S02 - 36C25221B0001 585-19-119.pdf

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION 3. DATE ISSUED PAGE OF PAGES

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014) STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within ____________ calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES NO

a. Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________ (hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than _______________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

1 53

36C25221B0001 X

09-28-2020

585-21-1-6985-0001

585-19-119

36C252

Department of Veterans Affairs Great Lakes Acquisition Center (GLAC) 115 S 84th Street, Suite 101

Milwaukee WI 53214-1476

Great Lakes Acquisition Center (GLAC) Department of Veteran Affairs 115 S 84th Street, Suite 101

Donita Grace 414-844-4860

Project 585-19-119 Upgrade Lighting Controls Construction at the Oscar G Johnson VA Medical Center in Iron Mountain, MI

Contractor shall completely prepare site for building operations, including demolition and removal of existing structure and furnish labor and materials and perform work for the Install Led Lighting project as required by drawings and specifications. This project includes: replacement of existing interior light fixtures to LED type in building 1, 2, 8, 10, and 19. Existing exterior light fixtures are to be replaced with LED type fixtures at buildings 8 and 11.

Diming controls to be added within building 1. All work shall be performed in accordance with all current NFPA, federal, state, and local authorities.

NAICS: 238210 - Electrical Contractors and Other Wiring Installation - Small Business Size Standard of $16.5 Million.

Project Magnitude: Between $250,000 and $500,000.

In accordance with VAAR 819.7003(b), at the time of submission of bid, the bidder must represent that it is a SDVOSB concern, a small business concern under the NAICS code assigned to the acquisition, and is CVE verified for eligibility in the VIP database.

NOTICE: VA and/or a third party (support contractor) will require access to Contractor records to assess Contractor compliance with the limitations on subcontracting requirements included at VAAR 852.219-10.

See VA Notice of Total Service-Disabled Veteran-Owned Small Business Set-Aside (JUL 2019) (DEVIATION).

SITE VISIT INFORMATION: Thursday, October 8, 2020 at 10:00 AM CST Oscar G Johnson VA Medical Center 325 East H. Street Iron Mountain, MI 49801 Point of Contact: Michael Seda (906) 774-3300 x32224 or michael.seda@va.gov

All bidders are responsible for monitoring and downloading any amendments from the "beta_SAM" website listed below:

https://beta.sam.gov/search?index=opp

ALL QUESTIONS REGARDING THIS SOLICITATION SHALL BE SENT TO THE FOLLOWING INDIVIDUALS:

Donita Grace -- Donita.Grace@va.gov Kristi Kluck --- Kristi.Kluck3@va.gov

10 150

X 52.211-10

X 7

Zero (0) 1:00 PM

10-28-2020

X

14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO 10 U.S.C. 2304(c)( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

PHONE: FAX:

28. NEGOTIATED AGREEMENT 29. AWARD Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code)

(Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

(Type or print)

(4 copies unless otherwise specified)

(Type or print) (Type or print)

(Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror)

(To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

SEE ATTACHED BID SCHEDULE.

36C252

Department of Veterans Affairs Great Lakes Acquisition Center (GLAC) 115 S 84th Street, Suite 101

Department of Veterans Affairs Financial Services Center PO Box 149971

Austin TX 78714-9971 877-353-9791 512-460-5540

BID SCHEDULE

SOLICITATION: 36C25221B0001

PROJECT: 585-19-119 UPGRADE LIGHTING CONSTRUCTION

Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for the Install LED Lighting project; VA project number 585-19-119 as required by drawings and specifications. The project includes, but not be limited to, replacement of existing interior light fixtures to LED type in building 1, 2, 8, 10, 12, and 19. Dimming controls also to be added within areas of building 1. Existing exterior light fixtures are to be replaced with LED type fixtures at buildings 8 and 11. All work shall be performed in accordance with all current NFPA, federal, state, and local authorities at the Oscar G. Johnson VA Medical Center, Iron Mountain, MI.

Base bid, Lump Sum: $_________________________ LUMP

SUM

NOTICE TO BIDDERS: Award will be made to the responsible bidder who submitted the lowest responsive bid.

