RFQ_SP330017Q5012.pdf

SP3300-17-Q-5012

NOTICE TO OFFERORS

1. This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in

Subpart 12.6 – Streamlined Procedures for Evaluation and Solicitation for Commercial Items in conjunction with the Federal Acquisition Regulations (FAR) Subpart 13.5 Simplified Procedures for

Certain Commercial Items. This announcement constitutes the only Solicitation; quotes are being requested and a written solicitation will not be issued. This is a Request for Quotation (RFQ) and the RFQ number is SP3300-17-Q-5012.

2. This notice incorporates provisions and clauses in effect through Federal Acquisition Circular (FAC) 2005-

95 effective 19 JAN 2017 and Defense Federal Acquisition Regulation Supplement (DFARS) DPN

20161222 edition and Defense Logistics Acquisition Directive (DLAD) Current to Revision 5 and

PROCLTR 2017-11. The complete text of any of the clauses and provisions may be accessed in full text at http://farsite.hill.af.mil.

3. This RFQ is being issued to establish a Firm-Fixed Price (FFP) contract to install and make operational a pallet packing conveyor system in Building 499. The Contractor shall provide, install, test and make operable the conveyor system. The Contractor shall train government personnel to maintain the conveyor system located at DLA Distribution Red River, Texas (DDRT). The above shall be performed in accordance with the

Technical Specifications provided at Attachment 1. Any award resulting from this RFQ will be issued on a

Standard Form (SF) 1449.

4. This RFQ is solicited as an unrestricted basis. The North American Industry Classification System

(NAICS) code for this project is 333922 and the size standard is 500 employees.

5. PERIOD OF PERFORMANCE: In accordance with Attachment 1, Technical Specifications, Final

Acceptance of this requirement is 270 days after contract award.

6. All work will be performed inside of normal duty hours which are Monday through Friday 0700 to 1530.

The Contractor will furnish training to DDJC personnel in the operation and maintenance of all equipment furnished.

7. A technical package is required from all offerors and shall be provided with the quotes. Please pay special attention to the Instructions to Offerors starting on page 39. The instructions require various items of documentation to submitted with offeror quote. The evaluation criteria, starting on page 45, explains how offeror’s quote will be evaluated for acceptability/unacceptability.

8. SITE VISIT:

Reference Page 38 of the RFQ.

9. QUOTE DUE DATE, TIME, METHOD:

QUOTES ARE DUE ON JUNE 7, 2017 at 1:00 PM EST. THE QUOTES MUST ARRIVE IN THE

ACQUISITION SPECIALISTS’S EMAIL INBOX BY THE DATE AND TIME DETAILED ON PAGE

40. QUOTES MUST BE SUBMITTED IN ELECTRONIC FORMAT (EMAIL) ONLY. ELECTRONIC

COPIES SHALL BE EMAILED TO THE ACQUISITION SPECIALIST AT Mogen.gilson@dla.mil. IT IS

HIGHLY ENCOURAGED THAT OFFEROR(S) CONFIRM THAT THE QUOTE HAS BEEN

RECEIVED BY THE ACQUISITION SPECIALIST. FURTHERMORE, THE FILE SIZE MAY NOT

EXCEED 10 MEGABYTES IN ANY ONE EMAIL. IF THE QUOTE EXCEEDS THE 10 MEGABYTES,

THEN THE QUOTE MAY BE BROKEN DOWN IN ORDER TO BE RECEIVED SUCCESSFULLY.

ALL PARTS OF THE QUOTE MUST BE RECEIVED BY THE DATE AND TIME OF QUOTE

CLOSING DEADLINE TO BE CONSIDERED RESPONSIVE.

10 INVOICING AND PAYMENT:

Invoicing and Payment will be made via Wide Area WorkFlow. See DFAR Clauses 252.232-7006 and

252.232-7003 found on page 15 of the RFQ.

http://farsite.hill.af.mil/

11 INSURANCE:

Any required insurance certifications must be submitted to the Contracting Officer within ten (10) days after the date of contract award as referenced in FAR 52.228-5.

12. Contractor shall type company name, address, and CAGE code exactly as it appears in the DoD System for

Award Management (SAM) Database.

