Solicitation Amendment FA485521R00050002 SF 30.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Section A - Solicitation/Contract Form

The following changes have been made:

INFORMATION FROM TO

Begin Performance Delivery Lead Time Duration 30 Calendar Days 10 Calendar Days Response Due Date 12 Feb 2021 16 Feb 2021

Party to receive Solicitation

FA4855

FA4855 27 SOCONS LGC

110 E ALISON AVE BLDG 600

CP 575 785 2321

CANNON AFB, NM 88103-5321

UNITED STATES

Section I - Contract Clauses

Miscellaneous text in this section has been modified to:

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities 1984-04 52.203-5 Covenant Against Contingent Fees. 2014-05 52.203-7 Anti-Kickback Procedures. 2020-06 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity. 2014-05 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. 2014-05 52.203-11Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. 2007-09 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements. 2017-01 52.204-9 Personal Identity Verification of Contractor Personnel. 2011-01 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. 2020-06 52.204-18 Commercial and Government Entity Code Maintenance. 2016-07 52.204-21 Basic Safeguarding of Covered Contractor Information Systems. 2016-06 52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities. 2018-07 52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. 2020-06 52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. 2018-10 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. 2015-11 52.211-13 Time Extensions 2000-9 52.215-8 Order of Precedence-Uniform Contract Format. 1997-10 52.219-3 Deviation 2019-O0003 Notice of HUBZone Set-Aside or Sole Source Award (DEVIATION 2019- O0003) 2011-11 52.219-8 Utilization of Small Business Concerns. 2018-10 52.219-13 Notice of Set-Aside of Orders. 2011-11 52.219-14 Deviation 2019-O0003 Limitations on Subcontracting (DEVIATION 2019-O0003) 2017-01 52.222-3 Convict Labor. 2003-06 52.222-4 Contract Work Hours and Safety Standards - Overtime Compensation 2018-05 52.222-21 Prohibition of Segregated Facilities. 2015-04 52.222-27 Affirmative Action Compliance Requirements for Construction. 2015-04 52.222-37 Employment Reports on Veterans. 2020-06

FA485521R00050002

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. 2010-12 52.222-50 Combating Trafficking in Persons. 2019-01 52.222-54 Employment Eligibility Verification. 2015-10 52.222-55 Minimum Wages Under Executive Order 13658. 2015-12 52.222-62 Paid Sick Leave Under Executive Order 13706. 2017-01 52.223-5 Pollution Prevention and Right-to-Know Information. 2011-05 52.223-6 Drug-Free Workplace. 2001-05 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. 2020-06 52.223-21 Foams. 2016-06 52.224-1 Privacy Act Notification. 1984-04 52.224-2 Privacy Act. 1984-04 52.225-13 Restrictions on Certain Foreign Purchases. 2008-06 52.228-2 Additional Bond Security. 1997-10 52.228-11 Pledges of Assets. 2018-08 52.228-12 Prospective Subcontractor Requests for Bonds. 2014-05 52.228-14 Irrevocable Letter of Credit. 2014-11 52.228-15 Performance and Payment Bonds-Construction. 2020-06 52.232-13 Notice of Progress Payments. 1984-04 52.232-14 Notice of Availability of Progress Payments Exclusively for Small Business Concerns. 1984-04 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. 2018-10 52.233-1 Disputes. 2014-05 52.233-3 Protest after Award. 1996-08 52.233-3 Alternate I Protest after Award. - (Alternate I) 1996-08 52.233-4 Applicable Law for Breach of Contract Claim. 2004-10 52.236-17 Layout of Work. 1984-04 52.236-28 Preparation of Proposals-Construction. 1997-10 52.236-21 Specifications and Drawings for Construction. 1997-02 52.236-26 Preconstruction Conference. 1995-02 52.243-1 Alternate I Changes-Fixed-Price. - (Alternate I) 1987-08 52.244-6 Subcontracts for Commercial Items. 2020-08 52.246-21 Warranty of Construction. 1994-03 52.249-3 Alternate I Termination for Convenience of the Government (Dismantling, Demolition, or Removal of Improvements). - (Alternate I) 2012-04 52.253-1 Computer Generated Forms. 1991-01 252.203-7001Prohibition on Persons Convicted of Fraud or Other Defense-Contract-Related Felonies. 2008-12 252.203-7003 Agency Office of the Inspector General. 2019-08 252.204-7002 Payment for Subline Items Not Separately Priced. 1991-12 252.204-7004 Antiterrorism Awareness Training for Contractors. 2019-02 252.204-7008 Compliance with Safeguarding Covered Defense Information Controls. 2016-10 252.205-7000 Provision of Information to Cooperative Agreement Holders 1991-12 252.209-7999 Representation by Corporations Regarding an Unpaid Delinquent Tax Liability or a Felony Conviction under any Federal Law 2012-01 252.219-7000 Advancing Small Business Growth. 2016-09 252.219-7011 Notification to Delay Performance. 1998-06 252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements. 2010-12 252.223-7004 Drug-Free Work Force. 1988-09 252.225-7016 Restriction on Acquisition of Ball and Roller Bearings. 2011-06 252.225-7048 Export-Controlled Items. 2013-06 252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns. 2019-04 252.231-7000 Supplemental Cost Principles 1991-12 252.232-7011 Payments in Support of Emergencies and Contingency Operations. 2013-05

