FA480018B0002_-_SOLICITATION_-_BAK-15_IFB_for_FBO.pdf

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Each

BAK 15 and Textile Brake Installation

FFP

The contractor shall furnish all plant, labor, equipment, materials, tools and perform all operations necessary to include demolition, grading, paving, relocation of existing equipment, and installation of the Zodiac Aerospace MB-60 Textile Module Brake and the Zodiac Aerospace BAK 15 Stanchion/Net System at runway ends (08 and 26) The two arresting systems shall be provided by the Government.

All work shall be in accordance with all attachments listed in section J.

FOB: Destination

PROJECT: MUHJ 10-4214

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 298 dys. ADC 1 633 CES/CEN - F2Q363

ANHTHU NGUYEN

37 SWEENEY BLVD

LANGLEY AFB VA 23665

(757) 764-1130 FOB: Destination

F2Q363

Section H - Special Contract Requirements

SPECIAL CONTRACT REQUIREMENTS

1.0 REQUIRED INSURANCE: In accordance with FAR 28.306(b) and the FAR clause entitled "Insurance . . ." the Contractor shall, at its own expense, procure and thereafter maintain the following kinds of insurance with respect to performance under the contract.

1.1 Workmen's Compensation and Employers Liability Insurance as required by law except that if this contract is to be performed in a State which does not require or permit private insurance, then compliance with the statutory or administrative requirements in any such State will be satisfactory. The required Workmen's Compensation insurance shall extend to cover employer's liability for accidental bodily injury or death and for occupational disease with a minimum liability limit of $100,000.

1.2 General Liability Insurance: Bodily injury liability insurance, in the minimum limits of $500,000 per occurrence shall be required on the comprehensive form of policy.

1.3 Automobile Liability Insurance: This insurance shall be required on the comprehensive form of policy and shall provide bodily injury liability and property damage liability covering the operation of all automobiles used in connection with the performance of the contract. At least the minimum limits of $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage shall be required.

1.4 Contractor shall provide proof of insurance coverage within 15 calendar days of issuance of the award.

2.0 NOTICE TO PROCEED: A notice to proceed will be issued. The Contracting Officer reserves the right to determine the issue date of any notice to proceed.

3.0 LIQUIDATED DAMAGES: In accordance with FAR Clause 52.211-12 the liquidated rate for this project is established at $457.18 first/last day and $165.99 for all other calendar days of delay.

4.0 CONTRACT ADMINISTRATION: Administration and inspection of this contract will be assumed by the 633d Contracting Squadron.

5.0 PERFORMANCE MEETINGS: Performance meetings will be held with the Contracting Officer or his/her designated representative, technical representatives, and the Contractor. The meetings will be held weekly, or on an as needed basis, to discuss ongoing and upcoming projects, potential problems, any concerns, the contract in general or any other items that need to be addressed.

6.0 Wage Rate Requirements (Construction): The Wage Rate Requirements (Construction) applicable to this contract is attached in Section J of this solicitation.

7.0 PAYMENT AND PERFORMANCE BONDS (IAW FAR 28.102): Payment and Performance Bonds are required on this contract.

8.0 IDENTIFICATION OF CORRESPONDENCE: All correspondence and data submitted by the Contractor under this contract shall reference the contract number, project title, and project number.

9.0 HOURS OF WORK: Working hours for the Contractor will be the normal trade hours in this locale (7:30 AM to 4:30 PM) excluding Saturdays, Sundays, and Federal holidays.

9.1 If the Contractor wishes to work during the periods other than the above, additional Government inspection forces may be required.

9.2 The Contractor must notify the Contracting Officer three (3) working days in advance of his/her intention to work during periods other than the above, to allow assignment of additional inspection forces when the Contracting Officer determines that the additional inspection force is reasonably available.

9.3 If such force is available, the Contracting Officer may authorize the Contractor during periods other than normal duty hours/days.

