Raleigh Police Department Evidence Facility.pdf

City of Raleigh 00100-1 Advertisement for Pre-Qualifications

ADVERTISEMENT FOR PRE-

QUALIFICATIONS POSTED: 7/15/2026

CITY BID NUMBER: 274-FY2027-CM-PSSP03

Project: Raleigh Police Department Evidence Facility

Owner: City of Raleigh, North Carolina, Engineering Services Department, One Exchange Plaza, Suite 620, Raleigh, NC 27601.

Construction Manager: Consigli Construction, 4819 Emperor Blvd. Suite 130 Durham, NC 27703 Contact: Manasa Badri, MBadri@consigli.com

Architect: Becker Morgan Group

Pursuant to NC statutes G.S. 143-128.1, Consigli has been selected as the CM at Risk and is seeking to prequalify trade partners for the Raleigh Police Department Evidence Facility project.

A non-mandatory information session will be held at 10:00AM Tuesday, July 21, 2026 at 2320 Law Enforcement Drive, Raleigh, NC 27610 in room 140.

A non-mandatory virtual information session will be held at 10:00AM Tuesday, July 28, 2026. For session link, please contact Manasa Badri.

The Project is located at 8120 Battle Bridge Road Raleigh, NC 27610. The project consists generally of the following major items:

One ground up 26,000 SF load bearing masonry structure, one 24,000 SF Pre-Engineered Metal Building, finishes, sitework/utilities & exterior improvements. The following bid packages are expected:

01 General Trades, 03 Concrete, 04 Masonry. Structural Steel & Misc. Metals, 06 Millwork, 07A Roofing, 07B Waterproofing & Joint Sealants, BP08A Doors Frames & Hardware, 08B Glass & Glazing, 08C Overhead Doors, BP 09A Drywall, BP 09B Acoustic Ceilings, BP 09C Flooring, BP 09D Painting & Coatings, BP 10A Specialties, BP 10B Wire Mesh Partitions, BP 10C Storage Shelving, BP 11A Equipment, BP 12A Furnishings, 13A Pre Engineered Metal Building, 13B Cold Storage, 21A Fire Protection, 22A Plumbing, 23A HVAC, 23B Geothermal Wells, 26A Electrical & Low Voltage, 31A Sitework & Utilities. See pre-qualification form for further information.

Pre-qualification forms are due August 6, 2026 at 5:00PM to Manasa Badri by email at MBadri@consigli.com. Late forms will not be accepted. Pre-qualification forms and additional information are included in this advertisement and may also be obtained by contacting Manasa Badri at 4819 Emperor Blvd. Suite 130 Durham, NC 27703 or by email at MBadri@consigli.com

City of Raleigh Janet Cowell, Mayor

END OF DOCUMENT

mailto:MBadri@consigli.com

Raleigh Police Department Evidence Facility project Prequalification Form for Subcontractors

July, 2026 Page 1 of 14

Pursuant to the statute, this form gathers information about the subcontractors seeking to qualify for the work and provides a general format for the prequalification criteria. Completing this questionnaire does not guarantee prequalification. Evaluation of the submittal shall be performed by the prequalification committee in accordance with GS 143-128.1, 143-135.8 and the City of Raleigh Prequalification Policy.

Subcontractors must use this project-specific form from the Prequalification Committee. Do not use a blank template from the North Carolina State Construction Office website or any other template previously used.

PREQUALIFICATION DUE DATE/TIME: August 6, 2026 5:00 pm.

(date) (time)

Submit to: Consigli Construction Company

Project:

Name of Project: RPD Evidence Facility

Project Owner: City of Raleigh

Project Architect: Becker Morgan Group

Project Start Date (Approx.): 4th Quarter 2026

Project/Phase Duration: 18 Months

Anticipated Bid Date: September 2026

Project Description:

The Evidence facility consists of 2 ground up structures. The main building is load bearing masonry with brick facade, with administrative office areas and secured storage areas throughout. The second building is an enclosed PEMB with SOG for auto storage. Site to include geothermal wells, retaining walls, utilities and underground storm detention.

