W81K0020Q0196 8.24.2020.pdf

SEE ADDENDUM

(No Collect Calls)

W81K0020Q0196 24-Aug-2020

b. TELEPHONE NUMBER

254-287-8900

8. OFFER DUE DATE/LOCAL TIME

10:00 AM 25 Sep 2020

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W81K009. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

SHENECQA N. SOARES

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

0011506237

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED ORX

SMALL BUSINESS

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

W40M USA HLTH CONTRACTING ACT

REGIONAL HEALTH CONTRACT OFF CENTRAL

POC: EMERITA TORRES

3551 ROGER BROOK DR BLDG 3600

FORT SAM HOUSTON TX 78234-6200

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

FAX:

TEL: 210-221-5187 SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

1,000

NAICS:

339112

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF74

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Each

POINT OF USE SUPPLY DISPENSING SYSTEM

FFP

POINT OF USE SUPPLY DISPENSING SYSTEM FOR CARL R DARNALL

ARMY MEDICAL CENTER, FORT HOOD, TEXAS, PLEASE SEE 52.212-1

ADDENDUM, 52.212.2 ADDENDUM, AND STATEMENT OF WORK FOR

SALIENT CHARACTERISTICS AND DETAIILS OF THE REQUIREMENT.

FOB: Destination

PURCHASE REQUEST NUMBER: 0011506237

PSC CD: 6515

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Each

RMF REQUIREMENT

FFP

THE AWARDEE MUST COMPLY WITH THE RMF REQUIREMENT IN

EXHIBIT A AND MUST COMPLETE THE RMF ASSESSMENT IN THE

TIMEFRAME STATED ON PAGE 9 OF EXHIBIT A.

FOB: Destination

PSC CD: 6515

NET AMT

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 31-OCT-2020 1 W2M5 CARL R DARNALL ARMY MED C

W2M5 CARL R DARNALL ARMY MED C

SANTE FE AVE

BLDG 36065

FORT HOOD TX 76544-4752

210-808-2837

W45CM1

0002 31-OCT-2020 1 N/A

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government

CLAUSES INCORPORATED BY FULL TEXT

52.212-4 CONTRACT TERMS AND CONDITIONS-- COMMERCIAL ITEMS (OCT 2018)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights (1) within a reasonable time after the defect was discovered or should have been discovered; and

(2) before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes'', as amended (41 U.S.C. 601-613).

Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement or any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include--

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer—System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer--Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.--

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C.

3903) and prompt payment regulations at 5 CFR part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall--

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the--

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C.

7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if--

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on--

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b.

destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C.

chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order: (1) the schedule of supplies/services; (2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause; (3) the clause at 52.212-5; (4) addenda to this solicitation or contract, including any license agreements for computer software; (5) solicitation provisions if this is a solicitation; (6) other paragraphs of this clause; (7) the Standard Form 1449; (8) other documents, exhibits, and attachments; and (9) the specification.

(t) Reserved.

(u) Unauthorized Obligations.

(1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C.

1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an ``I agree'' click box or other comparable mechanism (e.g., ``click-wrap'' or ``browse-wrap'' agreements), execution does not bind the Government or any Government authorized end user to such clause.

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(v) Incorporation by reference. The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of Clause)

ADDENDUM TO 52.212-4

Paragraph 52.212-4(w) is hereby added:

(w) The non-FAR Part 12 discretionary FAR and DFARS clauses included herein are incorporated into this contract either by reference or in full text. If incorporated by reference, see clause 52.252-2 herein for locations where full text can be found.