10.0 HOLIDAYS: The following Federal legal holidays are observed by Langley Air Force Base:

New Year's Day 1 January Martin Luther King's Birthday Third Monday in January President's Day Third Monday in February Memorial Day Last Monday in May Independence Day 4 July Labor Day First Monday in September Columbus Day Second Monday in October Veterans Day 11 November Thanksgiving Day Fourth Thursday in November Christmas Day 25 December Note: Any of the above holidays falling on a Saturday will be observed on the preceding Friday, holidays falling on a Sunday will be observed on the following Monday.

10.1 POTENTIAL WORK STOPPAGES: Subject to change with AF notification.

Langley AFB Tri-Lateral Exercise – April 2018 (Approximate) Langley AFB Air Show – May 2018 (Approximate)

11.0 RADIOACTIVE MATERIALS: Reference Section I, Clause 52.223-7, Notice of Radioactive Materials. In addition to clause requirements, the following applies:

11.1 Base Contracting (633 CONS) will ensure no Contractor or other non-Air Force organizations are using a radiation source (i.e., Lasers, RF emitters, and ionizing radiation sources) on Langley Air Force Base, without the approval or knowledge of the Base Radiation Safety Officer. The Contractor is required to follow applicable Air Force and Army directive, technical orders, and AFOSH standards conducting operations on Langley Air Force Base. Any Contractor bringing radioactive materials on either base or using radioactive materials will provide the following information to the contracting officer.

11.2 A written request for permission to bring any radioactive material on base must be received at least 30 calendar days before bringing the materials onto Langley Air Force Base.

11.3 Evidence of a valid Nuclear Regulatory Commission (NRC) or Agreement State Radioactive Materials License.

11.4 A copy of NRC Form 241, Report of Proposed Activities in Non-Agreement States, or similar document (such as a letter), listing the specific licensable items the Contractor wishes to use on the base (in the case of an Agreement State License, the original must be forwarded by the Contractor to the appropriate NRC region).

11.5 Report of last leak test, if testing is required by the NRC license.

11.6 Proof of a valid Air Force/Army contract.

12.0 HAZMAT/NON-HAZMAT REMOVAL: At the end of the performance of the contract and before facilities/projects are turned over to the Government, the Contractor will remove all hazardous and non-hazardous materials furnished and/or used by the Contractor from the installation. No materials will be left behind in the possession of the Government. This includes all solvents, paints, fuels, oils, greases, adhesives, etc.

12.1 The Government’s Contract Project Manager and/or Inspector will identify that the Contractor has been responsible for ensuring the materials are removed before accepting the job from the Contractor. Before finalizing the project, the Contractor will certify, by signing a statement, that all hazardous materials were removed from the installation. This statement will be placed in the contract file.

13.0 HAZARDOUS MATERIALS REPORTING: In compliance with AFI 32-7086, AFI 32-7086 ACC Sup 1 and JBLE-I 32-101, Contractors are required to report the usage of all hazardous materials to the Government. The Contractor will report the type and estimated usage of all Hazardous materials and will submit a copy of the Material Safety Data Sheet (MSDS) for each item to the 633FW/HAZMART, 633 CES/CEVQP, and the Contracting Officer prior to bringing the items on the installations. The following information along with MSDS for each item will be provided to the Government within ten (10) days after award of the contract. The information will consist of the title of the project, the project number, Contractor/company name, point of contact and telephone number, the name of the hazardous material, maximum amounts that will be stored on the jobsite at any given time.

13.1 The Langley AFB Hazardous Materials Management Process (HMMP) team will review the listing to ensure there are no concerns with the chemicals being used/stored on the installation. The report will be sent to the Contracting Officer and to the following addresses:

633 LRS/HAZMARD

Bldg. 330 23 Sweeney Blvd.

Langley AFB, VA 23665-2199

633 CES/CEVQP

Bldg. 328, Room 253 37 Sweeney Blvd.

Langley AFB, VA 23665-2107

13.2 Should the Contractor need to use additional hazardous materials at any time on the project that were not previously submitted, he/she shall submit a list of those items to the above offices as soon as he/she is aware of the need for the materials.

