FA521521R8001 ATTACHMENT 1 - CLAUSES _PROVISIONS.pdf

FA5215-21-R-8001

Solicitation Clauses and Provisions

CLAUSE NO. CLAUSE TITLE YEAR-MO SECTION

VARIATION

NAME DATE

252.201-7000 Contracting Officer's Representative 1991-12 SEC G

252.203-7000 Requirements Relating to Compensation of Former DoD Officials 2011-09 SEC I

252.203-7002 Requirement to Inform Employees of Whistleblower Rights. 2013-09 SEC I

252.203-7005 Representation Relating to Compensation of Former DoD Officials. 2011-11 SEC K

As prescribed in 203.171-4(b), insert the following provision:

252.204-7003 Control of Government Personnel Work Product. 1992-04 SEC I

252.204-7004 Antiterrorism Awareness Training for Contractors. 2019-02 SEC I

252.204-7006 Billing Instructions. 2005-10 SEC G

252.204-7008 Compliance with Safeguarding Covered Defense Information Controls. 2016-10 SEC I

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. 2016-10 SEC I

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. 2016-05 SEC I

252.205-7000 Provision of Information to Cooperative Agreement Holders 1991-12 SEC I

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the 2019-05 SEC I

Government of a Country that is a State Sponsor of Terrorism.

252.215-7013 Supplies and Services Provided by Nontraditional Defense Contractors. 2018-01 SEC L

252.219-7011 Notification to Delay Performance. 1998-06 SEC I

252.222-7002 Compliance with Local Labor Laws (Overseas). 1997-06 SEC I

252.223-7006 Prohibition on Storage, Treatment, and 2014-09 SEC I

Disposal of Toxic or Hazardous Materials.

252.225-7001 Buy American and Balance of Payments Program. 2017-12 SEC I

252.225-7002 Qualifying Country Sources as Subcontractors. 2017-12 SEC I

252.225-7005 Identification of Expenditures in the United States. 2005-06 SEC I

252.225-7012 Preference for Certain Domestic Commodities. 2017-12 SEC I

252.225-7043 Antiterrorism/Force Protection for Defense 2015-06 SEC I

Contractors Outside the United States.

252.225-7048 Export-Controlled Items. 2013-06 SEC I

252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic 2019-04 SEC I

Enterprises, and Native Hawaiian Small Business Concerns.

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2018-12 SEC G

252.232-7010 Levies on Contract Payments. 2006-12 SEC I

252.233-7001 Choice of Law (Overseas). 1997-06 SEC I

252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. 2013-06 SEC I

252.243-7001 Pricing of Contract Modifications. 1991-12 SEC I

252.243-7002 Requests for Equitable Adjustment. 2012-12 SEC I

252.244-7000 Subcontracts for Commercial Items 2013-06 SEC I

52.219-14 Limitations on Subcontracting (DEVIATION 2019-O0003) 2017-01 SEC I

Deviation 2019-O0003 2019-01

52.219-6 Notice of Total Small Business Set-Aside (DEVIATION 2019-O0003) 2011-11 SEC I

Deviation 2019-O0003 2019-01

52.203-6 Restrictions on Subcontractor Sales to the Government. - (Alternate I) 2006-09 SEC I

Alternate I 1995-10

52.203-15 Whistleblower Protections Under the American Recovery and

Reinvestment A

2009-06 SEC I

Reinvestment Act of 2009

52.203-16 Preventing Personal Conflicts of Interest 2020-06 SEC I

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. 2018-10 SEC I

52.204-14 Service Contract Reporting Requirements 2016-10 SEC I

52.204-16 Commercial and Government Entity Code Reporting. 2016-07 SEC I

52.204-19 Incorporation by Reference of Representation and 2014-12 SEC I

Certifications

52.204-18 Commercial and Government Entity Code Maintenance. 2016-07 SEC K

52.204-21 Basic Safeguarding of Covered Contractor Information Systems. 2016-06 SEC I

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video

Surveillance Services or Equipment

2019-08 SEC I

52.204 Security Requirement 1996-09 SEC I

52.204-7 System for Award Management. 2018-10 SEC I

52.216-24 Limitation of Government Liability 1984-04 SEC I

52.216-25 Contract Definitization 2010-10 SEC I

52.219-13 Notice of Set-Aside of Orders. 2011-11 SEC I

52.222-21 Prohibition of Segregated Facilities. 2015-04 SEC I

52.222-41 Service Contract Labor Standards. 2018-08 SEC I

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities 2020 Jun SEC I

Or Transaction Relating to Iran-Representation and Certifications

52.222-44 Fair Labor Standards Act and Service 2014-05 SEC I

Contract Labor Standards-Price Adjustment.