(End of Addendum)

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions JUN 2020 52.203-3 Gratuities APR 1984 52.203-6 Alt I Restrictions On Subcontractor Sales To The Government

(JUN 2020) -- Alternate I

OCT 1995

52.203-12 Limitation On Payments To Influence Certain Federal Transactions

JUN 2020

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-5 Women-Owned Business (Other Than Small Business) OCT 2014 52.204-7 System for Award Management OCT 2018 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

JUL 2018

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2019

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

JUN 2020

52.213-2 Invoices APR 1984 52.219-16 Liquidated Damages-Subcontracting Plan JAN 1999 52.222-19 Child Labor -- Cooperation with Authorities and Remedies JAN 2020 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-37 Employment Reports on Veterans JUN 2020 52.222-50 Alt I Combating Trafficking in Persons (JAN 2019) Alternate I MAR 2015 52.223-1 Biobased Product Certification MAY 2012 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

JUN 2020

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

JUN 2020

52.228-5 Insurance - Work On A Government Installation JAN 1997 52.229-6 Taxes--Foreign Fixed-Price Contracts FEB 2013 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.242-13 Bankruptcy JUL 1995 52.244-2 Subcontracts JUN 2020 52.246-2 Inspection Of Supplies--Fixed Price AUG 1996

Page 10 of

52.246-16 Responsibility For Supplies APR 1984 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Antiterrorism Awareness Training for Contractors. FEB 2019 252.204-7018 Prohibition on the Acquisition of Covered Defense

Telecommunications Equipment or Services

DEC 2019

252.225-7001 Buy American And Balance Of Payments Program-- Basic DEC 2017 252.225-7021 Trade Agreements--Basic SEP 2019 252.225-7036 Buy American--Free Trade Agreements--Balance of

Payments Program--Basic

DEC 2017

252.225-7048 Export-Controlled Items JUN 2013 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

APR 2019

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

DEC 2018

252.232-7006 Wide Area WorkFlow Payment Instructions DEC 2018 252.232-7010 Levies on Contract Payments DEC 2006 252.232-7017 Accelerating Payments to Small Business Subcontractors--

Prohibition on Fees and Consideration

APR 2020

52.212-1 Instructions to Offerors--Commercial Items JUN 2020

52.212-1 ADDENDUM

52.212-1 ADDENDUM

Offeror shall submit signed and dated quotes to Regional Health Contracting Office - Central office (RHCO-C) no later than the date and time specified in Block 8, of the Standard Form 1449, Solicitation/Contract/Order for Commercial Items. The quote shall have a title page identifying the offeror, the full address, phone and facsimile numbers, points of contact (POCs) of the offeror, the solicitation number and its contents.

Note: Only e-mail offers will be accepted, provided they meet the requirements listed above.

Offer shall clearly identify each part of their quote, as described below.

Administrative:

a. Request for Quotes. The offeror shall include a copy of the completed SF 1449, with the signature and include the name of the offeror, address, phone and fax numbers in Block 17a.

b. The offeror shall submit a completed copy of FAR 52.212-3, Representations and

Certifications

– Commercial Items. If the offeror has completed the Online Representations and Certifications Application (ORCA) at https://www.uscontractorregistration.com/ the offeror shall indicate such on the FAR clause. DFARS 252.212-7000, Offeror Representations and Certifications – Commercial Items. All offerors must be registered in the System for Award Management (SAM) prior to award, and lack of registration shall make an offer ineligible for award.

c. Section C of Exhibit “B” FAR Provision 52.0204-26 must be returned unless the section is completed online in the Reps and Certs to be eligible for award.

Page 11 of

Pricing:

a. Pricing for Requirements. The offeror shall submit quote pricing for all subContract Line Item, Numbers (subCLINs) identified in the Request for Proposal, unless otherwise noted. Include the unit price and the total extended price for each subCLIN.

**Must Provide a breakdown and detailed Price List”.

Price List must include at the minimum:

• Product Name with Product# or ID (Product descriptions)

• Quanitity of Products per location per the Statement of Work (SOW)

• The locations for installation of equipment per the Statement of Work

(SOW)

• Price per Product

• Price per total quantity of Products

• Price for installation (if applicable)

• Price for turnkey (if applicable)

• Price for incidental services (if applicable)

• Total cost of mandatory deliverables, task, products as required by the

Statement of Work (SOW).