Company Name: _________________________________

Company Address: _________________________________

Telephone: _________________________________

CAGE Code: _________________________________

EMAIL __________________________________

13. SYSTEM FOR AWARD MANAGEMENT – A prospective awardee shall be registered in the System for Award Management (SAM) database prior to award, during performance and through final payment of any contract resulting from this Quote. Offerors may obtain information on registration and annual confirmation requirements via the Internet at http://www.sam.gov.

Failure to register in the SAM database will make an offeror ineligible for award.

14. MARK CONTRACT NUMBER ON ALL CORRESPONDENCE

Contractor must mark the contract or purchase order number on all paperwork and shipments. The order number must appear on the exterior of the shipment. Failure to follow these instructions will hold up payment to you and could result in the return of merchandise at your expense.

15. WARRANTY: Notwithstanding inspection and acceptance by the Government or any provision of this contract concerning the conclusiveness thereof, the Contractor shall warranty for a period of one year after final acceptance by the Government all systems and services provided under this contract.

During the warranty period and in the event the Contractor is not able to make remedial action himself, contractor shall make arrangements to have the work accomplished. The Contractor shall furnish to the

Contracting Officer’s Representative (COR), the name and address of the selected individual and/or firm who can arrive at DDJC within 24 hours after notification of breakdown of the system to perform the necessary repairs.

16. PARTIAL PAYMENTS

a. Partial payments IAW FAR 32.102(d) are authorized for CLIN 0001-0006 of this contract as specified below:

*Payment 1 - For completion of demolition and for actual cost of materials delivered and accepted by the

Contracting Officer Representative (COR) to be validated with supplier invoices.

*Payment 2 - For 50% completion of the total project

*Payment 3 - For completion with operational testing

*Final payment – Shall be made upon final acceptance of all deliverables by the

Government and completion of final operation testing.

The total value of partial payments 1 – 3 shall not exceed 90 percent of the total dollar amount of CLINs 0001-0006.

http://www.sam.gov/

b. All material and work covered by the partial payments shall, at the time of payment, become the sole property of the Government, but this shall not be construed as-

(1) Relieving the contractor from the sole responsibility for all material and work upon which payments have been made for the restoration of any damaged work; or

(2) Waiving the right to the Government to require the fulfillment of all the terms of the contract.

C .Final payment of CLINs 0001-0006 shall be made upon final acceptance of all deliverables by the Government and completion of final operational test.

d. The final payment of CLINs 0001-0006 shall be the total price less partial

Payments 1 - 3.

17. SINGLE AWARD: The Government intends to make one firm-fixed-price award as a result of this solicitation. The total Contract price for CLINs 0001-0006 will be evaluated for lowest price if the quote has been evaluated as technically acceptable.

18. OPTIONAL CLINs

CLINs 0002-0006 are optional CLINs and may be exercised up to 120 days after contract award.

19. QUESTIONS SHALL BE SUBMITTED IN WRITING VIA EMAIL TO Mogen.gilson@dla.mil BY

1:00 PM EST MAY 24, 2017.

20. LIQUIDATED DAMAGES: Yes

52.211-11 -- Liquidated Damages -- Supplies, Services, or Research and Development (Sept 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of

$200.00 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default -- Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default --

Fixed-Price Supply and Service clause in this contract.

(End of Clause)

The Government is not soliciting for the “same old way” of doing business. The Government encourages quotes that will achieve savings through innovative processes. Furthermore, DLA Distribution personal are working to eliminate unnecessary requirements and negotiating for a reduction in supplies/material prices.

Therefore, your assistance is requested in reducing prices and improving our buying processes.

Unit of Issue: EA = Each, UN = Unit, LT= Lot mailto:Mogen.gilson@dla.mil

ATTACHMENTS:

Attachment 1 – Technical Specifications

Attachment 2 – Drawings

Attachment 3 – AutoCad Drawings

Attachment 4 – Contract Data Requirements List and Data Item Descriptions

Attachment 5 – Small Business Participation Plan (SBPP)

Attachment 6 - Subcontracting Plan Template

Attachment 7 – Past Performance Questionnaire

Attachment 8 – SF1449

SCHEDULE FOR SUPPLIES AND SERVICES

ITEM NO SUPPLIES/SERVICES QTY UNIT UNIT PRICE TOTAL PRICE

0001 All labor, material, engineering and 1 UNIT $__________ $___________ equipment for Pallet System

Replacement for bldg. 499 accordance with Attachment 1, Technical Specifications SECTION 1.4 –