52.222.50 Combating Trafficking in Persons 2019-Jan SEC I

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. 2011-08 SEC I

52.224-3 Privacy Training. 2017-01 SEC I

52.225-13 Restrictions on Certain Foreign Purchases. 2008-06 SEC I

52.232-33 Payment by Electronic Funds Transfer-System for Award Management. 2018-10 SEC I

52.232-40 Providing Accelerated Payments to Small Business Subcontractors. 2013-12 SEC I

52.237-2 Protection of Government Buildings, Equipment, and Vegetation. 1984-04 SEC I

52.209-11 Representation by Corporations Regarding Delinquent Tax 2016-02 SEC I

52.246-4 Inspection of Services Fixed Price 1996-09 SEC I

Liability or a Felony Conviction under any Federal Law.

52.204-1 Approval of Contract. 1989-12 SEC I

CLAUSES IN FULL TEXT

CLAUSE NO. CLAUSE TITLE

(MONTH

YEAR)

VARIATION

NAME DATE

CLAUSE TEXT

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal

Confidentiality Agreements or

Statements-Representation.

( 2017)

As prescribed in 3.909-3(a), insert the following provision:

Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-

Representation (Jan 2017)

(a) Definition. As used in this provision-

"Internal confidentiality agreement or statement, subcontract, and subcontractor", are defined in the clause at 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

(b) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations

Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions), Government agencies are not permitted to use funds appropriated (or otherwise made available) for contracts with an entity that requires employees or subcontractors of such entity seeking to report waste, fraud, or abuse to sign internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information.

(c) The prohibition in paragraph (b) of this provision does not contravene requirements applicable to Standard

Form 312, (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information

Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information.

(d) Representation. By submission of its offer, the Offeror represents that it will not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General).

(End of provision)

(End of Clause)

52.204-22 Alternative Line Item Proposal. ( 2017)

As prescribed in 4.1008 , insert the following provision:

Alternative Line Item Proposal (Jan 2017)

(a) The Government recognizes that the line items established in this solicitation may not conform to the Offeror's practices. Failure to correct these issues can result in difficulties in acceptance of deliverables and processing payments.

Therefore, the Offeror is invited to propose alternative line items for which bids, proposals, or quotes are requested in this solicitation to ensure that the resulting contract is economically and administratively advantageous to the

Government and the Offeror.

(b) The Offeror may submit one or more additional proposals with alternative line items, provided that alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation. However, acceptance of an alternative proposal is a unilateral decision made solely at the discretion of the Government. Offers that do not comply with the line items specified in this solicitation may be determined to be nonresponsive or unacceptable.

(End of provision)

(End of Clause)

52.204-24 Representation Regarding Certain

Telecommunications and Video Surveillance Services or Equipment Aug 2020

As prescribed in 4.2105(a), insert the following provision:

REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR

EQUIPMENT (AUG 2020)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it “does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument” in the provision at 52.204-26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Items.

(a) Definitions. As used in this provision—

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-

232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i)Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii)Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub.

L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to—

(i)Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii)Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM)

(https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

(d) Representation. The Offeror represents that—

(1)It □ will, □ will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds “will” in paragraph (d)(1) of this section; and https://www.acquisition.gov/content/42105-solicitation-provisions-and-contract-clause#id1989H0G40RF https://www.acquisition.gov/content/52204-26-covered-telecommunications-equipment-or-services-representation#id19CAC0P0ESS https://www.acquisition.gov/content/52212-3-offeror-representations-and-certifications-commercial-items#i1060550 https://www.acquisition.gov/content/52204-25-prohibition-contracting-certain-telecommunications-and-video-surveillance-services-or-equipment#id1989I600I4C https://www.sam.gov/

(2)After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that—

It □ does, □ does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds “does” in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded “will” in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i)For covered equipment—

(A)The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B)A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C)Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii)For covered services—

(A)If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B)If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded “does” in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i)For covered equipment—

(A)The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B)A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C)Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii)For covered services—

(A)If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B)If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(End of provision)

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. ( 2015)

As prescribed in 9.409 , insert the following clause:

Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for

Debarment (Oct 2015)

(a) Definition. "Commercially available off-the-shelf (COTS)" item, as used in this clause-

(1) Means any item of supply (including construction material) that is-

(i) A commercial item (as defined in paragraph (1) of the definition in FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

(b) The Government suspends or debars Contractors to protect the Government's interests. Other than a subcontract for a commercially available off-the-shelf item, the Contractor shall not enter into any subcontract, in excess of $35,000 with a Contractor that is debarred, suspended, or proposed for debarment by any executive agency unless there is a compelling reason to do so.