Anticipated Start of Construction: November 2026

Submittals: Interested Firms must submit one (1) hard copies of this form and all required attachments. Late submittals will not be accepted.

City of Raleigh Prequalification Policy: Please note that the City’s prequalification policy has been included in this document as Appendix C. First tier subcontractors unable to meet bonding requirements shall be ineligible for further consideration in the prequalification process. If the notary certification of this form is incomplete, the form is invalid.

If your firm is interested in prequalifying for this project, please complete the following document and submit as requested.

July, 2026 Page 2 of 14

SECTION 1. GENERAL COMPANY INFORMATION

1. a. Primary/Main office location:

Company Name:

Physical Address:

Mailing Address

City, State, and Zip Code

Phone number Fax number

Primary Contact Name Secondary Contact Name

Primary Contact Email Address Secondary Contact Email Address

Organization:

1. b. Business type (check box)

Corporation Partnership Limited Liability Company Sole Proprietor

Joint Venture

Is your firm registered with the State of North Carolina to do business?

Yes No

Is your firm owned or controlled by a parent or any other organization?

Describe Ownership if Yes:

July, 2026 Page 3 of 14

List all other names your firm has operated as for the past five (5) years:

List owners, officers, partners, or individuals authorized to represent or conduct business for or sign legal documents for the firm. This list must include the full legal name, typed or printed in a clear legible form.

[Note that firms experiencing changes in ownership, organizational structure, or material changes in assets must inform the Bid Agent prior to the award of a contract. Failure of the firm to comply with this requirement may result in the termination of any contract awarded by the City.]

1. c. Licensing Information (The Applicant must provide a copy of their North Carolina Contractor’s

License)

Name of licensee/NC License number:

License Limit / Level:

State / County / City Privilege License:

Has any license ever been denied or revoked?

If yes, please describe. Attach additional sheets as needed.

1. d. Type of Work Performed on a regular basis

Primary Scope of Work:

Secondary Scope of Work:

Other Scope of Work:

July, 2026 Page 4 of 14

What type of work does the firm self-perform? ______________________________________________

Provide a brief explanation (Note that the firm shall indicate the type(s) of work the firm’s workforce and equipment normally perform, licensure, and other pertinent information. Attach additional sheets as needed.):

Bonding:

1. e. (1) Attach letter, dated within the last 30 days, from your surety company, signed by their Attorney in Fact, verifying their willingness to issue sufficient payment and performance bonds for this project, on behalf of your firm and the dollar limits of that bond commitment, both single and aggregate. Surety company bond rating shall be rated “A” or better under the A.M. Best Rating system or The Federal

Treasury List.

Have you attached a surety letter?

1. e. (2) Have any Funds ever been expended by a Surety Company on your firm’s behalf?

If yes, please explain:

Insurance:

1. f. The minimum requirements of coverage are included in Appendix A (City of Raleigh Insurance

Requirements for a CONTRACT FOR CONSTRUCTION/REPAIR) located on pages 18 and 19 of this form. Firms must indicate that they can provide evidence of insurance coverage should they be the successful bidder by attaching a copy of their insurance certificate.

Have you attached a copy of your insurance certificate?

Yes No

Financials:

1. g. Attach a minimum of one year of complete audited financial statements from the past two years. If financial statements have NOT been audited in the last two years, please provide the most recent unaudited financial statements. Have you attached financial statement(s)?

July, 2026 Page 5 of 14

SECTION 2. GENERAL REQUIREMENTS

Experience – Size/Capacity/Workload:

2. a. (1) List the annual dollar value of construction work the company has performed for each year over the last (3) three calendar years as listed (if applicable).

2. a. (2) How many projects do you currently have under contract or in progress and what is their total dollar value?

• (# of projects);

• $ (Current projects contract amount);

• $ (Projects current amount remaining to bill)

2. a. (3) What was your largest job completed?

Sq. Ft.

$ Dollar Amount

Name of Project and Location

(City/State)

_____________________________________________________ Name of Owner, Designer, and General

Contractor

Year Completed

2. a. (4) Current Backlog:

$ ________ Dollar Amount

July, 2026 Page 6 of 14

2. a. (5) List the three largest contracts currently under contract or in progress, including for each, the name of the project, owner, architect and/or GC/CMAR and contact information below.

1 –Project Name

Description of Work Performed

Contract Delivery Method (CMAR/GC)?

Owner Name/Representative

Owner Address/Phone #/Email

Architect Name/Representative

Architect Address/Phone #/Email

GC or CM Name/Representative

GC or CM Address/Phone #/Email

Contract Dollar Value

Percentage Complete

Current Anticipated Completion Date

#2 –Project Name

Description of Work Performed

Contract Delivery Method (CMAR/GC)?

Owner Name/ Representative

Owner Address/Phone #/Email

Architect Name/Representative

Architect Address/Phone #/Email

GC or CMAR Name/Representative

GC or CMAR Address/Phone #/Email

July, 2026 Page 7 of 14

Contract Dollar Value

Percentage Complete

Current Anticipated Completion Date

#3 –Project Name

Description of Work Performed

Contract Delivery Method (CMAR/GC)?

Owner Name/Representative

Owner Address/Phone #/Email

Architect Name/Representative

Architect Address/Phone #/Email

GC or CMAR Name/Representative

GC or CMAR Address/Phone #/Email

Contract Dollar Value

Percentage Complete

Current Anticipated Completion Date

Office Locations:

2. b. Will this project be managed and directed from an office in NC? An office in NC is defined as “The principal place from which the trade or business of the bidder is directed or managed,” per GS 143-59c).

Location of Office Primarily Responsible for Work ____________________________________

July, 2026 Page 8 of 14

Litigation/Claims:

The firm will be required to submit information regarding its litigation history, including litigation with owners and subcontractors.

2. c. (1) has your company been involved in any judgments, claims, arbitration or mediation proceedings, or suits within the last five years, whether resolved or still pending resolution?

If yes, state the project name(s), year(s), case number, and case disposition:

2. c. (2) Are there currently any judgments, claims, arbitration or mediation proceedings or suits pending or outstanding against your company, its officers, owners, or agents?

Yes No

If yes, state the project name(s), year(s), case number, and case disposition (Provide additional sheets as needed):

2. c. (3) Has your company ever failed to complete work awarded to it?

If yes, state the project name(s), year(s) and reason why. (Provide additional sheets as needed):

2. c. (4) Have you ever paid liquidated damages on any project?

If yes, state the project name(s), ), year(s) and reason why. (Provide additional sheets as needed):

2. c. (5) Has your present company, its officers, owners, or agents ever been convicted of charges relating to conflicts of interest, bribery, or bid rigging?

If yes, state the project name(s), year(s) and reason why. (Provide additional sheets as needed):

July, 2026 Page 9 of 14

2. c. (6) Has your present company, its officers, owners, or agents ever been barred from bidding public work?

Yes No

If yes, state the project name(s) and location(s), year(s), case number, and reason(s) why (Provide additional sheets as needed):

Safety Record:

2. d. List your company’s Experience Modification Rate (EMR) for past three years. (Attach OSHA 300 Log for the last 3 years.). Firms must provide copies of any complaints, safety violations or reports from the

North Carolina Qualifications Board, OSHA, or any other regulating agency associated with any construction project (i.e., OSHA 300 log). Have these documents been attached?

Yes No

Current rate:

2026 rate:

2025 rate:

2024 rate:

If these rates reflect corporate performance over a number of locations, please explain, to the extent possible, the performance experience of the location serving this project:

List any OSHA fines and Jobsite fatalities in the past 3 years with an explanation:

2. e (1). Reserved

2. e (2). Reserved

July, 2026 Page 10 of 14

SECTION 3. PROJECT SPECIFICS/TEAM

3. a. The assigned project superintendent for this project shall be:

Include a resume. Have you included a resume?

3. b. The experience this superintendent has on this specific type of project is:

0-2 years 3-4 years 5-10 years greater than 10 years

3. c. The assigned project manager for this project shall be:

Include a resume. Have you included a resume?

