Solicitation.docx

FA4626-16-R-0032

Section B - Supplies or Services and Prices

Mobilization to A01, C01, K01, and M01

FFP

All costs related to general contract requirements and administration will be merged and included in the contract lump sum costs for "Mobilization". The cost of all insurance, permits, safety, fees, and licenses, shop drawings and samples, movement of equipment, tools, and other incidental work required for occupying the site and performing the work will be merged and included in the price for "Mobilization". Mobilization for the work will be paid as Each (EA).

FOB: Destination

SIGNAL CODE: A

NET AMT

Abandon and Replace Well at A01

All costs for labor, materials, and equipment associated with the existing well abandonment, geophysical survey, well log, interpretation, well drilling, casing, drop pipe, screen, well pump, torque arrestor, filing forms with Montana Bureau of .Mines and Geology, HDPE pipe, PEX pipe, fittings, pump house floor coring, connect to existing water line, bollards, site restoration, cleanup, and all other incidental items necessary to complete the work as specified in the specifications and drawings.

NET AMT

Abandon and Replace Well at C01

All costs for labor, materials, and equipment associated with the existing well abandonment, geophysical survey, well log, interpretation, well drilling, casing, drop pipe, screen, well pump, torque arrestor, filing forms with Montana Bureau of Mines and Geology, HDPE pipe, PEX pipe, fittings, pump house floor coring, connect to existing water line, bollards, site restoration, cleanup, and all other incidental items necessary to complete the work as specified in the specifications and drawings.

NET AMT

Abandon and Replace Well at K01

All costs for labor, materials, and equipment associated with the existing well abandonment, geophysical survey, well log, interpretation, well drilling, casing, drop pipe, screen, well pump, torque arrestor, filing forms with Montana Bureau of Mines and Geology, HDPE pipe, PEX pipe, fittings, pump house floor coring, connect to existing water line, bollards, site restoration, cleanup, and all other incidental items necessary to complete the work as specified in the specifications and drawings.

NET AMT

Abandon and Replace Well at M01

All costs for labor, materials, and equipment associated with the existing well abandonment, geophysical survey, well log, interpretation, well drilling, casing, drop pipe, screen, well pump, torque arrestor, filing forms with Montana Bureau of Mines and Geology, HDPE pipe, PEX pipe, fittings, pump house floor coring, connect to existing water line, bollards, site restoration, cleanup, and all other incidental items necessary to complete the work as specified in the specifications and drawings.

NET AMT

Locate Site Utilities at MAF's

Measurement and payment of this item shall be at the contract price for ''Locate Site Utilities" at MAF's A-01, C-01, M-01, and K-01. Payment shall include all costs for labor, materials, and equipment to hydro-vac existing utilities, cleanup, and all other incidental items necessary to complete the work as idenfified in the specifications and drawings.

NET AMT

Electrical & Controls at A01,C01,K01,M01

All costs for labor, materials, and equipment associated with the removing of the existing well pump controllers, associated feeders and control wiring. All costs for labor, materials, and equipment associated with the installing new reduced voltage soft starter controller, underground feeder to new well, grounding jumper between old and new well, control wiring from water system controller to soft starter, bond inner and outer well casings to existing well head in pump house, cleanup, and all other incidental items necessary to complete the work as specified in the specifications and drawings.

NET AMT

Government Delays

Should the Contracting Officer determine that the Contractor incurred a work stoppage or could not begin work as scheduled, and that the stoppage or delay is or was caused by the Government, the Contractor will be paid for delays which result in verifiable lost progress. Due to the location of this work the Contractor can expect an estimated delay of 30 minutes per day for on and off site processing. This on and off processing time will not be identified as a government delay. This cost will include crew, labor, and equipment time lost during normal work hours and will not include evenings, Saturdays, Sundays, Winter Exclusion, or Federal Holidays even if the Government gave permission for the Contractor to continue work on these days. Government Delays will be paid by the Crew-Hour (Cr-Hr).

NET AMT

Bonding

Shall be paid for as an Each (EA) for the exact actual amount paid for bonding. At no time shall the payment for this CLIN exceed the actual amount paid for bonds by the Offeror.