14.0 ENVIRONMENTAL IMPACT: All waste materials generated by the Contractor or any work under the contract performed on a Government installation shall be handled, transported, stored, and disposed of by the Contractor and by his subcontractors at all times in accordance with all applicable Federal, state, or local laws, ordinances, regulations, court orders, or other types of rules or rulings having the effect of law including, but not limited to Executive Order 12088, 13 October 1978; the Federal Water Pollution Control Act, as amended (33 U.S.C. 1251 ET SEQ); the Clean Air Act as amended (42 U.S.C. Sec 1857, ET SEQ); the Endangered Species Act, as amended (16 U.S.C. 6901 ET SEQ); the Toxic Substances Control Act, as amended (15 U.S.C. Sec 2601, ET SEQ); the National Historic Preservation Act, as amended (16 U.S.C. Sec 470, ET SEQ); the Solid Waste Disposal Act, as amended (42 U.S.C. 6901 ET SEQ); and the Archaeological and Historic Preservation Act, as amended (16 U.S.C. Sec 469 ET SEQ). Should the United States Government be held liable for any neglect or improper actions by the Contractor or a subcontractor regarding removal or disposal of any hazardous waste, the Contractor shall reimburse the Government for all such liability.

15.0 DAMAGE TO UTILITIES: In the event of a Contractor caused utility failure/disruption, the Contractor will first make the area safe, then immediately contact the Base Civil Engineer Call Desk (24-hour line), (757) 764-5451, and Contracting Officer.

15.1 Repairs to Contractor-damaged utilities will be at the Contractor’s expense if it is determined that such damage was caused as a result of negligence. Repairs will be performed in a timely manner at no additional cost to the Government.

15.2 Damage to unidentified utilities will be repaired by the Government at no cost to the Contractor.

16.0 TELEPHONE COMMUNICATION SECURITY MONITORING: All communications with Department of Defense (DoD) organizations are subject to emissions security (EMSEC) review. Contractor personnel will be aware telephone communications networks are continually subject to intercept by unfriendly intelligence organizations. The DoD has authorized the military departments to conduct EMSEC monitoring and recording of telephone call originating from, or terminating at DoD organizations. Therefore, civilian Contractor personnel are advised any time they place a call to, or receive a call from an USAF/USA organization, they are subject to EMSEC procedures. The Contractor will assume the responsibility for ensuring wide and frequent dissemination of the above information to all employees dealing with DoD information.

17.0 EMERGENCY MEDICAL TREATMENT: The Hospitals at Langley AFB will provide emergency medical treatment to employees of the Contractor for injuries incurred while working on base. The Contractor will be required to reimburse the Government at an established rate for non-beneficiaries in accordance with Air Force Handbook 41-114.

After receiving initial emergency treatment, the Contractor will provide the hospital with the name of the physician and/or hospital to which the injured personnel can be transferred for further treatment and care. Follow-on care after initial emergency treatment will not be provided.

18.0 ORDER OF WORK: The Contractor will submit for approval all work schedules to the Contracting Officer prior to the start of work. Approved schedules cannot be changed without the Contracting Officer approval.

19.0 WORK SCHEDULE: All work must be accomplished in such a manner that minimum inconvenience will be caused to the using agencies. In some cases, the Contractor will be required to work around or move Government equipment within the work area to protect it from debris and damage. Contractor is responsible for all damages to furnishing and equipment which must be relocated to perform necessary work.

20.0 UTILITY SERVICES: The Contracting Officer has determined that Government operated utilities are adequate and will be furnished to the Contractor without charge where existing utilities are available, and necessary for project performance. Contractor is responsible for installing temporary service outlets. See contract clause entitled “Availability and Use of Utility Services”, FAR 52.236-14.

21.0 CONSTRUCTION PERMITS: Prior to beginning any excavation, which may be required under this contract, the Contractor shall obtain from the Chief, Construction Management, Bldg. 328, Langley AFB, VA 23665, a Civil Engineer construction digging permit. Five (5) working days are normally required for processing of the permit.