ADDITIONAL PRIME CONTRACTOR INFORMATION - Safety or Environmental Violations and Experience Modification Rating Information

Information provided below shall be applicable to Project 585-19-119 Upgrade Lighting Controls Construction:

1.) All Bidders/Offerors shall submit information pertaining to their past Safety and Environmental record. The information must contain a certification that the bidder/offeror has no more than three (3) serious, or one (1) repeat or one (1) willful OSHA or any EPA violation(s) in the past three years. If such certification cannot be made, a Bidder/Offeror shall explain why and submit as much information as possible regarding the circumstances of its past safety and environmental record, including the number of EPA violations and/or the number of serious, repeat, and/or willful OSHA violations, along with a detailed description of those violations.

2.) All Bidders/Offerors shall submit information regarding their current Experience Modification Rate (EMR). This information shall be obtained from the Bidder’s/Offeror’s insurance carrier and be furnished on the insurance carrier’s letterhead. If a Bidder/Offeror’s EMR is above 1.0, Bidder/Offeror must submit a written explanation of the EMR from its insurance carrier furnished on the insurance carrier’s letterhead, describing the reasons for the elevated EMR and the anticipated date the EMR may be reduced to 1.0 or below.

3.) Self-insured contractors or other contractors that cannot provide their EMR rating on insurance letterhead must obtain a rating from the National Council on Compensation Insurance, Inc. (NCCI) by completing/submitting form ERM-6 and providing the rating on letterhead from NCCI. Note: Self insured contractors or other contractors that cannot provide EMR rating on insurance letterhead from the states or territories of CA, DE, MI, NJ, ND, OH, PA, WA, WY, and PR shall obtain their EMR rating from their state run worker’s compensation insurance rating bureau.

4.) If the NCCI cannot issue an EMR because the Bidder/Offeror lacks insurance history, Bidder/Offeror shall submit a letter indicating so from its insurance carrier furnished on the insurance carrier’s letterhead, and include a letter from the NCCI indicating that is has assigned Bidder/Offeror a Unity Rating of 1.0.

5.) The above information, along with other information obtained from Government systems, such as the OSHA and EPA online inspection history databases, will be used to make an initial Determination of Responsibility.

6.) This requirement is applicable to all subcontracting tiers, and prospective prime contractors are responsible for determining the responsibility of their prospective subcontractors.

Pre-Award Contractor Safety and Environmental Record Evaluation Form

Information provided below is current and applicable to Solicitation 36C25221B0001 for Project 585-19-119 Upgrade Lighting Construction

Company Name: ______________________________________________

Address: _____________________________________________________

Telephone: ______________________ Fax: ________________________

Email: _______________________________________________________

Contact: ______________________________________________________

1. Utilizing your OSHA 300 Forms, please complete the following information:

Category 2017 2018 2019 2020 Number of man hours (jobsite and office).

Number of cases involving days away from work, restricted activity, or both (Column H and I of OSHA 300).

Days away, restricted, or transferred rate (# of days away, restricted, or transferred cases x 200,000/# of man hours) (DART Rate).

Number of serious, willful, or repeat violations from OSHA within the last 3 years. Please attach explanation for any violations.

Please attach copies of the following documents: OSHA 300 and 300a Forms. These forms can be accessed through the OSHA publications search page:

http://www.osha.gov/pls/publications/publication.html.

2. Provide six-digit North American Industrial Classification System (NAICS) Code for this acquisition: __________________________________

3. Who administers your company’s Safety and Health Program?

4. Company’s Insurance Experience Modification Rate (EMR):

http://www.osha.gov/pls/publications/publication.html

CONTRACTOR INFORMATION

Name of Company: ___________________________________________

Address: ___________________________________________

City, State, Zip Code: ___________________________________________

Name(s) and Title of Company 1.) ________________________________________

Legal Binding Authority(s) 2.) ________________________________________

3.) _______________________________________

4.) _______________________________________

Primary Point of Contact: ___________________________________________

E-Mail Address: ___________________________________________

Address: ___________________________________________

City, State, Zip Code: ___________________________________________

Phone No: ___________________________________________

Fax No: ___________________________________________

TAX ID Number: ___________________________________________

DUNS Number: ___________________________________________

Experian Number: ___________________________________________

Past Performance Point of Contact (within your company), include name and email address:

INSTRUCTIONS, CONDITIONS AND OTHER STATEMENTS TO

BIDDERS/OFFERORS

Contracting Officer’s Special Instructions as follows:

FLU SHOT REQUIREMENT:

VHA Directive 1192 issued August 10, 2020 requires all contractor personnel to receive annual seasonal influenza vaccinations or obtain an exemption for medical or religious reasons.

Compliance with this directive is a requirement of this contract. A copy of VHA Directive

1192.01 is available at this link:

https://www.va.gov/vhapublications/ViewPublication.asp?pub_ID=8948.

SOLICITATION RFI’S AND QUESTIONS:

Requests for information or clarifications to solicitation documents shall be submitted to the pre-award contracting officer, at Kristi.Kluck3@va.gov, for action no later than ten (10) calendar days prior to the IFB closing date as shown in Block 13 of the Standard Form 1442.

After compiling all required information, submit the information in accordance with the "Bid Due Date" in Block 13 of the SF 1442. Return the original and specified number of copies to the issuing office listed in Block 8 of the SF 1442.

INQUIRIES:

Inquiries and all correspondence concerning this solicitation document should be submitted in writing to the Contracting Officer/Contract Specialist. YOU ARE INSTRUCTED SPECIFICALLY

TO CONTACT ONLY THE CONTRACT SPECIALIST ISSUING THE SOLICITATION ABOUT

ANY ASPECT OF THIS REQUIREMENT PRIOR TO CONTRACT AWARD.

CONTRACTOR'S SIGNATURE:

In accordance with Federal Acquisition Regulations Part 4, contractual documents (e.g. bids, proposals, awards, modifications, etc.) shall be completed and signed by the Contractor as follows:

(a) Individuals. Signed by the individual.

(b) Individual doing business as a firm. Signed by that individual, and the signature shall be followed by the individual's typed, stamped, or printed name and the words, "an individual doing business as __________________ (insert name of firm)".

https://www.va.gov/vhapublications/ViewPublication.asp?pub_ID=8948 mailto:Kristi.Kluck3@va.gov

(c) Partnership. Signed in the partnership name. Prior to award, provide list of all partners and designate which partners have authority to bind the partnership.

(d) Corporations. Signed in the corporate name followed by the word "by" and the signature, and title of the person authorized to sign. Prior to award, provide list of individuals who have authority to bind the corporation.

(e) Joint Ventures. Signed by each participant in the joint venture in the manner prescribed in

(a) through (d) above.

(f) Agents. When an agent is to sign the contract, other than as stated in paragraph (a) through (e) above, the agent's authorization to bind the principal must be established by evidence satisfactory to the contracting officer.

2.1 UNUSUALLY SEVERE WEATHER CONDITIONS:

(a) Claims by the contractor for delay attributed to unusually severe weather in accordance with FAR 52.249-10 must be supported by climatological data covering the period and the same period for the 10 preceding years. When the weather in question exceeds in intensity or frequency the 10-year average, the excess experienced shall be considered "unusually severe."

Comparison shall be on a monthly basis. Whether or not unusually severe weather in fact delays the work will depend upon the effect of weather on the branches of work being performed during the time under consideration. Normal weather conditions in this region typically include freezing temperatures, snowstorms, rainfall, and other weather events that could delay certain exterior construction activities. Normal weather conditions are to be considered when bidding and preparing schedules.

(END OF SECTION)

INFORMATION REGARDING BIDDING MATERIAL, BID GUARANTEE

AND BONDS

(a) This solicitation & all associated bid documents are available to interested parties in electronic file format from https://beta.sam.gov/search?index=opp. No hard copy documents will be provided by the government.

(b) A bid guarantee is required in an amount not less than 20 percent of the bid price but shall not exceed $200,000. Failure to furnish the required bid guarantee in the proper form and amount, by the time set for opening of bids, will result in rejection of the bid in all cases except those listed in FAR 28.101-4, and may be cause for rejection even then.

(c) The bidder to whom a contract is awarded will be required to furnish a Payment Bond, on form SF 25A, and a Performance Bond, on form SF 25. Each bond shall be issued for a penal sum equal to the value of the awarded contract. Copies of forms SF 25 and 25A may be obtained from the Contracting Officer upon request.