NET AMT

Section C - Descriptions and Specifications

DESCRIPTIONS & SPECIFICATIONS

C-1 SPECIFICATIONS, STANDARDS AND DRAWINGS IAW FAR 11-201

Furnish all labor, materials, supervision, quality control, testing, equipment and transportation necessary to perform the work required by the drawings and specifications applicable to Malmstrom AFB, Project No. NZAS: 15-6000, dated: December 2016 and that are identified as attachments to this solicitation in Section J hereof.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLAUSES INCORPORATED BY REFERENCE

Section F - Deliveries or Performance

DELIVERY INFORMATION

KEN MURPHY

40 78TH ST N BLDG 470

GREAT FALLS MT 59402

406-731-6865

F2W3D2

F2W3D2

F2W3D2

F2W3D2

F2W3D2

F2W3D2

F2W3D2

F2W3D2

F2W3D2

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 150 days after notice to proceed is issued for the complete project. Each MAF site is to be completed within 30 calendar days from the date work starts at each respective MAF. The time stated for completion shall include final cleanup of the premises.

Winter exclusion (if required) shall be from 15 November 2017 until 15 April 2018.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $855.12 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

Section G - Contract Administration Data

252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS (JUNE 2012)

(a) Definitions. As used in this clause–

(1) Contract financing payment and invoice payment have the meanings given in section 32.001 of the Federal Acquisition Regulation.

(2) Electronic form means any automated system that transmits information electronically from the initiating system to all affected systems. Facsimile, e-mail, and scanned documents are not acceptable electronic forms for submission of payment requests. However, scanned documents are acceptable when they are part of a submission of a payment request made using Wide Area WorkFlow (WAWF) or another electronic form authorized by the Contracting Officer.

(3) Payment request means any request for contract financing payment or invoice payment submitted by the Contractor under this contract.

(4) Receiving report means the data required by the clause at 252.246-7000, Material Inspection and Receiving Report.

(b) Except as provided in paragraph (c) of this clause, the Contractor shall submit payment requests and receiving reports using WAWF, in one of the following electronic formats that WAWF accepts: Electronic Data Interchange, Secure File Transfer Protocol, or World Wide Web input. Information regarding WAWF is available on the Internet at https://wawf.eb.mil/.

(c) The Contractor may submit a payment request and receiving report using other than WAWF only when–

(1) The Contracting Officer administering the contract for payment has determined, in writing, that electronic submission would be unduly burdensome to the Contractor. In such cases, the Contractor shall include a copy of the Contracting Officer's determination with each request for payment;

(2) DoD makes payment for commercial transportation services provided under a Government rate tender or a contract for transportation services using a DoD-approved electronic third party payment system or other exempted vendor payment/invoicing system (e.g., PowerTrack, Transportation Financial Management System, and Cargo and Billing System);

(3) DoD makes payment for rendered health care services using the TRICARE Encounter Data System (TEDS) as the electronic format; or

(4) When the Governmentwide commercial purchase card is used as the method of payment, only submission of the receiving report in electronic form is required.

(d) The Contractor shall submit any non-electronic payment requests using the method or methods specified in Section G of the contract.

(e) In addition to the requirements of this clause, the Contractor shall meet the requirements of the appropriate payment clauses in this contract when submitting payments requests.

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

2 in 1 Stand Alone

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

Destination

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

Provided upon award

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

WAWF Help Desk

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

Section H - Special Contract Requirements

SPECIAL CONTRACT REQUIREMENTS

MALM CONTRACTOR PASSES

1. Normal Installation Entry. Entry to MAFB requires possession and verification of approved identification credentials. Personnel without valid identification will be referred to the Visitor Control Center (VCC) located at the 2nd Avenue North Gate entrance. People who cannot be properly identified or sponsored will be denied entry.

2. Contractor Access: Upon award of a contract, the contractor awarded the contract will be issued a request for a Contractor Entry Authority List (CEAL) by the contract administrator. Upon receipt, the contractor must compile the information required for the CEAL and submit a completed CEAL to the contract administrator. Until this occurs, no employees will be permitted to enter Malmstrom AFB.

3. The contracting office approves the list and hand carries it to the Pass and Registration Section (341 SFS/S5B) for review. S5B personnel will compare the approving official's signature against a DD Form 577, Signature Card, or an appropriate letter on file at pass and registration. S5B then hand carries the submission to the 911 Dispatch Center.

4. A 911 dispatcher certified on the National Criminal Information Center system (NCIC) will run the contractor names through the NCIC for wants and warrants. The 911Dispatch Center will input all listed employees’ names and data into the National Criminal Information Center (NCIC) database for a background check in accordance with Air Force directives. Unfavorable results from the background check will result in individuals being denied access to the installation, including, but not limited to, individuals that are determined to fall into one or more of the following categories: those having outstanding wants or warrants, sex offenders, violent offenders, those who are on probation, and those who are in a pre-release program. The definition of sex offender and violent offender can be found at Montana Code Annotated § 46-23-502. After the dispatcher completes the NCIC check, they will sign the letters and return them to S5B. Unfavorable results will be grounds for denial of entry.

