Amendment_No._0004.pdf

(x)

R17PS00780

x x copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

Billings MT 59107

R60

PO Box 36900 Regional Office Great Plains Region Bureau of Reclamation

09/04/20170004

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

07/03/2017

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Fremont Canyon Powerplant Scroll Case Recoating, North Platte Project, Wyoming

See attachment for changes incorporated by this amendment:

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Gerri Voto-Braun

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

Amendment No. 0004

R17PS00780

Description of Changes:

1. In Part I – The Schedule, Specification Section 52 00 00 – Drawings, remove Page 52 00 00-3 and 52 00 00-4 and substitute therefor the attached revised page 52 00 00-3 and 52 00 00-4.

2. In Part I – The Schedule, remove Section F – Deliveries or Performance in its entirety and substitute therefor the attached revised Section F.

3. In Part II – Contract Clauses, remove Page I-3 and I-4 and substitute therefor the attached revised Page I-3 and I-4.

4. In Part II – Contract Clauses, remove Page I-37 and I-38 and substitute therefor the attached revised Page I-37 and I-38.

5. In Part IV – Representations, Certifications and Instructions, remove Section K – Representations, Certifications and Other Statements of Offerors in its entirety and substitute therefor the attached revised Section K.

For convenience, essential changes on the revised solicitation pages are indicated by a vertical line in the margin where lines or paragraphs changed from the previous version. However, all portions of the revised solicitation pages shall apply whether changes thereon have or have not been indicated.

Acknowledgement: See Block 11 on the SF-30 regarding how to acknowledge this amendment. The Government must receive the acknowledgement at the place designated for receipt of bids (See Block 10 of the Standard Form 1442).

Receipt of Proposals: The hour and date for receipt of proposals is extended to 2:00 pm MDT on September 13, 2017.

Third Party: If you have given a copy of the solicitation to someone else, please forward this amendment accordingly.

Fremont Canyon Powerplant Amendment No. 004 Scroll Case Recoating

Drawings

Revised 52 00 00 - 3

Table 52 00 00A - List of Drawings

Sheet No.

Drawing No. Title

15 449-D-1000 Fremont Canyon Power Plant – Penstocks – Turbine Inlet Pipes

16 449-M-D-57-8 Newport News Shipbuilding and Dry Dock Company – Newport News Virginia – Engineering Design Division – Hydraulic & Industrial Department – Spiral Case Assembly

– Hydraulic Turbine

17 449-M-D-57-5 Newport News Shipbuilding and Dry Dock Company – Newport News Virginia – Engineering Design Division – Hydraulic & Industrial Department – General Arrangement

– Hydraulic Turbine

18 449-D-1242 Fremont Canyon Power Plant – Approach Area Protective Roof – General Arrangement

END OF SECTION

Fremont Canyon Powerplant Amendment No. 004 Scroll Case Recoating

Drawings

Revised 52 00 00 - 4

This page intentionally left blank.

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

F - 1 (Revised)

SECTION F -- DELIVERIES OR PERFORMANCE

F.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK

APR 1984

The Contractor shall be required to:

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) Prosecute the work diligently, and (c) Complete the entire work ready for use not later than 375 calendar days after the date the Contractor receives the notice to proceed. The time stated for completion shall include final cleanup of the premises.

F.2 52.242-14 SUSPENSION OF WORK APR 1984

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed -

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

F - 2 (Revised)

THIS PAGE INTENTIONALLY LEFT BLANK

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

I - 3 (Revised)

I.2 DELETED

I.3 52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE

MAINTENANCE

JUL 2016

(a) Definition. As used in this clause—

“Commercial and government Entity (CAGE) code” means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or Government entity, or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file.

This type of code is known as the NATO CAGE (NCAGE) code.

(b) Contractors shall ensure that the CAGE code is maintained throughout the life of the contract. For contractors registered in the System for Award Management (SAM), the DLA Commercial and Government Entity (CAGE) Branch shall only modify data received from SAM in the CAGE master file if the contractor initiates those changes via update of its SAM registration. Contractors undergoing a novation or change-of-name agreement shall notify the contracting officer in accordance with subpart 42.12. The contractor shall communicate any change to the CAGE code to the contracting officer within 30 days after the change, so that a modification can be issued to update the CAGE code on the contract.

(c) Contractors located in the United States or its outlying areas that are not registered in SAM shall submit written change requests to the DLA Commercial and Government Entity (CAGE) Branch. Requests for changes shall be provided at https://cage.dla.mil. Change requests to the CAGE master file are accepted from the entity identified by the code.

(d) Contractors located outside the United States and its outlying areas that are not registered in SAM shall contact the appropriate National Codification Bureau (points of contact available at http://www.nato.int/structur/AC/135/main/links/contacts.htm) or NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx.

(e) Additional guidance for maintaining CAGE codes is available at https://cage.dla.mil.

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

I - 4 (Revised)

I.4 52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR

INFORMATION SYSTEMS

JUN 2016

(a) Definitions. As used in this clause--

“Covered contractor information system” means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

“Federal contract information” means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public Web sites) or simple transactional information, such as necessary to process payments.

“Information” means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009).

“Information system” means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502).

“Safeguarding” means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures.

(1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

I - 37 (Revised) marijuana, alcoholic beverages, and similar substances, except for use with valid medical prescription;

and explosives.

(xiv) Exceptions for Explosives. When needed for use in specifically limited amounts and controlled circumstances for construction work, explosives may be brought onsite with written prior authorization from the COR. As a hazardous material, the Contractor shall treat the use of explosives in accordance with regulations and guidance provided by Federal, State, and local authorities. The storage of explosives shall be in accordance with requirements of the Bureau of Alcohol, Tobacco, and Firearms or the State in which they are stored. If onsite storage of explosives is necessary, explosives shall be stored at a pre-designated, secure site approved by the COR. Prior to Government approval of storage, the Contractor shall develop and submit to the COR a complete storage/security/retrieval plan for approval. The storage/security plan can be included in a “Blasting Safety Plan.” The plan shall make accommodations for surveillance, detection, and response. Explosives firing systems shall be stored off-site and under no circumstances shall be stored together with explosives.

(xv) Photography. The use of photographic equipment and taking of photographs shall only be allowed as authorized by the COR.

(f) RESERVED.

I.35 WBR

1452.243-80

ALT 4

MODIFICATION PROPOSALS - ALTERNATE IV JUL 1998

(a) In submitting any proposal for a modification under this contract (including any proposal for an equitable adjustment resulting from a change under the Changes clause of this contract), the Contractor shall:

(1) Comply with the contract time limits for submission of a proposal or as specified by the Contracting Officer;

(2) Apply the contract cost principles and procedures in Part 31 of the Federal Acquisition Regulation (FAR) in effect on the date of this contract;

(3) Furnish a breakdown of all costs estimated to complete the work required by the modification (i.e., cost of added work, incurred cost of deleted work already performed, estimated cost of deleted work not yet performed, and net cost of the modification) to include all costs associated with materials (identified by item and quantity), equipment (identified by item, quantity and whether contractor-owned or rented), categories of direct labor, bond and insurance premium adjustments, subcontracts, overhead and other indirect costs, profit/fee, and any other pricing information requested by the Contracting Officer, in sufficient detail to permit a detailed analysis of fair and reasonable price and comply with the requirements of the Change Order Accounting and Equipment Ownership and Operating Expense clauses of this contract.

(4) Furnish a written justification for any requested time extensions; and

(5) For any pricing adjustment expected to exceed $500,000 (considering both increases and decreases) –

(i) Submit cost and pricing data using the format specified in Table 15-2 of FAR 15.408 unless the Contracting Officer agrees that an exception applies under the circumstances set forth in FAR 15.403-1;

(ii) Certify in substantially the format prescribed in FAR 15.406-2 that to the best of its knowledge and belief, the data are accurate, complete and current as of the date of agreement on the negotiated price of the modification; and

(iii) Comply with the requirements of either the Subcontractor Cost or Pricing Data clause or the Subcontractor Cost or Pricing Data -- Modifications clause of this contract when the adjustment includes a subcontract modification involving a pricing adjustment expected to exceed 500,000.

(b) Under the Changes clause of this contract, failure of the Contractor to timely assert its right for an adjustment or to

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

I - 38 (Revised) submit a proposal for an adjustment by the date specified in the clause (or another date specified by the Contracting Officer) may result in a unilateral adjustment of the contract by the Contracting Officer pursuant to the Disputes clause of this contract.

I.36 52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL

CONFIDENTIALITY AGREEMENTS OR STATEMENTS

JANUARY

(a) Definitions. As used in this clause–

“Internal confidentiality agreement or statement” means a confidentiality agreement or any other written statement that the contractor requires any of its employees or subcontractors to sign regarding nondisclosure of contractor information, except that it does not include confidentiality agreements arising out of civil litigation or confidentiality agreements that contractor employees or subcontractors sign at the behest of a Federal agency.

“Subcontract” means any contract as defined in subpart 2.1 entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.

“Subcontractor” means any supplier, distributor, vendor, or firm (including a consultant) that furnishes supplies or services to or for a prime contractor or another subcontractor.

(b) The Contractor shall not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General).

(c) The Contractor shall notify current employees and subcontractors that prohibitions and restrictions of any preexisting internal confidentiality agreements or statements covered by this clause, to the extent that such prohibitions and restrictions are inconsistent with the prohibitions of this clause, are no longer in effect.

(d) The prohibition in paragraph (b) of this clause does not contravene requirements applicable to Standard Form 312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information.

(e) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015, (Pub. L. 113-235), and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions) use of funds appropriated (or otherwise made available) is prohibited, if the Government determines that the Contractor is not in compliance with the provisions of this clause.

(f) The Contractor shall include the substance of this clause, including this paragraph (f), in subcontracts under such contracts.

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

K - 1 (Revised)

SECTION K -- REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS

K.1 52.203-18 PROHIBITION ON CONTRACTING WITH ENTITIES THAT

REQUIRE CERTAIN INTERNAL CONFIDENTIALITY

AGREEMENTS OR STATEMENTS-REPRESENTATION

JANUARY

(a) Definition.

“Internal confidentiality agreement or statement,” “subcontract”, and “subcontractor”, as used in this provision, are defined in the clause at 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

(b) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions), Government agencies are not permitted to use funds appropriated (or otherwise made available) for contracts with an entity that requires employees or subcontractors of such entity seeking to report waste, fraud, or abuse to sign internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information.

(c) The prohibition in paragraph (b) of this provision does not contravene requirements applicable to Standard Form 312, (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information.

(d) Representation. By submission of its offer, the Offeror represents that it will not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General).

K.2 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS JAN 2017

(a) (1) The North American Industry classification System (NAICS) code for this acquisition is 238320

(2) The small business size standard is $15 Million

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b) (1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in the System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certification in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

[_] (i) Paragraph (d) applies.

[_] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

K - 2 (Revised)

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

K - 3 (Revised)

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals—Representation.

This provision applies to solicitations that include the clause at 52.204-7.

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $79,507 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification.

This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

K - 4 (Revised)

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

___ (i) 52.204-17, Ownership or Control of Offeror.

___ (ii) 52.204-20, Predecessor of Offeror.

___ (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

___ (iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

___ (v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

___ (vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

___ (vii) 52.227-6, Royalty Information.

___ (A) Basic.

___ (B) Alternate I.

___ (viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM Web site accessed through https://www.acquisition.gov . After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

K.3 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS JUL 2013

(a) Definitions - As used in this provision—

“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceeding at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment;

and similar positions).

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

K - 5 (Revised)

(b) The offeror has does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

Fremont Canyon Powerplant Scroll Case Recoating Solicitation No. R17PS00780

K - 6 (Revised)

THIS PAGE INTENTIONALLY LEFT BLANK