22.0 RELEASE OF CLAIMS: Upon completion of the work and prior to final payment, the Contractor shall be required to furnish to the Contracting Officer a Release of Claims as specified by the clause entitled “Payment under Fixed-Price Construction“, FAR 52.232-5(h)(3).

23.0 ON SITE OFFICE TRAILERS AND STORAGE FACILITIES: On-base storage area will be made available for Contractor owned materials and equipment. The Contracting Officer will designate areas where above-mentioned equipment shall be staged. These staging areas will be unique for each respective delivery order.

24.0 Government Furnished Equipment: The BAK-15 System will be provided as government furnished equipment IAW with FAR 52.245-1. This equipiment will be provided in an “as-is” condition. Below is the equipment list information. The is list is also provided as an attachment in Section J.

ZODIAC

AEROSPACE

AERAZUR

292 Pare de I' Alambic

16100 MERPINS FRANCE

ITEM DESIGNATION P/N. ARZ QTY

E;:\tremite MB60-6-9i USAF is composed of:

Reclumge MB60-6-9IReset kit MB60-6-9:

COVER MB FIRST LINE

BRAKING MODULE

SHORT EXTENSION ASSEMBLY 3/4M

LONG CONNECTING STRAPS ASSEMBLY

SHORT DIRECTIONAL MODULE 25M

SHORT DIRECTIONAL MODULE 33M

SHACKLE

COVER MB SECOND LINE

SHEAR LINK ASSEMBLY 0.8M

TEST SAMPLE

STRAP CORD

WEBBING STRAP

CABLE TIE

SHACKLE 19 G 209-CMU

CABLE FOR TIRFOR T516

SHEAR LINK 2/3T ASSY

STROP 1M

221401-0 221601-0 1

001 219837-0 2

002 217140-0 30

003 216796-0 12

004 216500-0 2

005 219228-0 2

006 219230-0 2

007 1506140 4

008 219838-0 2

009 216637-0 2

010 215770-0 4

011 00909 10m

012 913015 5m

013 992373 12

014 954009 2

015 999367 2

216813 2

216636 2

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.203-18 Prohibition on Contracting With Entities That Require Certain Internal Confidentiality Agreements or Statements-- Representation

JAN 2017

52.204-7 System for Award Management OCT 2016 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.211-13 Time Extensions SEP 2000 52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-9 Small Business Subcontracting Plan JAN 2017 52.219-14 Limitations On Subcontracting JAN 2017 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-16 Approval of Wage Rates MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-23 Notice of Requirement for Affirmative Action to Ensure

Equal Employment Opportunity for Construction

FEB 1999

52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-32 Construction Wage Rate Requirements--Price Adjustment (Actual Method)

JAN 2017

52.222-35 Equal Opportunity for Veterans OCT 2015

52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.224-1 Privacy Act Notification APR 1984 52.224-2 Privacy Act APR 1984 52.225-9 Buy American--Construction Materials MAY 2014 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.227-1 Authorization and Consent DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-3 Worker's Compensation Insurance (Defense Base Act) JUL 2014 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.229-4 Federal, State, And Local Taxes (State and Local

Adjustments)

FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-16 Alt I Progress Payments (Apr 2012) - Alternate I MAR 2000 52.232-17 Interest MAY 2014 52.232-18 Availability Of Funds APR 1984 52.232-19 Availability Of Funds For The Next Fiscal Year APR 1984 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984

52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995 52.236-28 Preparation of Proposals--Construction OCT 1997 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.243-5 Changes and Changed Conditions APR 1984 52.244-6 Subcontracts for Commercial Items JAN 2017 52.245-9 Use And Charges APR 2012 52.246-21 Alt I Warranty of Construction (Mar 1994) - Alternate I APR 1984 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-3 Termination for Convenience of the Government (Dismantling, Demolition, or Removal of Improvements)