252.236-7005 Airfield Safety Precautions. 1991-12

CLAUSES INCORPORATED BY FULL TEXT

52.204-1 Approval of Contract. 1989-12 As prescribed in 4.103 , insert the following clause:

Approval of Contract (Dec 1989) This contract is subject to the written approval of Joseph Pittman and shall not be binding until so approved.

(End of clause)

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Aug 2020)

(a) Definitions. As used in this clause-- Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet). Covered foreign country means The People's Republic of China.

Covered telecommunications equipment or services means-

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means-

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled-

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub.

L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing--

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement.

(1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause

(i) Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial items.

(End of clause)

52.204-26 Covered Telecommunications Equipment or Services-Representation. 2019-12 As prescribed in 4.2105(c), insert the following provision:

Covered Telecommunications Equipment or Services-Representation (Dec 2019)

(a) Definitions. As used in this provision, "covered telecommunications equipment or services" has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(c) Representation. The Offeror represents that it [ ] does, [ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(End of provision)

52.209-7 Information Regarding Responsibility Matters. 2018-10 As prescribed at 9.104-7(b), insert the following provision:

Information Regarding Responsibility Matters (Oct 2018)

(a) Definitions. As used in this provision- Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means-

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in-

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed viahttps://www.sam.gov (see 52.204-7).

(End of provision)

52.211-10 Alternate I Commencement, Prosecution, and Completion of Work. - (Alternate I) 1984-04 As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

Commencement, Prosecution, and Completion of Work (Apr 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 120 calendar days. * The time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause) Alternate I (Apr1984). If the completion date is expressed as a specific calendar date, computed on the basis of the contractor receiving the notice to proceed by a certain day, add the following paragraph to the basic clause:

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by TBD. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. 2000-09 As prescribed in 11.503(a), insert the following clause in solicitations and contracts:

Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $345.47 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(End of clause)

52.211-12 Liquidated Damages-Construction. 2000-09 As prescribed in 11.503(b), insert the following clause in solicitations and contracts:

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $294.07 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.216-25 Alternate I Contract Definitization. - (Alternate I) 2010-10 As prescribed in 16.603-4(b)(3), insert the following clause:

CONTRACT DEFINITIZATION (OCT 2010)

(a) A ____ [insert specific type of contract] definitive contract is contemplated. The Contractor agrees to begin promptly negotiating with the Contracting Officer the terms of a definitive contract that will include (1) all clauses required by the Federal Acquisition Regulation (FAR) on the date of execution of the letter contract, (2) all clauses required by law on the date of execution of the definitive contract, and (3) any other mutually agreeable clauses, terms, and conditions. The Contractor agrees to submit a ____ [insert specific type of proposal (e.g., fixed-price or cost-and-fee)] proposal, including data other than certified cost or pricing data, and certified cost or pricing data, in accordance with FAR 15.408, Table 15-2, supporting its proposal.

(b) The schedule for definitizing this contract is [insert target date for definitization of the contract and dates for submission of proposal, beginning of negotiations, and, if appropriate, submission of make-or-buy and subcontracting plans and certified cost or pricing data]:____ ____

(c) If agreement on a definitive contract to supersede this letter contract is not reached by the target date in paragraph (b) of this section, or within any extension of it granted by the Contracting Officer, the Contracting Officer may, with the approval of the head of the contracting activity, determine a reasonable price or fee in accordance with subpart 15.4 and part 31 of the FAR, subject to Contractor appeal as provided in the Disputes clause. In any event, the Contractor shall proceed with completion of the contract, subject only to the Limitation of Government Liability clause.

