FA5575-14-R-0010 _Frequency_Converters.pdf

F3N7A04031A003

Project QUUG 09-1019. Install Frequency Converters, Moron Air Base, Spain

The magnitude of the project is betw een $500,000 and $1,000,000 U.S. Dollars. This is furnished for the convenience of prospective contractors. The actual extent of w ork requirements w ill be governed by the specif ications and draw ings. Offers w ill be evaluated according to the criteria in Section M.

A pre-proposal Conference / Site Visit w ill be held 27 June 2014, 10:00 hours local time, in the Contracting Conference room, bldg. 106.

Proposals must be received by the Contracting Officer no later than 12:00 hours local time on 21 July 2014. Proposals submitted by fascmile w ill NOT be accepted.

IN ACCORDANCE WITH THE OFFICE OF DEFENSE COOPERATION POLICY 400-5 "(4) SPANISH MATERIAL, LABOR AND EQUIPMENT MUST BE

USED IF PERMITTED BY THE REQUIREMENTS OF THE CONTRACT SPECIFICATIONS."

Notice to Offerors: Funds are not presently available w ith USAFE to fund this project. No aw ard w ill be made under this solicitation until funds are available, so bid acceptance period should be valid through 30 Sep 2014. In the event of unforeseen budget anomalies and as a result of the Budget Control Act of 2011, the government reserves the right to cancel bids w ith no obligation to the offeror by the government.

MATTHEW BOALS 722-8073

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

20-Jun-2014

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________310 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________21 Jul 2014 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______163 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

496 ABS/LGC (FA5575)

APARTADO 221

41530 MORON

SEVILLA

FA5575

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

12:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

(34) 95 848 054FAX:TEL: (34) 955 848 076 TEL: FAX:

FA5575-14-R-0010 35

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA5575-14-R-0010

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot Install Frequency Converters

FFP

Install Frequency Converters IAW project specifications, dated 30 May 2014, and project drawings, dated 21 November 2011.

FOB: Destination

PURCHASE REQUEST NUMBER: F3N7A04031A003

SIGNAL CODE: A

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-12 Inspection of Construction AUG 1996

252.229-7004 Status of Contractors as a Direct Contractor (Spain) JUN 1997

CLAUSES INCORPORATED BY FULL TEXT

252.246-7000 MATERIAL INSPECTION AND RECEIVING REPORT (MAR 2008)

(a) At the time of each delivery of supplies or services under this contract, the Contractor shall prepare and furnish to the Government a material inspection and receiving report in the manner and to the extent required by Appendix F, Material Inspection and Receiving Report, of the Defense FAR Supplement.

(b) Contractor submission of the material inspection and receiving information required by Appendix F of the

Defense FAR Supplement by using the Wide Area WorkFlow (WAWF) electronic form (see paragraph (b) of the clause at 252.232-7003) fulfills the requirement for a material inspection and receiving report (DD Form 250). Two copies of the receiving report (paper copies of either the DD Form 250 or the WAWF report) shall be distributed with the shipment, in accordance with Appendix F, Part 4, F-401, Table 1, of the Defense FAR Supplement.

(End of clause)

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 310 dys. ADC 1 496 ABS/CE (F3N7A0)

CIVIL ENGINEER FUNCTIONAL

COMMANDER

UNIT 6585

APO AE 09643

722-8060

FOB: Destination

F3N7A0

52.211-13 Time Extensions SEP 2000

52.247-34 F.O.B. Destination NOV 1991

Section H - Special Contract Requirements

BANK LETTER OF GUARANTEE

Within ten (10) calendar days after the date of contract award, the Contractor shall furnish the Contracting Officer a

Bank Letter of Guarantee for the performance of the work in the amount specified below. Failure to furnish the letter of guarantee will be considered nonconforming and the contract may be terminated for default in accordance with

FAR 52.249-10 in Section I.