COMPLETE 270 DAYS AFTER AWARD

0002 All labor, material, engineering, 1 UNIT $__________ $___________ and equipment to demo and dispose of existing system in accordance with Attachment 1, Technical Specifications SECTION 1.4–

(OPTION)

AWARD UP TO 120 DAYS AFTER AWARD

0003 All labor, material, engineering, 1 UNIT $__________ $___________ and equipment to include installation of AWOS in accordance with Attachment 1, Technical Specifications

SECTION 1.4 – (OPTION),

0004 All labor, material, engineering, 1 UNIT $__________ $___________ and equipment to include to repair towlines

18 and 19. in accordance with Attachment 1, Technical Specifications SECTION 1.4 –

(OPTION),

0005 All labor, material, engineering, 1 UNIT $__________ $___________ and equipment to include to install ergonomic workstations in accordance with

Attachment 1, Technical Specifications SECTION 1.4 –

0006 One year preventative/Corrective

Maintenance for the entire system. 1 UNIT $__________ $___________ in accordance with Attachment 1, Technical Specifications SECTION 1.4 –

000 0007 Contract Data Requirements List 1 LOT *NSP *NSP

(CDRL)

accordance with DD Forms 1423 and

DD Forms1664, Attachment 3, (NOTE: ALL COST FOR DATA MUST BE INCLUDED

IN THE PRICE OF THE SYSTEM.

CONTRACTOR SHALL NOT PRICE THESE ITEMS SEPARATELY.)

A001 Installation Schedule DI-S-SAT1

A002 Dwg. Eng. $ Associated List DI-E-SAT2

A003 Dwg. Eng. $ Associated List DI-E-SAT2

A004 Commercial Manual DI-E-SAT1

A005 Commercial Manual DI-E-SAT1

A006 Contractor Officer Representative List DI-E-SAT11

A007 Training Manual and Schedules DI-P-SAT

A008 Power Requirements DI-P-SAT1

*NSP = Not Separately Priced

TOTAL CONTRACT PRICE - CLINs 0001-0007 $________________________

Addenda to FAR 52.212-4 CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS

(JAN 2017)

Additional applicable clauses incorporated by reference:

FAR 52.203-3 -- GRATUITIES (APR 1984)

FAR 52.203-12 -- LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (OCT 2010)

FAR 52.203-17 -- CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND

REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS

(APR 2014)

FAR 52.204-4 -- PRINTED OR COPIED DOUBLE-SIDED ON POSTCONSUMER FIBER

CONTENT PAPER (MAY 2011)

FAR 52.204-7 -- SYSTEM FOR AWARD MANAGEMENT (OCT 2016)

FAR 52.204-9 -- PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL

(JAN 2011)

FAR 52.208-9 -- CONTRACTOR USE OF MANDATORY SOURCES OF SUPPLY AND

SERVICES (MAY 2014)

FAR 52.222-1 -- NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (FEB 1997)

FAR 52.222-37 -- EMPLOYMENT REPORTS ON VETERANS (FEB 2016)

FAR 52.223-5 -- POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (MAY

2011)

FAR 52.223-10 -- WASTE REDUCTION PROGRAM (MAY 2011)

FAR 52.227-1 -- AUTHORIZATION AND CONSENT (DEC 2007)

FAR 52.228-5 -- INSURANCE – WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

FAR 52.232-17-- INTEREST (MAY 2014)

FAR 52.232-39 -- UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

FAR 52.232-40 -- PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS (DEC 2013)

FAR 52.237-2 -- PROTECTION OF GOVERNMENT BUILDINGS, EQUIPMENT, AND

VEGETATION (APR 1984)

FAR 52.242-13 -- BANKRUPTCY (JUL 1995)

FAR 52.242-15 -- STOP WORK ORDER (AUG 1989)

FAR 52.246-2 -- INSPECTION OF SUPPLIES – Fixed-Price (AUG 1996)

FAR 52.246-16 -- RESPONSIBILITY FOR SUPPLIES (APR 1984)

FAR 52.253-1-- COMPUTER GENERATED FORMS (APR 1984)

DFARS 252.203-7000 -- REQUIREMENTS RELATING TO COMPENSATION OF FORMER

DOD OFFICIALS (SEP 2011)

DFARS 252.203-7003 -- AGENCY OFFICE OF THE INSPECTOR GENERAL (DEC 2012)

DFARS 252.203-7005 -- REPRESENTATION RELATING TO COMPENSATION OF FORMER

DOD OFFICIALS (NOV 2011)

DFARS 252.204-7000 -- DISCLOSURE OF INFORMATION (OCT 2016)

DFARS 252.204-7003 -- CONTROL OF GOVERNMENT PERSONNEL WORK PRODUCT (APR

1992)

DFARS 252.204-7012 -- SAFEGUARDING COVERED DEFENSE INFORMATION AND CYBER

INCIDENT REPORTING (OCT 2016)

DFARS 252.204-7015 -- NOTICE OF AUTHORIZED DISCLOSURE OF INFORMATION FOR

LITIGATION SUPPORT (MAY 2016)

DFARS 252.205-7000 -- PROVISION OF INFORMATION TO COOPERATIVE AGREEMENT

HOLDERS (DEC 1991)

DFARS 252.209-7004 -- SUBCONTRACTING WITH FIRMS THAT ARE OWNED OR

CONTROLLED BY THE GOVERNMENT OF A COUNTRY THAT IS A

STATE SPONSOR OF TERRORISM (OCT 2015)

DFARS 252.211-7003 – ITEM UNIQUE IDENTIFICATION AND VALUATION (MAR 2016)

DFARS 252.219-7003-- SMALL BUSINESS SUBCONTRACTING PLAN (DOD CONTRACTS)—

BASIC (AUG 2016)

DFARS 252.223-7006 -- PROHIBITION ON STORAGE, TREATMENT, AND BASIC DISPOSAL

OF TOXIC OR HAZARDOUS MATERIALS (SEP 2014)

DFARS 252.223-7008 -- PROHIBITION OF HEXAVALENT CHROMIUM (OCT 2016)

DFARS 252.225-7001 -- BUY AMERICAN AND BALANCE OF PAYMENTS PROGRAM -BASIC

(DEC 2016)

DFARS 252.225-7012 -- PREFERENCE FOR CERTAIN DOMESTIC COMMODITIES (DEC

2016)

DFARS 252.225-7021 -- TRADE AGREEMENTS—BASIC (DEC 2016)

DFARS 252.225-7048 -- EXPORT CONTROLLED ITEMS (JUNE 2013)

DFARS 252.226-7001 -- UTILIZATION OF INDIAN ORGANIZATIONS, INDIAN-OWNED

ECONOMIC ENTERPRISES AND NATIVE HAWAIIAN SMALL

BUSINESS CONCERTNS (SEP 2004)

DFARS 252.227-7015 -- TECHNICAL DATA—COMMERCIAL ITEMS (FEB 2014)

DFARS 252.227-7037-- VALIDATION OF RESTRICTIVE MARKINGS ON TECHNICAL DATA

(SEP 2016)

DFARS 252.232-7003 -- ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND

RECEIVING REPORTS (JUN 2012)

DFARS 252.232-7010 -- LEVIES ON CONTRACT PAYMENTS (DEC 2006)

DFARS 252.243-7002 -- REQUESTS FOR EQUITABLE ADJUSTMENT (DEC 2012)

DFARS 252.245-7004 -- REPORTING, REUTILIZATION, AND DISPOSAL (SEP 2016)

DLAD 52.204-9000 -- CONTRACTOR PERSONNEL SECURITY REQUIREMENTS (JUL

2015)

The following clauses are hereby incorporated by full text:

FAR 52.211-8 TIME OF DELIVERY (JUN 1997)

(a) The Government requires delivery to be made according to the following schedule:

0001 270 DADC

OPTION

OPTION 90 DAY AFTER AWARD

0003 OPTION 120 DAYS AFTER AWARD

0004 OPTION 120 DAYS AFTER AWARD

0005 OPTION 30 DAYS AFTER AWARD

0006 OPTION 365 DAYS AFTER ACCEPT.

0007 270 DADC

KEY: DADC = Days After Date of Contract

(End of Clause)

FAR 52.212-5 – CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS – COMMERCIAL ITEMS (JAN 2017)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017)

(section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77, 108-78 (19 U.S.C.

3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

_XX__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct

1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun

2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment

Act of 2009).

__XX_ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L.

109-282) (31 U.S.C. 6101 note).

___ (5) [Reserved]

___ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L.

111-117, section 743 of Div. C).

