A21_(Amendment_0003)_W90VN9-16-T-0010.pdf

0010792950

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

Amendment 0003 to Solicitation W90VN9-16-T-0010 includes the follow ing changes:

•Revisions to the specif ications

•Closing date extended to 06 April 2016 *Please note, the amended language is in red underlined italic font.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 23-Mar-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W90VN9-16-T-0010

X 9B. DATED (SEE ITEM 11)

24-Feb-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

23-Mar-2016

CODE

411TH CONTRACTING SUPPORT BRIGADE, KOREA

RCO DAEGU, UNIT #15682

APO AP 96218-5682

UNITED STATES OF AMERICA (THE)

W90VN9 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W90VN9-16-T-0010

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 1449 - CONTINUATION SHEET

SOLICITATION/CONTRACT FORM

The required response date/time has changed from 31-Mar-2016 03:00 PM to 06-Apr-2016 03:00 PM.

The following have been modified:

SPECIFICATIONS

Purchase Description (PR# 10792950) for Upholstery Fabric

1. SPECIFICATIONS:

1.1. Same or Equal (+/- 5% of Dimensions/Capacity /Function) item is acceptable.

1.2. The contractor shall provide all personnel, equipment, tools, materials, supervision, and all other necessities to purchase of upholstery fabric for PR# 10792950 as specified in specification.

The contractor shall complete delivery of the fabric within 60 (sixty) days after award of the contract.

1.3. The contractor shall deliver the upholstery fabric to SP# 47, Daegu storage

1.4. ORIENTATION

1.4.1. The contractor shall provide sampling approval of verifying the fabric with proposal.

1.5. INSPECTION

1.5.1. Type of inspection: Sampling Inspection.

Line Item# 1: Upholstery Fabric (15,000 yards)

A. SPECIFICATIONS:

Upholstery fabric material, Model#: AB427, Samwon Textile Co., Ltd or Equal is acceptable.

>>> Fancy weave fabric material, 100% acrylic fiber, flame retardant (Testing/certification required), treated with Scotchgard or equal (will not stain), waterproof, anti-bacterial and burgundy color. The contractor is required to provide water-proof, flame retardant, stain resistance, and anti-bacteria certification and test results. The Government reserves the right to conduct its own testing.

>>> Construction: Endss56+/-2, Picks54+/-1, Contents: 100% acrylic, Weight: 366gm/0.81Pound+/-2%, Wide:

50"/127cm, Backing: acrylic, Finishing: Anti-bacteria is required (Certification required).

B. Vendor MUST provide a minimum of one (1) sample (1 square yard of upholstery fabric) for technical evaluation of item, with original flame retardant certificates (Testing/certification required) treated with

Scotchgard, water-proof (testing required).

*** Vendor MUST provide any/all original certificates for verification prior to TEB and AFTER AWARD.

No original certificates will constitute non-compliance and will not be honored as acceptable or satisfactory.

C. External Package: Vendor must attach certified external package document on all package prior to housing acceptance.

- 1 roll must contain a minimum of 50 yards of upholstery fabric, packed.

- Vendor must certify external package after award by Housing Staff.

- Attached outside description must be show manufacturer information, manufacture date, delivery date, item description, contract number and amount.

- Design can be changeable, in case of design changed, please coordinate with staff of FMB

52.212-2 EVALUATION--COMMERCIAL ITEMS (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered.

The following factors shall be used to evaluate offers:

Technical

(i) The offeror(s) provided an acceptable 1 (one) square yard of upholstery fabric sample with original flame retardant testing and certification) required in accordance with the attached purchase description. The offered fabric meets all the specifications as identified in the solicitation. The offeror has the capability to deliver the product within 60 days of award. The offer included proof of the following certifications and testing: Waterproofing, Flame Retardant, Scotchgard (or equal) and Anti-Bacteria. The Government reserves the right to conduct its own testing.

(ii) The offeror includes 120 day or more warranty for 15,000 yards of fabric.

(iii) Offerors submitted a list of past or current contracts (including Federal, State, and local government and private industry) of similar effort and magnitude. If the offeror(s) does not have a record of relevant experience the offeror will not receive a favorable or unfavorable evaluation based on experience.

Each item under Technical will be rated using one of the following technical ratings. No award will be made to an offeror whose proposal receives a final rating of “unacceptable” for any item.

Rating Adjective Technical Ratings

Unacceptable Offeror’s quote does not meet requirements and contains one or more deficiencies. Proposal is un-awardable.

Acceptable Offeror’s quote meets requirements and indicates an adequate approach and understanding of the requirements.

Price

(i) The Offeror’s quote will be evaluated on the full understanding of the requirement for the supply and installation to be performed, and is consistent with the technical specifications provided in the RFQ. Offerors shall complete the pricing information for each contract line item identified.

Technical acceptability is approximately equal to price. The Government will evaluate the offers against the minimum technical specifications below to determine whether the offer is acceptable or unacceptable using the ratings and descriptions outlined in the table above.

(b) Options. N/A

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

(End of Summary of Changes)