B08 - Exhibit A - CDRLs MK158 MK160.pdf
PDF 2 MB Posted
- Attached to
- MK158 MK160 DELAY DETONATORS Federal contract opportunity
- Solicitation number
- W52P1J20R0068
About this file
This document provides a synopsis of Solicitation W52P1J-20-R-0068 issued by the Army Contracting Command - Rock Island for MK158 (17MS) and MK160 (25MS) delay detonators.
The solicitation will be for a firm-fixed price, one-year contract with a firm base quantity and one-year evaluated option. The Army intends to award to the lowest priced technically acceptable offer. The NAICS code is 325920 with a small business size standard of 750 employees. Offerors must be certified through the Joint Certification Program and have a current CAGE code. All individuals accessing the technical data package must have a SAM.BETA account. The estimated issue date is April 4, 2022 with responses due 30 days later. Interested parties should periodically check the SAM website for amendments. Any questions must be submitted in writing by the closing date.
View the file
Other files for this federal contract opportunity
Show all 16
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
CONTRACT DATA REQUIREMENTS LIST
(1 Data Item)
Form Approved OMB No. 0704-
Public reporting burden for this collection of information is estimated to average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget, Paperwork Reduction Project, (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY
TDP TM OTHER
E. CONTRACT / PR NO.
R11A01J94I
F. CONTRACTOR D. SYSTEM/ITEM
DELAY DENTONATOR (17MS), MK158 MOD 0
1. DATA ITEM NO.
A001
2. TITLE OF DATA ITEM
REQUEST FOR VARIANCE (RFV)
3. SUBTITLE
4. AUTHORITY (Data Acquisition Documentation No.)
DI-SESS-80640D
5. CONTRACT REFERENCE
SECTION C SOW
6. REQUIRING OFFICE
FCDD-ACE-SP
7. DD 250 REQ.
LT
9. DIST
STATEMENT
REQUIRED
10. FREQUENCY
ASREQ
12. DATE OF FIRST SUBMISSION
ASREQ
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
8. APP CODE
N/A
11. AS OF DATE
N/A
13. DATE OF
SUBSEQUENT
SUBMISSION
ASREQ
Draft Final
Reg Repro
DATA MUST BE IN GOVERNMENT COMPATIBLE SOFTWARE (i.e., MICROSOFT OFFICE OR PORTABLE DOCUMENT FORMAT (pdf)).
*DISTRIBUTION STATEMENT WILL BE ASSIGNED AND IMPLEMENTED BY
THE DOD CONFIGURATION CONTROL AUTHORITY. DISTRIBUTION
STATEMENT SHOULD BE THE HIGHEST LEVEL OF THE DRAWINGS.
DISTRIBUTION STATEMENT A IS THE LOWEST. FOR EXAMPLE, IF THE
DOCUMENT HAS A DISTRIBUTION STATEMENT A AND D DRAWING,
THEN THE WHOLE SUBMITTAL WILL BE LABELED "D".
THE PREFERRED METHOD FOR SUBMITTAL IS DD FORM 1694 LOCATED
AT www.dtic.mil/whs/directives/infomgt/forms/. SUBMIT ELECTRONICALLY TO usarmy.pica.ccdc-ac.mbx.ecp-document@mail.mil; COPY FURNISH THIS
SUBMITTAL TO THE GOVERNMENT CONTRACTING OFFICE.
ACO 0 1 0
PCO 0 1 0
15. TOTAL 0 2 0
H. DATE
2 Feb 2021
I. APPROVED BY J. DATE
DD FORM 1423-1 FEB 2001 PREVIOUS EDITIONS MAY BE USED. Page 1 of 6 Pages
G. PREPARED BY
K. Mosher, for SDMO, FCDD-ACE-SP
(1 Data Item)
Form Approved OMB No. 0704-
Public reporting burden for this collection of information is estimated to average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget, Paperwork Reduction Project, (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY
TDP TM OTHER
E. CONTRACT / PR NO.
R11A01J94I
F. CONTRACTOR D. SYSTEM/ITEM
DELAY DENTONATOR (17MS), MK158 MOD 0
1. DATA ITEM NO.
A002
2. TITLE OF DATA ITEM
ENGINEERING CHANGE PROPOSAL (ECP)
3. SUBTITLE
4. AUTHORITY (Data Acquisition Documentation No.)
DI-SESS-80639D
5. CONTRACT REFERENCE
SECTION C SOW
6. REQUIRING OFFICE
FCDD-ACE-SP
7. DD 250 REQ.
LT
9. DIST
STATEMENT
REQUIRED
10. FREQUENCY
ASREQ
12. DATE OF FIRST SUBMISSION
ASREQ
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
8. APP CODE
N/A
11. AS OF DATE
N/A
13. DATE OF
SUBSEQUENT
SUBMISSION
ASREQ
Draft Final
Reg Repro
DATA MUST BE IN GOVERNMENT COMPATIBLE SOFTWARE (i.e., MICROSOFT OFFICE OR PORTABLE DOCUMENT FORMAT (pdf)).
