18R0041_NMR_Spectrometer.docx

DOCX document 106 KB Posted Mar 13, 2018

Attached to: Nuclear Magnetic Resonance (NMR) Spectrometer
Solicitation number: N6893618R0041
Issued by: Department of the Navy Naval Air Systems Command Naval Air Warfare Center

About this file

From the source

18R0041 NMR Spectrometer Commercial Solicitation

View the file

Other files

File	Type	Posted
18R0041_Specifications.docx	DOCX document	Mar 13, 2018

On GovTribe

Work with this file

Download the original file
Contacts named in this file
Similar government files
Ask GovTribe AI about this file

Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

N6893618R0041

Section A - Solicitation/Contract Form

CLAUSES INCORPORATED BY FULL TEXT

FOR YOUR INFORMATION:

The following addresses and points of contact are provided:

Name:	Tabitha Weaver
Phone:	(760) 939- 8751
DSN:	437- 8751
FAX:	(760) 939-

Email address: tabitha.weaver@navy.mil

U.S. Postal Service Mailing Address:

COMMANDER

CODE 254210D (T. WEAVER – 760-939-8751)

NAVAIRWARCENWPNDIV

429 E. BOWEN RD. MAIL STOP 4015

CHINA LAKE, CA 93555-6108

Direct Delivery Address (UPS, FedEx, etc.):

COMMANDER

CODE 254210D (T. WEAVER)

NAVAIRWARCENWPNDIV

BLDG 982, MAIL STOP 4015

CHINA LAKE, CA 93555-6108

Section B - Supplies or Services and Prices

ITEM NO

SUPPLIES/SERVICES

QUANTITY

UNIT

UNIT PRICE

AMOUNT

Each

Nuclear Magnetic Resonance Spectrometer

FFP

The contractor shall provide an Nuclear Magnetic Resonance (NMR) Spectrometer as shown in the attached specification.

FOB: Destination

NSN: 66301000000824

PURCHASE REQUEST NUMBER: 1300686607

NET AMT

Section D - Packaging and Marking

5252.247-9508	PROHIBITED PACKING MATERIALS (NAVAIR)(JUN 1998)
	The use of asbestos, excelsior, newspaper or shredded paper (all types including waxed paper, computer paper and similar hydroscopic or non-neutral material) is prohibited. In addition, loose fill polystyrene is prohibited for shipboard use.

5252.247-9520	PRESERVATION, PACKAGING, AND PACKING (NAVAIR)(OCT 2005)
	(a) The contractor shall preserve, pack and package items procured for system stock, overseas destinations or ships at sea, in accordance with the MIL-STD-2073-1 Level A requirements delineated in the schedule or elsewhere in the contract or order. If specific requirements are not included in the contract or order, the contractor shall preserve and package in accordance with previously approved level A requirements, within the technical parameters contained in MIL-STD-2073-1. Preservation and packing materials shall be fire retardant/non-combustible as prescribed in the specific packaging requirements in the contract or order, and to the maximum extent practicable.
	(b) If the packaging materials specified in the contract or order are not fire retardant, and fire retardant varieties are included in commodity specifications for these materials, the contractor shall use fire retardant varieties. Fire retardant packaging materials are not required for items not used aboard ship. The use of plastic packaging materials is prohibited unless prescribed in specific packaging requirements in the contract or order, or unless required to adequately protect the item from damage.
	(c) For items procured for installation/immediate use, the contractor shall preserve and package in accordance with the Level C requirements of MIL-STD-2073-1. Packing for shipment (i.e., shipping container) shall be in accordance with MIL-STD-2073-1, Level A, for overseas surface shipments that are not containerized and all deliveries to ships at sea; Level B for all remaining overseas shipments; Level C or domestic shipments of items consumed at first destination. Fire retardant materials are not required in packing (i.e., shipping container) operations. All units, intermediate and shipping containers, shall be marked in accordance with MIL-STD-129. The use of shredded paper, excelsior, polystyrene and other loose-fill materials as a cushion is prohibited in all packaging and packing operation.
	(d) In accordance with 29 CFR, the contractor shall ensure that the following caution label is placed on all units, intermediate and shipping containers for all items containing asbestos in a form that can be inhaled:

CAUTION

CONTAINS ASBESTOS FIBERS

AVOID CREATING DUST

BREATHING ASBESTOS DUST MAY CAUSE SERIOUS BODILY HARM

(e) All items containing asbestos in a form that can be inhaled shall be packaged in sealed, impermeable bags or other impermeable containers, as required by 29 CFR.