5. Retired military members and dependents of active duty or retired military members who are contractor employees must use their valid DoD ID card when entering Malmstrom AFB for the performance of contract services and must prominently display identification badges while performing work on the installation. No Common Access Card (CAC) will be issued to these individuals with an Armed Forces ID. Under no circumstance will retired military members or dependents of active duty or retired military members vouch contractor personnel onto the installation utilizing their Armed Forces Identification Card. Only those contractors who have been issued a DoD CAC will be allowed to sign and escort people onto the installation.

6. Contractor personnel requesting a contractor pass will provide a picture ID to be verified against the Contractor EAL. Those employees, who clear the background check process, will be issued passes by S5B, located in Building 250, for the duration of the contract or one year, whichever period is shorter. For contracts lasting more than one year, including contract options, renewals and extensions, the contractor must repeat the above stated process on an annual basis. In addition, the process must be initiated for all new employees who are added to the CEAL after its initial submission.

7. Contractors are required to notify the contracting officer and S5B if an employee on a CEAL terminates his or her employment with the contractor or is involved in an incident that would result in unfavorable results from the background check including, but not limited to, those identified in paragraph 4 above. If a contractor terminates an employee, it is incumbent upon the contractor to ensure that the employee’s access badge is returned to the Pass and Registration office. If they are unable to retrieve the pass, they will contact S5B with the employee’s information. S5B will then contact the installation entry control points and have them retrieve the pass if the person attempts to re-enter the base. In the case of a missile field contractor the S5B will contact Keys and Codes Control Center.

8. Violations of the stated entry procedures will be considered a breach of contract and the contracting officer will take appropriate action in accordance with the contract. Repeated or flagrant violations of this policy may result in termination of the contract for default. Contractor/vendor passes are for granting access to the installation for the sole purpose of employment. These passes do not permit access to or usage of government facilities or services (i.e., gym, service station, and dining hall.) However, during contractor/vendor “duty hours,” the Burger King, Base Exchange Bowling Alley and Grizzly Bend Club eateries may be utilized.

9. Local delivery companies (e.g., food, furniture, appliances) will submit a letter to the 341 SFS Pass and Registration Section containing the name of the company, the driver’s name(s), date of birth, driver’s license number and vehicle information. All information will be cross-checked against the installation barment and revocation list and the NCIC via the 911 Dispatch Center prior to approval. A copy of the letter will be maintained in the possession of the driver requesting entry. If the driver does not possess a letter, he/she will be directed to the VCC where an AF IMT 75, Visitor/Vehicle Pass, will be issued after verification of the delivery has been made through the on-base residence sponsor.

10. Vehicles owned by your firm will be permitted entry to Malmstrom AFB if they are conspicuously marked with your firm’s name or log, with the exception of magnetic signs, when you have contract requiring performance on the base. If your vehicles are not so marked, it will be necessary for you to obtain a temporary vehicle registration for each vehicle to be operated on Malmstrom AFB. This registration is accomplished by the contractor or designated representative at the Pass and Registration Section. Proof of ownership and a current valid driver’s license are required for vehicle registration. You or your representative will be required to have insurance coverage on the vehicle to meet Montana State minimum requirement.

MALM General Insurance Requirements

(a) Workers’ compensation and employer’s liability. Contractors are required to comply with applicable Federal and State workers’ compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer’s liability section of the insurance policy, except when contract operations are so commingled with a contractor’s commercial operations that it would not be practical to require this coverage. Employer’s liability coverage of at least $1,000,000 shall be required, except in States with exclusive or monopolistic funds that do not permit workers’ compensation to be written by private carriers. (See 28.305(c) for treatment of contracts subject to the Defense Base Act.)

(b) General liability.

(1) The contracting officer shall require bodily injury liability insurance coverage written on the comprehensive form of policy of at least $1,000,000 per occurrence.

(2) Property damage liability insurance shall be required only in special circumstances as determined by the agency.