*DISTRIBUTION STATEMENT WILL BE ASSIGNED AND IMPLEMENTED BY
THE DOD CONFIGURATION CONTROL AUTHORITY. DISTRIBUTION
STATEMENT SHOULD BE THE HIGHEST LEVEL OF THE DRAWINGS.
DISTRIBUTION STATEMENT A IS THE LOWEST. FOR EXAMPLE, IF THE
DOCUMENT HAS A DISTRIBUTION STATEMENT A AND D DRAWING, THEN
THE WHOLE SUBMITTAL WILL BE LABELED "D".THE PREFERRED METHOD
FOR SUBMITTAL IS DD FORM 1692 LOCATED AT http:// www.dtic.mil/whs/directives/infomgt/forms/. SUBMIT ELECTRONICALLY TO usarmy.pica.ccdc-ac.mbx.ecp-document@mail.mil; COPY FURNISH THIS
SUBMITTAL TO THE GOVERNMENT CONTRACTING OFFICE..
ACO 0 1 0
PCO 0 1 0
15. TOTAL 0 2 0
H. DATE
2 Feb 2021
I. APPROVED BY J. DATE
DD FORM 1423-1 FEB 2001 PREVIOUS EDITIONS MAY BE USED. Page 2 of 6 Pages
K. Mosher for SDMO, FCDD-ACE-SP
DD FORM 1423-1 FEB 2001 PREVIOUS EDITIONS MAY BE USED. Page 3 of 6 Pages
(1 Data Item)
Form Approved OMB No. 0704-
Public reporting burden for this collection of information is estimated to average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget, Paperwork Reduction Project, (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY
TDP TM OTHER
E. CONTRACT / PR NO.
R11A01J94I
F. CONTRACTOR D. SYSTEM/ITEM
DELAY DENTONATOR (17MS), MK158 MOD 0
1. DATA ITEM NO.
A003
2. TITLE OF DATA ITEM
NOTICE OF REVISION (NOR)
3. SUBTITLE
4. AUTHORITY (Data Acquisition Documentation No.)
DI-SESS-80642D
5. CONTRACT REFERENCE
SECTION C SOW
6. REQUIRING OFFICE
FCDD-ACE-SP
7. DD 250 REQ.
LT
9. DIST
STATEMENT
REQUIRED
10. FREQUENCY
ASREQ
12. DATE OF FIRST SUBMISSION
ASREQ
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
8. APP CODE
N/A
11. AS OF DATE
N/A
13. DATE OF
SUBSEQUENT
SUBMISSION
ASREQ
Draft Final
Reg Repro
DATA MUST BE IN GOVERNMENT COMPATIBLE SOFTWARE (i.e., MICROSOFT OFFICE OR PORTABLE DOCUMENT FORMAT (pdf)).
*DISTRIBUTION STATEMENT WILL BE ASSIGNED AND IMPLEMENTED BY
THE DOD CONFIGURATION CONTROL AUTHORITY. DISTRIBUTION
STATEMENT SHOULD BE THE HIGHEST LEVEL OF THE DRAWINGS.
DISTRIBUTION STATEMENT A IS THE LOWEST. FOR EXAMPLE, IF THE
DOCUMENT HAS A DISTRIBUTION STATEMENT A AND D DRAWING, THEN
THE WHOLE SUBMITTAL WILL BE LABELED "D". THE PREFERRED
METHOD FOR SUBMITTAL IS DD FORM 1695 LOCATED AT http:// www.dtic.mil/whs/directives/infomgt/forms/. SUBMIT ELECTRONICALLY TO usarmy.pica.ccdc-ac.mbx.ecp-document@mail.mil; COPY FURNISH THIS
SUBMITTAL TO THE GOVERNMENT CONTRACTING OFFICE.