Amount of Contract Bank Letter

Under $100,000.00 None

(or Euro equivalent)

$100,000.00 - $500,000.00 12% of award amount

$500,000.00 and over 10% of award amount

The Bank Letter of Guarantee will be dated as of the contract date or as soon thereafter as possible. The Bank Letter of Guarantee shall state that a guarantee has been issued against the awarded contract and that the following conditions are in force.

1. When presented by a representative of the U.S. Government against debts due, redemption cannot be contested.

2. The value of the guarantee is to be cited in Euros.

3. The Bank Letter of Guarantee shall also state that the bank agrees and consents that the contract may be modified by change order or supplemental agreement without affecting the validity of the

Bank Letter of Guarantee. The Contracting Officer will not issue the Notice to Proceed until approval and acceptance of the Bank Letter of Guarantee.

The Bank Letter of Guarantee will continue in effect throughout the performance period. During the warranty period an amount equal to 5% of the original contract price shall be applicable.

Section I - Contract Clauses

52.203-5 Covenant Against Contingent Fees APR 1984

52.203-7 Anti-Kickback Procedures OCT 2010

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-6 Data Universal Numbering System Number JUL 2013

52.204-7 System for Award Management JUL 2013

52.204-7 Alt I System for Award Management-- Alternate I JUL 2013

52.204-8 Annual Representations and Certifications JAN 2014

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier Subcontract

Awards

JUL 2013

52.204-13 System for Award Management Maintenance JUL 2013

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

AUG 2013

52.215-2 Audit and Records--Negotiation OCT 2010

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997

52.215-19 Notification of Ownership Changes OCT 1997

52.222-50 Combating Trafficking in Persons FEB 2009

52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.223-19 Compliance with Environmental Management Systems MAY 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.225-14 Inconsistency Between English Version And Translation Of

Contract

FEB 2000

52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

DEC 2012

52.229-6 Taxes--Foreign Fixed-Price Contracts FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002

52.232-18 Availability Of Funds APR 1984

52.232-23 Assignment Of Claims JAN 1986

52.232-23 Alt I Assignment of Claims (Jan 1986) - Alternate I APR 1984

52.232-25 Prompt Payment JUL 2013

52.232-27 Prompt Payment for Construction Contracts JUL 2013

52.233-1 Disputes JUL 2002

52.233-1 Alt I Disputes (Jul 2002) - Alternate I DEC 1991

52.233-3 Protest After Award AUG 1996

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-14 Availability and Use of Utility Services APR 1984

52.236-17 Layout of Work APR 1984

52.236-19 Organization and Direction of the Work APR 1984

52.236-21 Specifications and Drawings for Construction FEB 1997

52.242-13 Bankruptcy JUL 1995

52.242-14 Suspension of Work APR 1984

52.243-4 Changes JUN 2007

52.243-5 Changes and Changed Conditions APR 1984

52.246-21 Alt I Warranty of Construction (Mar 1994) - Alternate I APR 1984

52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984

52.249-10 Alt I Default (Fixed-Price Construction) (Apr 1984) Alternate I APR 1984

52.249-14 Excusable Delays APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Terrorist Country

MAR 2014

252.222-7002 Compliance With Local Labor Laws (Overseas) JUN 1997

252.222-7004 Compliance With Spanish Social Security Laws and

Regulations

JUN 1997

252.223-7006 Prohibition On Storage And Disposal Of Toxic And

Hazardous Materials

APR 2012

252.223-7006 Alt I Prohibition on Storage and Disposal of Toxic and Hazardous

Materials (Apr 1993) - Alternate I

NOV 1995

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013

252.225-7043 Antiterrorism/Force Protection Policy for Defense Contractors

Outside the United States

MAR 2006

252.228-7006 Compliance With Spanish Laws and Insurance DEC 1998

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7008 Assignment of Claims (Overseas) JUN 1997

252.232-7010 Levies on Contract Payments DEC 2006

252.233-7001 Choice of Law (Overseas) JUN 1997

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.236-7006 Cost Limitation JAN 1997

252.236-7007 Additive or Deductive Items DEC 1991

252.239-7001 Information Assurance Contractor Training and Certification JAN 2008

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.247-7023 Transportation of Supplies by Sea APR 2014

252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the

Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 300 calendar days after issuance of notice to proceed. * The time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of Euro 390.85 for the first calendar day and Euro 280.21 for each calendar day of delay after the first calendar day until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

United States law will apply to resolve any claim of breach of this contract.