(c) Company Owned Automobile liability. The contracting officer shall require automobile liability insurance written on the comprehensive form of policy. The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the contract. Policies covering automobiles operated in the United States shall provide coverage of at least $500,000 per person and $1,000,000 per occurrence for bodily injury and $50,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

Section I - Contract Clauses

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-DESIGNATED ITEMS (MAY 2008)

Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall--

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to Mark Jefferson at 731-4014 or email mark.jefferson.1@us.af.mil

52.223-11 OZONE-DEPLETING SUBSTANCES AND HIGH GLOBAL WARMING POTENTIAL HYDROFLUOROCARBONS (JUN 2016)

Global warming potential means how much a given mass of a chemical contributes to global warming over a given time period compared to the same mass of carbon dioxide. Carbon dioxide's global warming potential is defined as 1.0.

High global warming potential hydrofluorocarbons means any hydrofluorocarbons in a particular end use for which EPA's Significant New Alternatives Policy (SNAP) program has identified other acceptable alternatives that have lower global warming potential. The SNAP list of alternatives is found at 40 CFR part 82, subpart G, with supplemental tables of alternatives available at (http://www.epa.gov/snap/).

Hydrofluorocarbons means compounds that only contain hydrogen, fluorine, and carbon.

Ozone-depleting substance means any substance the Environmental Protection Agency designates in 40 CFR part 82 as--

(1) Class I, including, but not limited to, chlorofluorocarbons, halons, carbon tetrachloride, and methyl chloroform; or

(2) Class II, including, but not limited to, hydrochlorofluorocarbons.

(b) The Contractor shall label products that contain or are manufactured with ozone-depleting substances in the manner and to the extent required by 42 U.S.C. 7671j (b), (c), (d), and (e) and 40 CFR part 82, subpart E, as follows:

Warning: Contains (or manufactured with, if applicable) *_______, a substance(s) which harm(s) public health and environment by destroying ozone in the upper atmosphere.

* The Contractor shall insert the name of the substance(s).

(c) Reporting. For equipment and appliances that normally each contain 50 or more pounds of hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons, the Contractor shall--

(1) Track on an annual basis, between October 1 and September 30, the amount in pounds of hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons contained in the equipment and appliances delivered to the Government under this contract by--

(i) Type of hydrofluorocarbon (e.g., HFC-134a, HFC-125, R-410A, R-404A, etc.);

(ii) Contract number; and

(iii) Equipment/appliance;

(2) Report that information to the Contracting Officer for FY16 and to www.sam.gov, for FY17 and after--

(i) Annually by November 30 of each year during contract performance; and

(ii) At the end of contract performance.

(d) The Contractor shall refer to EPA's SNAP program (available at http://www.epa.gov/snap) to identify alternatives. The SNAP list of alternatives is found at 40 CFR part 82, subpart G, with supplemental tables available at http://www.epa.gov/snap.

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (MAY 2014)

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison Construction material description Unit of measure Quantity Price (dollars) \1\ Item 1 Foreign construction material.... ........... ___ ........ ....... ………. ___ ................ ........ ___ Domestic construction material... ........ ___ ............... .............. ___ .................. ...... ___ Item 2 Foreign construction material.... ......... ___ ............. ........ ……. ___ ............... ......... ___ Domestic construction material... ....... ___ .................. ............. ___ ................. ....... ___ Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of provision)

52.228-5 INSURANCE--WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

(a) The Contractor shall, at its own expense, provide and maintain during the entire performance of this contract, at least the kinds and minimum amounts of insurance required in the Schedule or elsewhere in the contract.

(b) Before commencing work under this contract, the Contractor shall notify the Contracting Officer in writing that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government's interest shall not be effective (1) for such period as the laws of the State in which this contract is to be performed prescribe, or (2) until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in subcontracts under this contract that require work on a Government installation and shall require subcontractors to provide and maintain the insurance required in the Schedule or elsewhere in the contract. The Contractor shall maintain a copy of all subcontractors' proofs of required insurance, and shall make copies available to the Contracting Officer upon request.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil http://www.acq.osd.mil.dpap/dars.dfars/index.htm

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any DoD FAR Supplement (48 CFR Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.203-7999 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements. (DEVIATION 2015-O0010)

PROHIBITION ON CONTRACTING WITH ENTITIES THAT REQUIRE CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS (DEVIATION 2015-O0010)(FEB 2015)

1. The Contractor shall not require employees or subcontractors seeking to report fraud, waste, or abuse to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or contactors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information.

1. The Contractor shall notify employees that the prohibitions and restrictions of any internal confidentiality agreements covered by this clause are no longer in effect.

1. The prohibition in paragraph (a) of this clause does not contravene requirements applicable to Standard Form 312, Form 4414, or any other form issued by a Federal department or agency governing the nondisclosure of classified information.

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

AFFARS 5352.201-9101 OMBUDSMAN (Apr 2014)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an…