ACO 0 1 0
PCO 0 1 0
15. TOTAL 0 2 0
H. DATE
2 Feb 2021
I. APPROVED BY J. DATE
DD FORM 1423-1 FEB 2001 PREVIOUS EDITIONS MAY BE USED. Page 4 of 6 Pages
(1 Data Item)
Form Approved OMB No. 0704-
Public reporting burden for this collection of information is estimated to average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget, Paperwork Reduction Project, (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY
TDP TM OTHER
E. CONTRACT / PR NO.
R11A01J94I
F. CONTRACTOR D. SYSTEM/ITEM
DELAY DENTONATOR (17MS), MK158 MOD 0
1. DATA ITEM NO.
A004
2. TITLE OF DATA ITEM
Operations Security (OPSEC) Plan
3. SUBTITLE
4. AUTHORITY (Data Acquisition Documentation No.)
DI-MGMT-80934C
5. CONTRACT REFERENCE
OPSEC SOW
6. REQUIRING OFFICE
AMSJM-FP/G2
7. DD 250 REQ.
XX
9. DIST
STATEMENT
REQUIRED
D
10. FREQUENCY
ONE/R
12. DATE OF FIRST SUBMISSION
ASREQ
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
8. APP CODE
A
11. AS OF DATE
ASREQ
13. DATE OF
SUBSEQUENT
SUBMISSION
ASREQ
Draft Final
Reg Repro
16. REMARKS:
DELETE REFERENCE 'APPLYING OPSEC TO U.S. GOVERNMENT
CONTRACTS'. REPLACE WITH REFERENCE 'SAMPLE ACQUISITIONS
OPSEC PLAN'. 10 CALENDAR DAYS REQUIRED FOR GOVERNMENT
REVIEW AND APPROVAL. *30 CALENDAR DAYS AFTER THE
CONTRACTING OFFICER PROVIDES THE LIST OF KNOWN CRITICAL
INFORMATION (CI)/THREAT INFORMATION. ** RESUBMIT 10
CALENDAR DAYS AFTER GOVERNMENT REVIEW. SUBMIT
ELECTRONICALLY TO usarmy.ria.jmc.mbx.OPSEC-FD@mail.mil.
JMC OPSEC 0 1 0
PCO 0 1 0
15. TOTAL 0 2 0
H. DATE
2 Feb 2021
I. APPROVED BY J. DATE
1. DATA ITEM NO.
17. PRICE
GROUP
A005
18. ESTIMATED
TOTAL PRICE
LT
8. APP CODE
0 1 0
0 1 0
Page: 5 of 6DD Form 1423-1, FEB 2001 Previous editions may be used.
15. TOTAL
G. PREPARED BY
K. Mosher for SDMO, FCDD-ACE-SP
H. DATE
2 Feb 2021
I. APPROVED BY J. DATE
FCDD-ACE-LTP
N/A N/A Reg Repro
ASREQ
16. REMARKS
30 DAYS PRIOR TO FIRST ARTICLE TEST. REPORT TITLE SHALL INCLUDE ITEM NAME AND MODEL
NUMBER OF THE AMMUNITION THAT GOES INTO THE PACKAGE. IF ITEM IS A COMPONENT OF
AMMUNITION, THE AMMUNITION SYSTEM THAT THE ITEM IS USED ON SHALL ALSO BE INCLUDED.
REPORT SHALL BE SUBMITTED ELECTRONICALLY VIA E-MAIL TO
YUEN.H.LAM.CIV@MAIL.MIL AND DAVID.M.WALLS1.CIV@MAIL.MIL SAVED IN RICH TEXT
FORMAT (RTF), ASCII OR PDF FORMAT. SUBMIT EVERY TWO (2) YEARS.
CCDC ARM CTR PACKAGING
N/A
ASREQ ASREQ
a. ADDRESSEE
b. COPIES
11. AS OF DATE
13. DATE OF SUBSEQUENT SUBMISSION
Draft
Final
7. DD 250 REQ
9. DIST
STATEMENT
REQUIRED
10. FREQUENCY 12. DATE OF FIRST SUBMISSION
14. DISTRIBUTION
5. CONTRACT REFERENCE
4. AUTHORITY (Data Acquisition Document
No.)