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 15% percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting

Officer determines that the reduction would be to the advantage of the Government.

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

(a) The Contractor shall promptly, and before the conditions are disturbed, give a written notice to the Contracting

Officer of

(1) subsurface or latent physical conditions at the site which differ materially from those indicated in this contract, or

(2) unknown physical conditions at the site, of an unusual nature, which differ materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in the contract.

(b) The Contracting Officer shall investigate the site conditions promptly after receiving the notice. If the conditions do materially so differ and cause an increase or decrease in the Contractor's cost of, or the time required for, performing any part of the work under this contract, whether or not changed as a result of the conditions, an equitable adjustment shall be made under this clause and the contract modified in writing accordingly.

(c) No request by the Contractor for an equitable adjustment to the contract under this clause shall be allowed, unless the Contractor has given the written notice required; provided, that the time prescribed in (a) above for giving written notice may be extended by the Contracting Officer.

(d) No request by the Contractor for an equitable adjustment to the contract for differing site conditions shall be allowed if made after final payment under this contract.

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

(a) The Contractor acknowledges that it has taken steps reasonably necessary to ascertain the nature and location of the work, and that it has investigated and satisfied itself as to the general and local conditions which can affect the work or its cost, including but not limited to

(1) conditions bearing upon transportation, disposal, handling, and storage of materials;

(2) the availability of labor, water, electric power, and roads;

(3) uncertainties of weather, river stages, tides, or similar physical conditions at the site;

(4) the conformation and conditions of the ground; and (5) the character of equipment and facilities needed preliminary to and during work performance. The Contractor also acknowledges that it has satisfied itself as to the character, quality, and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site, including all exploratory work done by the

Government, as well as from the drawings and specifications made a part of this contract. Any failure of the

Contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from responsibility for estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expense to the Government.

(b) The Government assumes no responsibility for any conclusions or interpretations made by the Contractor based on the information made available by the Government. Nor does the Government assume responsibility for any understanding reached or representation made concerning conditions which can affect the work by any of its officers or agents before the execution of this contract, unless that understanding or representation is expressly stated in this contract.

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

(a) All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The

Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting

Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.

(b) The Contractor shall obtain the Contracting Officer's approval of the machinery and mechanical and other equipment to be incorporated into the work. When requesting approval, the Contractor shall furnish to the

Contracting Officer the name of the manufacturer, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer's approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the

Contractor shall provide full information concerning the material or articles. When directed to do so, the Contractor shall submit samples for approval at the Contractor's expense, with all shipping charges prepaid. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.

(c) All work under this contract shall be performed in a skillful and workmanlike manner. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State, and municipal laws, codes, and regulations applicable to the performance of the work. The Contractor shall also be responsible for all damages to persons or property that occur as a result of the Contractor's fault or negligence. The Contractor shall also be responsible for all materials delivered and work performed until completion and acceptance of the entire work, except for any completed unit of work which may have been accepted under the contract.

52.236-8 OTHER CONTRACTS (APR 1984)

The Government may undertake or award other contracts for additional work at or near the site of the work under this contract. The Contractor shall fully cooperate with the other contractors and with Government employees and shall carefully adapt scheduling and performing the work under this contract to accommodate the additional work, heeding any direction that may be provided by the Contracting Officer. The Contractor shall not commit or permit any act that will interfere with the performance of work by any other contractor or by Government employees.

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (APR 1984)

(a) The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so, and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workmen, the Contractor shall trim those limbs or branches with a clean cut and paint the cut with a tree-pruning compound as directed by the Contracting

Officer.

(b) The Contractor shall protect from damage all existing improvements and utilities

(1) at or near the work site, and

(2) on adjacent property of a third party, the locations of which are made known to or should be known by the

Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the Contractor fails or refuses to repair the damage promptly, the Contracting Officer may have the necessary work performed and charge the cost to the Contractor.

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the

Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the

Contracting Officer may terminate the Contractor's right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

If the Contracting Officer decides to conduct a preconstruction conference, the successful offeror will be notified and will be required to attend. The Contracting Officer's notification will include specific details regarding the date, time, and location of the conference, any need for attendance by subcontractors, and information regarding the items to be discussed.

52.236-28 PREPARATION OF PROPOSALS--CONSTRUCTION (OCT 1997)

(a) Proposals must be (1) submitted on the forms furnished by the Government or on copies of those forms, and (2) manually signed. The person signing a proposal must initial each erasure or change appearing on any proposal form.

(b) The proposal form may require offerors to submit proposed prices for one or more items on various bases, including--

(1) Lump sum price;

(2) Alternate prices;

(3) Units of construction; or

(4) Any combination of paragraphs (b)(1) through (b)(3) of this provision.

(c) If the solicitation requires submission of a proposal on all items, failure to do so may result in the proposal being rejected without further consideration. If a proposal on all items is not required, offerors should insert the words “no proposal” in the space provided for any item on which no price is submitted.

(d) Alternate proposals will not be considered unless this solicitation authorizes their submission.

(End of provision)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://fariste.hill.af.mil

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Department of Defense Federal Acquisition Regulation (48 CFR

Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.204-7006 BILLING INSTRUCTIONS (OCT 2005)

When submitting a request for payment, the Contractor shall--

(a) Identify the contract line item(s) on the payment request that reasonably reflect contract work performance; and

(b) Separately identify a payment amount for each contract line item included in the payment request.

252.229-7001 TAX RELIEF (JUN 1997)

(a) Prices set forth in this contract are exclusive of all taxes and duties from which the United States Government is exempt by virtue of tax agreements between the United States Government and the Contractor's government. The following taxes or duties have been excluded from the contract price:

NAME OF TAX: IVA RATE (PERCENTAGE): (Offeror Insert)

(b) The Contractor's invoice shall list separately the gross price, amount of tax deducted, and net price charged.

(c) When items manufactured to United States Government specifications are being acquired, the Contractor shall identify the materials or components intended to be imported in order to ensure that relief from import duties is obtained. If the Contractor intends to use imported products from inventories on hand, the price of which includes a factor for import duties, the Contractor shall ensure the United States Government's exemption from these taxes. The

Contractor may obtain a refund of the import duties from its government or request the duty-free import of an amount of supplies or components corresponding to that used from inventory for this contract.

252.229-7005 TAX EXEMPTIONS (SPAIN) (MAR 2012)

(a) As the Contractor represented in its offer, the contract price, including the prices in subcontracts awarded under this contract, does not include taxes from which the United States Government is exempt.

(b) In accordance with tax relief agreements between the United States Government and the Spanish Government, and because the incumbent contract arises from the activities of the United States Forces in Spain, the contract will be exempt from the following excise, luxury, and transaction taxes:

(1) Derechos de Aduana (Customs Duties).

(2) Impuesto de Compensacion a la Importacion (Compensation Tax on Imports).

(3) Transmissiones Patrionomiales (Property Transfer Tax).

(4) Impuesto Sobre el Lujo (Luxury Tax).

(5) Actos Juridocos Documentados (Legal Official Transactions).

(6) Impuesto Sobre el Trafico de Empresas (Business Trade Tax).

(7) Impuestos Especiales de Fabricacion (Special Products Tax).

(8) Impuesto Sobre el Petroleo y Derivados (Tax on Petroleum and its By-Products).

(9) Impuesto Sobre el Uso de Telefona (Telephone Tax).

(10) Impuesto General Sobre la Renta de Sociedades y demas Entidades Juridicas (General Corporation Income

Tax).

(11) Impuesto Industrial (Industrial Tax).

(12) Impuesto de Rentas Sobre el Capital (Capital Gains Tax).

(13) Plus Vailia (Increase on Real Property).

(14) Contribucion Territorial Urbana (Metropolitan Real Estate Tax).

(15) Contribucion Territorial Rustica y Pecuaria (Farmland Real Estate Tax).

(16) Impuestos de la Diputacion (County Service Charges).

(17) Impuestos Municipal y Tasas Parafiscales (Municipal Tax and Charges).

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2013) (DEVIATION)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area WorkFlow

(WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports http://www.acq.osd.mil/dpap/dars/dfars/html/current/252232.htm

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the Central Contractor Registration at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training

Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, File Transfer Protocol, or PayWeb.

(1) To access PayWeb, the vendor may go to the following site: https://onronline.onr.navy.mil/payweb/

(2) For instructions on PayWeb payment request submission, please contact the office identified below:

____________________Not Applicable____________________________________________

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

___________________Construction Invoice______________________________________________

(Contracting Officer: Insert applicable document type(s). Note: If a “Combo” document type is identified but not supportable by the Contractor’s business systems, an “Invoice” (stand-alone) and “Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in

WAWF, as specified by the contracting officer.

___________________Not Applicable______________________________________________

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC F78900

Issue By DoDAAC FA5575

Admin DoDAAC FA5575

Inspect By DoDAAC

Ship To Code

Ship From Code https://www.acquisition.gov/ https://wawf.eb.mil/ https://wawf.eb.mil/ https://onronline.onr.navy.mil/payweb/

Mark For Code

Service Approver (DoDAAC)

Service Acceptor (DoDAAC)

Accept at Other DoDAAC

LPO DoDAAC

DCAA Auditor DoDAAC

Other DoDAAC(s)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the e-mail address identified below in the “Send

Additional Email Notifications” field of WAWF once a document is submitted in the system.

____________matthew.boals@us.af.mil____________________________________________

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s

WAWF point of contact.

_______________Not Applicable__________________________________________________

(3) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

SEE SECTION J

5352.201-9101 OMBUDSMAN (APR 2010)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, concerned parties may contact the Center/MAJCOM ombudsmen:

Primary: Ms. Tara Petersen

HQ USAFE/A7K, UNIT 3050, Box 10, APO AE 09094-0110

HQ USAFE/A7K, Flugplatz Ramstein, 66877 Ramstein Germany

E-mail: tara.petersen@ramstein.af.mil

Tel: (49)-6371-47-2209, Fax: (49)-6731-47-2025 http://www.whitehouse.gov/omb/circulars/a076/a76_rev2003.pdf mailto:tara.petersen@ramstein.af.mil

Alternate: Ms. Heidi Hoehn

HQ USAFE/A7K, UNIT 3050, Box 10, APO AE 09094-0110

HQ USAFE/A7K, Flugplatz Ramstein, 66877 Ramstein Germany

E-mail: heidi.hoehn@ramstein.af.mil

Tel: (49)-6371-47-9330, Fax: (49)-6731-47-2025

Concerns, issues, disagreements, and recommendations that cannot be resolved at the MAJCOM/DRU level, may be brought by the concerned party for further consideration to the Air Force ombudsman, Associate Deputy Assistant

Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number

(703) 588-7004, facsimile number (703) 588-1067.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

As prescribed in 5323.804, insert the following clause in solicitations and contracts:

ELIMINATION OF USE OF CLASS I OZONE DEPLETING SUBSTANCES (ODSs)

(APR 2003)

(a) Unless the requiring activity has obtained prior Senior Acquisition Official (SAO) approval, contractors may not:

(1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS.