3. d. The experience this project manager has on this specific type of project is:

0-2 years 3-4 years 5-10 years greater than 10 years

3.e. Similar Projects: List three (3) current or completed projects of similar type which most closely reflects the size and complexity of the type of work being requested for the currently proposed project within the last 10 years.

Indicate if any project descriptions or other pertinent information are attached separately as a continuation page.

Additional project information related to this Construction Project is available or upon request and includes a current set of plans. (Note the additional project information is preliminary and IS LIKELY TO

CHANGE at the time of bid. This additional project information is provided solely as a courtesy for the purposes of responding to 3.e.)

July, 2026 Page 11 of 14

1 –Project Name

Description of Work Performed

Contract Delivery Method (CMAR/GC)?

Owner Name/Representative

Owner Address/Phone #/Email

Architect Name/Representative

Architect Address/Phone #/Email

GC or CMAR Name/Representative

GC or CMAR Address/Phone #/Email

Contract Dollar Value

If complete, was the project on time? If not, explain.

#2 –Project Name

Description of Work Performed

Contract Delivery Method (CMAR/GC)?

Owner Name/Representative

Owner Address/Phone #/Email

Architect Name/Representative

Architect Address/Phone #/Email

GC or CMAR Name/Representative

July, 2026 Page 12 of 14

GC or CMAR Address/Phone #/Email

Contract Dollar Value

#3 –Project Name

Description of Work Performed

Contract Delivery Method (CMAR/GC)?

Owner Name/Representative

Owner Address/Phone #/Email

Architect Name/Representative

Architect Address/Phone #/Email

GC or CMAR Name/Representative

GC or CMAR Address/Phone #/Email

Contract Dollar Value

July, 2026 Page 13 of 14

SECTION 4. CONTRACTOR PERFORMANCE EVALUATIONS

4.a. Have you received unsatisfactory performance evaluations during the performance of the work for which you were responsible for any projects you have been involved in as a general contractor or subcontractor?

Yes No

If the answer is yes, please provide an explanation on a separate sheet and provide responses to the following: 1) Name of the project; 2) Your role as general contractor or subcontractor; 3) Name of the general contractor if you were a subcontractor; 4) Identify the tier status if you were a subcontractor; 5)

Describe the scope of work for which you were responsible; 6) What remedial measures were instituted to cure the unsatisfactory performance evaluation; 7) Indicate if payment, in addition to retainage, was withheld for unsatisfactory work; 8) Indicate if your surety was notified; and 9) Describe any assistance provided by the surety to improve performance.

4.b. Have your received unsatisfactory at the conclusion of a project?

Yes No

If the answer is yes, please provide an explanation on a separate sheet.

4.c. Has your firm ever been defaulted on a project or notified of intent to default on a project?

If the answer is yes, please provide an explanation on a separate sheet and provide responses to the following: 1) Name of the project; 2) Your role as general contractor or subcontractor; 3) Name of the general contractor if you were a subcontractor; 4) Identify the tier status if you were a subcontractor; 5)

Describe the scope of work for which you were responsible; 6) What remedial measures were instituted to cure the unsatisfactory performance evaluation; 7) Indicate if payment, in addition to retainage, was withheld for unsatisfactory work; 8) Indicate if your surety was notified; 9) Describe any assistance provided by the surety to improve performance; 10) Indicate the amount of liquidated damages assessed, and 11) Provide the name, address, telephone number, and email address for a contact for each project cited.

July, 2026 Page 14 of 14

SECTION 5. SIGNATURE

By signing this document, you are acknowledging that all answers are true to the best of your knowledge.

Any answers found to be falsified will bar you from being prequalified on this project.

Company Name (as licensed in NC)

Physical Address

Mailing Address

a. Dated this day of:

b. Submitted by:

Signature By Authorized Officer

Print Title of Authorized Officer

Contact person’s telephone number

Contact person’s e-mail address

c. Notary Certification:

State of North Carolina, County, I, a Notary

Public of the County and State aforesaid, certify that , personally appeared before me this day and acknowledged the execution of the foregoing instrument.

Witness my hand and official seal, this the day of

, 2017.

(Official Notary Seal or Stamp)

Signature of Notary Public

My commission expires , 20__