DI-PACK-81059B SECTION D
6. REQUIRING OFFICE
FCDD-ACE-LTP (RI)
2. TITLE OF DATA ITEM
Performance Oriented Packaging (POP) Test Report
3. SUBTITLE
TDP____________ TM____________ OTHER____________
D. SYSTEM/ITEM
DELAY DENTONATOR (17MS), MK158 MOD 0
E. CONTRACT / PR NO.
R11A01J94I
F. CONTRACTOR
CONTRACT DATA REQUIREMENTS LIST
(1 Data Item)
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services Directorate (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the
Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY
Form Approved
OMB No. 0704-0188
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
Designed using Perform Pro, WHS/DIOR, Aug 96
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
(1 Data Item)
16. REMARKS
C. CATEGORY:
TDP ________ TM _______ OTHER _________________________
Form Approved OMB No. 0704-0188
15. TOTAL
PREVIOUS EDITION MAY BE USED.DD FORM 1423-1, AUG 96 (EG) Page ____ of ____ Pages
A. CONTRACT LINE ITEM NO. B. EXHIBIT
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
H. DATE J. DATEI. APPROVED BY
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (0701-0188), 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
QA CDRL Distribution block - IPT members list Distribution with specific contact information will be provided at Post Award
PQM – Product Quality Manager
PCO – Procuring Contracting Officer
CS – Contract Specialist
QAR – Quality Assurance Representative
PO or PM – Project Officer or Project Manager
AQE – Army Quality Engineer
APO - Army Lead Engineer (Project Officer)
DA – Design Agent (NAVSEA)
PL – Project Lead (NAVAIR)
NQA – Navy Quality Assurance
ME – Material Engineer (NAVAIR)
PE – Program Engineer (Air Force)
AEA – Acquisition Engineering Agent (NAVSEA) GE – Gage Engineer
Production Manager, JMC - Production Manager, Joint Munitions Command
MCEA – Marine Corp Engineering Activity
CDM – Configuration/Data Management (NAVAIR)
WARP - Worldwide Ammunition-Data Repository Program
SAFE - Safe Access File Exchange
FOR GOVERNMENT PERSONNEL FOR THE CONTRACTOR
Item A. Self-explanatory.
Item B. Self-explanatory.
Item C. Mark (X) appropriate category: TDP - Technical Data Package; TM -
Technical Manual; Other - other category of data, such as
"Provisioning,""Configuration Management," etc.
Item D. Enter name of system/item being acquired that data will support.
Item E. Self-explanatory (to be filled in after contract award). Item F. Self-explanatory (to be filled in after contract award). Item G. Signature of preparer of
CDRL.
Item H. Date CDRL was prepared.
Item I. Signature of CDRL approval authority.
Item J. Date CDRL was approved.
Item 1. See DoD FAR Supplement Subpart 4.71 for proper numbering.
Item 2. Enter title as it appears on data acquisition document cited in Item 4.
Item 3. Enter subtitle of data item for further definition of data item (optional entry).
Item 4. Enter Data Item Description (DID) number, military specification number, or military standard number listed in DoD 5010.12-L (AMSDL), or one-time DID number, that defines data content and format requirements.
Item 5. Enter reference to tasking in contract that generates requirement for the data item (e.g., Statement of Work paragraph number).
Item 6. Enter technical office responsible for ensuring adequacy of the data item.
Item 7. Specify requirement for inspection/acceptance of the data item by the
Government.
Item 8. Specify requirement for approval of a draft before preparation of the final data item.
Item 9. For technical data, specify requirement for contractor to mark the appropriate distribution statement on the data (ref. DoDD 5230.24).
Item 10. Specify number of times data items are to be delivered.
Item 11. Specify as-of date of data item, when applicable.
Item 12. Specify when first submittal is required.
Item 13. Specify when subsequent submittals are required, when applicable.
Item 14. Enter addressees and number of draft/final copies to be delivered to each addressee. Explain reproducible copies in Item 16.
Item 15. Enter total number of draft/final copies to be delivered.
Item 16. Use for additional/clarifying information for Items 1 through 15. Examples are: Tailoring of documents cited in Item 4; Clarification of submittal dates in Items
12 and 13; Explanation of reproducible copies in Item 14.; Desired medium for delivery of the data item.
Item 18. For each data item, enter an amount equal to that portion of the total price which is estimated to be attributable to the production or development for the Government of that item of data. These estimated data prices shall be developed only from those costs which will be incurred as a direct result of the requirement to supply the data, over and above those costs which would otherwise be incurred in performance of the contract if no data were required.
The estimated data prices shall not include any amount for rights in data. The
Government's right to use the data shall be governed by the pertinent provisions of the contract.
DD FORM 1423 (BACK)
Estimated Price - Costs to be included under Group I are those applicable to preparing and assembling the data item in conformance with Government requirements, and the administration and other expenses related to reproducing and delivering such data items to the
Government.
b. Group II. Definition - Data which is essential to the performance of the primary contracted effort but the contractor is required to perform additional work to conform to Government requirements with regard to depth of content, format, frequency of submittal, preparation, control, or quality of the data item.
a. Group I. Definition - Data which is not otherwise essential to the contractor's performance of the primary contracted effort (production, development, testing, and administration) but which is required by DD Form
1423.
INSTRUCTIONS FOR COMPLETING DD FORM 1423
Item 17. Specify appropriate price group from one of the following groups of effort in developing estimated prices for each data item listed on the DD Form
1423.
Estimated Price - Costs to be included under Group III are the administrative and other expenses related to reproducing and delivering such data item to the Government.
d. Group IV. Definition - Data which is developed by the contractor as part of his normal operating procedures and his effort in supplying these data to the
Government is minimal.
Estimated Price - Group IV items should normally be shown on the DD
Form 1423 at no cost.
Estimated Price - Costs to be included under Group II are those incurred over and above the cost of the essential data item without conforming to Government requirements, and the administrative and other expenses related to reproducing and delivering such data item to the
Government.
c. Group III. Definition - Data which the contractor must develop for his internal use in performance of the primary contracted effort and does not require any substantial change to conform to Government requirements with regard to depth of content, format, frequency of submittal, preparation, control, and quality of the data item.
6Page 6 of
| CDRL A001 Ammunition Data Card_Ammunition and Expl Tech Data |
| CDRL A002 Engineering Change Proposal ECP |
| CDRL A008 Quality Program Plan |
| CDRL A009 Management Plan-Process Control Plan (PCP) |
| CDRL A010 Critical Char Control Plan CDRL |
| CDRL A011 Critical Plan of Action (CPOA) CDRL |
| CDRL A012 CritSftyItemChar_CritDefRpt-CICLNotifiInvst_RestartRqstCDRL |
| QA_CDRLS_R11A01J941 |
| Distro List |
| Instructions |
R11A01J94I_ppi_CDRL
| TM: |
| TDP: |
| QPP(CDRL#): |
| QPP Exhibit: |
| QPP OTHER: MISC |
| QPP System: |
| QPP DID: A007 |
| QPP TITLE OF DATA ITEM: Quality Program Plan (QPP) |
| QPP SUBTITLE: N/A |
| QPP Authority: DI-QCIC-81722 (Current Revision) |
| QPP CONTRACT REFERENCE: Section: E |
| QPP REQUIRING OFFICE: AMJM-QA |
| QPP DD 250: LT |
| QPP 9 DIST STATEMENT REQUIRED: B |
| QPP FREQUENCY: ONE/R |
| QPP DATE OF FIRST SUBMISSION: 150DAC |
| QPP App Code: A |
| 11 QPP AS OF DATE: N/A |
| QPP DATE OF SUBSEQUENT SUBMISSION: ASREQ |
| QPP Addressee 1: PCO |
| QPP DraftRow1: 0 |
| QPP RegRow1: 1 |
| QPP ReproRow1: 0 |
| QPP Addressee 2: PQM |
| QPP DraftRow2: 0 |
| QPP RegRow2: 1 |
| QPP Remarks: BLK 12: Quality Program Plan (QPP) shall be submitted no later than 150 calendar days after contract award. The Government shall provide response within 30 calendar days of initial submission. If further revisions are necessary, the Contractor shall have 15 calendar days to provide revisions and the Government shall provide response within 15 calendar days. Approval is required prior to first article test (FAT), if FAT is required, or prior to initiation of production. Disposition will be provided by the Procuring Contracting Officer (PCO). |
BLK 13: Submit updates/revisions for review and approval prior to implementation.
BLK 14: Submit via email or SAFE https://safe.apps.mil/
When sending by email, the email subject line shall include the Data Item No., Title of Data Item and Subtitle. This information is found in Blocks 1, 2 and 3 of the CDRL.
