SF 1442.pdf

REPAIR SUBSTATION

NAICS: 237130

The Small Business Size Standard is $39,500,000.00 The magnitude of construction is betw een $500,000 to 1,000,000 The contract duration is 120 days after notice to proceed. This project is set aside 100% for Small Businesses.

Persons intending on bidding this project should attend the Pre-Bid Conf erence/Site Visit. See Section 00 21 00 f or specif ic registration information and details. Solicitation and all information, notices, amendments, for this solicitation w ill be posted at https://sam.gov. Funds are not presently available for this contract.

Aw ard w ill be made to the responsible bidder w hose bid conforms to the Invitation for Bids and is most advantageous to the Government considering only price and price related factors.

X

SEAN CONNOLLY 603-225-1226

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

31-May-2022

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______30 calendar days and complete it w ithin ________120 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________30 Jun 2022 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USPFO NH 157 MISSION SUPPORT CONTRACTING

302 NEWMARKET ST BLDG 145

PORTSMOUTH NH 03801-2886

W50S8A

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W50S8A22B5204 54

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Planning and Design

FFP

Conduct site investigation to plan all aspects of installation of a Substation IAW the SOW. Provide a design to the New Hampshire National Guard IAW SOW section 1.1.1.

FOB: Destination

PSC CD: J030

NET AMT

0002 1 Job Demolition

FFP

Remove and dispose of the failed transformer and any associated components notrequired to install the replacement transformer, in accordance to Federal and New Hampshire Department of Environmental Services regulations.

0003 1 Job Installation

FFP

Replace the existing 3 MVA transformer with a new 3 MVA unit. Make all line, load, controls, and any other connections to provide a full, safe, and properly functioning system.

0004 1 Job Substation and Materials

FFP

Provide the Government a Bill of Materials for Substation and all materials related to the demolition and installation. This is to ensure the Government has a record of materials used for the Substation.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 120 dys. ANP 1 F8N3CE

AUTUMN RICKER

302 NEWMARKET STREET

NEWINGTON NH 03801-0157

603-430-2384

F8N3CE

0002 120 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0003 120 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0004 120 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

Section 00 21 00 - Instructions

INSTRUCTIONS

TABLE OF CONTENTS

SOLICITATION, OFFER, AND AWARD SF 1442 and SF 1442 BACK

SECTION 00 10 00 – SOLICITATION

SECTION 00 21 00 – INSTRUCTIONS

SECTION 00 21 13 – SUPPLEMENTARY INSTRUCTIONS TO BIDDERS

SECTION 00 30 00 – AVAILABLE INFORMATION

SECTION 00 45 00 – REPRESENTATIONS & CERTIFICATIONS

SECTION 00 70 00 – CONDITIONS OF THE CONTRACT

SECTION 00 73 00 – SUPPLEMENTARY CONDITIONS

ATTACHMENT 1 – Statement of Work ATTACHMENT 2- Drawing – Substation As-builts ATTACHMENT 2- Drawing – Oil Containment

SECTION 00 21 00 NOTES

NOTES

1. All information relating to this IFB, including pertinent changes/amendments and information will be posted on web site: http://www.SAM.gov.

2. Facsimile transmission of bid is not authorized. Electronic submission of bids will NOT be accepted.

3. All information relating to this IFB, including pertinent changes/amendments and information will be posted on web site: http://www.SAM.gov. For security reasons, all potential offerors, plan rooms and printing companies are required to be registered in the GSA System for Award Management (SAM) database. Firms can register via the SAM internet site at https://www.sam.gov/portal/public/SAM/. Interested bidders are required to submit their representations and certifications at the same site.

4. A complete bid package must contain the following:

(a) Offer, Standard Form (SF) 1442 front and back signed

(b) Section 00010 Line Items- all items must be priced

(c) A Bid Bond and Power of Attorney is required along with the bid on the due date. The following is an alternative due to COVID changes, along with Policy Alert 020-084.

“A copy of the bond and POA may be submitted with the proposal, with the original signed copy with Seal to be submitted no later than June 30th, 2022. The bid bond must be on a SF24 form. Rejection of a bid bond shall be in accordance with FAR 28.101-4 Noncompliance with bid guarantee requirements.

(d) Section 00 45 00, Representations and Certifications, completed and return only additional certifications found in this section In addition, the offeror must have entered current and complete data within the past year in Online Representations and Certifications at www.sam.gov.

(e) When completing the “Offeror” portion of the SF 1442 (Blocks 14 – 20), an official having the authority to contractually bind the company must sign the SF 1442 in accordance with FAR 4.102.

One copy of the SF1442 is required to have an original signature.

(f) All amendments to the solicitation must be acknowledged.

(g) Mark the front of the envelope with the following: “BID No. W50S8A-22-B-5204”, and the Name and Address of Bidder. See Block 13A of SF 1442 for required number of copies.