NOTE TO SUPPLIERS: If the supplies to be furnished on this document require the asbestos caution label described above, the contractor shall notify the contract administrator indicated in the schedule prior to shipment.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN

INSPECT AT

INSPECT BY

ACCEPT AT

ACCEPT BY

0001

Destination

Government

Destination

Government

CLAUSES INCORPORATED BY REFERENCE

52.246-2

Inspection Of Supplies--Fixed Price

AUG 1996

52.246-16

Responsibility For Supplies

APR 1984

252.246-7000

Material Inspection And Receiving Report

MAR 2008

5252.246-9512	INSPECTION AND ACCEPTANCE (NAVAIR)(OCT 2005)
	(a) Inspection and acceptance of the supplies or services to be furnished hereunder shall be performed by [____*____].
	(b) Acceptance of all Contract Line Items/Sub Line Items (CLINs/SLINs) shall be made by signature of the accepting authority on a DD 250 submitted through the WAWF system. Acceptance will only occur when the accepting authority is sure that inspections performed demonstrate compliance with contract requirements.

* To be completed at time of award.

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN

DELIVERY DATE

QUANTITY

SHIP TO ADDRESS

DODAAC / CAGE

0001

01-OCT-2018

CDR NAWCWD CODE 4L4200D

LAWRENCE BALDWIN

1900 N KNOX ROAD STOP 6303

CHINA LAKE CA 93555

(760) 939-5270 FOB: Destination N68936

52.242-15

Stop-Work Order

AUG 1989

52.247-34

F.O.B. Destination

NOV 1991

F-TXT-10 SHIPPING INSTRUCTIONS (CHINA LAKE) (OCT 2017)

SHIP TO:	NAVAL AIR WARFARE CENTER WEAPONS DIVISION (NAWCWD)
		Attn: NAWCWD,(Lawrence Baldwin)

1900 N. KNOX RD. STOP 6302

CHINA LAKE, CA 93555-6106

Failure to mark each shipping label and packing list as indicated above may result in return of shipment at your expense, or will cause a delay in processing your invoice for payment.

DOCK HOURS are Monday through Thursday, and Alternating Fridays, 0730-1530. If you anticipate making delivery on a Friday please call Receiving at (760)939-2305 to verify receiving dock hours.

Section G - Contract Administration Data

252.232-7006	WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)
	(a) Definitions, as used in this clause--
	"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.
	"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).
	"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.
	(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.
	(c) WAWF access. To access WAWF, the Contractor shall--
		(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and
		(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.
	(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/.
	(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.
	(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:
		(1) Document type. The Contractor shall use the following document type(s).
	______________________________*_____________________________________________
	(Contracting Officer: Insert applicable document type(s). Note: If a "Combo" document type is identified but not supportable by the Contractor's business systems, an "Invoice" (stand-alone) and "Receiving Report" (stand-alone) document type may be used instead.)
		(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.
	________________________________*___________________________________________
	(Contracting Officer: Insert inspection and acceptance locations or "Not applicable.")
		(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*
Field Name in WAWF			Data to be entered in WAWF
Pay Official DoDAAC:			______________*__________
Issue By DoDAAC:			______________*__________
Admin DoDAAC:			______________*__________
Inspect By DoDAAC:			______________*__________
Ship To Code:				______________*__________
Ship From Code:			______________*__________
Mark For Code:			______________*__________
Service Approver (DoDAAC):		______________*__________
Service Acceptor (DoDAAC):		______________*__________
Accept at Other DoDAAC:		______________*________
LPO DoDAAC:			______________*_________
DCAA Auditor DoDAAC:		______________*_______
Other DoDAAC(s):			______________*__________
(*Contracting Officer: Insert applicable DoDAAC information or "See schedule" if multiple ship to/acceptance locations apply, or "Not applicable.")
	(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.
	(5) WAWF email notifications. The Contractor shall enter the email address identified below in the "Send Additional Email Notifications" field of WAWF once a document is submitted in the system.

(Contracting Officer: Insert applicable email addresses or "Not applicable.")

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact. For Navy WAWF questions call DFAS Customer Care 1-800-756-4571 option 6
	(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

*To be completed at time of award

5252.211- 9510	CONTRACTOR EMPLOYEES (NAVAIR)(MAY 2011)
	(a) In all situations where contractor personnel status is not obvious, all contractor personnel are required to identify themselves to avoid creating an impression to the public, agency officials, or Congress that such contractor personnel are Government officials. This can occur during meeting attendance, through written (letter or email) correspondence or verbal discussions (in person or telephonic), when making presentations, or in other situations where their contractor status is not obvious to third parties. This list is not exhaustive. Therefore, the contractor employee(s) shall:
		(1) Not by word or deed give the impression or appearance of being a Government employee;
		(2) Wear appropriate badges visible above the waist that identify them as contractor employees when in Government spaces, at a Government-sponsored event, or an event outside normal work spaces in support of the contract/order;
		(3) Clearly identify themselves as contractor employees in telephone conversations and in all formal and informal written and electronic correspondence. Identification shall include the name of the company for whom they work;
		(4) Identify themselves by name, their company name, if they are a subcontractor the name of the prime contractor their company is supporting, as well as the Government office they are supporting when participating in meetings, conferences, and other interactions in which all parties are not in daily contact with the individual contractor employee; and
		(5) Be able to provide, when asked, the full number of the contract/order under which they are performing, and the name of the Contracting Officer’s Representative.
	(b) If wearing a badge is a risk to safety and/or security, then an alternative means of identification maybe utilized if endorsed by the Contracting Officer’s Representative and approved by the Contracting Officer.
	(c) The Contracting Officer will make final determination of compliance with regulations with regard to proper identification of contractor employees.

5252.242-9511	CONTRACT ADMINISTRATION DATA (NAVAIR)(NOV 2017)
	(a) Contract Administration Office.
		(1) Contract administration functions (see FAR 42.302(a) and DFARS 242.302(a)) are assigned to: See the ADMINISTERED BY Block on the face page of the contract, modification, or order.
	(b) Special Instructions (see FAR 42.202(b) and (c)):
		(1) The following contract administration functions are retained (see FAR 42.302(a) and DFARS 242.302(a)):
		Functions Retained
	Retained for Performance By:

None

N/A

(2) The following additional contract administration functions are assigned (see FAR 42.302(b)):

Additional Functions

Retained for Performance By:

N/A

(c) Inquiries regarding payment should be referred to: MyInvoice through the Wide Area Workflow eBusiness Suite: https://wawf.eb.mil.

G-TXT-01	ATTENTION! E-MAIL ADDRESS REQUIRED FOR DISTRIBUTION
	All Naval Air Warfare Center Weapons Division Contracts/ Purchase Orders and other related documents are now distributed by electronic mail.
	Please provide the e-mail address to which distribution of contracts/purchase orders should be made.
	E-Mail Address:___________________________________________________

Section H - Special Contract Requirements

5252.211-9502	GOVERNMENT INSTALLATION WORK SCHEDULE (NAVAIR)(DEC 2014)
	(a) The Holidays applicable to this contract are: New Year's Day, Martin Luther King's Birthday, Presidents' Birthday, Memorial Day, Independence Day, Labor Day, Columbus Day, Veteran's Day, Thanksgiving Day, and Christmas Day.
	(b) In the event that any of the above holidays occur on a Saturday or Sunday, or alternate Friday, then such holiday shall be observed as they are by the assigned Government employees at the using activity.
	(c) The Naval Air Warfare Center Weapons Division works a 4/5/9 work schedule. Therefore alternate Fridays are not a part of the normal workweek for work performed on-site at a Naval Air Warfare Center Weapons Division site. The majority of the Government offices are closed on alternate Fridays.
	(d) No deviation in the normal workweek will be permitted without express advance approval by the designated Contracting Officer with coordination of the using departments.

Section I - Contract Clauses

52.203-3

Gratuities

APR 1984

52.203-6 Alt I

Restrictions On Subcontractor Sales To The Government (Sep 2006) -- Alternate I

OCT 1995

52.204-4

Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7

System for Award Management

OCT 2016

52.204-10

Reporting Executive Compensation and First-Tier Subcontract Awards

OCT 2016

52.204-13

System for Award Management Maintenance

OCT 2016

52.204-19

Incorporation by Reference of Representations and Certifications.

DEC 2014

52.204-22

Alternative Line Item Proposal

JAN 2017

52.209-6

Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9

Updates of Publicly Available Information Regarding Responsibility Matters

JUL 2013

52.209-10

Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.212-4

Contract Terms and Conditions--Commercial Items

JAN 2017

52.219-4

Notice of Price Evaluation Preference for HUBZone Small Business Concerns

OCT 2014

52.219-8

Utilization of Small Business Concerns

NOV 2016

52.219-28

Post-Award Small Business Program Rerepresentation

JUL 2013

52.222-3

Convict Labor

JUN 2003

52.222-19

Child Labor -- Cooperation with Authorities and Remedies

JAN 2018

52.222-21

Prohibition Of Segregated Facilities

APR 2015

52.222-25

Affirmative Action Compliance

APR 1984

52.222-26

Equal Opportunity

SEP 2016

52.222-35

Equal Opportunity for Veterans

OCT 2015

52.222-36

Equal Opportunity for Workers with Disabilities

JUL 2014

52.222-37

Employment Reports on Veterans

FEB 2016

52.222-40

Notification of Employee Rights Under the National Labor Relations Act

DEC 2010

52.222-50

Combating Trafficking in Persons

MAR 2015

52.222-50

Combating Trafficking in Persons

MAR 2015

52.222-54

Employment Eligibility Verification

OCT 2015

52.223-6

Drug-Free Workplace

MAY 2001

52.223-11

Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons.

JUN 2016

52.223-18

Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-13

Restrictions on Certain Foreign Purchases

JUN 2008

52.227-1

Authorization and Consent

DEC 2007

52.227-2

Notice And Assistance Regarding Patent And Copyright Infringement

DEC 2007

52.232-17

Interest

MAY 2014

52.232-33

Payment by Electronic Funds Transfer--System for Award Management

JUL 2013

52.232-39

Unenforceability of Unauthorized Obligations

JUN 2013

52.232-40

Providing Accelerated Payments to Small Business Subcontractors

DEC 2013

52.233-3

Protest After Award

AUG 1996

52.233-4

Applicable Law for Breach of Contract Claim

OCT 2004

52.242-13

Bankruptcy

JUL 1995

52.243-1

Changes--Fixed Price

AUG 1987

52.253-1

Computer Generated Forms

JAN 1991

252.203-7000

Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7002

Requirement to Inform Employees of Whistleblower Rights

SEP 2013

252.204-7000

Disclosure Of Information

OCT 2016

252.204-7003

Control Of Government Personnel Work Product

APR 1992

252.204-7004 Alt A

System for Award Management Alternate A

FEB 2014

252.204-7006

Billing Instructions

OCT 2005

252.204-7011

Alternative Line Item Structure

SEP 2011

252.204-7012

Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.204-7014

Limitations on the Use or Disclosure of Information by Litigation Support Contractors

MAY 2016

252.204-7015

Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.209-7004

Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.213-7000

Notice to Prospective Suppliers on Use of Past Performance Information Retrieval System--Statistical Reporting in Past Performance Evaluations

JUN 2015

252.225-7001

Buy American And Balance Of Payments Program-- Basic (Dec 2017)

DEC 2017

252.225-7002

Qualifying Country Sources As Subcontractors

DEC 2017

252.225-7012

Preference For Certain Domestic Commodities

DEC 2017

252.225-7048

Export-Controlled Items

JUN 2013

252.232-7003

Electronic Submission of Payment Requests and Receiving Reports

JUN 2012

252.232-7010

Levies on Contract Payments

DEC 2006

252.243-7001

Pricing Of Contract Modifications

DEC 1991

252.243-7002

Requests for Equitable Adjustment

DEC 2012

252.246-7003

Notification of Potential Safety Issues

JUN 2013

252.246-7007

Contractor Counterfeit Electronic Part Detection and Avoidance System

AUG 2016

52.212-5	CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS--COMMERCIAL ITEMS (DEVIATION 2013-O0019)(JAN 2018)
	(a) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (a) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation.
		(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.
		(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.
		(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.
	(b)(1) Notwithstanding the requirements of any other clause in this contract, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (b)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause--
			(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015)(41 U.S.C. 3509).
			(ii) 52.219-8, Utilization of Small Business Concerns (Nov 2016)(15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.
			(iii) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495). Flow down required in accordance with paragraph (1) of FAR Clause 52.222-17.
			(iv) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).
			(v) 52.222-26, Equal Opportunity (Sep 2016)(E.O. 11246).
			(vi) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212).
			(vii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014)(29 U.S.C. 793).
			(viii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017)(E.O. 13706).
			(ix) 52.222-37, Employment Reports on Veterans (Feb 2016)(38 U.S.C. 4212).
			(x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010)(E.O. 13496). Flow down required in accordance with paragraph (f) of clause 52.222-40.
			(xi) 52.222-41, Service Contract Labor Standards (May 2014)(41 U.S.C. Chapter 67).
			(xii)[ ](A) 52.222-50, Combating Trafficking in Persons (Mar 2015)(22 U.S.C. chapter 78 and E.O. 13627).
			[ ](B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. 78 and E.O. 13627).
			(xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standard to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. Chapter 67).
			(xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standard to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. Chapter 67).
			(xv) 52.222-54, Employment Eligibility Verification (Oct 2015).
			(xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015)(E.O. 13658).
			(xvii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706).
			(xviii)(A) 52.224-3, Privacy Training (Jan 2017)(5 U.S.C. 552a)
			(B) Alternate I (Jan 2017) of 52.224-3.
			(xix) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016)(Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).
			(xx) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014)(42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.
			(xxi) 52.247-64, Preference for Privately-Owned U.S.- Flag Commercial Vessels (Feb 2006)(46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.
		(2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

52.252-2	CLAUSES INCORPORATED BY REFERENCE (FEB 1998)
	This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/far/ or http://farsite.hill.af.mil.

52.252-6	AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)
	(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.
	(b) The use in this solicitation or contract of any Defense Federal Acquisition Regulation (48 CFR Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.211-7003	ITEM UNIQUE IDENTIFICATION AND VALUATION (MAR 2016)
	(a) Definitions. As used in this clause--
	“Automatic identification device” means a device, such as a reader or interrogator, used to retrieve data encoded on machine-readable media.
	“Concatenated unique item identifier” means--
		(1) For items that are serialized within the enterprise identifier, the linking together of the unique identifier data elements in order of the issuing agency code, enterprise identifier, and unique serial number within the enterprise identifier; or
		(2) For items that are serialized within the original part, lot, or batch number, the linking together of the unique identifier data elements in order of the issuing agency code; enterprise identifier; original part, lot, or batch number; and serial number within the original part, lot, or batch number.
	“Data matrix” means a two-dimensional matrix symbology, which is made up of square or, in some cases, round modules arranged within a perimeter finder pattern and uses the Error Checking and Correction 200(ECC200) specification found within International Standards Organization (ISO)/ International Electrotechnical Commission (IEC) 16022.
	“Data qualifier” means a specified character (or string of characters) that immediately precedes a data field that defines the general category or intended use of the data that follows.
	“DoD recognized unique identification equivalent” means a unique identification method that is in commercial use and has been recognized by DoD. All DoD recognized unique identification equivalents are listed at http://www.acq.osd.mil/dpap/pdi/uid/iuid_equivalents.html.
	“DoD item unique identification” means a system of marking items delivered to DoD with unique item identifiers that have machine-readable data elements to distinguish an item from all other like and unlike items. For items that are serialized within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier and a unique serial number. For items that are serialized within the part, lot, or batch number within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier; the original part, lot, or batch number; and the serial number.
	“Enterprise” means the entity (e.g., a manufacturer or vendor) responsible for assigning unique item identifiers to items.
	“Enterprise identifier” means a code that is uniquely assigned to an enterprise by an issuing agency.
	“Government's unit acquisition cost” means--
		(1) For fixed-price type line, subline, or exhibit line items, the unit price identified in the contract at the time of delivery;
		(2) For cost-type or undefinitized line, subline, or exhibit line items, the Contractor’s estimated fully burdened unit cost to the Government at the time of delivery; and
		(3) For items produced under a time-and-materials contract, the Contractor’s estimated fully burdened unit cost to the Government at the time of delivery.
	“Issuing agency” means an organization responsible for assigning a globally unique identifier to an enterprise, as indicated in the Register of Issuing Agency Codes for ISO/IEC 15459, located at http://www.aimglobal.org/?Reg_Authority15459.
	“Issuing agency code” means a code that designates the registration (or controlling) authority for the enterprise identifier.
	“Item” means a single hardware article or a single unit formed by a grouping of subassemblies, components, or constituent parts.
	“Lot or batch number” means an identifying number assigned by the enterprise to a designated group of items, usually referred to as either a lot or a batch, all of which were manufactured under identical conditions.
	“Machine-readable” means an automatic identification technology media, such as bar codes, contact memory buttons, radio frequency identification, or optical memory cards.
	“Original part number” means a combination of numbers or letters assigned by the enterprise at item creation to a class of items with the same form, fit, function, and interface.
	“Parent item” means the item assembly, intermediate component, or subassembly that has an embedded item with a unique item identifier or DoD recognized unique identification equivalent.
	“Serial number within the enterprise identifier” means a combination of numbers, letters, or symbols assigned by the enterprise to an item that provides for the differentiation of that item from any other like and unlike item and is never used again within the enterprise.
	“Serial number within the part, lot, or batch number” means a combination of numbers or letters assigned by the enterprise to an item that provides for the differentiation of that item from any other like item within a part, lot, or batch number assignment.
	“Serialization within the enterprise identifier” means each item produced is assigned a serial number that is unique among all the tangible items produced by the enterprise and is never used again. The enterprise is responsible for ensuring unique serialization within the enterprise identifier.
	“Serialization within the part, lot, or batch number” means each item of a particular part, lot, or batch number is assigned a unique serial number within that part, lot, or batch number assignment. The enterprise is responsible for ensuring unique serialization within the part, lot, or batch number within the enterprise identifier.
	“Type designation” means a combination of letters and numerals assigned by the Government to a major end item, assembly or subassembly, as appropriate, to provide a convenient means of differentiating between items having the same basic name and to indicate modifications and changes thereto.
	“Unique item identifier” means a set of data elements marked on items that is globally unique and unambiguous. The term includes a concatenated unique item identifier or a DoD recognized unique identification equivalent.
	“Unique item identifier type” means a designator to indicate which method of uniquely identifying a part has been used. The current list of accepted unique item identifier types is maintained at http://www.acq.osd.mil/dpap/pdi/uid/uii_types.html.
	(b) The Contractor shall deliver all items under a contract line, subline, or exhibit line item.
	(c) Unique item identifier.
		(1) The Contractor shall provide a unique item identifier for the following:
			(i) Delivered items for which the Government's unit acquisition cost is $5,000 or more, except for the following line items:
				Contract Line, Subline, or Exhibit Line Item Number Item Description
				_________________________________________N/A_________________________________
				________________________________________________________________________________
				________________________________________________________________________________
			(ii) Items for which the Government's unit acquisition cost is less than $5,000 that are identified in the Schedule or the following table:
				Contract Line, Subline, or Exhibit Line Item Number Item Description
				__________________________________________N/A___________________________________
				__________________________________________________________________________________
				__________________________________________________________________________________
					(If items as identified in the Schedule, insert "See Schedule" in this table.)
			(iii) Subassemblies, components, and parts embedded within delivered items, items with warranty requirements, DoD serially managed reparables and DoD serially managed nonreparables as specified in Attachment Number ______.
			(iv) Any item of special tooling or special test equipment as defined in FAR 2.101 that have been designated for preservation and storage for a Major Defense Acquisition Program as specified in Attachment Number ______.
			(v) Any item not included in (i), (ii), (iii), or (iv) for which the contractor creates and marks a unique item identified for traceability.
		(2) The unique item identifier assignment and its component data element combination shall not be duplicated on any other item marked or registered in the DoD Item Unique Identification Registry by the contractor.
		(3) The unique item identified component data elements shall be marked on an item using two dimensional data matrix symbology that complies with ISO/IEC International Standard 16022, Information technology - International symbology specification - Data matrix; ECC200 data matrix specification.
		(4) Data syntax and semantics of unique item identifiers. The Contractor shall ensure that--
			(i) The data elements (except issuing agency code) of the unique item identifier are encoded within the data matrix symbol that is marked on the item using one of the following three types of data qualifiers, as determined by the Contractor:
				(A) Application Identifiers (AIs) (Format Indicator 05 of ISO/IEC International Standard 15434), in accordance with ISO/IEC International Standard 15418, Information Technology--EAN/UCC Application Identifiers and Fact Data Identifiers and Maintenance and ANSI MH 10.8.2 Data Identifier and Application Identifier Standard.
				(B) Data Identifiers (DIs) (Format Indicator 06 of ISO/IEC International Standard 15434), in accordance with ISO/IEC International Standard 15418, Information Technology--EAN/UCC Application Identifiers and Fact Data Identifiers and Maintenance and ANSI MH 10.8.2 Data Identifier and Application Identifier Standard.
				(C) Text Element Identifiers (TEIs) (Format Indicator 12 of ISO/IEC International Standard 15434), in accordance with the Air Transport Association Common Support Data Dictionary; and
			(ii) The encoded data elements of the unique item identifier conform to the transfer structure, syntax, and coding of messages and data formats specified for Format Indicators 05, 06, and 12 in ISO/IEC International Standard 15434, Information Technology--Transfer Syntax for High Capacity Automatic Data Capture Media.
		(5) Unique item identifier.
			(i) The Contractor shall--
				(A) Determine whether to--
					(1) Serialize within the enterprise identifier;
					(2) Serialize within the part, lot, or batch number; or
					(3) Use a DoD recognized unique identification equivalent (e.g. Vehicle Identification Number); and
				(B) Place the data elements of the unique item identifier (enterprise identifier; serial number; DoD recognized unique identification equivalent; and for serialization within the part, lot, or batch number only: original part, lot, or batch number) on items requiring marking by paragraph (c)(1) of this clause, based on the criteria provided in MIL-STD-130, Identification Marking of U.S. Military Property, latest version;
				(C) Label shipments, storage containers and packages that contain uniquely identified items in accordance with the requirements of MIL-STD-129, Military Marking for Shipment and Storage, latest version; and
				(D) Verify that the marks on items and labels on shipments, storage containers, and packages are machine readable and conform to the applicable standards. The contractor shall use an automatic identification technology device for this verification that has been programmed to the requirements of Appendix A, MIL-STD-130, latest version.
			(ii) The issuing agency code--
				(A) Shall not be placed on the item; and
				(B) Shall be derived from the data qualifier for the enterprise identifier.
	(d) For each item that requires item unique identification under paragraph (c)(1)(i), (ii), or (iv) of this clause or when item unique identification is provided under paragraph (c)(1)(v), in addition to the information provided as part of the Material Inspection and Receiving Report specified elsewhere in this contract, the Contractor shall report at the time of delivery, either as part of the Material Inspection and Receiving Report, the following information:
		(1) Unique item identifier.
		(2) Unique item identifier type.
		(3) Issuing agency code (if concatenated unique item identifier is used).
		(4) Enterprise identifier (if concatenated unique item identifier is used).
		(5) Original part number (if there is serialization within the original part number).
		(6) Lot or batch number (if there is serialization within the lot or batch number).
		(7) Current part number (optional and only if not the same as the original part number).
		(8) Current part number effective date (optional and only if current part number is used).
		(9) Serial number (if concatenated unique item identifier is used).
		(10) Government's unit acquisition cost.
		(11) Unit of measure.
		(12) Type designation of the item as specified in the contract schedule, if any.
		(13) Whether the item is an item of Special Tooling or Special Test Equipment.
		(14) Whether the item is covered by a warranty.
	(e) For embedded subassemblies, components, and parts that require DoD unique item identification under paragraph (c)(1)(iii) of this clause or when item unique identification is provided under paragraph (c)(1)(v), the Contractor shall report as part of the Material Inspection and Receiving Report specified elsewhere in this contract, the following information:
		(1) Unique item identifier of the parent item under paragraph (c)(1) of this clause that contains the embedded subassembly, component, or part.
		(2) Unique item identifier of the embedded subassembly, component, or part.
		(3) Unique item identifier type.**
		(4) Issuing agency code (if concatenated unique item identifier is used).**
		(5) Enterprise identifier (if concatenated unique item identifier is used).**
		(6) Original part number (if there is serialization within the original part number).**
		(7) Lot or batch number (if there is serialization within the lot or batch number).**
		(8) Current part number (optional and only if not the same as the original part number).**
		(9) Current part number effective date (optional and only if current part number is used).**
		(10) Serial number (if concatenated unique item identifier is used).**
		(11) Description.
			** Once per item.
	(f) The Contractor shall submit the information required by paragraphs (d) and (e) of this clause as follows:
		(1) End items shall be reported using the receiving report capability in Wide Area WorkFlow (WAWF) in accordance with the clause at 252.232-7003. If WAWF is not required by this contract, and the contractor is not using WAWF, follow the procedures at http://dodprocurementtoolbox.com/site/uidregistry/.
		(2) Embedded items shall be reported by one of the following methods--
			(i) Use of the embedded items capability in WAWF;
			(ii) Direct data submission to the IUID Registry following the procedures and formats at http://dodprocurementtoolbox.com/site/uidregistry/; or
			(iii) Via WAWF as a deliverable attachment for exhibit line item number (fill in) _____, Unique Item Identified Report for Embedded Items, Contract Data Requirements List, DD Form 1423.
	(g) Subcontracts. If the Contractor acquires by subcontract, any item(s) for which item unique identification is required in accordance with paragraph (c)(1) of this clause, the Contractor shall include this clause, including this paragraph (g), in the applicable subcontract(s), including subcontracts for commercial items.

Section J - List of Documents, Exhibits and Other Attachments

Exhibit/Attachment Table of Contents

DOCUMENT TYPE

DESCRIPTION

PAGES

DATE

Attachment 1

Specifications

22-FEB-2018

Section K - Representations, Certifications and Other Statements of Offerors

52.203-11

Certification And Disclosure Regarding Payments To Influence Certain Federal Transactions

SEP 2007

52.204-19

Incorporation by Reference of Representations and Certifications.

DEC 2014

52.209-2

Prohibition on Contracting with Inverted Domestic Corporations--Representation

NOV 2015

52.214-34

Submission Of Offers In The English Language

APR 1991

52.214-35

Submission Of Offers In U.S. Currency

APR 1991

252.203-7005

Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7008

Compliance With Safeguarding Covered Defense Information Controls

OCT 2016

252.213-7000

Notice to Prospective Suppliers on Use of Past Performance Information Retrieval System--Statistical Reporting in Past Performance Evaluations

JUN 2015

252.222-7007

Representation Regarding Combating Trafficking in Persons

JAN 2015

252.225-7031

Secondary Arab Boycott Of Israel

JUN 2005

252.225-7050

Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism

JAN 2018

52.203-2	CERTIFICATE OF INDEPENDENT PRICE DETERMINATION (APR 1985)
	(a) The offeror certifies that --
		(1) The prices in this offer have been arrived at independently, without, for the purpose of restricting competition, any consultation, communication, or agreement with any other offeror or competitor relating to (i) those prices, (ii) the intention to submit an offer, or (iii) the methods of factors used to calculate the prices offered:
		(2) The prices in this offer have not been and will not be knowingly disclosed by the offeror, directly or indirectly, to any other offeror or competitor before bid opening (in the case of a sealed bid solicitation) or contract award (in the case of a negotiated solicitation) unless otherwise required by law; and
		(3) No attempt has been made or will be made by the offeror to induce any other concern to submit or not to submit an offer for the purpose of restricting competition.
	(b) Each signature on the offer is considered to be a certification by the signatory that the signatory --
		(1) Is the person in the offeror's organization responsible for determining the prices offered in this bid or proposal, and that the signatory has not participated and will not participate in any action contradictory to subparagraphs (a)(1) through (a)(3) above; or
		(2) (i) Has been authorized, in writing, to act as an agent for the following principals in certifying that those principals have not participated, and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) above ______________________________________________ (insert full name of person(s) in the offeror's organization responsible for determining the prices offered in this bid or proposal, and the title of his or her position in the offeror's organization);		(ii) As an authorized agent, does certify that the principals named in subdivision (b)(2)(i) above have not participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) above; and
			(iii) As an agent, has not personally participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) above.
	(c) If the offeror deletes or modifies subparagraph (a)(2) above, the offeror must furnish with its offer a signed statement setting forth in detail the circumstances of the disclosure.

52.209-7	INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013)
	(a) Definitions. As used in this provision--
	“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.
	“Federal contracts and grants with total value greater than $10,000,000” means--
		(1) The total value of all current, active contracts and grants, including all priced options; and
		(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).
	“ Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).
	(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.
	(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:
		(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:
			(i) In a criminal proceeding, a conviction.
			(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.
			(iii) In an administrative proceeding, a finding of fault and liability that results in--
				(A) The payment of a monetary fine or penalty of $5,000 or more; or
				(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.
			(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.
		(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.
	(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database at http://www.acquisition.gov (see 52.204-7).

52.209-11	REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)
	(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub.L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that --
		(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or
		(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.
	(b) The Offeror represents that --
		(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and
		(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under any Federal law within the preceding 24 months,

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS - COMMERCIAL ITEMS (NOV 2017) - ALTERNATE I (OCT 2014) An offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certifications electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision:

This is the start of the file's text. The full file is on GovTribe.

File details come from the government source that posted it.