APR 2012

52.249-10 Default (Fixed-Price Construction) APR 1984 52.251-1 Government Supply Sources APR 2012 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7006 Billing Instructions OCT 2005 252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.223-7001 Hazard Warning Labels DEC 1991 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.227-7033 Rights in Shop Drawings APR 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7004 DOD Progress Payment Rates OCT 2014 252.232-7006 Wide Area WorkFlow Payment Instructions MAY 2013 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7001 Contract Drawings, and Specifications AUG 2000 252.236-7005 Airfield Safety Precautions DEC 1991 252.236-7008 Contract Prices-Bidding Schedules DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012

CLAUSES INCORPORATED BY FULL TEXT

52.202-1 DEFINITIONS (NOV 2013)

When a solicitation provision or contract clause uses a word or term that is defined in the Federal Acquisition Regulation (FAR), the word or term has the same meaning as the definition in FAR 2.101 in effect at the time the solicitation was issued, unless--

(a) The solicitation, or amended solicitation, provides a different definition;

(b) The contracting parties agree to a different definition;

(c) The part, subpart, or section of the FAR where the provision or clause is prescribed provides a different meaning;

or

(d) The word or term is defined in FAR Part 31, for use in the cost principles and procedures.

(End of clause)

52.204-6 UNIQUE ENTITY IDENTIFIER (OCT 2016)

(a) Definitions. As used in this provision--

Electronic Funds Transfer (EFT) indicator means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

Unique entity identifier means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable.

(c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for establishment of the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information:

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company physical street address, city, state and Zip Code.

(4) Company mailing address, city, state and Zip Code (if separate from physical).

(5) Company telephone number.

(6) Date the company was started.

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

http://www.sam.gov/ http://www.sam.gov/

(10) Company headquarters name and address (reporting relationship within your entity).

(End of provision)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY

MATTERS (JULY 2013)

(a) The Contractor shall update the information in the Federal Awardee Performance and Integrity Information System (FAPIIS) on a semi-annual basis, throughout the life of the contract, by posting the required information in the System for Award Management database via https://www.acquisition.gov.

(b) As required by section 3010 of the Supplemental Appropriations Act, 2010 (Pub. L. 111-212), all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available. FAPIIS consists of two segments--

(1) The non-public segment, into which Government officials and the Contractor post information, which can only be viewed by--

(i) Government personnel and authorized users performing business on behalf of the Government; or

(ii) The Contractor, when viewing data on itself; and

(2) The publicly-available segment, to which all data in the non-public segment of FAPIIS is automatically transferred after a waiting period of 14 calendar days, except for--

(i) Past performance reviews required by subpart 42.15;

(ii) Information that was entered prior to April 15, 2011; or

(iii) Information that is withdrawn during the 14-calendar-day waiting period by the Government official who posted it in accordance with paragraph (c)(1) of this clause.

(c) The Contractor will receive notification when the Government posts new information to the Contractor's record.

(1) If the Contractor asserts in writing within 7 calendar days, to the Government official who posted the information, that some of the information posted to the non-public segment of FAPIIS is covered by a disclosure exemption under the Freedom of Information Act, the Government official who posted the information must within 7 calendar days remove the posting from FAPIIS and resolve the issue in accordance with agency Freedom of Information procedures, prior to reposting the releasable information. The contractor must cite 52.209-9 and request removal within 7 calendar days of the posting to FAPIIS.

(2) The Contractor will also have an opportunity to post comments regarding information that has been posted by the Government. The comments will be retained as long as the associated information is retained, i.e., for a total period of 6 years. Contractor comments will remain a part of the record unless the Contractor revises them.

(3) As required by section 3010 of Pub. L. 111-212, all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available.

(d) Public requests for system information posted prior to April 15, 2011, will be handled under Freedom of Information Act procedures, including, where appropriate, procedures promulgated under E.O. 12600.

https://www.acquisition.gov/

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 30 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 298 calendar days from the issuance of notice to proceed. The time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $457.18 first/last day and $165.99 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

27.1 6.9

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is The covered area includes Langley AFB, in Hampton, Virginia located in Hampton county.

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (JAN 1997)

(a) "Hazardous material", as used in this clause, includes any material defined as hazardous under the latest version of Federal Standard No. 313 (including revisions adopted during the term of the contract).