5. Joint Venture Requirements - Parties wishing to propose as a joint venture must submit, with the Pro Forma documents, an executed copy of the joint venture agreement. The joint venture agreement shall be executed in accordance with FAR 4.102(d). Each joint venture partner shall submit evidence satisfactory to the Contracting Officer that its Board of Directors has approved its participation in the joint venture or by an instrument of similarly binding character in the case of an unincorporated entity. Offerors are reminded that to obtain an award the awardee, to include a joint venture, must be registered in the System for Award Management (SAM) database. Applicable to set-aside solicitations: Joint Ventures must meet applicable size standards (See FAR Subpart 19.1). Submit with the proposal any size determination for the Joint Venture entity received from the Small Business Administration. A Joint Venture where-in one party is not a small business may be referred to the Small Business Administration ( IAW FAR 19.302 (b)) to determine eligibility. All questions regarding Joint Ventures must be directed to the Small Business Administration (SBA) and not the Contracting Officer.

End of Section 00 21 00

Section 00 22 13 - Supplementary Instructions to Bidders

SUPPLEMENTARY INSTRUCTIONS

SUPPLEMENTARY INSTRUCTIONS

1. INSTRUCTIONS TO BIDDERS:

1.1. You are invited to submit a bid in response to our Invitation for Bids (IFB) entitled W50S8A-22-B-5204 entitled Repair Substation at Pease ANGB, NH.

1.2. As a result of this solicitation, the Government intends to award a Firm Fixed Price (FFP) contract resulting from this solicitation to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantageous to the Government, considering only price.

1.3. This solicitation is set-aside 100% for small business.

2. NOTICE OF PRE-BID CONFERENCE AND SITE VISIT:

2.1. A pre-bid conference will be conducted on Friday, June 10, 2022 at 09:00 AM EST for the purposes of briefing on the bid requirements and answering questions regarding this solicitation.

This conference will be held at the New Hampshire Air National Guard, Joint Contracting Conference Room, Bldg. 145, Pease ANGB, NH. Interested Contractors are highly encouraged to attend the pre-bid conference and are encouraged to invite their potential subcontractors. The site visit will be held following the conference.

2.2. Due to security conditions, all offerors must register to attend this conference and site visit.

Email the following information for all attendees to the following addresses:

sean.m.connolly1.mil@mail.mil and william.j.cole68.mil@army.mil.

Firm Name and Telephone Number Visitor’s Name and Driver’s License Citizenship

2.3. This information must be provided in advance, not later than 2 business days prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. Even if you have access to the base you must register to ensure adequate seating. The furnishing of the above information is voluntary; however, your failure to furnish all or part of the requested information may result in the Government’s denial of your access to the pre-proposal conference. This information will be provided to the Base Security Forces who will authorize your entrance to the site.

2.4. Visitors must be escorted onto base through the Installation’s Contractor Entry Gate prior to arrival. The Contractors & Visitors will meet in the parking lot right outside the Contractor Gate and once all Contractors have arrived and signed-in, a Government person will escort everyone through the Contractor Entry Date. You will be required to present a Valid Driver’s License information upon arrival. Any of the above information furnished by you is protected under the Privacy Act and shall not be released unless permitted by law and/or you have consented to such.

2.5. Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitation is amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

2.6. A record of the conference shall be made and furnished to all prospective bidders via posting at http://www.SAM.gov. The record will include minutes of the meeting, including questions (on a non-attribution basis) and answers.

3. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS:

3.1. Submit all questions on a word document, in the format shown below, by email. Do NOT contact AE or Engineering personnel directly. Doing so will only delay your answer. All questions must come through the Contracting Office.

Subject Line: Reference No. SOLICITATION W50S8A-22-B-5202 Email: Scott.L.Ballweg.civ@mail.mil and william.j.cole68.mil@army.mil

PRE-BID INQUIRY FORMAT

Date of Bid Inquiry:

From: Company Name:

Address:

Phone Number: Fax Number:

Email address:

Bid Inquiry: (Please clearly state your question) (If sent via an attachment word docs are preferred to facilitate posting of answers to the master Q&A document.)

1.

2.

3.

4.

3.2. Any explanation desired by an offeror regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach bidders before the submission of their bid.

3.3. All questions and requests for information (RFI) must be received NO LATER THAN

Wednesday, June 15, 2022 by COB. OFFERORS ARE STRONGLY ENCOURAGED TO

SUBMIT QUESTIONS EARLY IN THIS PROCESS.

3.4. Any changes to the drawings, specifications, etc. will be issued in the form of an amendment.

However, any answers that clarify or provide an interpretation to the drawings, specifications, etc. will NOT be posted via amendment but rather as a response to the RFI on SAM.gov at http://SAM.gov.

3.5. Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of bids.

3.6. For security reasons, all technical and engineering data related to this solicitation will be distributed using the System Award Management (SAM.gov). SAM.gov is a web- based dissemination tool designed to safeguard acquisition-related information for all Federal agencies.

Interested bidders/offerors must register with SAM before accessing the system. SAM registration requires the following information:

3.7. Amendments, if/when issued will be posted to http://SAM.gov for electronic downloading. This will normally be the only method of distributing amendments prior to closing; therefore, it is the offerors responsibility to check the website periodically for any amendments to the solicitation.

Websites are occasionally inaccessible due to various reasons.