(1) After the Contracting Officer's determination of price or fee, the contract shall be governed by-

(i) All clauses required by the FAR on the date of execution of this letter contract for either fixed-price or cost-reimbursement contracts, as determined by the Contracting Officer under this paragraph (c);

(ii) All clauses required by law as of the date of the Contracting Officer's determination; and

(iii) Any other clauses, terms, and conditions mutually agreed upon.

(2) To the extent consistent with paragraph (c)(1) of this section, all clauses, terms, and conditions included in this letter contract shall continue in effect, except those that by their nature apply only to a letter contract.

(End of clause) Alternate I (Apr1984). In letter contracts awarded on the basis of price competition, add the following paragraph

(d) to the basic clause:

(d) The definitive contract resulting from this letter contract will include a negotiated ____ [insert "price ceiling" or "firm fixed price"] in no event to exceed ____ [insert the proposed price upon which the award was based].

52.219-14 Limitations on Subcontracting. 2020-03 As prescribed in 19.507(e), insert the following clause:

LIMITATIONS ON SUBCONTRACTING (MAR 2020)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Applicability. This clause applies only to-

(1) Contracts that have been set aside for small business concerns or 8(a) participants;

(2) Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) participants;

(3) Orders set aside for small business concerns or 8(a) participants under multiple-award contracts as described in 8.405-5 and 16.505(b)(2) (i)(F); and

(4) Orders issued directly to small business concerns or 8(a) participants under multiple-award contracts as described in 19.504(c)(1)(ii).

(c) Limitations on subcontracting. By submission of an offer and execution of a contract, the Contractor agrees that in performance of the contract in the case of a contract for-

(1) Services (except construction). At least 50 percent of the cost of contract performance incurred for personnel shall be expended for employees of the concern.

(2) Supplies (other than procurement from a nonmanufacturer of such supplies). The concern shall perform work for at least 50 percent of the cost of manufacturing the supplies, not including the cost of materials.

(3) General construction. The concern will perform at least 15 percent of the cost of the contract, not including the cost of materials, with its own employees.

(4) Construction by special trade contractors. The concern will perform at least 25 percent of the cost of the contract, not including the cost of materials, with its own employees.

(d) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraph (b)(1) and (2) of this clause- [Contracting Officer check as appropriate.] _ By the end of the base term of the contract and then by the end of each subsequent option period; or _ By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (b)(3) and (4) of this clause, by the end of the performance period for the order.

(End of clause)

52.219-28 Post-Award Small Business Program Rerepresentation. 2020-05 As prescribed in 19.309(c)(1), insert the following clause:

POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (MAY 2020)

(a) Definitions. As used in this clause Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract.

The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

(g) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (f) or (h) of this clause.

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it is, is not a small business concern under NAICS Code ____ assigned to contract number ____.

(2) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it is, is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause. ] The Contractor represents that it is, is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the Contractor represented itself as a women-owned small business concern in paragraph (h)(3) of this clause.] The Contractor represents that-

(i) It is, is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It is, is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(4)(i) of this clause is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The Contractor shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture:____.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern.[Complete only if the Contractor represented itself as a women-owned small business concern eligible under the WOSB Program in (h)(4) of this clause. ] The Contractor represents that-

(i) It is, is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It is, is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(5)(i) of this clause is accurate for each EDWOSB concern participating in the joint venture. [The Contractor shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ____.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause. ] The Contractor represents that it is, is not a veteran-owned small business concern.

(7) [ Complete only if the Contractor represented itself as a veteran-owned small business concern in paragraph (h)(6) of this clause.] The Contractor represents that it is, is not a service-disabled veteran-owned small business concern.

(8) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause. ] The Contractor represents that-

(i) It is, is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It is, is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (h)(8)(i) of this clause is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The Contractor shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ____.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

[Contractor to sign and date and insert authorized signer's name and title.] (End of clause)

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction.

1999-02 As prescribed in 22.810(b), insert the following provision:

Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (Feb 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade Goals for Female Participation for Each Trade N/A N/A These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the-

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is ____ [Contracting Officer shall insert description of the geographical areas where the contract is to be performed, giving the state, county, and city].

(End of provision)

52.222-26 Equal Opportunity. 2016-09 As prescribed in 22.810(e), insert the following clause:

EQUAL OPPORTUNITY (SEPT 2016)

(a) Definition. As used in this clause.