(c) The Contractor shall require each proposed subcontractor whose subcontract will exceed $35,000, other than a subcontractor providing a commercially available off-the-shelf item, to disclose to the Contractor, in writing, whether as of the time of award of the subcontract, the subcontractor, or its principals, is or is not debarred, suspended, or proposed for debarment by the Federal Government.

(d) A corporate officer or a designee of the Contractor shall notify the Contracting Officer, in writing, before entering into a subcontract with a party (other than a subcontractor providing a commercially available off-the-shelf item) that is debarred, suspended, or proposed for debarment (see FAR 9.404 for information on the System for Award Management

(SAM) Exclusions). The notice must include the following:

(1) The name of the subcontractor.

(2) The Contractor's knowledge of the reasons for the subcontractor being listed with an exclusion in SAM.

(3) The compelling reason(s) for doing business with the subcontractor notwithstanding its being listed with an exclusion in SAM.

(4) The systems and procedures the Contractor has established to ensure that it is fully protecting the Government's interests when dealing with such subcontractor in view of the specific basis for the party's debarment, suspension, or proposed debarment.

(e) Subcontracts. Unless this is a contract for the acquisition of commercial items, the Contractor shall include the requirements of this clause, including this paragraph (e) (appropriately modified for the identification of the parties), in each subcontract that-

(1) Exceeds $35,000 in value; and

(2) Is not a subcontract for commercially available off-the-shelf items.

(End of clause)

(End of Clause)

52.212-2 Evaluation-Commercial Items.

As prescribed in 12.301(c), the Contracting Officer may insert a provision substantially as follows:

Evaluation-Commercial Items (Oct 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

1. Technical Acceptability Factor: The Government will evaluate technical proposal on a pass/fail basis and assign an

Acceptable or Unacceptable rating as described in Table 1 below.

Table 1. Technical Ratings

Rating Description

Acceptable Proposal meets the requirement of the solicitation

Unacceptable Proposal does not meet the requirements of the solicitation

Subfactor 1 – Experience

Offeror’s submittal documentation addressing requirements in paragraph 1.4.1 of the PWS.

Subfactor 2 – Security Offeror’s confirmation ability to obtain SERCET clearance on the start of period of performance. Addressing requirement in section 4.2.1.

2. Price Evaluation Factor. The Government will evaluate the offer based on Total Contract Price. The price evaluation will be the sum of all priced line items. The Government reserves the right to perform price realism analysis.

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) In order to meet the requirements of FAR Part 6 and FAR Part 17, the price equivalent to the six (6) months extension of services authorized by FAR 52.217-8 will be evaluated and factored as part of the total evaluated price for award. The Government will calculate prices for a quantity equivalent to 6 months by prorating prices offered for CLIN 0001 and all applicable CLINs including Options under FAR 52.217-9. The total evaluated price will be calculated on the basis of potential maximum 6-month extension using the following formula:

i.CLIN 0001 Unit Price x 6 months ii.CLIN 1001 Unit Price x 6 months

52.217-5 Evaluation of Options. (1990)

As prescribed in 17.208(c), insert a provision substantially the same as the following:

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government’s best interests, the

Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of Provision)

52.217-8 Option to Extend Services (1999)

As prescribed in 17.208(f), insert a clause substantially the same as the following:

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within 30 DAYS of Contract Expiration.

52.217-9 Option to Extend the Term of the Contract

(2000)

As prescribed in 17.208(g), insert a clause substantially the same as the following:

(a) The Government may extend the term of this contract by written notice to the Contractor at least 30

DAYS of Contract Expiration; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 60 days before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed four (4) years, and six (6) months.