4 BID REPOSITORY AND BID OPENING:

4.1 The bid opening will occur at the time and date specified in Block 13 of the SF1442 Portsmouth

Armory, 801 McGee Drive, Portsmouth NH. All interested offerors and their major subcontractors are encouraged to attend the bid opening.

4.2 Bid Repository

4.2.1 The Bid Respository is provided for hand carried bids and is located at Portsmouth Armory, 801 McGee Drive, Portsmouth NH. Bid repository will be established at 0900.

Hand carried bids must be deposited in the repository prior to the time established for opening of bids. Late receipt of bids due to entry delays may not be deemed excusable and the Contracting Officer may declare the bid “late” in accordance with FAR 14.304.

4.3 Mail Bids:

4.3.1 All mailed bids must be received prior to the time and date specified in Block 13 of the

SF 1442 at 302 Newmarket St, Building 145, Portsmouth, NH 03801 ATTN: Scott Balleg. Late receipt of bids due to delays in shipping may not be deemed excusable and the Contracting Officer may declare the bid “late” in accordance with FAR 14.304.

5 WAGE DETERMINATION:

5.1 Davis Bacon Wage Rates are applicable to this project. Current prevailing wage determination(s) at time of issuance of solicitation are NH20200022, dated March 18, 2022, Rockingham County in New Hampshire, as shown below in section 00 73 00.

6 BID PREPARATION EXPENSES AND PRE-CONTRACT COSTS:

6.1 This IFB does not commit the Government to pay costs incurred in preparation and submission of bids or for other costs incurred prior to award of a formal contract.

7 CLAUSES:

7.1 Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

7.2 Clauses and provisions in this document may not appear in consecutive order.

7.3 REMOVAL OF SECTIONS AT TIME OF AWARD: Sections 00 21 00, 00 21 13, and 00 45 00 will be physically removed as a result of an award, but will be deemed to be incorporated by reference in that award.

8 DISPOSITION OF UNSUCCESSFUL BIDS:

8.1 In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful bids including the bid bonds. The Government will destroy extra copies of unsuccessful bids. No destruction certificate will be provided.

9 OFFERORS QUALIFICATIONS:

9.1 To establish its responsibility, the apparent low bidder may be requested by the Government prior to award, to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial and bonding resources and plant available to be used in performing the work. This action may be requested to determine if the contractor is responsible.

Section 00 30 00 - Available Information

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-22 Alternative Line Item Proposal JAN 2017 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

252.204-7008 Compliance With Safeguarding Covered Defense Information Controls

OCT 2016

252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements MAR 2022

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed-Price contract resulting from this solicitation.

(End of provision)

52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (SEP 2021)

(a) Definitions. As used in this provision--

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

Small business concern--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (b) of this provision.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

Small disadvantaged business concern, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States, and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13 CFR 124.106) by individuals who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

Veteran-owned small business concern means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

Women-owned small business concern means a small business concern--

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

(b)(1) The North American Industry Classification System (NAICS) code for this acquisition is [insert NAICS code].

(2) The small business size standard is [insert size standard].

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce (i.e., nonmanufacturer), is 500 employees if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(c) Representations. (1) The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small business concern. (2) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ___ ] is, [ ___ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(3) of this provision.] The offeror represents as part of its offer that--

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(4)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___ --.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a women-owned small business concern eligible under the WOSB Program in (c)(4) of this provision.] The offeror represents as part of its offer that--

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(5)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ___ --.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a veteran-owned small business concern.

(7) [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(6) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a service-disabled veteran-owned small business concern.

(8) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(8)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ___ --.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Notice. Under 15 U.S.C. 645(d), any person who misrepresents a firm's status as a business concern that is small, HUBZone small, small disadvantaged, service-disabled veteran-owned small, economically disadvantaged women-owned small, or women-owned small eligible under the WOSB Program in order to obtain a contract to be awarded under the preference programs established pursuant to section 8, 9, 15, 31, and 36 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall—

(1) Be punished by imposition of fine, imprisonment, or both;

(2) Be subject to administrative remedies, including suspension and debarment; and

(3) Be ineligible for participation in programs conducted under the authority of the Act.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

4% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is New Hampshire, Rockingham County, city of Newington.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3 Million whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Scott Ballweg, 302 Newmarket St, B145, Portsmouth NH 03803.

Protests to NG Protest Decision Authority shall be filed at:

National Guard Bureau

Office of the Director of Acquisitions

ATTN: NGB-AQ-O

111 S. George Mason Dr.

Arlington, VA 22204 Email: ng.ncr.ngb-arng.mbx.ngb-task-order-ombudsman@mail.mil

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting: see solicitation section 00 22 13 part 3.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Federal Acquisition Regulation Supplemnt (DFARS) (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00 45 00 - Representations and Certifications

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.239-7098 (Dev) Prohibition on Contracting to Maintain or Establish a Computer Network Unless Such Network is Designed to Block Access to Certain Websites - Representation.

(Deviation 2021-O0003)

APR 2021

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2022)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237130.

(2) The small business size standard is $39,500,000.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $92,319, the provision with its Alternate II applies.

(D) If the acquisition value is $92,319 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

X (i) 52.204-17, Ownership or Control of Offeror.

X (ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying…