RFQ-90327 CO-16 Statement of Qualifications.docx

CO-16

CONTRACTOR'S STATEMENT

OF QUALIFICATIONS

RFQ-90327

CO-16 – STATEMENT OF QUALIFICATIONS

TO BE COMPLETED BY OFFERORS IN RESPONSE TO RFQ-90327 AND THE QUALIFICATION CRITERIA PROVIDED THEREIN

TABLE of CONTENTS

I. General Information

II. Bonding

III. Judgments

IV. Convictions and Debarment

V. Compliance

VI. Experience

VII. Signatures

CONTRACTOR'S STATEMENT OF QUALIFICATIONS

I. General Information

1. Submitted to the City of Fairfax, VA, City of Fairfax Schools:

Address: 10455 Armstrong Street Fairfax, VA 22030-3630

2. For: RFQ-90327 – Construction Manager at Risk

Project: Renovations and Additions to City of Fairfax Schools

3. Type of work you wish to qualify for: Construction Manager at Risk

4. Contractor's Name:

Mailing Address:

Street Address: (If not the same as mailing address)

Web site:

Telephone Number: ( )

Contact Person:

Contact Person’s Phone Number: ( )

State Contractor's License Number:

Designated Employee Registered with the Virginia Board for Contractors:

Provide the name and title, direct telephone number (including extension), cellular telephone number and direct e-mail address of the highest ranking individual within the organization that will have oversight responsibility for the organization's involvement with the Project (if not the designated contact person above):

If different from the location provided above, provide the organization's local or regional office information (including physical address, mailing address, telephone number, and main e-mail address or web site address) to be used in delivering the requested services to be provided on the Project:

Provide the number of years that the organization has been providing services similar to those requested by this RFQ, including a delineation of this information for both the headquarters location and the local or regional office (as appropriate) that will be used in delivering the requested services on the Project.

5. Check type of organization:

Corporation ___ Partnership ___

Individual ___ Joint Venture ___

Other (describe) _________________________________

If the Proposal is being made by a legal joint venture, the response must include the information required within this section of the Form CO-16 for both organizations that constitute the joint venture and a copy of the joint venture agreement must be attached.

6. If a corporation -

State of Incorporation:

Date of Incorporation:

Federal I.D. #:

Officers Name / Contact Info Years in Position

Chief Executive Officer:

Chief Financial Officer:

President:

Vice President:

Secretary:

Treasurer:

Office Manager of local office that will have primary responsibility for delivering this project:

Are you a Subchapter S Corporation? Yes ___ No ___

7. If a partnership -

Date organized:

Type of partnership:

List of General Partners:

Name Phone # Years as G.P.

8. If individually owned -

Years in Business:

9. Have you ever operated under another name? Yes ___ No ___

If yes -

Other name:

Number of years in business under this name:

State license number under this name:

10. Department of Small Business and Supplier Diversity (DSBSD) Certifications:

Check all that apply:

Micro Business DSBSD Certification No.:_

Small Business DSBSD Certification No.:_

Small Women-Owned Business DSBSD Certification No.:_

Small Minority-Owned Business DSBSD Certification No.:_

Small Service Disabled Veteran-Owned Business DSBSD Certification No.:_

II. Bonding

Provide a letter from your surety company listing your organization’s current single Project and total Projects bonding capacity, including such information for the local or regional office that will be used in delivering the services to be provided on the Project (if the local or regional office is separately bonded); attach this letter to the Form CO-16.

1. Bonding Company's name:

Address:

Representative (Attorney-in-fact):

2. Is the Bonding Company listed on the United States Department of the Treasury list of acceptable surety corporations?

Yes ___ No ___

3. Is the Bonding Company licensed to transact surety business in the Commonwealth of Virginia?

Yes ___ No ___

4. Describe the capacity the organization has to meet the project schedule and demands. Include an analysis of current workload.

III. Judgments

In the last ten (10) years, has your organization, or any officer, director, partner or owner, had judgments entered against it or them for the breach of contracts for construction?

Yes ___ No ___

If yes, on a separate attachment, state the person or entity against whom the judgment was entered, give the location and date of the judgment, describe the project involved, and explain the circumstances relating to the judgment, including the names, addresses and phone numbers of persons who might be contacted for additional information.

IV. Convictions and Debarment If you answer yes to any of the following, on a separate attachment, state the person or entity against whom the conviction or debarment was entered, give the location and date of the conviction or debarment, describe the project involved, and explain the circumstances relating to the conviction or debarment, including the names, addresses and phone numbers of persons who might be contacted for additional information.

1. In the last ten (10) years, has your organization or any officer, director, partner, owner, project manager, procurement manager or chief financial officer of your organization:

a. ever been fined or adjudicated of having failed to abate a citation for building code violations by a court or local building code appeals board?

Yes ___ No ___

b. ever been found guilty on charges relating to conflicts of interest?

Yes ___ No ___

c. ever been convicted on criminal charges relating to contracting, construction, bidding, bid rigging or bribery?

Yes ___ No ___

d. ever been convicted: (i) under Va. Code Section 2.2-4367 et seq. (Ethics in Public Contracting); (ii) under Va. Code Section 18.2-498.1 et seq. (Va. Governmental Frauds Act); (iii) under Va. Code Section 59.1-68.8 et seq. (Conspiracy to Rig Bids); (iv) of a criminal violation of Va. Code Section 40.1-49.4 (enforcement of occupational safety and health standards); or (v) of violating any substantially similar federal law or law of another state?