__XX_ (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (31 U.S.C. 6101 note).

_XX__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41

U.S.C. 2313).

___ (10) [Reserved]

___ (11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).

___ (ii) Alternate I (Nov 2011) of 52.219-3.

_XX__ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014)

(if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a).

___ (ii) Alternate I (Jan 2011) of 52.219-4.

___ (13) [Reserved]

___ (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644).

___ (ii) Alternate I (Nov 2011).

___ (iii) Alternate II (Nov 2011).

___ (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

___ (ii) Alternate I (Oct 1995) of 52.219-7.

___ (iii) Alternate II (Mar 2004) of 52.219-7.

_XX__ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)).

_XX__ (17) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637 (d)(4)).

___ (ii) Alternate I (Nov 2016) of 52.219-9.

___ (iii) Alternate II (Nov 2016) of 52.219-9.

___ (iv) Alternate III (Nov 2016) of 52.219-9.

___ (v) Alternate IV (Nov 2016) of 52.219-9.

___ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

_XX__ (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)).

XX___ (20) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

___ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C.

657f).

___ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)).

___ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-

Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

___ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns

Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

__XX_ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

_XX__ (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126).

_XX__ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

_XX__ (28) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

_XX__ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

_XX__ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

_XX__ (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

___ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O.

13496).

_XX__ (33) (i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

___ (ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627).

___ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in

22.1803.)

__XX_ (35) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (Oct 2016). (Applies at $50 million for Quotes and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for

Quotes and resultant contracts issued after April 24, 2017).

Note to paragraph (b)(35): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

___ (36) 52.222-60, Paycheck Transparency (Executive Order 13673) (Oct 2016).

___ (37) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008)

(42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun

2016) (E.O.13693).

___ (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners

(Jun 2016) (E.O. 13693).

___ (40) (i) 52.223-13, Acquisition of EPEAT® -Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and

13514

___ (ii) Alternate I (Oct 2015) of 52.223-13.

___ (41) (i) 52.223-14, Acquisition of EPEAT® -Registered Television (Jun 2014) (E.O.s 13423 and 13514).

___ (ii) Alternate I (Jun 2014) of 52.223-14.

___ (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

___ (43) (i) 52.223-16, Acquisition of EPEAT® -Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514).

___ (ii) Alternate I (Jun 2014) of 52.223-16.

_XX__ (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011) (E.O.

13513).

___ (45) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

___ (46) 52.223-21, Foams (Jun 2016) (E.O. 13696).

___ (47) (i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

___ (ii) Alternate I (Jan 2017) of 52.224-3.

___ (48) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

___ (49) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43).

___ (ii) Alternate I (May 2014) of 52.225-3.

___ (iii) Alternate II (May 2014) of 52.225-3.

___ (iv) Alternate III (May 2014) of 52.225-3.

___ (50) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_XX__ (51) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

___ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016)

(Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

___ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

___ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C.

5150).

__XX_ (55) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505), 10

U.S.C. 2307(f)).

___ (56) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

_XX__ (57) 52.232-33, Payment by Electronic Funds Transfer— System for Award Management (Jul 2013) (31

U.S.C. 3332).

___ (58) 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management (Jul 2013)

(31 U.S.C. 3332).

___ (59) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

___ (60) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

___ (61) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(12)).

___ (62) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx

1241(b) and 10 U.S.C. 2631).

___ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

___ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495)

___ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67.).

___ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C.

chapter 67).

___ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple

Year and Option Contracts) (May 2014) (29 U.S.C.206 and 41 U.S.C. chapter 67).

___ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014)

(29 U.S.C. 206 and 41 U.S.C. chapter 67).

___ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67).

___ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Requirements (May 2014) (41 U.S.C. chapter 67).

___ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658).

___ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

___ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792).

___ (11) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792).

___ (12) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph

(d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017)

(section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iv) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17.

(v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vi) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

(vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(ix) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

(x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xi) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67).

(xii) (A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627).

(xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Requirements (May 2014) (41 U.S.C. chapter 67)

(xv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989).

(xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

(xvii) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (Oct 2016) (Applies at $50 million for

Quotes and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for Quotes and resultant contracts issued after April 24, 2017).

Note to paragraph (e)(1)(xvii): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xviii) 52.222-60, Paycheck Transparency (Executive Order 13673) (Oct 2016).