(b) The offeror must list any hazardous material, as defined in paragraph (a) of this clause, to be delivered under this contract. The hazardous material shall be properly identified and include any applicable identification number, such as National Stock Number or Special Item Number. This information shall also be included on the Material Safety Data Sheet submitted under this contract.

Material Identification No.

(If none, insert "None")

(c) This list must be updated during performance of the contract whenever the Contractor determines that any other material to be delivered under this contract is hazardous.

(d) The apparently successful offeror agrees to submit, for each item as required prior to award, a Material Safety Data Sheet, meeting the requirements of 29 CFR 1910.1200(g) and the latest version of Federal Standard No. 313, for all hazardous material identified in paragraph (b) of this clause. Data shall be submitted in accordance with Federal Standard No. 313, whether or not the apparently successful offeror is the actual manufacturer of these items.

Failure to submit the Material Safety Data Sheet prior to award may result in the apparently successful offeror being considered nonresponsible and ineligible for award.

(e) If, after award, there is a change in the composition of the item(s) or a revision to Federal Standard No. 313, which renders incomplete or inaccurate the data submitted under paragraph (d) of this clause, the Contractor shall promptly notify the Contracting Officer and resubmit the data.

(f) Neither the requirements of this clause nor any act or failure to act by the Government shall relieve the Contractor of any responsibility or liability for the safety of Government, Contractor, or subcontractor personnel or property.

(g) Nothing contained in this clause shall relieve the Contractor from complying with applicable Federal, State, and local laws, codes, ordinances, and regulations (including the obtaining of licenses and permits) in connection with hazardous material.

(h) The Government's rights in data furnished under this contract with respect to hazardous material are as follows:

(1) To use, duplicate and disclose any data to which this clause is applicable. The purposes of this right are to--

(i) Apprise personnel of the hazards to which they may be exposed in using, handling, packaging, transporting, or disposing of hazardous materials;

(ii) Obtain medical treatment for those affected by the material; and

(iii) Have others use, duplicate, and disclose the data for the Government for these purposes.

(2) To use, duplicate, and disclose data furnished under this clause, in accordance with subparagraph (h)(1) of this clause, in precedence over any other clause of this contract providing for rights in data.

(3) The Government is not precluded from using similar or identical data acquired from other sources.

52.223-7 NOTICE OF RADIOACTIVE MATERIALS (JAN 1997)

(a) The Contractor shall notify the Contracting Officer or designee, in writing, Thirty (30) Calendar days prior to the delivery of, or prior to completion of any servicing required by this contract of, items containing either (1) radioactive material requiring specific licensing under the regulations issued pursuant to the Atomic Energy Act of 1954, as amended, as set forth in Title 10 of the Code of Federal Regulations, in effect on the date of this contract, or

(2) other radioactive material not requiring specific licensing in which the specific activity is greater than 0.002 microcuries per gram or the activity per item equals or exceeds 0.01 microcuries. Such notice shall specify the part or parts of the items which contain radioactive materials, a description of the materials, the name and activity of the isotope, the manufacturer of the materials, and any other information known to the Contractor which will put users of the items on notice as to the hazards involved (OMB No. 9000-0107).

(b) If there has been no change affecting the quantity of activity, or the characteristics and composition of the radioactive material from deliveries under this contract or prior contracts, the Contractor may request that the Contracting Officer or designee waive the notice requirement in paragraph (a) of this clause. Any such request shall-

(1) Be submitted in writing;

(2) State that the quantity of activity, characteristics, and composition of the radioactive material have not changed;

and

(3) Cite the contract number on which the prior notification was submitted and the contracting office to which it was submitted.

(c) All items, parts, or subassemblies which contain radioactive materials in which the specific activity is greater than 0.002 microcuries per gram or activity per item equals or exceeds 0.01 microcuries, and all containers in which such items, parts or subassemblies are delivered to the Government shall be clearly marked and labeled as required by the latest revision of MIL-STD 129 in effect on the date of the contract.