252.232-7006 Wide Area WorkFlow Payment Instructions. (2018)

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause-

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area

WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

Payment request and receiving report are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation

Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award

Management at https:// www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based

Training Course and use the Practice Training Site before submitting payment requests through WAWF.

Both can be accessed by selecting the Web Based Training link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the

Contracting Officer.

NOT END USE ITEM

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

INVOICE 2in1

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF combo document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

| Field Name in WAWF || Data to be entered in WAWF |

| Pay Official DoDAAC || PROVIDED ON AWARD DOCUMENT |

| Issue By DoDAAC || PROVIDED ON AWARD DOCUMENT |

| Admin DoDAAC || PROVIDED ON AWARD DOCUMENT |

| Inspect By DoDAAC || PROVIDED ON AWARD DOCUMENT |

| Ship To Code || |

| Ship From Code || |

| Mark For Code || |

| Service Approver (DoDAAC) || PROVIDED ON AWARD DOCUMENT |

| Service Acceptor (DoDAAC) || PROVIDED ON AWARD DOCUMENT |

| Accept at Other DoDAAC || |

| LPO DoDAAC || |

| DCAA Auditor DoDAAC || |

| Other DoDAAC(s) || |

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal

Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS

Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activitys WAWF point of contact.

PROVIDED ON AWARD DOCUMENT

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed. (End of clause)

252.232-7007 Limitation of Government’s Obligation.

As prescribed in 232.705-70, use the following clause:

LIMITATION OF GOVERNMENT’S OBLIGATION (APR 2014)

(a) Contract line item(s) [Contracting Officer insert after negotiations] is/are incrementally funded. For this/these item(s), the sum of $ [Contracting Officer insert after negotiations] of the total price is presently available for payment and allotted to this contract. An allotment schedule is set forth in paragraph (j) of this clause.

(b) For item(s) identified in paragraph (a) of this clause, the Contractor agrees to perform up to the point at which the total amount payable by the Government, including reimbursement in the event of termination of those item(s) for the Government’s convenience, approximates the total amount currently allotted to the contract. The Contractor is not authorized to continue work on those item(s) beyond that point. The Government will not be obligated in any event to reimburse the Contractor in excess of the amount allotted to the contract for those item(s) regardless of anything to the contrary in the clause entitled “Termination for Convenience of the Government.” As used in this clause, the total amount payable by the Government in the event of termination of applicable contract line item(s) for convenience includes costs, profit, and estimated termination settlement costs for those item(s).

(c) Notwithstanding the dates specified in the allotment schedule in paragraph (j) of this clause, the Contractor will notify the Contracting Officer in writing at least ninety days prior to the date when, in the Contractor’s best judgment, the work will reach the point at which the total amount payable by the Government, including any cost for termination for convenience, will approximate 85 percent of the total amount then allotted to the contract for performance of the applicable item(s). The notification will state (1) the estimated date when that point will be reached and (2) an estimate of additional funding, if any, needed to continue performance of applicable line items up to the next scheduled date for allotment of funds identified in paragraph (j) of this clause, or to a mutually agreed upon substitute date. The notification will also advise the Contracting Officer of the estimated amount of additional funds that will be required for the timely performance of the item(s) funded pursuant to this clause, for a subsequent period as may be specified in the allotment schedule in paragraph (j) of this clause or otherwise agreed to by the parties. If after such notification additional funds are not allotted by the date identified in the Contractor’s notification, or by an agreed substitute date, the Contracting Officer will terminate any item(s) for which additional funds have not been allotted, pursuant to the clause of this contract entitled “Termination for Convenience of the Government.”

(d) When additional funds are allotted for continued performance of the contract line item(s) identified in paragraph (a) of this clause, the parties will agree as to the period of contract performance which will be covered by the funds. The provisions of paragraphs (b) through (d) of this clause will apply in like manner to the additional allotted funds and agreed substitute date, and the contract will be modified accordingly.

(e) If, solely by reason of failure of the Government to allot additional funds, by the dates indicated below, in amounts sufficient for timely performance of the contract line item(s) identified in paragraph (a) of this clause, the

Contractor incurs additional costs or is delayed in the performance of the work under this contract and if additional funds are allotted, an equitable adjustment will be made in the price or prices (including appropriate target, billing, and ceiling prices where applicable) of the item(s), or in the time of delivery, or both. Failure to agree to any such equitable adjustment hereunder will be a dispute concerning a question of fact within the meaning of the clause entitled

“Disputes.”

(f) The Government may at any time prior to termination allot additional funds for the performance of the contract line item(s) identified in paragraph (a) of this clause.

(g) The termination provisions of this clause do not limit the rights of the Government under the clause entitled

“Default.” The provisions of this clause are limited to the work and allotment of funds for the contract line item(s) set forth in paragraph (a) of this clause. This clause no longer applies once the contract is fully funded except with regard to the rights or obligations of the parties concerning equitable adjustments negotiated under paragraphs (d) and (e) of this clause.

(h) Nothing in this clause affects the right of the Government to terminate this contract pursuant to the clause of this contract entitled “Termination for Convenience of the Government.”

https://www.acq.osd.mil/dpap/dars/dfars/html/r20100908/232_7.htm#232.705-70

(i) Nothing in this clause shall be construed as authorization of voluntary services whose acceptance is otherwise prohibited under 31 U.S.C. 1342.

(j) The parties contemplate that the Government will allot funds to this contract in accordance with the following schedule:

On execution of contract $ ________

(month) (day), (year) $ ________

52.209-9 Updates of Publically Available Information (2018)

Regarding Responsibility Matters

As prescribed at 9.104-7 (c), insert the following clause:

Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018)

(a) The Contractor shall update the information in the Federal Awardee Performance and Integrity Information

System (FAPIIS) on a semi-annual basis, throughout the life of the contract, by posting the required information in the System for Award Management via https://www.sam.gov.

(b) As required by section 3010 of the Supplemental Appropriations Act, 2010 (Pub. L. 111-212), all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available. FAPIIS consists of two segments-

(1) The non-public segment, into which Government officials and the Contractor post information, which can only be viewed by-

(i) Government personnel and authorized users performing business on behalf of the Government; or

(ii) The Contractor, when viewing data on itself; and

(2) The publicly-available segment, to which all data in the non-public segment of FAPIIS is automatically transferred after a waiting period of 14 calendar days, except for-

(i) Past performance reviews required by subpart 42.15;

(ii) Information that was entered prior to April 15, 2011; or

(iii) Information that is withdrawn during the 14-calendar-day waiting period by the Government official who posted it in accordance with paragraph (c)(1) of this clause.

(c) The Contractor will receive notification when the Government posts new information to the Contractor's record.

(1) If the Contractor asserts in writing within 7 calendar days, to the Government official who posted the information, that some of the information posted to the non-public segment of FAPIIS is covered by a disclosure exemption under the Freedom of Information Act, the Government official who posted the information must within 7 calendar days remove the posting from FAPIIS and resolve the issue in accordance with agency Freedom of Information procedures, prior to reposting the releasable information.

The contractor must cite 52.209-9 and request removal within 7 calendar days of the posting to FAPIIS.

(2) The Contractor will also have an opportunity to post comments regarding information that has been posted by the Government. The comments will be retained as long as the associated information is retained, i.e., for a total period of 6 years. Contractor comments will remain a part of the record unless the Contractor revises them.

(3) As required by section 3010 of Pub. L. 111-212, all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available.

(d) Public requests for system information posted prior to April 15, 2011, will be handled under

Freedom of Information Act procedures, including, where appropriate, procedures promulgated under E.O. 12600.

(End of clause)

(End of Clause)

52.209-7 Information Regarding Responsibility Matters. ( 2018)

As prescribed at 9.104-7 (b), insert the following provision:

Information Regarding Responsibility Matters (Oct 2018) http://www.sam.gov/

(a) Definitions. As used in this provision-

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals

Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables. Federal contracts and grants with total value greater than $10,000,000 means-

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award

Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [_] has [_] does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked has in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity

Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in-

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in

FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed viahttps://www.sam.gov (see 52.204-7).

52.212-4 Contract Terms and Conditions-Commercial Items. ( 2018)

As prescribed in 12.301(b)(3), insert the following clause:

Contract Terms and Conditions-Commercial Items (Oct 2018)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in http://www.sam.gov/ the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31U.S.C.3727). However, when a third party makes payment (e.g.,use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41U.S.C.chapter71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers.

The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the

Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include-

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer-

System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C.3903) and Office of

Management and Budget (OMB) prompt payment regulations at 5 CFR Part1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.-

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act (31

U.S.C.3903) and prompt payment regulations at 5 CFR Part1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall-

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the-

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if-

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the

Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting

Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on-

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in

32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part…