Sol_P16PS02226.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040287006

NPS, WASO - WCP Contracting

P.O.Box 25287 MS WCP

Denver CO 80225

PWA

National Park Service

WASO Denver Historic Preser. Training Center 4801A Urbana Pike Frederick, MD 21704

Sheila Rushlow 3016638206

1x 08/09/2016

P16PS02226

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Furnish and install a Certi-Sawn Tapersawn Premium Grade Western Red Cedar Shakes and Certigrade Shingles for the Johnstown Flood National Memorial Visitor Center

Roof, South Fork, PA. Work shall be done in accordance with Sections A through M of the Solicitation document including all Attachments.

The estimated construction range for the work associated with this Solicitation is between $100,000 and $250,000.

The Government anticipated award of a firm-fixed price resulting from this contract on or before September 21, 2016

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

7 309 calendar days and complete it within ________________ ________________ calendar days after receiving

09/07/2016

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

DOI, NPS, Historic Pres Trng Ctr 4801A Urbana Pike

Frederick MD 21704

WA2

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 16

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

P16PS02226

Johnstown Flood National Memorial Visitor Center

Roof, South Fork, PA

Legacy Doc #: NPS

Delivery: 12/09/2016

Delivery Location Code: 0009060777

NPS, HPTC

106 COMMERCE STREET

FREDERICK MD 21701-5612 US

FOB: Destination

Period of Performance: 04/03/2017 to 08/03/2017

00010 Remove and install a Certi-Sawn Tapersawn Premium

Grade Western Red Cedar Shakes and Certigrade

Shingles for the Johnstown Flood Visitor Center roof, South Fork, PA.

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

A - Solicitation/Contract Form Clauses

B - Supplies or Services/Prices Clauses

C - Description/Specifications Clauses

D - Packaging and Marking Clauses

E - Inspection and Acceptance Clauses

F - Deliveries or Performance Clauses

G - Contract Administration Data Clauses

H - Special Contract Requirements Clauses

I - Contract Clauses Clauses

J - List of Documents, Exhibits and Other Attachments List of Documents, Exhibits, and Other Attachments Clauses

K - Representations, Certifications, and Other Statements of Bidders Clauses

L - Instructions,Conditions, and Notices to Bidders Clauses

M - Evaluation Factors for Award Clauses

A - Solicitation/Contract Form

Clauses

52.232-5 Payments Under Fixed-Price Construction Contracts. (MAY 2014)

52.236-5 Material and Workmanship. (APR 1984)

52.236-7 Permits and Responsibilities. (NOV 1991)

B - Supplies or Services/Prices

Clauses

C - Description/Specifications

Clauses

D - Packaging and Marking

Clauses

E - Inspection and Acceptance

Clauses

F - Deliveries or Performance

Clauses

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 7 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 309 calendar days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) - Alternate I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 7 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 309 calendar days . The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by [Contracting Officer insert date]. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

CONTRACT WORK HOURS (NOV 2007)

The performance period established for this contract is based upon all work being conducted during regular working hours. Regular working hours are limited to the time between 7:30 a.m. and 5:00 p.m., Monday through Friday, excluding Government holidays. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, and Government holidays, a request must be submitted to the Contracting Officer Representative in sufficient time to allow satisfactory arrangements to be made by the Government for access to the work site and inspection.

(End of Clause)

G - Contract Administration Data

Clauses

Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (April 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor.

To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice [CO to edit and include the documentation required under this contract]:

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause)

CONTRACTOR PERFORMANCE INFORMATION (DIAPR) 2010-14, Amendment 1

CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (JULY 2010)

(a) FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

(b) The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

(c) We request that you furnish the Contracting Officer with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official. The report information must be protected as source selection sensitive information not releasable to the public.

(d) When your Contractor Representative(s) (Past Performance Points of Contact) are registered in CPARS, they will receive an automatically-generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at http://www.cpars.csd.disa.mil/. The CPARS User Manual, registration for On Line Training for Contractor Representatives, and a practice application may be found at this site.

(e) Within 60 days after the end of a performance period, the Contracting Officer will complete an interim or final past performance evaluation, and the report will be accessible at http://www.cpars.csd.disa.mil/.

Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment. Comments are limited to the space provided in Block 22. Your comments should focus on objective facts in the Assessing Official's narrative and should provide your views on the causes and ramifications of the assessed performance. In addition to the ratings and supporting narratives, blocks 1 - 17 should be reviewed for accuracy, as these include key fields that will be used by the Government to identify your firm in future source selection actions. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in Block 22, and then signing and dating Block 23 of the form. Without a statement in Block 22, you will be unable to sign and submit the evaluation back to the Government. If you do not sign and submit the CPAR within 30 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment."

Your response is due within 30 calendar days after receipt of the CPAR.

(f) The following guidelines apply concerning your use of the past performance evaluation:

(1) Protect the evaluation as "source selection information." After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the Contracting Officer for instructions.

(2) Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

(3) Prohibit the use of or reference to evaluation data for advertising, promotional material, preaward surveys, responsibility determinations, production readiness reviews, or other similar purposes.

(g) If you wish to discuss a past performance evaluation, you should request a meeting in writing to the Contracting Officer no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 30-day review period.

(h) A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of notice)

H - Special Contract Requirements

Clauses

PART 1403 IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST

1403.570 Restrictions on contractor advertising.

PRESERVATION OF HISTORICAL AND ARCHEOLOGICAL DATA (NOV 2007)

(a) The Historic and Archeological Data Preservation Act of 1974, provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

(b) If, in connection with operations under this contract, the Contractor, subcontractors, or the employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the cultural value and shall notify the Contracting Officer in writing, giving the location and nature of the findings. No objects of cultural resource value may be removed.

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the Changes clause.

(d) The Contractor will be responsible for protecting the cultural resources within the effected area from damage. In addition, the contractor will be liable for all damage to the identified cultural resources caused by their actions or the actions of their agents or representatives. The Contractor shall immediately notify the Contracting Officer or his representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed.

(e) The Contractor agrees to insert this paragraph in all subcontracts that involve the performance of work on the terrain of the site.

Alternate 1:

Insert the following paragraph (f) if the work is being performed on tribal lands:

(f) If the discovery occurs on tribal lands, the Contractor shall immediately orally notify the responsible tribal official and the Contracting Officer, and follow with written confirmation within 2 days to the responsible tribal official and the Contracting Officer. The contact information for the tribal official may be obtained at: http://web.cast.uark.edu/other/nps/nacd.

(End of Clause)

AUTHORITIES AND DELEGATIONS (SEPT 2011)

Authorities and Delegations (SEP 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting

Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum.

The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

ORGANIZATIONAL CONFLICT OF INTEREST DISCLOSURE (NOV 2007)

1. Definition. Organizational conflict of interest means that because of other activities or relationships with other persons, a person is unable or potentially unable to render impartial assistance or advice to the Government, or the person¿s objectivity in performing the contract work is or might be otherwise impaired, or a person has an unfair competitive advantage.

2. Disclosure. By submission of this offer, offeror represents that it is not aware of any information bearing on the existence of any actual or potential organizational conflicts of interest in connection with this solicitation or any resulting contract, except as provided in its disclosure statement. In the disclosure statement, list any potential or actual organizational conflicts of interest. Describe all relevant information concerning any past, present, or planned interests bearing on whether this firm (including its chief executives and directors, any proposed consultants or subcontractors) may have a potential organizational conflict of interest. If no potential or actual conflicts exist, so indicate with a check mark:

____ No potential or actual organizational conflicts of interest are known.

3. Failure to provide the disclosure or representation will be deemed a minor informality (FAR 14.405) and the offeror will be required to promptly correct the omission. Refusal to provide the disclosure or representation and any additional information as required will result in disqualification of the offeror for award.

4. The contractor agrees that, if after award he discovers an organizational conflict of interest with respect to this contract, he shall make an immediate and full disclosure in writing to the Contracting Officer, which shall include a description of the action which the contractor has taken or proposes to take to avoid, eliminate, or neutralize the conflict. The Government may, however, terminate the contract for the convenience of the Government if it would be in the best interests of the Government.

5. In the event that the contractor was aware of organizational conflict of interest prior to the award of this contract and failed to disclose the conflict to the Contracting Officer, the Government may terminate the contract at no cost to the Government.

6. If the Contracting Officer determines that a potential or actual conflict exists, the offeror will not receive an award unless the conflict can be avoided or otherwise resolved through the inclusion of a special contract clause or other appropriate means. The terms of any special clause are subject to negotiation.

Offerors should refer to FAR Subpart 9.5 for policies and procedures for avoiding, neutralizing, or mitigating organizational conflicts of interest.

Alternate 1:

When a potential or actual organizational conflict of interest is known to the Government, replace paragraph 2 with:

2. The contracting officer considers that there is potential for organizational conflicts of interest involving this procurement or services to be performed under the resultant contract, as follows:

None

By submission of this offer, offeror represents that it is not aware of any information bearing on the existence of any actual or potential organizational conflicts of interest in connection with this solicitation or any resulting contract, except as provided in its disclosure statement. In the disclosure statement, list any potential or actual organizational conflicts of interest. Describe all relevant information concerning any past, present, or planned interests bearing on whether this firm (including its chief executives and directors, any proposed consultants or subcontractors) may have a potential organizational conflict of interest. If no potential or actual conflicts exist, so indicate with a check mark:

____ No potential or actual organizational conflicts of interest exist.

(End of Clause)

Agency Protests

(a) Interested parties may request an independent review at a level above the Contracting Officer of protests filed directly with the agency. This review is available as an alternative to consideration of the protest by the Contracting Officer or as an appeal of the Contracting Officer's response to the protest. An interested party may:

(1) Protest to the Contracting Officer;

(2) Protest directly to the Bureau Procurement Chief without first protesting to the Contracting Officer; or

(3) Appeal a contracting officer¿s decision to the Bureau Procurement Chief.

(b) Requests for Bureau Procurement Chief review should be addressed to:

National Park Service 1201 Eye Street NW 12th Floor, Room 578 Washington, DC 20005

(c) Requesting independent agency review will not extend the Government Accountability Office¿s (GAO¿s) timeliness requirements. Any subsequent protest to the GAO must be filed within ten days of knowledge of initial adverse agency action (see 4 CFR 21.2(a)(3).)

(End of Clause)

I - Contract Clauses

Clauses

52.203-5 Covenant Against Contingent Fees. (MAY 2014)

52.203-7 Anti-Kickback Procedures. (MAY 2014)

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights. (APR 2014)

52.222-50 Combating Trafficking in Persons. (MAR 2015)

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. (AUG 2011)

52.225-13 Restrictions on Certain Foreign Purchases. (JUN 2008)

52.232-27 Prompt payment for construction contracts. (MAY 2014)

52.232-39 Unenforceability of Unauthorized Obligations. (JUN 2013)

52.233-3 Protest after Award. (AUG 1996)

52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements.

(APR 1984)

52.244-6 Subcontracts for Commercial Items. (JUN 2016)

52.246-12 Inspection of Construction. (APR 1996)

1452.204-70 Release of Claims (JUL 1996)

1452.210-70 Brand Name or Equal (JUL 1996)

1452.225-70 Use of Foreign Construction Materials (JUL 1996)

1452.228-70 Liability Insurance (JUL 1996)

1452.236-70 Prohibition Against Use of Lead-based Paint (JUL 1996)

1480.602 Performance and payment bonds.

J - List of Documents, Exhibits and Other Attachments

List of Documents, Exhibits, and Other Attachments

Attachment Number Title Date

1 Attachment 1, Section B, Supplies or Services and Price 08/09/2016 2 Attachment 2, Section C, Descriptions and Specifications 08/09/2016

Attachment Number Title Date

3 Attachment 3, Section D, Packaging and Marking 08/09/2016 4 Attachment 4, Section E, Inspection and Acceptance 08/09/2016 5 Attachment 5, Section F, Deliveries or Performance 08/09/2016 6 Attachment 6, Section G, Contract Administration Data 08/09/2016 7 Attachment 7, Section H, Special Contract Requirements 08/09/2016

8 Attachment 8, Section J, List of Documents, Exhibits and Other Attachments 08/09/2016

9 Attachment 9, Section L, Instructions, Conditions and Notice to Bidders 08/09/2016

10 Attachment 10, Section M, Evaluation Factors for Award 08/09/2016 11 Attachment 11, General Decision Number: P20150104 08/09/2016 12 Attachment 12, Past Performance Questionnaire 08/09/2016 13 Attachment 13, Johnstown Flood NM Drawings 08/09/2016

Clauses

K - Representations, Certifications, and Other Statements of Bidders

Clauses

52.204-8 Annual Representations and Certifications. (APR 2016)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238160.

(2) The small business size standard is $15 million average annual receipts for the last three years..

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in the System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

___ (i) Paragraph (d) applies.

___ (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless-

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include provision at 52.204-7, System for Award Management.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations- Representation.

(vi) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(viii) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(ix) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(x) 52.219-1, Small Business Program Representations (Basic & Alternate I).

This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xi) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiii) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xv) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvi) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xvii) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xviii) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xix) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xx) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan-Certification. This provision applies to all solicitations.

(xxi) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications.

This provision applies to all solicitations.

(xxii) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

(Contracting Officer check as appropriate.)

[ ] (i) 52.204-17, Ownership or Control of Offeror.

[ ] (ii) 52.204-20, Predecessor of Offeror.

[ ] (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[ ] (iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Certification.

[ ] (v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Certification.

[ ] (vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

[ ] (vii) 52.227-6, Royalty Information.

[ ] (A) Basic.

[ ] (B) Alternate I.

[ ] (viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM Web site accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph

(c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below (offeror to insert changes, identifying change by clause number, title, date). These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause No. Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.204-19 Incorporation by Reference of Representations and Certifications. (DEC 2014)

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. (OCT 2015)

52.236-28 Preparation of Proposals - Construction. (OCT 1997)

L - Instructions,Conditions, and Notices to Bidders

52.233-2 Service of Protest. (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from HPTC, National Park Service, 4801A Urbana Pike, Frederick, MD 21704

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

1452.215-71 Use and Disclosure of Proposal Information-Department of the Interior. (APR 1984)

1452.233-2 Service of Protest

M - Evaluation Factors for Award