DESCRIPTION OF WORK:

PROJECT 585-19-119 Upgrade Lighting Controls Construction

Cost Range: $250,000 - $500,000.00.

https://beta.sam.gov/search?index=opp

2.2 52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE

REPORTING (AUG 2020)

(a) Definition. As used in this provision—

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity by unique location; or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

(b) The Offeror shall provide its CAGE code with its offer with its name and location address or otherwise include it prominently in its proposal. The CAGE code must be for that name and location address. Insert the word "CAGE" before the number. The CAGE code is required prior to award.

(c) CAGE codes may be obtained via—

(1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision).

(2) The DLA Commercial and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the Offeror does not otherwise register in SAM, an Offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil.

(3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity's country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity's country is not a member of NATO or a sponsored nation. Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm.

(d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil.

http://www.sam.gov/ https://cage.dla.mil/ https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx http://www.nato.int/structur/AC/135/main/links/contacts.htm https://cage.dla.mil/

(e) When a CAGE code is required for the immediate owner and/or the highest-level owner by Federal Acquisition Regulation (FAR) 52.204-17 or 52.212-3(p), the Offeror shall obtain the respective CAGE code from that entity to supply the CAGE code to the Government.

(f) Do not delay submission of the offer pending receipt of a CAGE code.

(g) If the solicitation includes FAR clause 52.204-2, Security Requirements, a subcontractor requiring access to classified information under a contract shall be identified with a CAGE code on the DD Form 254. The Contractor shall require a subcontractor requiring access to classified information to provide its CAGE code with its name and location address or otherwise include it prominently in the proposal. Each location of subcontractor performance listed on the DD Form 254 is required to reflect a corresponding unique CAGE code for each listed location unless the work is being performed at a Government facility, in which case the agency location code shall be used. The CAGE code must be for that name and location address. Insert the word "CAGE" before the number. The CAGE code is required prior to award.

(End of Provision)

2.3 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT

2018)

(a) Definitions. As used in this provision—

"Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

"Federal contracts and grants with total value greater than $10,000,000" means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

"Principal" means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of Provision)

2.4 52.209-13 VIOLATION OF ARMS CONTROLS TREATIES OR

AGREEMENTS—CERTIFICATION (JUL 2020)

(a) This provision does not apply to acquisitions below the simplified acquisition threshold or to acquisitions of commercial items as defined at FAR 2.101.

(b) Certification. [Offeror shall check either (1) or (2).]

_____ (1) The Offeror certifies that—

(i) It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President’s or Secretary of State’s determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C.

2593a). The report is available via the internet at https://www.state.gov/bureaus-offices/under-https://www.sam.gov/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; and

(ii) No entity owned or controlled by the Offeror has engaged in any activity that contributed to or was a significant factor in the President’s or Secretary of State’s determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available via the internet at https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; or

_____ (2) The Offeror is providing separate information with its offer in accordance with paragraph (d)(2) of this provision.

(c) Procedures for reviewing the annual unclassified report (see paragraph (b)(1) of this provision). For clarity, references to the report in this section refer to the entirety of the annual unclassified report, including any separate reports that are incorporated by reference into the annual unclassified report.

(1) Check the table of contents of the annual unclassified report and the country section headings of the reports incorporated by reference to identify the foreign countries listed there.

Determine whether the Offeror or any person owned or controlled by the Offeror may have engaged in any activity related to one or more of such foreign countries.

(2) If there may have been such activity, review all findings in the report associated with those foreign countries to determine whether or not each such foreign country was determined to be in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or to be not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. For clarity, in the annual report an explicit certification of noncompliance is equivalent to a determination of violation. However, the following statements in the annual report are not equivalent to a determination of violation:

(i) An inability to certify compliance.

(ii) An inability to conclude compliance.

(iii) A statement about compliance concerns.

(3) If so, determine whether the Offeror or any person owned or controlled by the Offeror has engaged in any activity that contributed to or is a significant factor in the determination in the report that one or more of these foreign countries is in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. Review the narrative for any such findings reflecting a determination of violation or non-adherence related to those foreign countries in the https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ report, including the finding itself, and to the extent necessary, the conduct giving rise to the compliance or adherence concerns, the analysis of compliance or adherence concerns, and efforts to resolve compliance or adherence concerns.

(4) The Offeror may submit any questions with regard to this report by email to NDAA1290Cert@state.gov. To the extent feasible, the Department of State will respond to such email inquiries within 3 business days.

(d) Do not submit an offer unless—

(1) A certification is provided in paragraph (b)(1) of this provision and submitted with the offer;

or

(2) In accordance with paragraph (b)(2) of this provision, the Offeror provides with its offer information that the President of the United States has—

(i) Waived application under U.S.C. 2593e(d) or (e); or

(ii) Determined under 22 U.S.C. 2593e(g)(2) that the entity has ceased all activities for which measures were imposed under 22 U.S.C.2593e(b).

(e) Remedies. The certification in paragraph (b)(1) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly submitted a false certification, in addition to other remedies available to the Government, such as suspension or debarment, the Contracting Officer may terminate any contract resulting from the false certification.

2.5 52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.

2.6 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—

SECONDARY SITE OF THE WORK (MAY 2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

2.7 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO

ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION

(FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

0.9 % 6.9 %

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is

Iron Mountain Dickinson State of Michigan

2.8 52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT—

CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American—Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

2.9 52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or 200,000, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

2.10 52.233-2 SERVICE OF PROTEST (SEP 2006)

Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

Kristi Kluck

Contracting Officer Hand-Carried Address:

Department of Veteran Affairs

GLAC (36C252)

115 South 84th Street, Suite 101 Milwaukee WI 53214-1476 Mailing Address:

Department of Veterans Affairs

GLAC (36C252)

115 South 84th Street, Suite 101 Milwaukee WI 53214-1476

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

2.11 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I

(FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for—

Details provided on Page 1

(c) Participants will meet at—

Details provided on Page 1

2.12 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY

REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html http://www.va.gov/oal/library/vaar/

FAR

Number

Title Date

52.204-7 SYSTEM FOR AWARD MANAGEMENT OCT 2018

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE

REPORTING

AUG 2020

52.204-22 ALTERNATIVE LINE ITEM PROPOSAL JAN 2017

52.211-6 BRAND NAME OR EQUAL AUG 1999

52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS DEC 2016

52.214-4 FALSE STATEMENTS IN BIDS APR 1984

52.214-5 SUBMISSION OF BIDS DEC 2016

52.214-6 EXPLANATION TO PROSPECTIVE BIDDERS APR 1984

52.214-7 LATE SUBMISSIONS, MODIFICATIONS, AND

WITHDRAWALS OF BIDS

NOV 1999

52.214-18 PREPARATION OF BIDS—CONSTRUCTION APR 1984

52.214-19 CONTRACT AWARD—SEALED BIDDING—

CONSTRUCTION

AUG 1996

2.13 VAAR 852.233-70 PROTEST CONTENT/ALTERNATIVE DISPUTE

RESOLUTION (OCT 2018)

(a) Any protest filed by an interested party shall—

(1) Include the name, address, fax number, email and telephone number of the protester;

(2) Identify the solicitation and/or contract number;

(3) Include an original signed by the protester or the protester’s representative and at least one copy;

(4) Set forth a detailed statement of the legal and factual grounds of the protest, including a description of resulting prejudice to the protester, and provide copies of relevant documents;

(5) Specifically request a ruling of the individual upon whom the protest is served;

(6) State the form of relief requested; and

(7) Provide all information establishing the timeliness of the protest.

(b) Failure to comply with the above may result in dismissal of the protest without further consideration.

(c) Bidders/offerors and Contracting Officers are encouraged to use alternative dispute resolution (ADR) procedures to resolve protests at any stage in the protest process. If ADR is used, the Department of Veterans Affairs will not furnish any documentation in an ADR proceeding beyond what is allowed by the Federal Acquisition Regulation.

PLEASE NOTE: The correct mailing information for filing alternate protests is as follows:

Deputy Assistant Secretary for Acquisition and Logistics, Risk Management Team, Department of Veterans Affairs 810 Vermont Avenue, N.W.

Washington, DC 20420 Or for solicitations issued by the Office of Construction and Facilities Management:

Director, Office of Construction and Facilities Management 811 Vermont Avenue, N.W.

Washington, DC 20420

REPRESENTATIONS AND CERTIFICATIONS

3.1 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR

2020) (a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238210.

(2) The small business size standard is $16.5 Million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204–7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services—Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations— Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2,…