Specific email addresses for the distribution list will be provided after contract award.
| QPP ReproRow2: 0 |
| QPP Addressee 3: QAR |
| QPP DraftRow3: 0 |
| QPP RegRow3: 1 |
| QPP ReproRow3: 0 |
| QPP Addressee 4: |
| QPP DraftRow4: |
| QPP RegRow4: |
| QPP ReproRow4: |
| QPP Addressee 5: |
| QPP DraftRow5: |
| QPP RegRow5: |
| QPP ReproRow5: |
| QPP Addressee 6: |
| QPP DraftRow6: |
| QPP RegRow6: |
| QPP ReproRow6: |
| QPP Addressee 7: |
| QPP DraftRow7: |
| QPP RegRow7: |
| QPP ReproRow7: |
| QPP Addressee 8: |
| QPP DraftRow8: |
| QPP RegRow8: |
| QPP ReproRow8: |
| QPP Reg15 TOTAL: 3 |
| QPP number: |
| CCCP Exhibit: |
| A CCCP 0(CDRL#): |
| CCCP OTHER: MGMT |
| CCCP System: |
| E CCCP CONTRACTPR NO: |
| F CCCP CONTRACTOR: |
| CCCP CDRL #: A008 |
| CCCP Authority: DI-MGMT-81986 (Current Revision) |
| CCCP TITLE OF DATA ITEM: Critical Characteristics Control Plan (CCCP) |
| CCCP SUBTITLE: N/A |
| CCCP CONTRACT REFERENCE: Section: E |
| 6 CCCP REQUIRING OFFICE: AMJM-QA |
| CCCP DD 250: LT |
| 17: |
| 18: |
| 9 CCCP DIST STATEMENT REQUIRED: B |
| CCCP FREQUENCY: ANNLY |
| CCCP DATE OF FIRST SUBMISSION: 120DAC |
| CCCP App Code: A |
| 11 CCCP AS OF DATE: N/A |
| CCCP DATE OF SUBSEQUENT SUBMISSION: ASREQ |
| CCCP Addressee 1: PCO |
| DATE: |
| CCCP DraftRow1: 0 |
| CCCPRegRow1: 1 |
| CCCP ReproRow1: 0 |
| CCCP Addressee 2: PQM |
| CCCP DraftRow2: 0 |
| CCCPRegRow2: 1 |
| CCCP ReproRow2: 0 |
| CCCP Remarks: BLK 12: Critical Characteristics Control Plan (CCCP) shall be submitted no later than 120 calendar days after contract award. Government shall provide response within 45 calendar days of initial submission. Disposition of the CCCP will be provided by the procuring contracting officer (PCO). If further revisions are necessary, the contractor shall have 15 calendar days to provide revisions and the Government shall provide a response within 15 calendar days. The CCCP shall be approved prior to first article test (FAT), if FAT is required, or the initiation of production. |
BLK 13: Submit updates/revisions for review and approval prior to implementation. Government shall provide a response within 15 calendar days of receipt and contractor shall response to any comments within 15 calendar days.
BLK 14: Submit via email or SAFE https://safe.apps.mil/
When sending by email, the email subject line shall include the Data Item No., Title of Data Item and Subtitle. This information is found in Blocks 1, 2 and 3 of the CDRL.
Specific email addresses for the distribution list will be provided after contract award.
A CCCP Review Guide is available to assist Contractors on the Public Website (http://www.ardec.army.mil/organizations/QESA/) in the application of the CCCP requirement. The CCCP Review Guide's content, in its entirety, is provided solely for REFERENCE and GUIDANCE PURPOSES ONLY- it is not, nor is it intended to be, contractually binding. Accordingly, the information contained within the CCCP Review Guide is expressly not, nor shall it be construed to be, incorporated either directly or by reference into the terms of the CCCP requirement itself nor into the terms and conditions of any underlying contract which contains the CCCP requirement.
| CCCP Addressee 3: |
| CCCP DraftRow3: |
| CCCPRegRow3: |
| CCCP ReproRow3: |
| CCCP Addressee 4: |
| CCCP DraftRow4: |
| CCCPRegRow4: |
| CCCP ReproRow4: |
| CCCP Addressee 5: |
| CCCP DraftRow5: |
| CCCPRegRow5: |
| CCCP ReproRow5: |
| CCCP Addressee 6: |
| CCCP DraftRow6: |
| CCCPRegRow6: |
| CCCP ReproRow6: |
| CCCP Addressee 7: |
| CCCP DraftRow7: |
| CCCPRegRow7: |
| CCCP ReproRow7: |
| CCCP Addressee 8: |
| CCCP DraftRow8: |
| CCCPRegRow8: |
| CCCP ReproRow8: |
| Draft15 TOTAL: 0 |
| CCCP Reg15 TOTAL: 2 |
| Repro15 TOTAL: 0 |
| A DATE: |
| number: |
| CCCP number: |
This is the start of the file's text. The full file is on GovTribe.
File details come from the government source that posted it. Updated .