Compensation means any payments made to, or on behalf of, an employee or offered to an applicant as remuneration for employment, including but not limited to salary, wages, overtime pay, shift differentials, bonuses, commissions, vacation and holiday pay, allowances, insurance and other benefits, stock options and awards, profit sharing, and retirement.

Compensation information means the amount and type of compensation provided to employees or offered to applicants, including, but not limited to, the desire of the Contractor to attract and retain a particular employee for the value the employee is perceived to add to the Contractor's profit or productivity; the availability of employees with like skills in the marketplace; market research about the worth of similar jobs in the relevant marketplace; job analysis, descriptions, and evaluations; salary and pay structures; salary surveys; labor union agreements; and Contractor decisions, statements and policies related to setting or altering employee compensation.

Essential job functions means the fundamental job duties of the employment position an individual holds. A job function may be considered essential if-

(1) The access to compensation information is necessary in order to perform that function or another routinely assigned business task; or

(2) The function or duties of the position include protecting and maintaining the privacy of employee personnel records, including compensation information.

Gender identity has the meaning given by the Department of Labor's Office of Federal Contract Compliance Programs, and is found at http://www.dol.gov/ofccp/LGBT/LGBT_FAQs.html.

Sexual orientation has the meaning given by the Department of Labor's Office of Federal Contract Compliance Programs, and is found at http://www.dol.gov/ofccp/LGBT/LGBT_FAQs.html.

United States, means the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, and Wake Island.

(b) (1) If, during any 12-month period (including the 12 months preceding the award of this contract), the Contractor has been or is awarded nonexempt Federal contracts and/or subcontracts that have an aggregate value in excess of $10,000, the Contractor shall comply with this clause, except for work performed outside the United States by employees who were not recruited within the United States. Upon request, the Contractor shall provide information necessary to determine the applicability of this clause.

(2) If the Contractor is a religious corporation, association, educational institution, or society, the requirements of this clause do not apply with respect to the employment of individuals of a particular religion to perform work connected with the carrying on of the Contractor's activities (41

CFR 60-1.5).

(c) (1) The Contractor shall not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity, or national origin. However, it shall not be a violation of this clause for the Contractor to extend a publicly announced preference in employment to Indians living on or near an Indian reservation, in connection with employment opportunities on or near an Indian reservation, as permitted by 41 CFR 60-1.5.

(2) The Contractor shall take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, sexual orientation, gender identity, or national origin. This shall include, but not be limited to-

(i) Employment;

(ii) Upgrading;

(iii) Demotion;

(iv) Transfer;

(v) Recruitment or recruitment advertising;

(vi) Layoff or termination;

(vii) Rates of pay or other forms of compensation; and

(viii) Selection for training, including apprenticeship.

(3) The Contractor shall post in conspicuous places available to employees and applicants for employment the notices to be provided by the Contracting Officer that explain this clause.

(4) The Contractor shall, in all solicitations or advertisements for employees placed by or on behalf of the Contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin.

(5) (i) The Contractor shall not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This prohibition against discrimination does not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the Contractor's legal duty to furnish information.

(ii) The Contractor shall disseminate the prohibition on discrimination in paragraph (c)(5)(i) of this clause, using language prescribed by the Director of the Office of Federal Contract Compliance Programs (OFCCP), to employees and applicants by-

(A) Incorporation into existing employee manuals or handbooks; and

(B) Electronic posting or by posting a copy of the provision in conspicuous places available to employees and applicants for employment.

(6) The Contractor shall send, to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, the notice to be provided by the Contracting Officer advising the labor union or workers' representative of the Contractor's commitments under this clause, and post copies of the notice in conspicuous places available to employees and applicants for employment.

(7) The Contractor shall comply with Executive Order11246, as amended, and the rules, regulations, and orders of the Secretary of Labor.

(8) The Contractor shall furnish to the contracting agency all information required by Executive Order11246, as amended, and by the rules, regulations, and orders of the Secretary of Labor. The Contractor shall also file Standard Form100 (EEO-1), or any successor form, as prescribed in 41 CFR Part 60-1. Unless the Contractor has filed within the 12 months preceding the date of contract award, the Contractor shall, within 30 days after contract award, apply to either the regional Office of Federal Contract Compliance Programs (OFCCP) or the local office of the Equal Employment Opportunity Commission for the necessary forms.

(9) The Contractor shall permit access to its premises, during normal business hours, by the contracting agency or the OFCCP for the purpose of conducting on-site compliance evaluations and complaint…