FRANK_DREW_(WLM_175)_DS_JCC_15R0.docx

USCGC FRANK DREW (WLM 557)

SPECIFICATION FOR DOCKSIDE REPAIRS

FY2015

Developed By: Jonathan C Copley (Rev-0, 07 October 2014)

TABLE OF CONTENTS

USCGC FRANK DREW (WLM-175) DOCKSIDE AVAILABILITY FY2015

Revisions Record This page is used to record specification revisions, which may have occurred subsequent to a Revision 0 (Rev-0) package. Information listed is intended to provide contractors and field unit personnel a means to ensure all the current specification revision pages are present when reviewing or utilizing this specification package.

NOTE : All work item and paragraph numbers listed above for a given revision correspond to same numbers in the previous revision. This revised specification is self-contained with all of the above listed changes incorporated.

USCGC FRANK DREW (WLM-175) DOCKSIDE AVAILABILITY FY2015

Consolidated List of References The below-listed documents form a part of this specification to the extent specified herein. Approval/publication dates or revision dates/numbers are also identified, to ensure that same document versions are used at time of specification writing and during contract execution.

All Coast Guard drawings, technical publications, and standard specifications will be provided to contractors by the Coast Guard at an appropriate time, or upon request, free of charge. Other Government documents may be accessed – free of charge – as follows:

· MIL/DOD/CID Specifications: http://www.assistdocs.com/search/search_basic.cfm

· Commandant Instruction Manuals: http://www.uscg.mil/directives/default.asp

· Public Laws, Code of Federal Regulations, U.S Codes, and other Federal Government laws:: www.gpoaccess.gov The Government is aware of the following internet web links where contractors may procure commercial specifications:

· American Welding Society (AWS): http://www.awspubs.com/index.php

· ANSI, ASTM, IEEEE, NFPA, ASME, SAE Standards: http://www.techstreet.com/

· NFPA: http://www.nfpa.org

· SSPC Standards and pictorial guides: http://shopping.netsuite.com/sspcmarketplace

COAST GUARD DRAWINGS

Coast Guard Drawing 175 WLM 259-001, Rev A, Combustion Exhaust Diagram Coast Guard Drawing 175 WLM 259-005, Rev C, Combustion Exhaust A&D, Hull Block 970 Coast Guard Drawing 175 WLM 320-001, Rev AF, Electrical One Line Diagram Coast Guard Drawing 175 WLM 320-002, Rev F, Power System Deck Plan Frame 24 Fwd, Hull Blocks 910 & 901 Coast Guard Drawing 175 WLM 320-009, RevN, Power Sys Elem Wiring Diagram Coast Guard Drawing 175 WLM 330-002, Rev E, Lighting System Fr 24 Fwd, Hull Blk 910 & 901 Coast Guard Drawing 175 WLM 437-007, Rev P, Buoy Deck Control Sys Block, ISO & Elementary Wiring Diagram Coast Guard Drawing 175 WLM 512-001, Rev E, HVAC Diagram Coast Guard Drawing 175 WLM 528-002, Rev L, Weather Deck Drains Diagram Coast Guard Drawing 175 WLM 533-006, Rev D, Independent Tank Potable Water Hb 950 Coast Guard Drawing 175 WLM 556-001, Rev J, Hydraulic System Diagram Coast Guard Drawing 175 WLM 556-004, Rev D, Fwd Hydraulic System A/D Hull Block 920 Coast Guard Drawing 175 WLM 573-001, Rev M; Buoy Deck Arrangement Coast Guard Drawing 175 WLM 573-001, Rev R, Buoy Deck Arrangement Coast Guard Drawing 175 WLM 573-051, Rev B, Chain Stopper Structural Modifications for Hydraulic Roller Assembly Coast Guard Drawing 175 WLM 581-001, Rev E, Anchor Handling System Coast Guard Drawing 175 WLM 601-003, Rev F, Booklet of General Drawings (552-564) Coast Guard Drawing 175 WLM 601-003, Rev F, Booklet of General Plans Coast Guard Drawing 175 WLM 601-003, Rev F, Booklet of General Plans Coast Guard Drawing 175 WLM 601-003, Rev F, Booklet Of General Plans Coast Guard Drawing 175 WLM 601-03, Rev -L, Booklet of General Plans Coast Guard Drawing 175 WLM 612-1, Rev, Rails, Stanchions and Lifelines Coast Guard Drawing 175 WLM 801-019, Rev - C, Shell Expansion.

Coast Guard Drawing 175 WLM 801-06, Rev - J, Docking Plan.

Coast Guard Drawing 175 WLM 920-001, Rev K, Hull Block 920 Panels Coast Guard Drawing 175 WLM 920-002, Rev L, Hull Block 920 Modules Coast Guard Drawing 175 WLM 920-003, Rev G, Hull Block 920 Block Assembly Coast Guard Drawing 175-WLM 320-1, Rev U, Electrical One-Line Diagram Coast Guard Drawing 175-WLM 437-7, Rev L, Buoy Dk Control Sys Block, ISO & Elem Wrg Diag Coast Guard Drawing 175-WLM 505-002, Rev F, Mechanical Remote Valve Operators Arrangement & Details Coast Guard Drawing 175-WLM 506-001, Rev G, Overflows, Air Escapes & Sounding Tubes Diagrams Coast Guard Drawing 175-WLM 506-003, Rev D, Vents & Sounding Tubes A & D Frame 6 Fwd, Hull Block 901 Coast Guard Drawing 175-WLM 529-002, Rev G, Main Drainage System Diagram Coast Guard Drawing 175-WLM 549-001, Rev E, Onboard Lubrication Requirements Coast Guard Drawing 175-WLM 573-001, Rev K, Buoy Deck Arrangement Coast Guard Drawing 175-WLM 573-001, Rev R, Buoy Deck Arrangement Coast Guard Drawing 175-WLM 573-001, Rev T, Buoy Deck Arrangement Coast Guard Drawing 175-WLM 601-001, Rev N, General Arr, Inboard and Outboard Profiles Coast Guard Drawing 175-WLM 601-001, Rev P, General Arr Inboard and Outboard Profiles Coast Guard Drawing 175-WLM 601-003, Rev L, Booklet of General Plans Coast Guard Drawing 175-WLM 635-001, Rev F, Hull Thermal & Acoustic Insulation Schedule Coast Guard Drawing 175-WLM 801-015, Rev C, Scantlings, Decks & Platforms Coast Guard Drawing 175-WLM 910-002, Rev H, Hull Block 910 Modules Coast Guard Drawing 175-WLM 990-001, Rev J, Hull Block Erection Plan Coast Guard Drawing FL 2605-037, Rev-, Mechanical Chain Stopper 175' WLM & 225' WLB Re-installation Coast Guard Drawing FL 7101-573, Rev L, Buoy Chain Winch Assy Model CW1 Coast Guard Fleet Drawing FL-2605-29, Rev H, Chain Stopper System – Rising Sheave Assembly NAVSEA Drawing 2803-980209, Plates, Label NAVSEA Drawing 804-5773931, Rev A, Acoustic & Thermal Insulation For Compartments Installation Details

COAST GUARD PUBLICATIONS

Coast Guard Technical Publication (TP) 3631, Feb 2010. Manufacturer’s Instruction Book – SWBS Groups 573-581 Coast Guard Commandant Instruction (COMDTINST)_MI0360.3 (series), Coatings and Color Manual Coast Guard Technical Publication (TP) 3498, Aug 2013, Buoy Chain Winch Coast Guard Technical Publication (TP) 3498, Section A, Feb 2008, Buoy Chain Winch Coast Guard Technical Publication (TP) 3498,, Jul 1999, Buoy Chain Winch Coast Guard Technical Publication (TP) 3558, Nov 2010, Manufacturer's Instruction Book - SWBS Group(s) 573, Section 573-A (Winch, Cross Deck - Model Bmd 390), Section 573-B, (Winch, Cross Deck - Model Bmd 471) Coast Guard Technical Publication (TP) 3619, 13-AUG-98, Manufacturers Instruction Book-SWBS Group(s) 324 Coast Guard Technical Publication (TP) 3630, 07-JAN-97, Manufacturers Instruction Book-SWBS Group(s) 573 Coast Guard Technical Publication (TP) 3630, Manufacturer’s Instruction Book – SWBS Group 573 Coast Guard Technical Publication (TP) 3630, Section 573-A, Mar 2008, Manufacturer's Instruction Book-SWBS Group 573, Buoy Crane Coast Guard Technical Publication (TP) 3631, Mar 2007, Manufacturer’s Instruction Book-SWBS Group(s) 573-581, Section B, Cross Deck Winch – Appleton Marine Model BMD-463 Coast Guard Technical Publication (TP) 3632, Jul 2011, Manufacturer's Instruction Book-SWBS Groups 582-583 Coast Guard Technical Publication (TP) 3939, SWBS 573-A, Apr 2007, Rising Sheave Chain Stopper Coast Guard Technical Publication (TP) 5458, SWBS 555, Oct 2012, Winch, Radial – Model 50.2PT (270 WMEC A-Class) Naval Engineering Directive (NED) 5890-02, March 2005, Inspection and Test Procedure For Buoy Crane Model SB230-42 Onboard WLM 551-564 Surface Forces Logistics Center Standard Specification (SFLC Std Spec) 5000, Jan 2012, Inspect, Repair, And Test Auxiliary Machine Systems Surface Forces Logistics Center Standard Specification 0000 (SFLC Std Spec 0000), 2012, General Requirements Surface Forces Logistics Center Standard Specification (SFLC Std Spec) 0740, Jan 2009, Welding and Allied Processes Surface Forces Logistics Center Standard Specification 0740 (SFLC Std Spec 0740), 2012, Requirements for Welding and Allied Processes Surface Forces Logistics Center Standard Specification 0740 (SFLC Std Spec 0740), 2012, Welding and Allied Processes Surface Forces Logistics Center Standard Specification 0740 (SFLC Std Spec 0740), 2012, Welding and Allied Processes.

Surface Forces Logistics Center Standard Specification 5000 (SFLC Std Spec 5000), 2012, Auxiliary Machine Systems Installation Details Surface Forces Logistics Center Standard Specification 5000 (SFLC Std Spec 5000), 2012, Auxiliary Machine Systems Surface Forces Logistics Center Standard Specification 5100 (SFLC Std Spec 5100), 2012, Clean Shipboard Ventilation Systems Surface Forces Logistics Center Standard Specification 6310 (SFLC Std Spec 6310), 2012, Preserve Ship Structures Surface Forces Logistics Center Standard Specification 6310 (SFLC Std Spec 6310), 2012, Requirements for Preservation of Ship Structures Surface Forces Logistics Center Standard Specification 8636 (SFLC Std Spec 8636), 2012, Temporary Hull Accesses Surface Forces Logistics Command (SFLC) Naval Engineering Directive (NED) 5735-01, Inspection and Test Procedure for Buoy Chain Winch Model CW-1 Onboard WLM 551-564 and WLB 201-215, May 2010

OTHER REFERENCES

American National Standard Institute/American Water Works Association ANSI/AWWA C217, 2009, Petrolatum and Petroleum Wax Tape Coatings for the Exterior of Connections and Fittings for Steel Water Pipeline American National Standards Institute/American Water Works Association (ANSI/AWWA) C652, 2002, Disinfection of Water-Storage Facilities American National Standards Institute/American Water Works Association (ANSI/AWWA) C652, 2011, Disinfection of Water-Storage Facilities American National Standards Institute/NSF International (ANSI/NSF) 61, 2008, Drinking Water System Components - Health Effects ASTM International (ASTM) 6966, 2008, Standard Practice for Collection of Settled Dust Samples Using Wipe Sampling Methods for Subsequent Determination of Metals ASTM International (ASTM) A53, 2005, Standard Specification for Pipe, Steel, Black and Hot-Dipped, Zinc-Coated Welded and Seamless ASTM International (ASTM) D1330, 2004, Standard Specification for Rubber Sheet Gaskets ASTM International (ASTM) D5363, 2008, Standard Specification for Anaerobic Single Component Adhesives (AN) Code of Federal Regulations (CFR) Title 29, Part 1910, Jul 2008, Occupational Safety and Health Standards Code of Federal Regulations (CFR) Title 29, Part 1915, Jul 2008, Occupational Safety and Health Standards for Shipyard Employment Code of Federal Regulations (CFR) Title 29, Part 1915, Section 15, 2007, Shipyard Employment Code of Federal Regulations (CFR) Title 33 CFR, Jul 2010, Navigation and Navigable Waters Code of Federal Regulations (CFR) Title 40, Chapter I, 2008, Environmental Protection Agency Code of Federal Regulations (CFR) Title 49, Chapter I, 2008, Pipeline and Hazardous Materials Safety Administration, Department Of Transportation Commercial Item Description (CID) A-A-59588, 2005, Rubber Silicone DOD-STD-2188, Apr 1987, Babbitting of Bearing Shells Federal Specification (Fed Spec) HH-P-151, Mar 1991, Rubber-Sheet, Cloth Insert MIL-PRF-24176 , Oct 2004, Cement, Epoxy, Metal Repair And Hull Smoothing (Metric) MIL-S-45180, 1998; Sealing Compound, Gasket, Hydrocarbon Fluid and Water Resistant MIL-STD-419, Jul 1987, Cleaning and Protecting Piping, Tubing and Fittings for Hydraulic Power Transmission Equipment National Electrical Manufacturers Association (NEMA) Stds, Pub. No. AB4, 2003, Guidelines for Inspection and Preventive Maintenance of Molded Case Circuit Breakers Used in Commercial and Industrial Applications Society of Automotive Engineers (SAE) Aerospace Material Specification (AMS) C6183, 2007, Cork and Rubber Composition Sheet; For Aromatic Fuel and Oil Resistant Gaskets Society of Automotive Engineers (SAE) Aerospace Material Specification (AMS) C6183, 2007, Cork and Rubber Composition Sheet; For Aromatic Fuel And Oil Resistant Gaskets The Society for Protective Coatings (SSPC) Surface Preparation Specification No.11 (SSPC-SP 11), 2004, Power Tool Cleaning to Bare Metal The Society for Protective Coatings (SSPC)/NACE International (NACE) Joint Surface Preparation Standard SSPC-SP 10/NACE No.2, 2007, Near-White Blast Cleaning Underwriters Laboratories Inc. (UL) 489, May 2002, Molded Case Circuit Breaker

USCGC FRANK DREW (WLM-175) DOCKSIDE AVAILABILITY FY2015

Consolidated List of Government-furnished Property The following is a list of property, which the Government will furnish. This list supersedes any other material obligations indicated or implied by referenced drawings.

($/UNIT)

(DWG: AMD-1111-03 / PG 143

*Government-loaned property, which shall be returned to the vessel upon completion of the availability.

**New or refurbished equipment that the Government may provide for installation in place of existing equipment.

***Government-furnished property, which is to be supplied by either the vessel or the C4IT ServiceCenter

Consolidated List of Critical Inspection Items The following is a list of work items, which contain Critical Inspection reports, which the Contractor must complete within the first 25% of the availability contract period (see SFLC Std Spec 0000, paragraph 3.2.6.5 (Inspection report particulars)):

PC_175_WLM_1113

Principal Characteristics

175' WLM BUOY TENDER

PHYSICAL CHARACTERISTICS

MACHINERY CHARACTERISTICS

Two Ulstein 360 degree steerable Z-Drives, 403 SRPM @ 1600 ERPM

TANK CAPACITIES

00000_0714_FLT

REC_00000_FLT_ Commercial Project @ CG Facility (1212) General Requirements

1. SCOPE

1.1 Intent. This standard specification invokes general requirements for conducting vessel repairs performed by commercial contractors at a Coast Guard facility for Coast Guard vessels.

1.2 Term interchangeability. The terms 'Contractor', 'CG Yard', 'NAVSTA EVERETT', 'shipyard', 'Base', and 'Coast Guard Industrial' are used interchangeably in this specification. Where the primary service provider is Coast Guard personnel, references to contractor and other noted descriptors within this specification or within drawings, publications, SFLC Standard Specifications or other commercial and military references are deemed the same as prime service provider.

2. REFERENCES

Coast Guard Drawings None Coast Guard Publications Coast Guard Commandant Instruction (COMDTINST)_MI0360.3 (series), Coatings and Color Manual Surface Forces Logistics Center Standard Specification 0000 (SFLC Std Spec 0000), 2012, General Requirements Surface Forces Logistics Center Standard Specification 0740 (SFLC Std Spec 0740), 2012, Welding and Allied Processes Surface Forces Logistics Center Standard Specification 6310 (SFLC Std Spec 6310), 2012, Requirements for Preservation of Ship Structures Other References ASTM International (ASTM) 6966, 2008, Standard Practice for Collection of Settled Dust Samples Using Wipe Sampling Methods for Subsequent Determination of Metals Code of Federal Regulations (CFR) Title 29, Part 1910, Jul 2008, Occupational Safety and Health Standards The Society for Protective Coatings (SSPC) Surface Preparation Specification No.11 (SSPC-SP 11), 2004, Power Tool Cleaning to Bare Metal Code of Federal Regulations (CFR) Title 33 CFR, Jul 2010, Navigation and Navigable Waters Code of Federal Regulations (CFR) Title 40, Chapter I, 2008, Environmental Protection Agency Code of Federal Regulations (CFR) Title 49, Chapter I, 2008, Pipeline and Hazardous Materials Safety Administration, Department Of Transportation

3. REQUIREMENTS

3.1 General. The Contractor shall conform to all requirements specified in SFLC Std Spec 0000 and in this item, as applicable, during the performance of this availability.

NOTE

The requirements of paragraph 3.1 (General) applies to all work under the scope of this contract, whether explicitly stated in work items or not, and to all other work subsequently authorized by changes, modifications, or extensions to the contract.

3.2 Contractor-provided fire watch personnel. The Contractor shall provide fire watch personnel and equipment.

3.3 Preservation requirements. The Contractor shall accomplish all preservation tasks, including touch-ups, in accordance with SFLC Std Spec 6310.

3.3.1 Brand name approval. Ensure that all contractor-furnished coatings are in accordance with SFLC Std Spec 6310, Appendix C (Authorized Coatings for Use on Cutters and Boats).

3.3.2 Coating colors and system color schemes. Ensure that all colors and color coat/paint schemes are in accordance with (COMDTINST)_MI0360.3C , Chapter 11 (Cutter and Boat Colors Exterior and Interior).

NOTE

Unless a waiver has been granted (in writing) by the KO, deviations from authorized coatings (listed in Appendix C of SFLC Std Spec 6310) and colors and color schemes (provided in Chapter 5 of COMDTINST MI0360.3) are strictly prohibited.

3.4 Welding and brazing requirements. The Contractor shall perform all welding and allied processes, and NDI in accordance with SFLC Std Spec 0740.

3.5 Environmental protection requirements. The Contractor shall adhere to the following environmental protection requirements in accordance with the SFLC Stand Spec 0000:

3.5.1 USCG facilities. The Contractor shall provide and maintain environmental protection as defined in SFLC Std Spec 0000 Appendix B, Requirements for Environmental Protection at USCG Facilities, during the performance of this availability. Contractor shall plan for and provide environmental protective measures to control pollution that develops during normal practice, as well as plan for and provide environmental protective measures required to correct conditions that develop during the project. Contractor shall comply with applicable Federal, state, and local laws, codes, ordinances, and regulations in their entirety. Any reference to a specific portion of a Federal, state, or local law, code, ordinance, or regulation in this or any other item shall not be construed to mean that relief is provided from any other sections of the law, code, ordinance, or regulation.

3.5.1.1 USCG Generator status. The activity Generator Status for the Coast Guard Facility is “Large Quantity Generator. ”

3.5.1.2 Plans and permits. The CG Facility has unit specific permits including the following:

Spill Prevention Control and Countermeasures (SPCC) Plan: Unit has a SPCC Plan which requires certain unit-specific procedures be followed for the storage, inspection, and transfer of petroleum products in containers 55 gallons or greater.

National Pollutant Discharge Elimination System (NPDES) Storm Water (SW) Permit: Unit has an NPDES SW permit which requires unit-specific procedures be followed for the storage and inspection of equipment and materials which may contribute contaminants to storm water discharges.

Air Emission Permit: Unit has a Air Emission Permit which requires unit-specific procedures be followed for the emissions of VOCs and hazardous air pollutants.

3.5.2 Test and procedures. The Contractor shall be required to promptly conduct tests and procedures for the purpose of assessing whether operations are in compliance with applicable Environmental Laws. Analytical work shall be done by qualified laboratories; and where required by law, the laboratories shall be certified.

3.5.3 Regulatory notifications. The Contractor shall be responsible for all regulatory notification requirements in accordance with Federal, State and local regulations. In cases where the Coast Guard must also provide public notification, such as storm water permitting, the Contractor must coordinate with the Contracting Officer or COR, and if work is being performed at a USCG Facility, the local Facility Engineer or Engineering Officer. The Contractor shall submit copies of all regulatory notifications to the Contracting Officer and the local Facility Engineer or Engineering Officer prior to commencement of work activities. Regulatory notifications shall be provided for including but not limited to demolition, renovation, National Pollutant Discharge Elimination System (NPDES) defined site work, and remediation of controlled substances such as asbestos, hazardous waste, and lead paint.

3.5.4 Environmental manager. The Contractor shall appoint in writing an Environmental Manager for the project, and shall be responsible for coordinating Contractor compliance with Federal, State, local, and station environmental requirements. The Environmental Manager shall ensure compliance with Hazardous Waste Program requirements, including hazardous waste handling, storage, manifesting, and disposal; implement the Contractors’ Environmental Management Plan; ensure that all environmental permits are obtained, maintained, and closed out; ensure compliance with Storm Water Program Management requirements; ensure compliance with Hazardous Materials including storage, handling, and reporting requirements; as well as coordinate any remediation of regulated substances such as lead, asbestos, and polychlorinated biphenyl (PCB). This may be a collateral position; however the individual must be trained to adequately accomplish the following duties; ensure waste segregation and storage compatibility requirements are met; inspect and manage Satellite Accumulation areas; ensure only authorized personnel add wastes to containers; ensure all Contractor personnel are trained in 40 CFR requirements and individual position requirements; coordinate removal of waste containers; and maintain the Environmental Records binder and required documentation, including environmental permits compliance and close-out.

3.6 HW disposal. The Contractor shall be aware of the following:

3.6.1 No Contractor or Subcontractor shall have the authority to sign a Hazardous Waste Manifest using the Coast Guard facility’s EPA Generator ID Number or remove contract generated hazardous waste from the Coast Guard facility without COR or KO-approval.

3.6.2 Local environmental regulations at the Government facilities may be more stringent. As with all environmental regulations, the Contractor shall prepare for and comply with local and state regulations.

3.6.3 Coast Guard facilities do not maintain Facilities Response Plans (FRPs) per 33 CFR 154. Contractor shall furnish the FRP when required for over-the-water liquids transfers to and from vessels, and is required for oil/fuel transfers to/from vessels for 250 barrels (7,875 gallons) or more.

3.7.1 SFLC Std Spec 8634, Drydocking, Appendix A, page A5, paragraph A2.7.1.3 Side Blocks: Remove formula value shown as g – Acceleration of gravity – 32.3 Ft/sec2, and replace with formula value g - Acceleration of gravity - 32.174 ft/sec2.

3.7.2 SFLC Std Spec 0740, Welding and Allied Processes. SFLC Std Spec 0740 added Appendix E, Stray Current Protection: New Appendix is posted with SFLC Standard Specifications as a separate document on internet and intranet webpage.

3.7.2.1 SFLC Std Spec 0740, page 1, paragraph 1.2 Appendices: Add ‘Stray Current Protection’ to ‘Process Standard column of appendices table. Add ‘E’ to ‘Appendix’ column of appendices table.

3.7.2.2 SFLC Std Spec 0740, page 4, paragraph 3.1.3 Stray current protection: Add “The Contractor shall meet all requirements for stray current protection as specified in Appendix E - Stray Current Protection.” directly after paragraph 3.1.3 title.

3.7.2.3 SFLC Std Spec 0740, page 4, paragraph 3.1.3 Stray current protection: Delete paragraphs 3.1.3.1 and 3.1.3.2.

3.7.3 SFLC Std Spec 0450, Electrical Power for Contractor’s Tools and Equipment, page 1, paragraph 1.1 Intent: Add sentence, “Note that stray current protection for welding equipment is covered in SFLC Standard Specification 0740, Welding and Allied Processes, Appendix E.” to end of paragraph.

3.7.3.1 SFLC Std Spec 0450, page 5, paragraph 3.4 Equipment Grounding: Add sentence, “Stray current protection for welding equipment is covered in SFLC Standard Specification 0740, Welding and Allied Processes, Appendix E.” to end of paragraph.

3.7.3.2 SFLC Std Spec 0450, page 6, paragraph 3.4 Equipment Grounding: Delete paragraphs 3.4.1.4 and 3.4.1.5.

3.7.3.3 SFLC Std Spec 0450, page 6, paragraph 3.4 Equipment Grounding: Delete Figure 5.

3.7.4 SFLC Std Spec 0000, General Requirements, Appendix A Requirements for Environmental Protection has been superseded by SFLC Std Spec 0000, General Requirements, Appendix A Requirements for Environmental Protection at Contractor Operated (Non USCG) Facilities, with addition of SFLC Std Spec 0000 Appendix B Requirements for Environmental Protection at USCG Facilities. The new Appendices are posted with SFLC Standard Specifications as separate documents on SFLC Standard Specification webpage.

3.7.4.1 SFLC Std Spec 0000, page 22, paragraph 3.3.3.1 NOTE. Add "Flame-retardant polyethylene deck plate with a non-slip diamond pattern from 10 to 40mil thickness" to body of Note.

3.7.4.2 SFLC Std Spec 0000, page 3, bullet “ISC.” Delete “lead-contaminated materials.”

3.7.4.3 SFLC Std Spec 0000, page 27, after Note box under paragraph 3.3.13.1.2 add the following paragraphs:

“3.3.13.1.3 Dock and Sea trials. The Contractor shall conduct dock trials to test the work performed during the contract when required by individual work items (see 3.3.13 Tests and Inspections). This shall include operational tests or inspections, as appropriate, of all machinery, piping, wiring, insulation, preservation work, deck coverings, and any other article removed, moved, disturbed, or damaged by the Contractor in accomplishing the work outlined in the specification. Schedule for these specific dockside tests or inspections shall be included within the planning document (see 3.2.5 Planning document).

3.3.13.1.3.1 The Contractor shall provide a pier facility or allow the vessel to move to a Coast Guard pier to support dock trials. The Contractor shall not conduct trials that require the vessel to be waterborne while the vessel is floating inside a dock (e.g., graving dock, floating drydock).

3.3.13.1.3.2 Sea trials to conduct equipment operational tests are not required unless a Sea Trial Performance work item is specifically included within the specification.”

3.7.4.4 SFLC Std Spec 0000, page 11, paragraph 3.2.5, add the following bullets to the bulleted list:

Identifies the “critical paths” for the project.

Shows calculations for the “float” along the critical paths and labels the critical paths with the number of delay days the critical paths can absorb without affecting the final delivery date.

3.7.4.5 SFLC Std Spec 0000, page 11, Add the following Note between paragraphs 3.2.5 and 3.2.5.1:

NOTE

Float is the number of days that the critical paths can be delayed without affecting the final delivery date.

3.7.4.6 SFLC Std Spec 0000, page 12, add the following paragraphs and Note after Figure 1:

“3.2.5.4 When the critical path extends beyond or encroaches upon the final delivery date, provide a resource constraint and scheduling evaluation of the critical path before any request for extension will be entertained. Submit the resource constraint and scheduling evaluation via a CFR.

NOTE

The intent of the resource constraint and scheduling evaluation is to identify the resources necessary to ‘crash’ the critical path or make adjustments to the production schedule to meet the delivery date in lieu of a project extension.”

3.7.4.7 Std Spec 0000, General Requirements, page 4, paragraph 1.3 Acronyms and term definitions, “Paint Containing Lead” remove lead content percent of “0.06 percent by weight (0.12 mg/cm2, or 600 ppm)” and replace with “0.009 percent by weight (0.018 mg/cm2, or 90 ppm)”

3.7.5 SFLC Std Spec 6310, Requirements For Preservation Of Ship Structures, page 10, add “3.1.6.5 Preconstruction Primers. Also known as shop primers, preconstruction primers are used as a temporary coating to protect steel from corrosion during welding, storage, and fabrication. Preconstruction primers shall be removed prior to applying the permanent coating system on all critical coated surfaces. Preconstruction primers may be left in place in other interior areas (such as machinery spaces, habitability spaces, etc.) if they are intact, uncontaminated, and compatible with the overcoating system.”

3.7.5.1 Std Spec 6310, Appendix B, page B12 , the formatting for of Notes 17-19 change and add as per the following:

SFLC Std Spec 6310, Cutter And Boat Interior Painting Systems, Appendix B12, Note 17, delete sentence, “Persistent corrosion in a particular area of an aluminum bilge may dictate the need for a protective High Build Epoxy coating to be applied to that local area.”

SFLC Std Spec 6310, Cutter And Boat Interior Painting Systems, Appendix B12, Note 18, replace entire note with “Persistent corrosion in a particular area of an aluminum bilge may dictate the need for a protective High Build Epoxy coating to be applied to that local area. “ SFLC Std Spec 6310, Cutter And Boat Interior Painting Systems, Appendix B12, Note 19, replace entire note with “Painting plastic surfaces is highly discouraged, but after it is done once, it must be maintained.”

SFLC Std Spec 6310, Cutter And Boat Interior Painting Systems, Appendix B12, Add Note “20. For aluminum surfaces, remove all oil, grease, dirt, metal oxides (corrosion products) and other foreign material by cleaning per SSPC-SP 1 prior to blast cleaning and following blast cleaning immediately prior to coating. The end result of abrasive blasting will be a surface cleanliness similar to that of SSPC-SP 10 for steel with all coating removed.

3.7.5.2 Std Spec 6310, Appendix E, pages E1, E3, and E4, QA Inspection Forms QA-1, QA-3a, and QA-3b respectively, reference The Society for Protective Coatings (SSPC)/NACE International (NACE) Joint Surface Preparation Standard SSPC-SP 12/NACE No. 5 erroneously, and are corrected as per the following:

3.7.5.2.1 Std Spec 6310, Appendix E, pages E1, QA Inspection Form QA-1, Check point 5- Surface Preparation, check box description 2, replace “(i.e.: SSPC SP-12, SP-11, SP-10…).” with “(i.e.: SSPC SP-11, SP-10, SP WJ-2…).”

3.7.5.2.2 Std Spec 6310, Appendix E, page E3, QA Inspection Form QA-3a, Surface Preparation Method column of the Profile Achieved table, 2nd record, replace “SSPC-SP-12/NACE No. 5” with “SSPC-SP WJ-1/NACE WJ-1”.

3.7.5.2.2.1 Add record to table beneath “SSPC-SP WJ-1/NACE WJ-1” and label as “SSPC-SP WJ-2/NACE WJ-2”

3.7.5.2.2.2 Add record to table beneath “SSPC-SP WJ-2/NACE WJ-2” and label as “SSPC-SP WJ-3/NACE WJ-3”

3.7.5.2.2.3 Add record to table beneath “SSPC-SP WJ-3/NACE WJ-3” and label as “SSPC-SP WJ-4/NACE WJ-4”

3.7.5.2.3 Std Spec 6310, Appendix E, page E4, QA Inspection Form QA-3b, Surface Preparation Method column of the Profile Achieved table, 2nd record, replace “SSPC-SP-12/NACE No. 5” with “SSPC-SP WJ-1/NACE WJ-1”.

3.7.5.2.3.1 Add record to table beneath “SSPC-SP WJ-1/NACE WJ-1” and label as “SSPC-SP WJ-2/NACE WJ-2”

3.7.5.2.3.2 Add record to table beneath “SSPC-SP WJ-2/NACE WJ-2” and label as “SSPC-SP WJ-3/NACE WJ-3”

3.7.5.2.3.3 Add record to table beneath “SSPC-SP WJ-3/NACE WJ-3” and label as “SSPC-SP WJ-4/NACE WJ-4”

3.7.6 SFLC Std Spec 8635, Temporary Services, page 2, delete paragraph 3.3.2.2.

3.7.7 SFLC Std Spec 5000, Auxiliary Machine Systems, Appendix C, page C9: Replace paragraph C2.8.1.3 and Table C-3, and add additional paragraphs C2.8.1.4, C2.8.1.5, and C2.8.1.6. as follows:

“C2.8.1.3 Flushing fluid minimum flow rate requirements. Ensure the minimum flow rates provided in Table C-3 are maintained for each circuit. If multiple loops are flushed concurrently, each loop shall be provided with a flow measuring device. Provide calibrated flow meters. Prior to flushing, submit the certification of calibration to the CG Inspector.

TABLE C-3 - MINIMUM FLOW RATE FOR FLUSHING WITH FLUID

Pipe Size inside dia (Inch) Gal/Min

NOTES

1. Flow rates represent minimum flows needed to achieve a turbulent flow condition and maximize benefits of flushing effort.

2. Flow rate selected for flow velocity of 25 ft/sec in the schedule 80/160 pipe, as applicable. If there is a conflict between the pressure and flow rate requirements of this specification, the minimum flow rates shall be governing, unless the working pressure of the system is exceeded. The uses of by-pass (flow control) valves are not allowed downstream of the flow meters.

C2.8.1.4 Whenever a noticeable increase in the pressure drop across strainers is observed, the strainers should be cleaned and bag renewed. Be aware that this may occur as frequency as 15 min intervals.

C2.8.1.5 During flushing, constant monitoring of the flushing oil must be maintained in order to determine the contamination level. Filtering shall continue until the fluid entering the return flow filter meets the particle population ISO cleanliness code of 17/14, in accordance with ISO 4406. All flushing fluid shall pass through the return filter after passing through each system flushing circuit. All samples shall be taken at a point just prior to this filter C2.8.1.6 Take a representative sample of oil from the hydraulic system of the hydraulic system. Send samples out for laboratory analysis. Analysis shall include viscosity, moisture, total acid number, particle size and population in sufficient detail to determine ISO cleanliness code of 17/14, in accordance with ISO 4406. Submit CFR.”

3.7.8 SFLC Std Spec 6341, Appendix A, Paragraph A2.1.1, replace with “A2.1.1 Cove vase. Include a cove base, using the same epoxy resin deck covering system material, to a maximum height of four inches at all adjacent vertical bounding surfaces, where applicable."

4. NOTES

4.1 QA inspection forms. QA inspection forms (QA-1 thru QA-5), required in SFLC Std Spec 6310 to be completed and submitted during preservation of “critical-coated surfaces”, are provided at the end of this document.

QA-1 - QUALITY ASSURANCE INSPECTION FORM

(PRESERVATION CHECKLIST)

CHECKPOINT 1 – COATING SYSTEM COMPLIANCE

Ensure all coatings are in compliance with SFLC Std Spec 6310, Appendix C.

CHECKPOINT 2 - PAINT STORAGE

Ensure all coatings are kept at a temperature of 65 to 85°F at all times, unless otherwise specified by the coating mfgr.

CHECKPOINT 3 - AMBIENT CONDITIONS

Ensure surface and surrounding temperatures are each between 50 and 90°F for water-containing coatings, and 35 and 95°F for other coatings, unless otherwise specified by the coating manufacturer(s).

Ensure maximum relative humidity (RH) is as follows, from surface preparations through final curing of topcoat: 50% for tanks, voids, and vent plenum; and 85% for all other areas, unless otherwise specified by manufacturer(s).

Ensure surface temperature is at least 5°F above the dew point, unless otherwise specified by the coating mfgr.

CHECKPOINT 4 - PRE-SURFACE PREPARATION

Remove surface contaminants (soluble salts, loose rust, mud, and marine growth) with low pressure fresh water wash down (maximum 5,000 psi). If oil and grease are present, perform solvent cleaning, as per SSPC SP-1.

Verify equipment setup, blast media, and surface preparation methods match designated test coupon.

CHECKPOINT 5 - SURFACE PREPARATION

Verify environmental conditions (see CHECKPOINT 3).

Ensure cleanliness of prepared surface is as per specification (i.e.: SSPC SP-11, SP-10, SP WJ-2…).

Verify surface anchor profile using ASTM D4417-Methods B or C against SFLC Std Spec 6310. Conduct profile readings at a minimum of 5 locations for the first 1000-sqft area, and 2 locations for each succeeding 1000-sqft area.

Measure soluble salt conductivity in accordance with SSPC-Guide 15. Conduct 5 measurements per each 1000-sqft area (max. threshold: 70 microsiemens/cm for non-submerged surfaces, 30 microsiemens/cm for submerged surfaces).

CHECKPOINT 6 - PRIMER COAT APPLICATION

Verify environmental conditions (see CHECKPOINT 3).

Verify proper mixing and stand-in (induction) times.

Ensure no paint is applied when the temperature is expected to drop to freezing before the paint has dried.

Ensure surfaces are completely dry, unless otherwise allowed by the coating manufacturer(s).

Verify wet film thickness (WFT) at random, to prevent under or over application. Verify final DFT.

Brush out all runs, sags, drips, and puddles.

Perform visual inspection for holidays and other defects.

CHECKPOINT 7 – STRIPE COAT APPLICATION

Verify environmental conditions (see CHECKPOINT 3).

Ensure overcoating window is as per manufacturer’s instructions.

After primer coat (mist coat after inorganic zinc), brush-apply un-thinned coat of same primer paint over edges, weld seams, cut-outs, and areas of complex geometries @ 3-4 mils wet film thickness (WFT).

CHECKPOINT 8 – TOP COAT APPLICATION

Verify environmental conditions (see CHECKPOINT 3).

Ensure overcoating window is as per manufacturer’s instructions.

Verify proper mixing and stand-in (induction) times, as applicable.

Verify wet film thickness at random, to prevent under or over application.

Brush out all runs, sags, drips, and puddles.

CHECKPOINT 9 – FINAL INSPECTION

Verify final system dry film thickness. Conduct 5 sets of 3 readings for each of the first 3 100-sqft areas, followed by 5 sets of 3 readings for each succeeding 1000-sqft area.

Ensure that system cure is in accordance with manufacturer's recommendation for intended service.

Ensure potable water tank exhaust ventilation is maintained continuously from and during coating application through final system cure, to exhaust all solvent to the atmosphere and to prevent solvent entrapment.

For immersion coatings (including tank U/W body), record date and time of the following events:

Final coat application: _____/_____; Return to service or removal from environment controls: _____/_____

CHECKPOINT 10 – RECORD KEEPING

Complete, sign, and submit all provided QA Inspection Forms.

QA-2 - QUALITY ASSURANCE INSPECTION FORM

(ENVIRONMENTAL READINGS)

Use one sheet for each activity. Record conditions every four hours from before surface preparation to application of final coating system coat.

| DP - Surface |

QA-3a - QUALITY ASSURANCE INSPECTION FORM

(SURFACE PROFILE LOG FOR PROFILE MEASUREMENTS IAW ASTM D4417-METHOD-C)

SSPC-SP-10/NACE No. 2

SSPC-SP WJ-1/NACE WJ-1

SSPC-SP WJ-2/NACE WJ-2

SSPC-SP WJ-3/NACE WJ-3

SSPC-SP WJ-4/NACE WJ-4

SSPC-SP-3

SSPC-SP-11

SSPC-SP-11 (inaccessible area)

Brush-blasting (non-metallic substrate)

Abrasive Manufacturer and Sieve Size: _________________________________ Place surface profile replica tapes in the spaces provided below, to serve as permanent QA record. Maintain a separate log for each location. When an area is divided into separate sections, maintain a separate log for each section.

Place Surface Profile Replica Tape Here Reading:__________ mils Place Surface Profile Replica Tape Here Reading:__________ mils Place Surface Profile Replica Tape Here Reading:__________ mils

Place Surface Profile Replica Tape Here Reading:__________ mils Place Surface Profile Replica Tape Here Reading:__________ mils Place Surface Profile Replica Tape Here Reading:__________ mils

Place Surface Profile Replica Tape Here Reading:__________ mils Place Surface Profile Replica Tape Here Reading:__________ mils Place Surface Profile Replica Tape Here Reading:__________ mils

Place Surface Profile Replica Tape Here Reading:__________ mils Place Surface Profile Replica Tape Here Reading:__________ mils Place Surface Profile Replica Tape Here Reading:__________ mils

Place Surface Profile Replica Tape Here Reading:__________ mils Place Surface Profile Replica Tape Here Reading:__________ mils Place Surface Profile Replica Tape Here Reading:__________ mils

Mean Mil Reading (IAW ASTM D4417-Method C) for above 15 readings: ______________

QA-3b - QUALITY ASSURANCE INSPECTION FORM

(SURFACE PROFILE LOG FOR PROFILE MEASUREMENTS IAW ASTM D4417-METHOD-B)

SSPC-SP-10/NACE No. 2

SSPC-SP WJ-1/NACE WJ-1

SSPC-SP WJ-2/NACE WJ-2

SSPC-SP WJ-3/NACE WJ-3

SSPC-SP WJ-4/NACE WJ-4

SSPC-SP-3

SSPC-SP-11

SSPC-SP-11 (inaccessible area)

Brush-blasting (non-metallic substrate)

Abrasive Manufacturer and Sieve Size: _________________________________ Record measurements taken in the spaces provided below, to serve as permanent QA record. Maintain separate log for each location. When an area is divided into separate sections, maintain a separate log for each section.

Mean Mil Reading (IAW ASTM D4417-Method B) for above 10 readings (by column):

QA-4 - QUALITY ASSURANCE INSPECTION FORM

(SURFACE SOLUBLE SALT CONDUCTIVITY LOG)

SOLUBLE SALT CONDUCTIVITY MEASUREMENTS IAW SSPC-GUIDE 15

(microsiemens/cm)

QA-5 - QUALITY ASSURANCE DATA FORM

(COATING THICKNESS)

(Use one sheet for each sequence)

DRY FILM THICKNESS (DFT) MEASUREMENTS IAW SSPC-PA 2

*BASE METAL READING (BMR)

*Required, If Magnetic Pull-Off (Type I/Banana)…