All installation, turnkey, or incidental services must be directly related to the supply of equipment being purchased and must meet the Government minimum requirements. All installation, turnkey, or incidental services pricing must be evaluated together with the equipment in order to determine which vendor represents the best value to the Government.

Technical:

a. The technical quote shall be addressed in sufficient written detail for the Government to determine if the offeror’s product(s) adequately perform the specific requirements as stated in 52.212-2 and Statement of Work (SOW).

b. Offeror must meet the salient physical, functional, or performance characteristic specified in this solicitation and clearly describes any modification the offeror plans to make in a product to make it conform to the solicitation requirements.

Mark any descriptive material to clearly show the modification.

c. Offeror must provide documentary proof from a DoD organization that the Offeror currently satisfies the Authority to Operate/Risk Management Framework (ATO/RMF) requirements for the proposed equipment that will access the DoD informational technology system. If the Offeror does not satisfy the ATO/RMF requirements at the time the initial corrective action revised proposals are due, then the Offeror must provide a written plan/explanation (to include a timeline to meet the electronic interface requirements) of how the Offeror would satisfy the ATO/RMF requirements within six months after contract award if the Offeror were to become the awardee. Failing to provide the specified documentary proof or failing to provide an Acceptable plan/explanation (to include a timeline to meet the electronic interface requirements) of how the Offeror would satisfy the required ATO/RMF requirements within six months after contract award shall make the proposal Unacceptable. See Defense Health Agency (DHA) Cyber Logistics (CyberLOG) Cybersecurity/Risk Management

Page 12 of

Framework (RMF) Requirements (dated March 25, 2019) and Department of Defense Instruction 8510.01 (dated March 12, 2014).

(m) The non-FAR Part 12 discretionary FAR, DFARS, AFARS, and LOCAL provisions included herein are incorporated into this solicitation either by reference or in full text. If incorporated by reference, see provision 52.252-1 herein for locations where full text can be found.

(End of Provision)

52.212-2 EVALUATION--COMMERCIAL ITEMS (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

See 52.212-2 Addendum

(b) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

52.212-2 ADDENDUMS

Award will be made using the Lowest- Price Technically-Acceptable (LPTA) source selection process. Award will be made to the responsible offeror on the basis of the lowest evaluated price of proposals meeting or exceeding the acceptability standards for non-cost factors. Award may be made without discussions with offerors (except communications conducted for the purpose of minor clarification). Therefore, each initial offer should contain the offeror's best terms from a technical and price standpoint.

However, the Government reserves the right to conduct discussions if it is later determined by the contracting officer to be necessary.

(a). The Government will award a Purchase Order resulting from this solicitation, to the responsible Request For Quote (RFQ) conforming to the solicitation, with the lowest price technically acceptable. Award will be on an all or none basis. The following evaluation factors shall be used to evaluate offers: Technical Acceptability and Price.

Award will be made using the Lowest-Price, Technically-Acceptable source selection process. The Government will initially list proposals from lowest to highest price. The Government will evaluate the lowest priced proposal first. If that proposal is determined to be Technically Unacceptable, the Government will evaluate the next lowest priced proposal and continue in that manner until a proposal is rated Technically Acceptable. Once a proposal is rated Technically Acceptable, the proposed pricing will be evaluated to determine if the proposed pricing is fair and reasonable. Once a proposal is rated Technically Acceptable and its proposed

Page 13 of pricing has been determined to be fair and reasonable, the evaluation process will stop.

*Section C of Exhibit “B” FAR Provision 52.204-26 must be returned unless the section is completed online in the Reps and Certs to be eligible for award.*

USING THIS PROCEDURE, THE GOVERNMENT MIGHT NOT EVALUATE ALL PROPOSALS

1. Technical Acceptability: Point of Use Supply Dispensing System.

a. Technical Proposal must meet all Mandatory deliverables, task, and

Salient Characteristics in the Statement of Work (SOW) in order to be found “Acceptable”.

b. Clearly identify the items by – (1). Brand name, if any: and

(2). Make or model number:

c. Include descriptive literature such as illustrations, drawings, or a clear reference to previously furnished descriptive data or information available to the Contracting Officer. All installation, turnkey, or incidental services must be directly related to the supply of equipment being purchased and must meet the Governments minimum requirements.

d. Salient Characteristics – Must be able to meet all the mandatory minimum requirements of the Statement of Work (SOW).

e. ATO/RMF Requirement- Must be able to satisfy the Authority to Operate/Risk Management Framework (ATO/RMF) requirements. The Contracting Officer will evaluate the Technical proposal to determine whether the Offeror provided documentary proof from a DoD organization that the Offeror satisfies the Authority to Operate/Risk Management Framework (ATO/RMF) requirements for the proposed equipment that will access the DoD informational technology system. If the Offeror does not submit the required proof that it satisfies the ATO/RMF requirements at the time the initial corrective action revised proposals are due, then the Contracting Officer will evaluate the Technical proposal to determine whether the Offeror provided an Acceptable written plan/explanation (to include a timeline to meet the electronic interface requirements) of how the Offeror would satisfy the required ATO/RMF requirements within six months after contract award if the Offeror were to become the awardee. Failing to provide the specified documentary proof or failing to provide an Acceptable plan/explanation (to include a timeline to meet the electronic interface requirements) of how the Offeror would satisfy the required ATO/RMF requirements within six months after contract award shall make the proposal Unacceptable.

Page 14 of

*The Technical Proposal must meet all mandatory deliverables, task and salient characteristics in the Statement of Work (SOW) in order to be found “Acceptable.”

f. The evaluation factors for Technical Acceptability.

Acceptable: Documentation provided must clearly show the company can meet the minimum requirements of the solicitation.

Unacceptable: Documentation provided does not show the company can meet the minimum requirements of the solicitation.

2. Price: Price will be evaluated by using various price analysis techniques and procedures IAW FAR 15.404-1(b), primarily comparing the proposed prices with the Independent Government Cost Estimate and with the Government's market research.

Evaluation of price will include a determination that the price is fair and reasonable.

Price must be determined to be fair and reasonable. *All installation, turnkey, or incidental services pricing must be evaluated together with equipment in order to determine which vendor represents the best value to the Government.*

(a). Quotes must be submitted no later than the offer due date/local time CST by submitting by e-mailing to: shenecqua.n.soares.civ@mail.mil, Attn: Shenecqua Soares. Questions must be received by 10:00AM CST on 1 September 2020 and answers will be posted by 1:00PM CST on 4 September 2020. No telephonic questions will be accepted, only through email. A signed SF form 1449 with completed pricing data must be submitted. Email is the only acceptable method.

(b). The award decision will be IAW FAR 15.101-2 and based on the lowest price technically acceptable (LPTA) source selection process.

(c). A written notice of award or acceptance of an offer, will be furnished via e-mail to the successful offeror within the time for acceptance specified in the offer and shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

52.204-24

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment.

As prescribed in 4.2105(a), insert the following provision:

REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (AUG 2020)

Page 15 of

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it “does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument” in the provision at 52.204-26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Items.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub.

L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services.”

(d) Representations. The Offeror represents that—

(1) It [] will, [] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds “will” in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that—

It [] does, [] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds “does” in paragraph (d)(2) of this section.

Page 16 of

(e) Disclosures. (1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded “will” in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded “does” in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

Page 17 of

52.204-25

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

As prescribed in 4.2105(b), insert the following clause:

PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE

SERVICES OR EQUIPMENT (AUG 2020)

(a) Definitions. As used in this clause—

Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

Covered foreign country means The People's Republic of China.

Covered telecommunications equipment or services means—

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means—

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

Page 18 of

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled—

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology;

or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services

Page 19 of as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing—

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement.

(1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense,…