(d) This clause, including this paragraph (d), shall be inserted in all subcontracts for radioactive materials meeting the criteria in paragraph (a) of this clause.

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED ITEMS (MAY 2008)

(a) Definitions. As used in this clause--

Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall--

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to 633d Contracting Squadron/PKB, 14 Burrel St, Langley AFB, VA, 23665-2088.

52.225-11 BUY AMERICAN--CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS (OCT

2016)

(a) Definitions. As used in this clause--

Caribbean Basin country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a Caribbean Basin country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a Caribbean Basin country into a new and different construction material distinct from the materials from which it was transformed.

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4)such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Designated country means any of the following countries:

(1) A World Trade Organization Government Procurement Agreement (WTO GPA) country (Armenia, Aruba, Austria, Belgium, Bulgaria, Canada, Croatia, Cyprus, Czech Republic, Denmark, Estonia, Finland, France, Germany, Greece, Hong Kong, Hungary, Iceland, Ireland, Israel, Italy, Japan, Korea (Republic of), Latvia, Liechtenstein, Lithuania, Luxembourg, Malta, Moldova, Montenegro, Netherlands, New Zealand, Norway, Poland, Portugal, Romania, Singapore, Slovak Republic, Slovenia, Spain, Sweden, Switzerland, Taiwan, Ukraine, or United Kingdom);

(2) A Free Trade Agreement (FTA) country (Australia, Bahrain, Canada, Chile, Colombia, Costa Rica, Dominican Republic, El Salvador, Guatemala, Honduras, Korea (Republic of), Mexico, Morocco, Nicaragua, Oman, Panama, Peru, or Singapore);

(3) A least developed country (Afghanistan, Angola, Bangladesh, Benin, Bhutan, Burkina Faso, Burundi, Cambodia, Central African Republic, Chad, Comoros, Democratic Republic of Congo, Djibouti, Equatorial Guinea, Eritrea, Ethiopia, Gambia, Guinea, Guinea-Bissau, Haiti, Kiribati, Laos, Lesotho, Liberia, Madagascar, Malawi, Mali, Mauritania, Mozambique, Nepal, Niger, Rwanda, Samoa, Sao Tome and Principe, Senegal, Sierra Leone, Solomon Islands, Somalia, South Sudan, Tanzania, Timor-Leste, Togo, Tuvalu, Uganda, Vanuatu, Yemen, or Zambia); or

(4) A Caribbean Basin country (Antigua and Barbuda, Aruba, Bahamas, Barbados, Belize, Bonaire, British Virgin Islands, Curacao, Dominica, Grenada, Guyana, Haiti, Jamaica, Montserrat, Saba, St. Kitts and Nevis, St. Lucia, St.

Vincent and the Grenadines, Sint Eustatius, Sint Maarten, or Trinidad and Tobago).

Designated country construction material means a construction material that is a WTO GPA country construction material, an FTA country construction material, a least developed country construction material, or a Caribbean Basin country construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

Least developed country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a least developed country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a least developed country into a new and different construction material distinct from the materials from which it was transformed.

“Free Trade Agreement country construction material” means a construction material that—

(1) Is wholly the growth, product, or manufacture of a Free Trade Agreement (FTA) country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a FTA country into a new and different construction material distinct from the materials from which it was transformed.

“Least developed country construction material” means a construction material that—

(1) Is wholly the growth, product, or manufacture of a least developed country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a least developed country into a new and different construction material distinct from the materials from which it was transformed.

United States means the 50 States, the District of Columbia, and outlying areas.

WTO GPA country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a WTO GPA country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a WTO GPA country into a new and different construction material distinct from the materials from which it was transformed.

(b) Construction materials.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). In addition, the Contracting Officer has determined that the WTO GPA and Free Trade Agreements (FTAs) apply to this acquisition. Therefore, the Buy American restrictions are waived for designated country construction materials.

(2) The Contractor shall use only domestic or designated country construction material in performing this contract, except as provided in paragraphs (b)(3) and (b)(4) of this clause.

(3) The requirement in paragraph (b)(2) of this clause does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government…