(xix) 52.222-62, Paid sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

(xx) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xxi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section

862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxiii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx

1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

FAR 52.217-7 – – Option for Increased Quantity- Separately Priced Line Item (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within 120 Days after Contract Award. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

(End of Clause)

FAR 52.252-2 – CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil

DFARS 252.201-7000 -- CONTRACTING OFFICER’S REPRESENTATIVE (DEC 1991)

(a) Definition. “Contracting officer's representative” means an individual designated in accordance with subsection

201.602-2 of the Defense Federal Acquisition Regulation Supplement and authorized in writing by the contracting officer to perform specific technical or administrative functions.

(b) If the Contracting Officer designates a contracting officer's representative (COR), the Contractor will receive a copy of the written designation. It will specify the extent of the COR's authority to act on behalf of the contracting officer. The COR is not authorized to make any commitments or changes that will affect price, quality, quantity, delivery, or any other term or condition of the contract.

DFARS 252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area

WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and

Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

http://farsite.hill.af.mil/ http://www.acq.osd.mil/dpap/dars/dfars/html/current/252232.htm https://www.acquisition.gov/ https://wawf.eb.mil/

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training

Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data

Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

____________ 2 –in – 1 Invoice____________________

(Contracting Officer: Insert applicable document type(s).

Note: If a “Combo” document type is identified but not supportable by the Contractor’s business systems, an

“Invoice” (stand-alone) and “Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in

WAWF, as specified by the contracting officer.

__________________N/A__________________________________________

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable.”)

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC

SL4701

Issue By DoDAAC

SP3300

Admin DoDAAC

SP3300

Inspect By DoDAAC N/A

Ship To Code N/A

Ship From Code N/A

Mark For Code N/A

Service Approver (DoDAAC) N/A

Service Acceptor (DoDAAC)

SB3200

Accept at Other DoDAAC N/A

LPO DoDAAC N/A

DCAA Auditor DoDAAC N/A https://wawf.eb.mil/

Other DoDAAC(s) N/A

(*Contracting Officer: Insert applicable DoDAAC information or “See schedule” if multiple ship to/acceptance locations apply, or “Not applicable.”)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the e-mail address identified below in the “Send

Additional Email Notifications” field of WAWF once a document is submitted in the system.

_____TIM.FLYNN@dla.mil ______________________

________mogen.gilson@dla.mil________________________________________________________

(Contracting Officer: Insert applicable email addresses or “Not applicable.”)

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s

WAWF point of contact.

__________________________daniel.walker@dla.mil ___________________________

(Contracting Officer: Insert applicable information or “Not applicable.”)

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

The following provisions are incorporated by reference:

FAR 52.217-5—EVALUATION OF OPTIONS (JUL 1990)

DFARS 252.204-7004 -- ALTERNATE A, SYSTEM FOR AWARD MANAGEMENT (FEB 2014)

DFARS 252.204-7008 -- COMPLIANCE WITH SAFEGUARDING COVERED DEFENSE INFORMATION

CONTROLS (OCT 2016)

The following provisions are hereby incorporated by full text:

FAR 52.209-7 – INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013)

(a) Definitions. As used in this provision—

“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceeding at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award

Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [_] has [_] does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

FAR 52.216-1 – TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed Price contract resulting from this RFQ.

(End of Provision)

FAR 52.219-1—SMALL BUSINESS PROGRAM REPRESENTATIONS (OCT 2014)

(a) Definitions. As used in this provision--

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

“Service-disabled veteran-owned small business concern”--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) “Service-disabled veteran” means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and the size standard in paragraph (b) of this provision.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States, and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13 CFR 124.106) by individuals who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Veteran-owned small business concern” means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned small business concern” means a small business concern--

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the

United States.

(b)

(1) The North American Industry Classification System (NAICS) code for this acquisition is

_____________333922____________ [insert NAICS code].

(2) The small business size standard is _500 EMPLOYEES____________ [insert size standard].

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(c) Representations.

(1) The offeror represents as part of its offer that it [_] is, [_] is not a small business concern.

(2) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(3) of this provision.] The offeror represents as part of its offer that—

(i) It [_] is, [_] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(4)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: _________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a women-owned small business concern eligible under the WOSB Program in

(c)(4) of this provision.] The offeror represents as part of its offer that--

(i) It [_] is, [_] is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(5)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: _____________.]

Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a veteran-owned small business concern.

(7) [Complete only if the offeror represented itself as a veteran-owned…