Yes ___ No ___

e. ever been convicted on charges relating to employment of illegal aliens on construction projects?

Yes ___ No ___

V. Compliance

If you answer yes to any of the following, on a separate attachment give the date of the termination order, or payment, describe the project involved, and explain the circumstances relating to same, including the names, addresses and phone numbers of persons who might be contacted for additional information.

1. Has your organization:

VI. Experience

If your organization has multiple offices, provide the following information for the office that would handle projects under this prequalification. If that office has limited history, list its experience first.

1. Attach a list of all projects, giving project name, location, size, dollar value, and completion date for each that your organization has completed in the last ten (10) years.

2. Attach a list of your organization's projects in progress, if any, at the time of this statement. At a minimum, provide project names and addresses, contract amounts, percentages complete and contact names and numbers for the architects and owners.

3. If this statement is for a particular project, identify three (3) projects from those identified in 1 and 2 above which are most relevant or similar to the project(s) for which you are seeking prequalification; these projects are designated as your “Firm’s Representative Projects” and will also be included on Attachment 3, “CO-16 Crosswalk of Firm and Key Personnel Experience”.

Firm Representative Project 1.

Project Name:

Project Address:

Owner's Name:

Address:

Phone Number:

Contact:

Architect's Name:

Address:

Phone Number:

Contact:

Provide additional project data as required in the “CO-16 Crosswalk of Firm and Key Personnel Experience Provide explanations for any cost or schedule growth greater than 10%.

Describe key lessons learned:

Provide evidence that any preconstruction services provided resulted in cost savings and effective schedule management:

Firm Representative Project 2.

Project Name:

Project Address:

Owner's Name:

Address:

Phone Number:

Contact:

Architect's Name:

Address:

Phone Number:

Contact:

Provide additional project data as required in the “CO-16 Crosswalk of Firm and Key Personnel Experience”. Provide explanations for any cost or schedule growth greater than 10%.

Provide evidence that any preconstruction services provided resulted in cost savings and effective schedule management:

Firm Representative Project 3.

Project Name:

Project Address:

Owner's Name:

Address:

Phone Number:

Contact:

Architect's Name:

Address:

Phone Number:

Contact:

Provide additional project data as required in the “CO-16 Crosswalk of Firm and Key Personnel Experience”. Provide explanations for any cost or schedule growth greater than 10%.

Provide evidence that any preconstruction services provided resulted in cost savings and effective schedule management:

4. Staffing: Describe how your firm would staff this project. The Proposal must include a description of the duties and responsibilities of all key Project team members and an organizational chart indicating the title or function of each individual and the reporting structure and functional relationships between the team members.

5. Personnel experience: For all designated key personnel (i.e.: project manager, superintendent, preconstruction manager etc.), describe the background and experience that would qualify him or her to serve successfully on this project. For all key personnel to be assigned to this project, provide as an attachment a resume which includes:

a. Title (Principal, Project Manager, Superintendent, etc.).

b. Number of years of experience in the construction industry.

c. Summary of education, including the name(s) of the institution(s) from which the individual graduated and the year(s) of graduation.

d. Listing of professional registrations, including registration numbers and dates that the respective registrations were first obtained, per state, along with any certifications relevant to the individual’s proposed function on this project.

e. List of any professional / trade organization affiliations and associations in which the individual actively participates.

f. Identification of at least three (3) similar or comparable projects on which each proposed key personnel have served in that capacity or positions of similar or comparable responsibility within the last ten (10) years, including at least one of those within the last five years. For these three (3) projects, if the project is NOT a “Firm Representative Project” for which this information was previously provided above, then provide the names, addresses, and phone numbers of the Owner’s and Architect’s contact person for each that can be contacted to obtain an assessment of the individual’s competencies and capabilities for the project.

Project Name:

Project Address:

Owner’s Name:

Address:

Phone Number:

Contact:

Architect’s Name:

Address:

Phone Number:

Contact:

For all designated key personnel, also provide project-specific information by completing “CO-16 Crosswalk of Firm and Key Personnel Experience”. This data includes the percentage of each key individual’s time which will be committed to the project (i.e.: 100%, 80%, etc.)

6. Provide additional attachments, as required, in response to any additional agency-specified prequalification criteria provided in the RFQ.

VII. Signatures

The undersigned certifies under oath that the information contained in this Statement of Qualifications and attachments hereto is complete, true and correct as of the date of this Statement.

(Name of entity signing this Statement of Qualifications)

By: Name of Signer (print)

(Signature in ink)

Title:

Date:

Notary

State of:

County/City of:

Subscribed and sworn to before me this day of _ _____, 20 _ .

Notary Public Signature

My commission expires:

Notary Seal:

Attachments (to be provided):

1. Surety Statement of Bonding Eligibility.

2. Additional information, if any, provided under CO-16 Sections III, IV, V.

3. Information required under CO-16 Section VI (i.e.: project listings, organizational chart, key personnel resumes, completed “CO-16 Crosswalk of Firm and Key Personnel Experience” (DGS-30-172), etc.).

4. Signature on DGS-30-466 (RFQ-90327 form).

5. Completed RFQ-90327 SCC form.

image1.gif