collected, trade secrets, production experience and special skills necessary for the production of cannon and the technical information and inventions necessary for the manufacture of cannon and relating to the manufacture of cannon.

(b) TECHNICAL DOCUMENTATION: manufacturing technical data comprised of drawings, specifications, schemes, composition, descriptions, methods of calculations, instructions and other information necessary for the manufacture of cannon.

(c) TECHNICAL ASSISTANCE: all assistance required to make practical and economical use of the technology required to manufacture cannon, such as delivery of documentation, training of personnel, instructions, consultations and acquainting of specialists with the most economical method of using this technology in the manufacture of cannon.

(d) EQUIPMENT AND MACHINES: production machines, machine accessories, apparatuses, spare parts and tooling used for cannon manufacture.

JOB SITE AVAILABILITY:

The work site will be available for performance during normal business hours:

Monday through Thursday Business Hours: 7:00 a.m. EST to 4:00 p.m. EST

Friday Business Hours: Every other Friday from 7:00 a.m. EST to 3:00 p.m. EST

Fridays will be staggered with every other Friday being a closed business day. The first Friday of 2018 to be closed is January 5, 2018.

Based on the above, service contractors should call contract/purchase order administrator in advance if service is scheduled for a Friday to determine if the Arsenal will be open for business.

When a federal holiday is normally observed on Friday, the Arsenal may be closed on the preceding Thursday. In this case, contact the contract/purchase order administrator in advance if scheduling service to determine if the Arsenal will be open for business.

Work at other than the above hours won’t be allowed unless the contractor makes an application at least 48 hours in advance and gets written contracting officer approval. No guarantee is made that the job site will be made available other than as stated above.

CONTROL OF FOREIGN VISITORS TO WATERVLIET ARSENAL:

Offerors are advised that any employee or representative of their company who is not a U.S. citizen, (or is representing a foreign company) and is a U.S. citizen), planning on visiting the Watervliet Arsenal for the purpose of attending: bid conferences, bid openings, site visits, engineering services, or any other visit related to this solicitation will be escorted at all times by an arsenal representative while on the installation grounds.

Therefore, offerors must notify the Contracting Officer in advance (a minimum of two [2] weeks) of any proposed visit by a non-U.S. citizen or U.S. citizen representing a foreign firm, to assure proper clearance for entry into the arsenal. Failure to comply, or disclose a foreign national visitor, may subject the Contractor to the penalties set forth in 18 U.S.C.A. Section 1001, Chapter 14.

Due to manpower constraints, Watervliet Arsenal is often unable to provide escort services during contract performance. Therefore, if the resulting contract requires performance on Watervliet Arsenal property, employees, individuals or subcontractors representing the successful offeror who are not U.S. citizens may not, depending on staffing levels and the availability of escorts, be allowed access to the Arsenal for purpose of contract performance.

Be further advised that the inability of the Arsenal to provide escorts resulting in denial of access to Watervliet Arsenal of the aforementioned personnel will not be considered an excusable delay to contract performance as defined in the contract clause “Default” contained in the contract. Therefore, offerors should consider the above contingencies during offer preparation.

CONTRACTOR IDENTIFICATION:

Contractor employees shall identify themselves as contractor personnel by introducing themselves or being introduced as contractor personnel and displaying distinguishing badges or other visible identification for meetings with Government personnel. In addition, contractor personnel shall appropriately identify themselves as contractor employees in telephone conversations and in formal and informal written correspondence, and when working in situations where their actions could be construed as official government acts.

(END OF NOTICE)

Section C - Descriptions and Specifications

52.0000-4020 ACCESS AND GENERAL PROTECTION/SECURITY POLICY AND PROCEDURES (MAR 2015) (ACC-WRN)

a. The contractor and all associated subcontractors’ employees shall comply with applicable installation, facility, and area commander installation and facility access and local security policies and procedures (provided by the Government representative). The contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by the installation Provost Marshal Office, Director of Emergency Services, or Security Office. The contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9 “Personal Identity Verification of Contractor Personnel”) as directed by DoD, HQDA, and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes.

b. For contractors requiring Common Access Card (CAC). Before CAC issuance, the contractor employee requires, at a minimum, a favorably adjudicated National Agency Check with Inquiries (NACI) or an equivalent or higher investigation in accordance with Army Directive 2014-05, The contractor employee will be issued a CAC only if duties involve one of the following: (1) Both physical access to a DoD facility and access, via logon, to DoD networks on-site or remotely; (2) Remote access, via logon, to a DoD network using DoD-approved remote access procedures; or (3) Physical access to multiple DoD facilities or multiple non-DoD federally controlled facilities on behalf of the DoD on a recurring basis for a period of six (6) months or more. At the discretion of the sponsoring activity, an initial CAC may be issued on a favorable review of the FBI fingerprint check and a successfully scheduled NACI at the Office of Personal Management (see clause 52.204-4959 “Trusted Associate Sponsorship System (TASS) Program” (Local ACC-WRN (WVA)).

c. For contractors that do not require CAC, but require access to a DoD facility or installation. Contractor and all associated sub-contractors employees shall comply with adjudication standards, and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05/AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (see “Watervliet Arsenal (WVA) Information For Contractors” incorporated by reference in ACC-WRN (WVA) notice 52.0000-4200, “Notice of Watervliet Arsenal Information/Requirements” and available at: http://www.wva.army.mil/Documents/Contracting/WAIC.pdf ) or at OCONUS locations, in accordance with Status of Forces Agreement and other theater regulations.

(End of Clause)

52.0000-4970 Scope of Work/Submission of Recordable Injuries and Illness Cases (Dec 2012) (ACC-WRN (WVA)) Watervliet Arsenal is pursuing OSHA Voluntary Protection Program (VPP) recognition. The VPP impacts all contractors whose employees cummulatively work more than 1000 hours per quarter within a calendar year at Watervliet Arsenal (herein referred to as “applicable contractors”).

It is the contractor’s responsibility to ensure its employees and managers are in full compliance with OSHA requirements and have a general understanding of VPP. Detailed information on VPP is available on the OSHA website at http://www.osha.gov/dcsp/vpp/index.html . All contractors, whether regularly involved in routine site operations or engaged in temporary projects such as construction or repair, must follow the safety and health rules of Watervliet Arsenal.

Applicable contractors are required to annually submit to Watervliet Arsenal, ATTN: TAWV-XO-S/Safety Office, Bldg. 10, 1 Buffington Street, Watervliet, NY 12189-4000 or email: usarmy.watervliet.tacom.list.wate-safety@mail.mil the following documents (covering the previous calendar year quarters) by 15 January:

· Total Case Incidence Rate (TCIR) - the number of recordable injuries and illness cases per 100 full-time employees that a site has experienced in a given time frame.

· Days Away, Restricted, and/or Transfer Case Incident Rate (DART) - Number of recordable injuries and illness cases per 100 full-time employees resulting in days away from work, restricted work activity, and/or job transfer that a site has experienced in a given time frame.

· OSHA Form 300A Applicable contractors may submit the above immediately following the completion of a quarter, if desired.

(End of Scope of Work)

Section E - Inspection and Acceptance

CLAUSES INCORPORATED BY REFERENCE

Section F - Deliveries or Performance

DELIVERY INFORMATION

SERVICES TEAM

ATTN: CCTA-HDW/BLDG 10

1 BUFFINGTON STREET

WATERVLIET NY 12189-4000

518-266-4535

W911PT

W911PT

W911PT

W911PT

W911PT

W911PT

W911PT

W911PT

Section G - Contract Administration Data

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

Construction Payment Invoice

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

Not Applicable

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF

Other DoDAAC(s)

CONTRACTING OFFICER W911PT

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

N/A

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

N/A

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

Section H - Special Contract Requirements

H2 INSURANCE (Fixed Price Contract)

Pursuant to the requirements of the contract clause titled “Insurance-Work on a Government installation,” the contractor shall obtain and maintain at least the following kinds of insurance and minimum liability coverage during any period of contract performance.

a. Workmen’s Compensation and occupational disease coverage as required by law except that, if this contract is to be performed in a state which does not require or permit private insurance, then compliance with the statutory or administrative requirements in any such state will be satisfactory. The required Workmen’s Compensation Insurance shall extend to cover employers’ liability for accidental bodily injury or death and for occupational disease with a minimum liability limit of $100,000.

b. Comprehensive General Liability Insurance in the minimum limit of $500,000 per occurrence for bodily injury liability.

c. Comphrensive Automotive Liability Insurance with minimum limits of $200,000 per person and $500,000 per occurrence for bodily injury, and a minimum limit of $20,000 per occurrence for property damage.

(end of clause)

FAR 52.228-5, INSURANCE- WORK ON A GOVERNMENT INSTALLATION (JAN 1997) is hereby incorporated by reference as a result of inclusion of H2 INSURANCE.

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.0000-4953 ORDER OF PRECEDENCE (Jan 2006) (ACC-WRN)

(a) In accordance with Army Policy issued 12 Jul 05, subject: Proper Use of Non-Department of Defense (Non-DoD) contracts, DoD unique terms have been added to this order.

(b) In the event a conflict or inconsistency exists between the terms of this order and the terms and conditions of the underlying contract, the terms and conditions of this order shall govern.

(END OF CLAUSE)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM

EMPLOYEES OF WHISTLEBLOWER RIGHTS (APR 2014)

(a) This contract and employees working on this contract will be subject to the whistleblower rights and remedies in the pilot program on Contractor employee whistleblower protections established at 41 U.S.C. 4712 by section 828 of the National Defense Authorization Act for Fiscal Year 2013 (Pub. L. 112-239) and FAR 3.908.

(b) The Contractor shall inform its employees in writing, in the predominant language of the workforce, of employee whistleblower rights and protections under 41 U.S.C. 4712, as described in section 3.908 of the Federal Acquisition Regulation.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts over the simplified acquisition threshold.

(End of clause)

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS OR STATEMENTS (JAN 2017)

Internal confidentiality agreement or statement means a confidentiality agreement or any other written statement that the contractor requires any of its employees or subcontractors to sign regarding nondisclosure of contractor information, except that it does not include confidentiality agreements arising out of civil litigation or confidentiality agreements that contractor employees or subcontractors sign at the behest of a Federal agency.

Subcontract means any contract as defined in subpart 2.1 entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.

Subcontractor means any supplier, distributor, vendor, or firm (including a consultant) that furnishes supplies or services to or for a prime contractor or another subcontractor.

(b) The Contractor shall not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General).

(c) The Contractor shall notify current employees and subcontractors that prohibitions and restrictions of any preexisting internal confidentiality agreements or statements covered by this clause, to the extent that such prohibitions and restrictions are inconsistent with the prohibitions of this clause, are no longer in effect.

(d) The prohibition in paragraph (b) of this clause does not contravene requirements applicable to Standard Form 312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information.

(e) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015, (Pub. L. 113-235), and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions) use of funds appropriated (or otherwise made available) is prohibited, if the Government determines that the Contractor is not in compliance with the provisions of this clause.

(f) The Contractor shall include the substance of this clause, including this paragraph (f), in subcontracts under such contracts.

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014)

The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

52.204-22 ALTERNATIVE LINE ITEM PROPOSAL (JAN 2017)

(a) The Government recognizes that the line items established in this solicitation may not conform to the Offeror's practices. Failure to correct these issues can result in difficulties in acceptance of deliverables and processing payments. Therefore, the Offeror is invited to propose alternative line items for which bids, proposals, or quotes are requested in this solicitation to ensure that the resulting contract is economically and administratively advantageous to the Government and the Offeror.

(b) The Offeror may submit one or more additional proposals with alternative line items, provided that alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation. However, acceptance of an alternative proposal is a unilateral decision made solely at the discretion of the Government. Offers that do not comply with the line items specified in this solicitation may be determined to be nonresponsive or unacceptable.

(End of provision)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 7 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than each specified line item completion date* The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $50 for each calendar day of delay until the individual foundation work is substantially completed (ready for machine installation) or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code - assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (OCT 2015)

``Active duty wartime or campaign badge veteran,'' ``Armed Forces service medal veteran,'' ``disabled veteran,'' ``protected veteran,'' ``qualified disabled veteran,'' and ``recently separated veteran'' have the meanings given at FAR 22.1301.

(b) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-300.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified protected veterans, and requires affirmative action by the Contractor to employ and advance in employment qualified protected veterans.

(c) Subcontracts. The Contractor shall insert the terms of this clause in subcontracts of $150,000 or more unless exempted by rules, regulations, or orders of the Secretary of Labor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUL 2014)

(a) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-741.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified individuals on the basis of disability, and requires affirmative action by the Contractor to employ and advance in employment qualified individuals with disabilities.

(b) Subcontracts. The Contractor shall include the terms of this clause in every subcontract or purchase order in excess of $15,000 unless exempted by rules, regulations, or orders of the Secretary, so that such provisions will be binding upon each subcontractor or vendor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs of the U.S. Department of Labor, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (OCT 2015)

(a) Definitions. As used in this clause--Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply that is--

(i) A commercial item (as defined in paragraph (1) of the definition at 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products. Per 46 CFR 525.1(c)(2), ``bulk cargo'' means cargo that is loaded and carried in bulk onboard ship without mark or count, in a loose unpackaged form, having homogenous characteristics. Bulk cargo loaded into intermodal equipment, except LASH or Seabee barges, is subject to mark and count and, therefore, ceases to be bulk cargo.

Employee assigned to the contract means an employee who was hired after November 6, 1986 (after November 27, 2009, in the Commonwealth of the Northern Mariana Islands), who is directly performing work, in the United States, under a contract that is required to include the clause prescribed at 22.1803. An employee is not considered to be directly performing work under a contract if the employee--

(1) Normally performs support work, such as indirect or overhead functions; and

(2) Does not perform any substantial duties applicable to the contract.

Subcontract means any contract, as defined in 2.101, entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.

Subcontractor means any supplier, distributor, vendor, or firm that furnishes supplies or services to or for a prime Contractor or another subcontractor.

United States, as defined in 8 U.S.C. 1101(a)(38), means the 50 States, the District of Columbia, Puerto Rico, Guam, the Commonwealth of the Northern Mariana Islands, and the U.S. Virgin Islands.

(b) Enrollment and verification requirements.

(1) If the Contractor is not enrolled as a Federal Contractor in E-Verify at time of contract award, the Contractor shall--

(i) Enroll. Enroll as a Federal Contractor in the E-Verify program within 30 calendar days of contract award;

(ii) Verify all new employees. Within 90 calendar days of enrollment in the E-Verify program, begin to use E-Verify to initiate verification of employment eligibility of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section); and

(iii) Verify employees assigned to the contract. For each employee assigned to the contract, initiate verification within 90 calendar days after date of enrollment or within 30 calendar days of the employee's assignment to the contract, whichever date is later (but see paragraph (b)(4) of this section).

(2) If the Contractor is enrolled as a Federal Contractor in E-Verify at time of contract award, the Contractor shall use E-Verify to initiate verification of employment eligibility of--

(i) All new employees. (A) Enrolled 90 calendar days or more. The Contractor shall initiate verification of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section); or

(B) Enrolled less than 90 calendar days. Within 90 calendar days after enrollment as a Federal Contractor in E-Verify, the Contractor shall initiate verification of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section); or

(ii) Employees assigned to the contract. For each employee assigned to the contract, the Contractor shall initiate verification within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever date is later (but see paragraph (b)(4) of this section).

(3) If the Contractor is an institution of higher education (as defined at 20 U.S.C. 1001(a)); a State or local government or the government of a Federally recognized Indian tribe; or a surety performing under a takeover agreement entered into with a Federal agency pursuant to a performance bond, the Contractor may choose to verify only employees assigned to the contract, whether existing employees or new hires.