[Note: This prohibition does not apply to manufacturing.]

(b) For the purposes of Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32-7086) are Class I ODSs:

(1) Halons: 1011, 1202, 1211, 1301, and 2402;

mailto:heidi.hoehn@ramstein.af.mil http://pklunx.hill.af.mil/farsite/reghtml/regs/far2afmcfars/af_afmc/affars/5323.htm#P32_477 http://www.e-publishing.af.mil/pubfiles/af/32/afi32-7086/afi32-7086.pdf

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-215, CFC-216, and CFC-

217, and the blends R-500, R-501, R-502, and R-503; and

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

[NOTE: Material that uses one or more of these Class I ODSs as minor constituents do not meet the Air Force definition of a Class I ODS.]

(c) The requiring activity has obtained SAO approval to permit the contractor to use the following Class I ODS(s):

Class I ODS/ Application or Use/Quantity (lbs.) per contract period of performance

NONE

(d) The offeror/contractor is required to notify the contracting officer if any Class I ODS that is not specifically listed above is required in the test, operation, or maintenance of any system, subsystem, item, component, or process.

As prescribed at 5328.310(b), insert the following clause in solicitations and contracts:

SPANISH INSURANCE CERTIFICATE (USAFE) (JUNE 2006)

(a) Below follows the Insurance Certificate required for any Third Country National Contractor

(TCN), other than U.S. or Spanish, required for use under this contract. The certificate is provided to standardize base access procedures. It must be completed and signed by the policyholder and the insurer.

(b) The amount of coverage minimum is 90,151.82 Euros per insured party (personal injury), 60,101.21 Euros per accident (property damage), and 6, 010.12 Euros security deposit for legal fees. In all cases the amount of coverage, if different from the above amounts, will be determined by the insurer, except in situations where the minimum coverage applies.

(c) The request for base access and the insurance certificate should be processed to the Spanish authorities 15 days prior to the actual time of arrival for contract performance.

http://pklunx.hill.af.mil/farsite/reghtml/regs/far2afmcfars/af_afmc/affars/5328.htm#P47_789

(d) Complete the following certification:

SPANISH INSURANCE CERTIFICATION

CERTIFICATE OF INSURANCE COVERAGE OF THE CIVIL LIABILITY REFERRED TO

UNDER ARTICLE 5 OF ANNEX 6 TO THE AGREEMENT BETWEEN THE KINGDOM OF

SPAIN AND THE UNITED STATES OF AMERICA ON COOPERATION FOR THE

DEFENSE, SIGNED THE 1

st

OF DECEMBER 1988.

The insurance Company _______________________________________________ with legal domicile in _______________________________________________________________

Tel: __________________________ of Spanish/US nationality, registered in the Mercantile Registry of_______________________________________

Date:____________________, Number________, Book:_______, Section _____, Volume________, Page_______.

CERTIFIES

That Mr./Mrs. ____________________of_____________________ nationality, with passport number_______________, has contracted with this company Policy Number _____________ of civil liability against damages to persons or property which could arise from his/her actions or omissions in the performance of his/her official functions/professional activities in Spain because of the contract of ______________________________________________________ for the U.S.

forces, and during the visit which, in respect of such contract, he/she may make to the

_______________ Military Base, according to the general conditions in force for this type of insurance and also to the special conditions created for this purpose in the Spanish-U.S.

Permanent Committee; that he/she has paid the premium according to the agreed conditions; and that such Policy is in force.

The Policy establishes as coverage of the mentioned risks the following amounts:

INDEMNITY LIMITS:

- For casualty: -------------------------- 601,012.10 Euros

With the following sub-limits for each injured person:

- For personal liability:----------------- 90,151.82 Euros

- For property damage:----------------- 60,101.21 Euros

- For Judiciary Bond:-------------------- 6, 010.12 Euros

The granted coverage is effective from ________________ through________________, and does not include any type of franchise, or similar limitation, to be deducted from the mentioned guarantees or any clause which requires the submission to any type of arbitration. The underwriting insurance company considers that the established amounts adequately cover the insured risks.

The policy sets forth the following clauses:

1. “The insurance company waives any right of subrogation against the United States of America which may arise by reason of any payment under this Policy.”

2. “The parties hereto explicitly agree to submit to the jurisdiction of the Spanish Courts of Law and to the Spanish Laws to settle any matter related to the construction or enforcement of the clauses and conditions of this Policy.”

IN WITNESS HEREOF, the present document is signed in______________________________, on the____________of_____________20____

For the Insured Company (signature) For the Insurance (signature)

CERTIFICADO DE COBERTURA DE SEGURO DE LA RESPONSABILIDAD CIVIL A QUE

SE REFIERE EL ARTICULO 5 DEL ANEXO 6 AL CONVENIO ENTRE EL REINO DE

ESPAÑA Y LOS ESTADOS UNIDOS DE AMERICA SOBRE COOPERACION PARA LA

DEFENSA, FIRMADO EL DIA 1 DE DICIEMBRE DE 1988.

La Compañia de Seguros ______________________________________ con domicilio social en la Calle/Avda./Pla.

____________________________________________________________________, Tlfo.:

_________________ , de nacionalidad española/norteamericana, inscrita en el Registro

Mercantil de______________________________, fecha _________________, Número

________, Libro _________, Sección ______, Tomo _______, Folio_______.

CERTIFICA:

Que D. __________________________, de nacionalidad _________________________, provisto del pasaporte número _______________________, tiene suscrita con esta Compañia la

Póliza número ____________________________, de responsabilidad civil contra daños a personas y cosas que pudieran derivarse de acciones u omisiones realizadas en el desempeño de sus funciones oficiales/actividades profesionales en España con ocasión del contrato de

__________________________________________, para las Fuerzas de los EE.UU. y con la visita que en relación con dicho contrato realice a la Base Militar de

___________________________, según las condiciones generales vigentes para este tipo de seguros y además las condiciones especiales elaboradas a este fin en el Comité Permanente

Hispano-Norteamericano; habiéndose satisfecho la prima según las condiciones pactadas, y encontrándose dicha Póliza en vigor.

La Póliza establece como cobertura de los riesgos mencionados las siguientes cuantías:

LIMITES DE INDEMNIZACION:

- Por siniestro: -------------------------- 601.012,10 Euros

Con los siguientes sublímites por perjudicado:

- Por daños personales:----------------- 90.151,82 Euros

- Por daños materiales: ----------------- 60.101,21 Euros

- Por fianzas judiciales:-_--------------- 6.010,12 Euros

Las coberturas otorgadas son efectivas desde el ___________________________, hasta el

_________________________, no incluyéndose en las mismas ningún tipo de franquicia o limitación similar a deducir de las garantías indicadas ni ninguna disposición que requiera la sumisión a cualquier tipo de arbitraje. La Compañia aseguradora que suscribe considera que las cuantías establecidas cubren adecuadamente los riesgos asegurados.

La Póliza establece las siguientes cláusulas:

1. “La Compañia Aseguradora renuncia a cualquier derecho de subrogación contra los Estados

Unidos de América que pueda provenir por razones diferentes a pago, bajo la Póliza epígrafiada.”

2. “Las partes se someten expresamente a la jurisdicción de los tribunales españoles y al derecho español para resolver cualquier cuestión relativa a la interpretación o aplicación de las cláusulas y condiciones de la Póliza.”

Y para que conste a los efectos oportunos, se firma el presente en __________________ a

_______________ de _____________ 2.0___._______________________________________

Tomador: Asegurador:

(END OF CERTIFICATE)

(End of Clause)

5352.242-9000 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (AUGUST

2007)

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent…