HSCG85-13-R-P45154_Alder_Specification.doc

USCGC ALDER (WLB 216)

225 FOOT "B CLASS" SEAGOING BUOY TENDER

SPECIFICATION FOR UNPLANNED DRYDOCK REPAIRS

FY2013

Developed By: Paul F Gates (Rev - 001, 12 October 2012)

TABLE OF CONTENTS

iiiRevisions Record ivConsolidated List of References viConsolidated List of Government-furnished Property viiiConsolidated List of Critical Inspection Items ixPrincipal Characteristics

1General Requirements

18WORK ITEM 1: Drydocking

22WORK ITEM 2: Temporary Services, Provide

25WORK ITEM 3: Sea Trial Performance, Provide Support

29WORK ITEM 4: Controllable Pitch Propeller System Repair

48WORK ITEM 5: Towing Services, Provide

Revisions Record This page is used to record specification revisions, which may have occurred subsequent to a Revision 0 (Rev-0) package. Information listed is intended to provide contractors and field unit personnel a means to ensure all the current specification revision pages are present when reviewing or utilizing this specification package.

NOTE : All work item and paragraph numbers listed above for a given revision correspond to same numbers in the previous revision. This revised specification is self-contained with all of the above listed changes incorporated.

Consolidated List of References

The below-listed documents form a part of this specification to the extent specified herein. Approval/publication dates or revision dates/numbers are also identified, to ensure that same document versions are used at time of specification writing and during contract execution.

All Coast Guard drawings, technical publications, and standard specifications will be provided to contractors by the Coast Guard at an appropriate time, or upon request, free of charge. Other Government documents may be accessed – free of charge – as follows:

· MIL/DOD/CID Specifications: http://www.assistdocs.com/search/search_basic.cfm

· Commandant Instruction Manuals: http://www.uscg.mil/directives/default.asp

· Public Laws, Code of Federal Regulations, U.S Codes, and other Federal Government laws:: www.gpoaccess.gov The Government is aware of the following internet web links where contractors may procure commercial specifications:

· American Welding Society (AWS): http://www.awspubs.com/index.php

· ANSI, ASTM, IEEEE, NFPA, ASME, SAE Standards: http://www.techstreet.com/

· NFPA: http://www.nfpa.org

· SSPC Standards and pictorial guides: http://shopping.netsuite.com/sspcmarketplace

COAST GUARD DRAWINGS

Coast Guard Drawing 225B WLB 801-001, Rev A, Lines and Offsets

Coast Guard Drawing 225B WLB 801-003, Rev A, Curves of Forms and Cross Curves of Stability

Coast Guard Drawing 225B WLB 801-006, Rev D, Docking Drawing

Coast Guard Drawing 225B-WLB 243-2, Rev E; Stern Tube and Bearing a & D

Coast Guard Drawing 225B-WLB 562-2, Rev C, Rudder Structural a & D

COAST GUARD PUBLICATIONS

Coast Guard Commandant Instruction (COMDTINST) M10360.3, Jun 2006, Coatings and Colors Manual

Coast Guard Commandant Instruction (COMDTINST) M16672.2D, Mar 1999, Navigation Rules, International-Inland

Coast Guard Technical Publication (TP) 3524, 07-JAN-97, Manufacturer's Instruction Book-SWBS Group(s) 243-262

Surface Forces Logistics Center Standard Specification (SFLC Std Spec) 0000, Jan 2009, General Requirements

Surface Forces Logistics Center Standard Specification (SFLC Std Spec) 0740, Jan 2009, Welding and Allied Processes

Surface Forces Logistics Center Standard Specification 8634 (SFLC Std Spec 8634), Jan 2009, Drydocking

Surface Forces Logistics Center Standard Specification 8635 (SFLC Std Spec 8635), Jan 2009, Provide Temporary Services

OTHER REFERENCES

ASTM International (ASTM) D4417, 2003, Standard Test Methods for Field Measurement of Surface Profile of Blast Cleaned Steel

Coast Guard Technical Publication (TP) 3524, Jan 1997, Manufacturer's Instruction Book-SWBS

Code of Federal Regulations (CFR) Title 33 CFR, 2008, Navigation and Navigable Waters

Code of Federal Regulations (CFR) Title 40, Chapter I, 2008, Environmental Protection Agency

Code of Federal Regulations (CFR) Title 49, Chapter I, 2008, Pipeline and Hazardous Materials Safety Administration, Department Of Transportation

Commercial Item Description (CID) A-A-59316, Nov 2003, Abrasive Materials for Blasting

Federal Standard (FED-STD) 595, 2008, Colors Used In Government Procurement

MIL-A-22262, Mar 1996, Abrasive Blasting Media Ship Hull Blast Cleaning

NAVSEA T9074-AS-GIB-010/271, Rev 97; Requirements for Non-Destructive Testing Methods

NAVSEA Technical Publication T9074-AD-GIB-010/1688, (TP 1688), May 1997, Requirements for Fabrication, Welding, and Inspection of Submarine Structure

The Society for Protective Coatings (SSPC) VIS 1, 2004, Guide and Reference Photographs for Steel Surfaces Prepared by Dry Abrasive Blast Cleaning

The Society for Protective Coatings (SSPC)/NACE International (NACE) Joint Surface Preparation Standard SSPC-SP 10/NACE No.2, 2004, Near-White Blast Cleaning

Consolidated List of Government-furnished Property

The following is a list of property, which the Government will furnish. This list supersedes any other material obligations indicated or implied by referenced drawings.

($/Unit)

1,250.00

*Government-loaned property, which shall be returned to the vessel upon completion of the availability.

**New or refurbished equipment that the Government may provide for installation in place of existing equipment.

***Government-furnished property, which is to be supplied by either the vessel or the C4IT ServiceCenter

Consolidated List of Critical Inspection Items The following is a list of work items, which contain Critical Inspection reports, which the Contractor must complete within the first 25% of the availability contract period (see SFLC Std Spec 0000_STD, paragraph 3.2.6.5 (Inspection report particulars)):

PC_225B_WLB_1109

Principal Characteristics

225' WLB (B-CLASS)

Physical Characteristics

Hull Characteristics

Frame Spacing

Machinery Characteristics

Tank CAPACITIES

00000_PWB_0312_FLT

REC_0000_FLT_ Commercial Project @ Contractor’ Facility (0212) General Requirements

1. SCOPE

1.1 Intent. This item describes the general requirements to be followed by the Contractor while conducting this availability.

2. REFERENCES

Coast Guard Drawings

None.

Coast Guard Publications

Coast Guard Commandant Instruction (COMDTINST) M10360.3C, Change 1, Jun 2006, Coatings and Color Manual

Surface Forces Logistics Center Standard Specification 0000 (SFLC Std Spec 0000), Jan 2009, General Requirements

Surface Forces Logistics Center Standard Specification 0740 (SFLC Std Spec 0740), Jan 2009, Welding and Allied Processes

Other References

ASTM International (ASTM) D4417, 2003, Standard Test Methods for Field Measurement of Surface Profile of Blast Cleaned Steel

Commercial Item Description (CID) A-A-59316, Nov 2003, Abrasive Materials for Blasting

Federal Standard (FED-STD) 595, 2008, Colors Used In Government Procurement

MIL-A-22262, Mar 1996, Abrasive Blasting Media Ship Hull Blast Cleaning

NAVSEA Technical Publication T9074-AD-GIB-010/1688, (TP 1688), May 1997, Requirements for Fabrication, Welding, and Inspection of Submarine Structure

The Society for Protective Coatings (SSPC) VIS 1, 2004, Guide and Reference Photographs for Steel Surfaces Prepared by Dry Abrasive Blast Cleaning

Code of Federal Regulations (CFR) Title 33 CFR, 2008, Navigation and Navigable Waters Code of Federal Regulations (CFR) Title 40, Chapter I, 2008, Environmental Protection Agency Code of Federal Regulations (CFR) Title 49, Chapter I, 2008, Pipeline and Hazardous Materials Safety Administration, Department Of Transportation

3. REQUIREMENTS

3.1 General. The Contractor shall conform to all requirements specified in SFLC Std Spec 0000 and in this item, as applicable, during the performance of this availability.

NOTE

The requirements of paragraph 3.1 (General) applies to all work under the scope of this contract, whether explicitly stated in work items or not, and also to all other work subsequently authorized by changes, modifications, or extensions to the contract.

3.2 Contractor-provided fire watch personnel. The Contractor shall provide fire watch personnel and equipment.

3.3 Welding and brazing requirements. The Contractor shall perform all welding and allied processes, and NDI in accordance with SFLC Std Spec 0740.

NOTE

NAVSEA approval is NOT required for welding procedures submitted but the procedures must be reviewed and shown to satisfy the requirements set forth in NAVSEA TP 1688, by a welding regulatory agency. The requirements for welding Weldox 900 shall be considered the same as those for welding HY-130

3.4 HW disposal. The Contractor is considered as the generator of all contract-generated hazardous wastes and shall use its facility’s EPA generator ID number for management, transportation, and disposal of said hazardous wastes. Ensure the following:

3.4.1 Contractor’s hazardous waste handlers shall comply with applicable requirements of 40 CFR 262.

3.4.2 All contract generated hazardous wastes shall be packaged in 49 CFR-compliant containers.

3.4.3 The designated wastes shall be disposed of at a state or Federally-approved and permitted HW TSDF.

3.4.4 Name of destination TSDF shall be submitted to the KO at the Arrival Conference.

3.5 Interim changes and additions to SFLC Std Spec 0000. The Contractor shall be aware of the following interim changes and additions to the 2009 Edition of SFLC Std Spec 0000:

3.5.1 Acronyms and term definitions – paragraph 1.3 (Acronym and term definitions).

3.5.1.1 The term “COTR” has been replaced with “COR”, which is defined as follows:

“COR”: Contracting Officer’s Representative – the person delegated by the KO as the on-scene representative for matters concerning performance of work; this includes correctness, timeliness, and quality of the Contractor’s work. Normally, the CO/OINC is designated the COR.”

3.5.1.2 Definition addition for the term “Ungrounded, as follows:

· “Ungrounded”: A power system where all of the current-carrying conductors and windings (including any neutral connection) are insulated from ground. In contrast, a generator or transformer in which at least one conductor or point (usually the midpoint or corner of a delta winding or the common center of a wye winding) is intentionally grounded, either solidly or through an impedance, is considered grounded. Note that the distinction concerns only current-carrying conductors; for both ungrounded and grounded power systems, non-current carrying metal parts and equipment grounding conductors are always bonded to earth ground for personnel safety. At non-Governmental facilities, dockside wye connected transformer secondary windings are almost always grounded and are generally not suitable for connection to a Coast Guard cutter without a separate Contractor furnished isolation transformer.”

3.5.2 Changes to paragraph 3.2.4 2.3 (QP-1 Inspector or Tech Rep duties).

“3.2.4.2.3 QP 1 Inspector or Tech Rep duties.

3.2.4.2.3.1 The Coating Inspector for the “QP 1-certified” Contractor or the Contractor-provided NACE-certified Tech Rep shall remain on site, to perform the following duties, as applicable, for each work item that involves preservation of “critical-coated surfaces”:

· Verify inspection instrument calibration.

· Verify and approve the suitability of ambient conditions before surface preparation is begun, and before each coat of paint is applied.

· Verify all aspects of surface preparation – including, but not limited to:

· Cleanliness of compressed air.

· Adequacy of solvent cleaning.

· Proper handling of blast media.

· Actual surface preparation procedure.

· Inspect and approve final surface preparation, before application of primer coat.

· Supervise and approve coating system preparation and application procedures, including but not limited to: mixing and thinning, stripe coating application, spray techniques, and film thickness measurements and recordings.

· Determine when applied coats have sufficiently cured for overcoating, or for system service resumption (see paragraph A2.1.18 (Critical drying time requirements)).

· Complete and sign the quality assurance (QA) inspection forms (see QA-1 thru QA-5), provided in Appendix A (Requirements for Preservation of Ship Structures) of this document.

· Submit all completed QA inspection forms to the COR (through the Contractor), upon completion of work.

3.2.4.2.3.2 The Contractor shall ensure the NACE Inspector is formally informed - via suitable subcontract documentation- and is willing and able to perform of all duties listed above. Submit documentation of this contract and assumption of duties to the KO at the Arrival Conference.”

3.5.3 Changes to contents of paragraph 3.2.5 (Planning document).

“3.2.5 Planning document. The Contractor shall generate a legible Planning Document (PD) with the following characteristics:

· Graphical in format (see Fig. 1 (Sample Planning Document Submittal)).

· Shows overall period of performance for each CLIN, with start and stop dates of major sub-tasks.

· Contains due dates for Critical Inspection Reports (CIR) and any events requiring Coast Guard Inspector presence.

· Identifies all work item time periods that require OEM Tech Rep assistance.

· Identifies the “critical paths” for the project.

· Shows calculations for the “float” along the critical paths and labels the critical paths with the number of delay days the critical paths can absorb without affecting the final delivery date.

NOTE

Float is the number of days that the critical paths can be delayed without affecting the final delivery date.

3.2.5.1 Ensure that the PD also includes the names, contact information, and written commitment from all Tech Reps required by the Contract - indicating they are available for work during the proposed time period.

3.2.5.2 Submit a preliminary electronic copy of the PD to the COR - for Government review - no later than one week after contract award.

3.2.5.3 Submit 3 copies of the PD to the COR, 15 days prior to the start of the performance period, and at all weekly Progress Meetings.

NOTE

A separate document, specifically prepared for the Government is not desired or required. A copy or summary of the Contractor’s internal scheduling document is preferred.

FIG. 1 - SAMPLE PLANNING DOCUMENT SUBMITTAL

3.2.5.4 When the critical path extends beyond or encroaches upon the final delivery date, provide a resource constraint and scheduling evaluation of the critical path before any request for extension will be entertained. Submit the resource constraint and scheduling evaluation via a CFR.

NOTE

The intent of the resource constraint and scheduling evaluation is to identify the resources necessary to ‘crash’ the critical path or make adjustments to the production schedule to meet the delivery date in lieu of a project extension.”

3.5.4 Additional sub-paragraphs to paragraph to 3.2.6.5 (Inspection report particulars).

“3.2.6.5.3 CFR tracking system. The Contractor shall create and maintain a CFR tracking system for the project. At a minimum, ensure that the CFR tracking system shall list all required reports, broken down by the following:

· Work item and paragraph number.

· Due dates.

· Submission dates.

· CFR/CIR submission number.

3.2.6.5.3.1 Be aware that the COR will respond via the CFR reply as to whether the CIR/CFR ‘fully’ or ‘partially’ satisfied the inspection and reporting requirements in the associated work item.

3.2.6.5.3.2 When submitting a CFR, ensure that the applicable work item and paragraph number for which the inspection report is being submitted is included on the CFR.

3.2.6.5.3.3 Submit a copy of the CFR tracking sheet to the COR at the arrival conference.

3.2.6.5.3.4 At a minimum the Contractor shall update and submit a copy of the CFR tracking sheet to the COR the day before each weekly progress meeting. At the required CFR due date, submit the CFR tracking sheet to the COR via a CFR for review and formal archiving with the project records.”

3.5.5 Changes to contents of paragraph 3.2.11.1 (Sanitary facilities for vessel-personnel due to disruption of grey water and sewage systems).

“3.2.11.1 (Sanitary facilities for vessel-personnel due to disruption of grey water and sewage systems. When the shipboard grey water and sewage systems are disrupted due to repairs required by contract work, the Contractor shall provide vessel-personnel with a sanitary facility, within a five minute walking distance from the vessel, to include the amenities listed in Table II (Sanitary Facility Amenities). Ensure the following:

· Shower stalls are equipped with privacy screens.

· Sinks are provided with fresh hot and cold water.

· Electrical convenience GFI receptacles, in accordance with NFPA 70, National Electric Code (NEC), are located in vicinity of sinks.

· Toilets have doors or privacy dividers.

· Lockers are capable of being locked.”

3.5.6 Changes to contents of paragraph 3.3.2.1.1 (Water depth).

“3.3.2.1.1 Water depth. Ensure that water depth is sufficient at the pier to allow the vessel's lowest underwater appendage to clear the bottom by at least two feet at:

· Ordinary low water mark on non-tidal rivers.

· At all tide conditions predicted during the availability for tidal rivers and other navigable waterways (Bay, Lake, etc.).”

3.5.7 Electrical compliance planning.

“3.3.14 Electrical compliance planning. For cutter availabilities, the Contractor shall submit to the KO the following electrical compliance planning documentation during the pre-award phase of the contract.

3.3.14 1 Shore power. When ungrounded shore power is to be provided per SFLC Std Spec 8635, provide a one line electrical diagram showing how such power will be supplied, including the winding and grounding configuration and rating of any generator or isolation transformer. For drydock availabilities, separate diagrams should be submitted for waterborne and non-waterborne periods.

3.3.14.2 Arc welding. When electric arc welding is to be performed per SFLC Std Spec 0740 while the vessel is waterborne, provide a diagram showing the general proposed location of each welding machine, the grounding configuration of each machine, and the return current conductor size and length. For drydock availabilities, separate diagrams may be necessary for waterborne and non-waterborne periods.

3.3.14.3 Hull bonding and lightning protection. For work periods while the vessel is not waterborne, provide a diagram showing how the hull grounding straps required by SFLC Std Spec 8635 will be sized (length and gauge) and connected.

3.3.14.4 Tool and equipment power. Provide a diagram showing how Contractor tool and equipment power will be supplied and distributed for dockside and shipboard use in accordance with SFLC Std Spec 0450. For drydock availabilities, separate diagrams should be submitted for waterborne and non-waterborne periods.”

3.5.8 Changes to paragraph to A2.1.1.3 (Document submission).

A1.1 “A2.1.1.3 Document submission.

A1.2 A2.1.1.3.1 For all work involving preservation of “critical-coated surfaces”, ensure the following is submitted to the COR at the Arrival Conference, for each coating system intended to be applied:

· Coating system manufacturer’s name.

· Product data sheets.

· MSDS.

· COC.

A1.3 A2.1.1.3.2 Documentation shall be broken out by work item, to also include the following information:

· Brand name.

· Color.

· Intended mil thickness.

· Time between coats.

· Intended final cure time prior to immersion or full duty rating, as applicable.

A1.4 A2.1.1.3.3 For work involving preservation of surfaces not designated as “critical-coated surfaces”, submit all product data sheets, MSDS, and COC to the COR, prior to commencement of work.”

3.5.9 Requirements changes to paragraphs A2.1.5 (Tenting) and A2.1.6 (Ambient condition control).

“A2.1.5 Tenting and ambient condition control – “for critical-coated surfaces”.

A2.1.5.1 When the ambient condition parameters necessary for full paint cure or to meet environmental conditions, as required in paragraph A.2.1.4 (Ambient condition parameters), cannot be met for successful application and curing of “critical-coated” surface coating systems, the Contractor shall provide the following, at no additional cost to the Government:

· Suitable tenting, as applicable, for exterior surface preservation.

· Suitable ambient condition control equipment, which may include, but not be limited to the below-listed, to create and maintain ambient conditions recommended by the coating system’s manufacturer, and facilitate successful coating application and curing.

· AC system.

· Heaters.

· Blowers.

· Dehumidifiers.

A2.1.5.2 Submit an ambient condition control plan to the COR within 24 hours prior to initiating ambient condition control process

NOTE

The Contractor is expected to be aware of the advent of environmental conditions that are adverse to preservation of critical-coated surfaces and include all costs in

3.5.10 Pre-surface preparation requirements – additional to paragraph A2.1.7 (Pre-surface preparation requirements).

“A2.1.7.4 Coupon test. In order to ensure production of required surface profile, the Contractor shall accomplish the following, tasks, whenever abrasive-blasting is required in a work item:

A2.1.7.4.1 Conduct a performance test on all abrasive blasting operations on a Contractor- provided test coupon, prior to starting abrasive blasting operations on the vessel. Use a new metal plate, of the same metal type and material properties as the area to be blasted, steel or aluminum plate, as applicable. For steel plates, the new plate shall have the mill scale intact and the plate will be in a Rust Grade "A" condition, per the SSPC-VIS 1 visual standard cards. No existing anchor profile, other than the surface irregularities from the manufacturing process are permitted on the test coupon. The test coupon shall be flat, with nothing welded to the side used for the anchor profile test, no thinner than a 1/8-inch plate and measuring no smaller than 1-foot by 1-foot. The test coupon shall be affixed so as to not permit excessive movement during the performance test.

CAUTION!

Do not affix the coupon to the vessel nor shall the blast media from the performance test strike the vessel during the test

A2.1.7.4.2 Ensure that the abrasive blasting operation test on the test coupon is with the very same setup that will be used to blast the vessel. The setup shall include, but not be limited to:

· The abrasive media to be used (material and media size).

· Nozzle size and type (straight bore, high velocity nozzle, angle nozzle...).

· Delivery rate and pressure settings.

A2.1.7.4.3 Blast an one-square foot area on one side of the test coupon to the abrasive surface preparation standard specified in the applicable work item and perform an anchor profile test of the blasted surface in accordance with ASTM D4417, method A or C. Notify the COR in advance of the abrasive blasting operation test, to permit the witnessing of the test by appropriate Coast Guard personnel. Submit a CFR documenting the results of the abrasive blasting operation test. CFR shall include at a minimum, the following:

· Area of the vessel that the verified setup will be used to abrasive blast with.

· The abrasive media used.

· The nozzle size and type.

· The delivery rate and pressure.

· The test coupon starting properties (material type and surface conditions).

· The resultant anchor profile readings from the test.

NOTES

1. Ultra high pressure water jetting does not create an anchor profile and is exempt from the anchor profile test coupon check.

2. The reverse side of the test coupon may be used for the subsequent test, provided that the conditions in paragraph A2.1.7.4 (Coupon test) are met.

A2.1.7.4.3 Repeat the abrasive blasting operation test in the following instances:

· The setup, as defined in paragraph A2.1.7.4.1 is changed.

· The resultant anchor profile readings observed on the vessel are outside the specified anchor profile range.

· Media is changed from MIL-A-22262 to CID A-A-59316 or vice versa.

· The supplier of the abrasive blasting media changes, regardless if the new source for the media has the same specifications.

· When Directed by the COR.

NOTE

A performance test of the abrasive blasting operations on a test coupon and measuring the anchor profile prior to performing the operation on the cutter, in order to confirmed that the anchor profile range that the operation is going to produce. An abrasive blasting operation test is prudent, as there are enough variables in the equipment setup and media properties that the resulting anchor profiles from one contractor to the next vary significantly.

3.5.11 Post-surface preparation requirements - additional to paragraph A2.1.8 (Post-surface preparation requirements).

A2.1.8.8 Substrate profile measurements - during and post-surface preparation. In order to ensure production of required surface profile, the Contractor shall accomplish the following tasks, whenever abrasive-blasting is required in a work item for complete preservation of a ”critical-coated” surface:

A2.1.8.8.1 During surface preparation by abrasive blasting or waterjetting operations, spot check the existing anchor profile per 500-square feet, in order to 'project' the need to manage the excessive anchor inspect for both excessive and insufficient anchor profiles . When the Contractor elects to prepare a substrate by waterjetting, the Contractor shall inspect the substrate for areas of insufficient or excessive anchor profile, both visually and in accordance with ASTM D4417, Method A or C. Submit a CFR detailing the location, square footage, measured anchor profiles, and the anchor profile range required for the applicable coating system.

A2.1.8.8 2 Post completion of surface preparation, measure the profile of the resultant bare surfaces, in accordance with ASTM D4417, Method A or C.”

3.5.12 Caution verbiages – additional to paragraph A2.1.18 (Critical drying and cure time requirements).

“CAUTIONS!

1. Hard cure times or cure time prior to immersion for any “critical coated system” shall be met as published on the Product Data Sheets available online. No early undocking or relaxation of these published requirements is permitted without prior approval from the KO. Coating system manufacturer’s Sales or Technical Representatives may not relax these requirements. Painting and curing of all tank coating systems (except for tanks that are inboard and not touching the skin of the vessel (side and/or bottom) shall occur while the cutter is out of the water.

2. CAPAC systems shall not be energized until full cure of all underwater paint systems has occurred.”

3.5.13 Preservation Plan.

“A2.2 Preservation Plan (PP). The contractor shall submit a PP to the COR at the arrival conference, to allow for review of all work items pertaining to the preservation of the vessel. At a minimum, PP shall include the following and be broken down by work item:

· Coatings to be applied – listed by manufacturer and product identification numbers.

· Target wet and dry film thickness values.

· Authorized reducers/solvents - including maximum percent by volume for reducers/solvents.

· Colors by FED-STD-595 color number.

· Application method for each coat.

· Application pressure and nozzle size requirements listed on the manufacturer’s product data sheet(s).

· Minimum recoat windows for applying subsequent coats, maximum recoat windows to apply subsequent coats, adjusted for anticipated temperatures.

· Any special instructions or environmental limits listed by the coating manufacturer.

· Intended final cure times prior to immersion or full duty rating (as applicable).”

3.5.14 Changes to paragraph B2.2.3.3.1.

“B2.2.3.3.1 Do not release lead or lead-contaminated materials into the environment. Conduct periodic air monitoring (as appropriate) for lead in the worker’s breathing zone, during the course of any abatement work involving lead containing materials, to prevent exposure at or above the PEL. Submit results of all air monitoring samples to the COR, within 24 hours of completion of sampling.”

3.5.15 Booming requirements during the offload or on-load of petroleum products.

“B2.2.10 Booming requirements during the offload or load of petroleum products. The Contractor shall provide a containment boom system and boom off the cutter during all petroleum cargo on-loads and offloads. The cutter shall be boomed off by the contractor during both shipyard functions and the final bunkering of the cutter by ship's force. The contractor is responsible to provide the labor to deploy and recover the boom during all operations, including operations conducted by ship's force. The containment boom shall at a minimum, fullly encapsulate the cutter from the pier wall in front of the cutter to the pier wall at the stern of the cutter. When moored alongside a pier that does not provide a fully intact pier wall that will contain a spill, the containment boom shall wrap completely around the cutter on all sides to provide spill containment. For tug and barge configurations, the containment boom shall encapsulate both the cutter and the barge, as applicable.”

4. NOTES

4.1 Access to COMDTINST M10360.3. The COMDTINST M10360.3 may be accessed at the following URL address: http://www.uscg.mil/directives/cim.asp

4.2 QA inspection forms. QA inspection forms (QA-1 thru QA-5), required in SFLC Std Spec 0000 to be completed and submitted during preservation of “critical-coated surfaces”, are provided at the end of this document.

QA-1 - QUALITY ASSURANCE INSPECTION FORM

(PRESERVATION CHECKLIST)

CHECKPOINT 1 – COATING SYSTEM COMPLIANCE

Ensure all coatings are in compliance with COMDTINST M10360.3, Appendix C.

CHECKPOINT 2 - PAINT STORAGE

Ensure all coatings are kept at a temperature of 65 to 85°F at all times, unless otherwise specified by the coating mfgr.

CHECKPOINT 3 - AMBIENT CONDITIONS

Ensure surface and surrounding temperatures are each between 50 and 90°F for water-based coatings, and 35 and 95°F for other coatings, unless otherwise specified by the coating manufacturer(s).

Ensure maximum relative humidity (RH) is as follows, from surface preparations through final curing of topcoat: 50% for tanks, voids, and vent plenum; and 85% for all other areas, unless otherwise specified by manufacturer(s).

Ensure surface temperature is at least 5°F above the dew point, unless otherwise specified by the coating mfgr.

CHECKPOINT 4 - PRE-SURFACE PREPARATION

Remove surface contaminants (soluble salts, loose rust, mud, and marine growth) with low pressure fresh water wash down (maximum 5,000 psi). If oil and grease are present, perform solvent cleaning, as per SSPC SP-1.

Verify equipment setup, blast media, and surface preparation methods match designated test coupon.

CHECKPOINT 5 - SURFACE PREPARATION

Verify environmental conditions (see CHECKPOINT 3).

Ensure cleanliness of prepared surface is as per specification (i.e.: SSPC SP-12, SP-11, SP-10…).

Verify surface anchor profile using ASTM D4417-Methods B or C against COMDTINST M10360.3. Conduct profile readings at a minimum of 5 locations for the first 1000-sqft area, and 2 locations for each succeeding 1000-sqft area.

Measure soluble salt conductivity in accordance with SSPC-Guide 15. Conduct 5 measurements per each 1000-sqft area (max. threshold: 70 microsiemens/cm for non-submerged surfaces, 30 microsiemens/cm for submerged surfaces).

CHECKPOINT 6 - PRIMER COAT APPLICATION

Verify environmental conditions (see CHECKPOINT 3).

Verify proper mixing and stand-in (induction) times.

Ensure no paint is applied when the temperature is expected to drop to freezing before the paint has dried.

Ensure surfaces are completely dry, unless otherwise allowed by the coating manufacturer(s).

Verify wet film thickness (WFT) at random, to prevent under or over application. Verify final DFT.

Brush out all runs, sags, drips, and puddles.

Perform visual inspection for holidays and other defects.

CHECKPOINT 7 – STRIPE COAT APPLICATION

Verify environmental conditions (see CHECKPOINT 3).

Ensure overcoating window is as per manufacturer’s instructions.

After primer coat (mist coat after inorganic zinc), brush-apply un-thinned coat of same primer paint over edges, weld seams, cut-outs, and areas of complex geometries @ 3-4 mils wet film thickness (WFT).

CHECKPOINT 8 – TOP COAT APPLICATION

Verify environmental conditions (see CHECKPOINT 3).

Ensure overcoating window is as per manufacturer’s instructions.

Verify proper mixing and stand-in (induction) times, as applicable.

Verify wet film thickness at random, to prevent under or over application.

Brush out all runs, sags, drips, and puddles.

CHECKPOINT 9 – FINAL INSPECTION

Verify final system dry film thickness. Conduct 5 sets of 3 readings for each of the first 3 100-sqft areas, followed by 5 sets of 3 readings for each succeeding 1000-sqft area.

Ensure that system cure is in accordance with manufacturer's recommendation for intended service.

Ensure potable water tank exhaust ventilation is maintained continuously from and during coating application through final system cure, to exhaust all solvent to the atmosphere and to prevent solvent entrapment.

For immersion coatings (including tank U/W body), record date and time of the following events:

Final coat application: _____/_____; Return to service or removal from environment controls: _____/_____

CHECKPOINT 10 – RECORD KEEPING

Complete, sign, and submit all provided QA Inspection Forms.

QA-2 - QUALITY ASSURANCE INSPECTION FORM

(ENVIRONMENTAL READINGS)

Use one sheet for each activity. Record conditions every four hours from before surface preparation to application of final coating system coat.

| DP - Surface |

QA-3a - QUALITY ASSURANCE INSPECTION FORM

(SURFACE PROFILE LOG FOR PROFILE MEASUREMENTS IAW ASTM D4417-METHOD-C)

SSPC-SP-10/NACE No. 2

SSPC-SP-12/NACE No. 5

SSPC-SP-3

SSPC-SP-11

SSPC-SP-11 (inaccessible area)

Brush-blasting (non-metallic substrate)

Abrasive Manufacturer and Sieve Size: _________________________________

Place surface profile replica tapes in the spaces provided below, to serve as permanent QA record. Maintain a separate log for each location. When an area is divided into separate sections, maintain a separate log for each section.

Place Surface Profile Replica Tape Here

Reading:__________ mils Place Surface Profile Replica Tape Here

Reading:__________ mils Place Surface Profile Replica Tape Here

Reading:__________ mils

Place Surface Profile Replica Tape Here

Reading:__________ mils Place Surface Profile Replica Tape Here

Reading:__________ mils Place Surface Profile Replica Tape Here

Reading:__________ mils

Place Surface Profile Replica Tape Here

Reading:__________ mils Place Surface Profile Replica Tape Here

Reading:__________ mils Place Surface Profile Replica Tape Here

Reading:__________ mils

Place Surface Profile Replica Tape Here

Reading:__________ mils Place Surface Profile Replica Tape Here

Reading:__________ mils Place Surface Profile Replica Tape Here

Reading:__________ mils

Place Surface Profile Replica Tape Here

Reading:__________ mils Place Surface Profile Replica Tape Here

Reading:__________ mils Place Surface Profile Replica Tape Here

Reading:__________ mils

Mean Mil Reading (IAW ASTM D4417-Method C) for above 15 readings: ______________

QA-3b - QUALITY ASSURANCE INSPECTION FORM

(SURFACE PROFILE LOG FOR PROFILE MEASUREMENTS IAW ASTM D4417-METHOD-B)

SSPC-SP-10/NACE No. 2

SSPC-SP-12/NACE No. 5

SSPC-SP-3

SSPC-SP-11

SSPC-SP-11 (inaccessible area)

Brush-blasting (non-metallic substrate)

Abrasive Manufacturer and Sieve Size: _________________________________

Record measurements taken in the spaces provided below, to serve as permanent QA record. Maintain separate log for each location. When an area is divided into separate sections, maintain a separate log for each section.

Mean Mil Reading (IAW ASTM D4417-Method B) for above 10 readings (by column):

QA-4 - QUALITY ASSURANCE INSPECTION FORM

(SURFACE SOLUBLE SALT CONDUCTIVITY LOG)

SOLUBLE SALT CONDUCTIVITY Measurements IAW SSPC-GUIDE 15

(microsiemens/cm)

QA-5 - QUALITY ASSURANCE DATA FORM

(COATING THICKNESS)

(Use one sheet for each sequence)

Dry Film Thickness (DFT) Measurements IAW SSPC-PA 2

*BASE METAL READING (BMR)

*Required, If Magnetic Pull-Off (Type I/Banana) Gauge Is Used.

Location (Frame Reference): ___________________

Avg.

Avg.

Avg.

86340_0712_FLT

REC_86340_FLT_225B WLB ‘B’ Class (ALL) (0812) WORK ITEM 1: Drydocking

1. SCOPE

1.1 Intent. This work item describes the requirements for the Contractor to drydock and undock the cutter and perform various drydocking-related tasks.

1.2 Government-furnished property.

($/UNIT)

*Government-loaned property, which shall be returned to the vessel upon completion of the availability.

2. REFERENCES

Coast Guard Drawings

Coast Guard Drawing 225B WLB 801-001, Rev A, Lines and Offsets Coast Guard Drawing 225B WLB 801-003, Rev A, Curves of Forms and Cross Curves of Stability Coast Guard Drawing 225B WLB 801-006, Rev D, Docking Drawing

Coast Guard Publications

Surface Forces Logistics Center Standard Specification 8634 (SFLC Std Spec 8634), Jan 2009, Drydocking

Other References

None.

3. REQUIREMENTS

3.1 General.

3.1.1 CIR.

None.

3.1.2 Technical Representative.

Not applicable.

3.1.3 Protective measures.

Not applicable.

3.1.4 Interferences.

None.

3.2 Docking requirements. The Contractor shall drydock and undock the cutter, in accordance with SFLC Std Spec 8634, using Coast Guard Drawing 225B WLB 801-001, 225B WLB 801-003, and 225B WLB 801-006 for guidance.

3.2.1 Cutter Conditions. The Contractor shall use the Full Load Condition, listed below for purposes of performing Pre-Award calculations as described in Appendix A (Requirements for Calculations) of SFLC Std Spec 8634.

· Displacement (LT SW): 1905.49

· VCG (FT ABL): 17.87

· LCG (FT aft FP): 106.29

· LCF (FT aft FP): 108.94

· Trim (FT by stern): 0.83

· MT1” (LT-FT/Inch): 212.89

3.2.1.1 Cable, sling, or strap tension calculation. If the Contractor plans to use a vertical lift, crane, or travel/mobile lift to haul out the vessel, the Contractor shall submit the cable, sling, or strap tension calculation specified in Table A1 and paragraph A2.7.2.7 of SFLC Std Spec 8634 with the Pre-Award calculations, using the loading condition specified in paragraph 3.2.1.

3.2.2 Blocking position. The Contractor shall arrange keel and side blocks, as shown on the vessel's docking plan, to facilitate docking of the vessel in blocking position No. 2. Ensure that the minimum keel block height is 48 inches above the docking facility deck.

3.3 Underwater body cleaning-removal of marine growth. Within four hours after the vessel has been docked, the Contractor shall start cleaning the entire underwater hull from the upper edge of the boot top down, including sea chest gratings, sea chest interiors, fairwaters, rope guards, rudder, shaft strut, z-drive, thruster tunnel, and zinc anodes, as applicable. The Contractor shall remove all marine growth, fouling, salt, and dirt from the underwater hull by High Pressure Fresh Water Wash, using a minimum pressure at the nozzle of 3,500 psi and maximum pressure of 7,000 psi. Complete the hull cleaning before marine growth hardens. Removal of gratings is not required. Do not use chemical additives in the freshwater wash. Take extreme care to avoid damaging or removing existing intact underwater body coating. Conduct the work in this paragraph in lieu of the work described in SFLC Std Spec 8634 paragraphs 3.4.4.1 and 3.4.4.2.

NOTE

When setting keel blocks particular attention should be paid to ensure clearance around the speed log transducer and cover plate at Frames 16-20.

NOTE

Fuel offloading is not mandatory to drydock the vessel.

4.1 Arrival conditions. The COTR will advise the Contractor of the actual tank and draft readings when the vessel arrives, and will discuss with the Contractor any liquid loading changes necessary.

4.2 Keel loading. The keel loading is expected to be between 12 and 16 LT/ft.

4.3 Block Omit No keel blocks shall be placed under the forward scan radar. A minimum of a 24-inch clearance must be maintained.

86350_0712_FLT

WORK ITEM 2: Temporary Services, Provide

1. SCOPE

1.1 Intent. This work item describes the requirements for the Contractor to provide temporary services to the vessel, during the performance of this availability.

1.2 Government-furnished property.

None.

2. REFERENCES

Coast Guard Drawings

None.

Coast Guard Publications

Surface Forces Logistics Center Standard Specification 8635 (SFLC Std Spec 8635), Jan 2009, Provide Temporary Services

Other References

None.

3. REQUIREMENTS

3.1 General.

3.1.1 CIR.

None.

3.1.2 Technical Representative.

Not applicable.

3.1.3 Protective measures.

Not applicable.

3.1.4 Interferences.

None.

3.2 Temporary service particulars. The Contractor shall provide the below listed temporary services, in accordance with SFLC Std Spec 8635.

TABLE I - Service Selection

*Each sub-paragraph number relates directly to the identical sub-paragraph number in SFLC Std Spec 8635.

TABLE 2 - HazaRdous waste disposal – LIQUIDS (Gallons)

TABLE 3 - HazaRdous waste disposal – solids

(LBS)

*Previously housed hazardous materials.

3.2 Extended temporary services. If the performance period of the contract is extended by the KO, the contractor shall continue to provide all temporary services as specified herein for the extension period.

3.3 Electrical shore-tie. The Contractor shall provide 450 VAC, 400 Amp, 3-Phase, 60 Hz, if only grounded power is available, an in-line isolation transformer shall be provided by the Contractor to provide ungrounded power.

4. NOTES

This section is not applicable to this work item.

86850_PWB_0712_FLT

WORK ITEM 3: Sea Trial Performance, Provide Support

1. SCOPE

1.1 Intent. This work item describes the requirements for the Contractor to provide support for the performance of sea trials.

1.2 Government-furnished property.

None.

2. REFERENCES

Coast Guard Drawings

None.

Coast Guard Publications

None.

Other References

None.

3. REQUIREMENTS

3.1 General.

3.1.1 CIR. The Contractor shall submit a CIR for the inspections listed in the following paragraph(s):

None.

3.1.2 Tech Rep.

Not applicable.

3.1.3 Protective measures. The Contractor shall furnish and install suitable covering to seal off and protect all non-affected surfaces/equipment and spaces in the vicinity of the work area against contamination during the performance of work. Upon completion of work, remove protective material and inspect for the presence of contamination. Clean all equipment and spaces, contaminated due to improper protection, to original condition of cleanliness.

3.1.4 Interferences. The Contractor shall handle all interferences in accordance with SFLC Std Spec 0000, paragraph 3.3.5 (Interferences).

3.1.5 Trial applicability. The Contractor shall provide support to the vessel crew to perform sea trials for all work items that require conducting operational tests while the vessel is waterborne or underway, prior to the item certification as being complete. The Contractor shall be responsible for ensuring all test procedures are prepared, approved, and distributed for the sea trials, and shall be responsible for recording test data and submitting CFRs to the COTR.

3.2 Sea trial agenda. The Contractor shall prepare an agenda that details the Contractor’s plans for ensuring completion of the required sea trials.

3.2.1 Agenda contents.

3.2.1.1 The agenda shall consist of chronological list of administrative events, inspection events and test events. Events shall be arranged to permit expeditious conduct with minimum interference between concurrent events.

NOTE

Mutually compatible events may be scheduled simultaneously.

3.2.1.2 The agenda shall identify installation of any test equipment or component modification that could impact the normal operation of equipment or systems during performance of the trials.

3.2.1.3 The agenda shall identify any operating instructions or special test procedures that could impact the normal operations of equipment or systems.

3.2.1.4 The agenda shall include the full name, title, security clearance, home address, home telephone number and name of next of kin of each Contractor-personnel scheduled to ride the ship during performance of the trials.

3.2.2 Agenda submission requirements. The Contractor shall submit four legible copies of the sea trial agenda to the COTR two days prior to the scheduled trials.