Atch_8_Spec_Oct_16.pdf

TECHNICAL SPECIFICATIONS

(FOR CONSTRUCTION CONTRACT)

CORRECTED FINAL

REPLACE LIVE FRONT

TRANSFORMERS/DISCONNECTS

WSA (FY 16)

FE WARREN AFB, WYOMING

PREPARED BY:

U.S. Army Corps of Engineers, Omaha District

OCTOBER 2016

This page was intentionally left blank for duplex printing.

00 01 10 - 1 PROJECT TABLE OF CONTENTS

TECHNICAL SPECIFICATIONS FOR CONSTRUCTION

REPLACE LIVE FRONT

TRANSFORMERS/DISCONNECTS

WSA (FY16)

FE WARREN AFB, WYOMING

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 01 10 PROJECT TABLE OF CONTENTS

00 10 00CLIN CONTRACT LINE ITEM BID SCHEDULE

DIVISION 01 - GENERAL REQUIREMENTS

01 33 00 SUBMITTAL PROCEDURES

REGISTER SUBMITTAL REGISTER

E4025 ENG FORM 4025 TRANSMITTAL FORM

01 41 26.04 24 (WYOMING) NPDES PERMIT REQUIREMENTS FOR STORM WATER

DISCHARGES FROM CONSTRUCTION SITES

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

02 84 33 REMOVAL AND DISPOSAL OF POLYCHLORINATED BIPHENYLS (PCBs)

DIVISION 26 - ELECTRICAL

26 05 00.00 40 COMMON WORK RESULTS FOR ELECTRICAL

26 05 13.00 40 MEDIUM-VOLTAGE CABLES

26 08 00 APPARATUS INSPECTION AND TESTING

26 12 19.10 THREE-PHASE PAD-MOUNTED TRANSFORMERS

26 13 01 PAD-MOUNTED DEAD-FRONT AIR INSULATED SWITCHGEAR

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION WITH ARC FLASH HAZARD

STUDY

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

DIVISION 33 - UTILITIES

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

-- End of Project Table of Contents --

CLIN SCHEDULE

CONTRACT LINE ITEM BIDDING SCHEDULE

ITEM

NO.

DESCRIPTION ESIMATED

QUANTITY

UNIT UNIT PRICE ESTIMATED

AMOUNT

BASIC ITEMS

Entire work complete, to construct Replace Live Front Transformers/Disconnects, WSA (FY16) in accordance with the plans and specs.

Job

XXX

TOTAL AMOUNT $_________________________________

NOTES:

1. Bid prices must be entered for all items of the schedule. Total amounts submitted without bid prices being entered on individual items will be rejected. In case of variation between the Job (lump sum) prices and the total amount, the lump sum prices will be considered the bid price submitted.

2. A modification to a bid which provides for a single adjustment to the total amounts, should state the application of the adjustment to each respective lump sum price and unit price affected.

Replace Transformers, F.E. Warren AFB, WY FE94

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

05/11; OMA 1/15

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

1.1.2 Approving Authority

1.1.3 Work

1.1.4 Administrative Submittals

1.2 SUBMITTALS

1.3 ELECTRONIC SUBMITTALS

1.3.1 Exceptions

1.3.2 File Format

1.3.3 Digital File Naming

1.3.4 Content

1.3.5 Delivery

1.4 SUBMITTAL CLASSIFICATION

1.5 PREPARATION

1.5.1 Transmittal Form

1.6 VARIATIONS

1.6.1 Considering Variations

1.6.2 Proposing Variations

1.6.3 Warranting That Variations Are Compatible

1.6.4 Review Schedule Is Modified

1.7 SUBMITTAL REGISTER

1.7.1 Use of Submittal Register

1.7.2 Contractor Use of Submittal Register

1.7.3 Approving Authority Use of Submittal Register

1.7.4 Contractor Action Code and Action Code

1.7.5 Copies Delivered to the Government

1.8 SUBMITTAL ITEM PROCEDURES

1.8.1 "G-DO" or "G-AE" Submittals

1.8.2 Government Approved (G-AO/G-RO) and FIO Submittals

1.8.3 Certificates of Compliance

1.8.4 Purchase Orders

1.8.5 Operation and Maintenance Data/Manuals

1.9 SCHEDULING

1.10 GOVERNMENT APPROVING AUTHORITY

1.11 DISAPPROVED OR REJECTED SUBMITTALS

1.12 APPROVED/ACCEPTED SUBMITTALS

1.13 APPROVED SAMPLES

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 33 00 Page 1

-- End of Section Table of Contents --

SECTION 01 33 00 Page 2

SECTION 01 33 00

SUBMITTAL PROCEDURES

05/11; OMA 1/15

PART 1 GENERAL

Attachments: Submittal Register ENG Form 4025, Transmittal Form

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

Submittals requirements are specified in the technical sections.

Submittals are identified by Submittal Description (SD) numbers and titles as follows:

SD-01 Preconstruction Submittals

Submittals which are required prior to start of construction (work) Unless otherwise designated, the submittals listed below will be handled as Administrative Submittals.

Certificates of insurance

Surety bonds

List of proposed Subcontractors

List of proposed products

Construction Progress Schedule

Network Analysis Schedule (NAS)

Submittal register

Schedule of prices

Health and safety plan

Work plan

Quality Control(QC) plan

Permits

Environmental protection plan

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating the

SECTION 01 33 00 Page 3 product or system into the project.

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials, systems or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Fabricated or unfabricated physical examples of materials, equipment or workmanship that illustrate functional and aesthetic characteristics of a material or product and establish standards by which the work can be judged.

Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project.

Field samples and mock-ups constructed on the project site establish standards by which the ensuring work can be judged. Includes assemblies or portions of assemblies which are to be incorporated into the project and those which will be removed at conclusion of the work.

SD-05 Design Data

Design calculations, mix designs, analyses or other data pertaining to a part of work.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. (Testing must have been within three years of date of contract award for the project.)

Report which includes findings of a test required to be performed by the Contractor on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports.

Daily logs and checklists.

Final acceptance test and operational test procedure.

SD-07 Certificates

SECTION 01 33 00 Page 4

Statements printed on the manufacturer's letterhead and signed by responsible officials of manufacturer of product, system or material attesting that product, system or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a manufacturer, supplier, installer or Subcontractor through Contractor, the purpose of which is to further quality of orderly progression of a portion of the work by documenting procedures, acceptability of methods or personnel qualifications.

Confined space entry permits.

Text of posted operating instructions.

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and (MSDS)concerning impedances, hazards and safety precautions.

SD-09 Manufacturer's Field Reports

Documentation of the testing and verification actions taken by manufacturer's representative at the job site, in the vicinity of the job site, or on a sample taken from the job site, on a portion of the work, during or after installation, to confirm compliance with manufacturer's standards or instructions. The documentation must be signed by an authorized official of a testing laboratory or agency and must state the test results; and indicate whether the material, product, or system has passed or failed the test.

Factory test reports.

SD-10 Operation and Maintenance Data

Data that is furnished by the manufacturer, or the system provider, to the equipment operating and maintenance personnel, including manufacturer's help and product line documentation necessary to maintain and install equipment. This data is needed by operating and maintenance personnel for the safe and efficient operation, maintenance and repair of the item.

This data is intended to be incorporated in an operations and maintenance manual or control system.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

Special requirements necessary to properly close out a construction contract. For example, Record Drawings, special warranties, posted operating instructions, training plan and as-built drawings. Also, submittal requirements necessary to properly close out a major phase of construction on a multi-phase contract.

SECTION 01 33 00 Page 5

Interim "DD Form 1354" with cost breakout for all assets 30 days prior to facility turnover.

1.1.2 Approving Authority

Office or designated person authorized to approve submittal.

1.1.3 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce submittals, construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction.

1.1.4 Administrative Submittals

The submittal items listed below are not to be included on the Submittal Register (as discussed below). Unless directed otherwise by the Contracting Officer, the following administrative submittals are submitted to the Area or Resident (as directed) Office, for acceptance, via a Serial Letter: Submittal Register (this section), Quality Control Plans (Section 01 45 00.00 10 QUALITY CONTROL, Accident Prevention Plans (Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS, Revisions to Environmental Protection Plans (Section 01 57 20.00 10 ENVIRONMENTAL PROTECTION) and other submittals as directed by the Contracting Officer. Format for the Serial Letter is as directed by the Area or Resident Office. Submit three (3) copies of administrative submittal items, unless directed otherwise.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with this section.

Administrative Submittals

Submittal Register

1.3 ELECTRONIC SUBMITTALS

Electronic format will be utilized for submission of construction submittal items required by the specifications, including ENG Form 4025 Transmittal Form, with exceptions noted below.

1.3.1 Exceptions

Submit all SD-04 (Samples) submittals and other submittals, where noted in the specifications to be in physical, hard-copy form. Other known exceptions include: Operation and Maintenance Data/Manuals. Number of hard copies shall be as required in the "SUBMITTAL ITEM PROCEDURES" paragraph below.

1.3.2 File Format

Electronic submittals may be submitted by any means readily accessible to the Government including, but not limited to, the following:

SECTION 01 33 00 Page 6

a. E-mails with text and all attachments less than or equal to 14MB in size. The Government IT system does not currently support e-mail transmissions of greater than 14MB. Should this e-mail transmission size limitation change during the course of the Contract, larger e-mail transmissions may become acceptable, but no time extensions will be granted for transmission errors resulting from oversized email attachments.

b. Internet Secure File Transfer Protocol (FTP) systems compatible with Government IT systems.

c. Mailed CD-ROM or DVD-ROM media.

d. Contractor-funded file sharing website compatible with Government IT systems.

e. Any other secure, Government-approved means of transmitting digital media.

Means of transfer must provide documents freely accessible to the Government. If the means of transfer is by e-mail, FTP repository, or similar, files shall be capable of being downloaded without errors or disruption. Regardless of the method of transfer, the files shall be able to be archived on Government IT systems without error or restriction.

Once provided, all submittal documents shall become Government property.

ZIP-file or similar archives requiring a password for access to the archive are permissible provided the password for the archive is static, permanent, not use-limited, and provided to the Government at the time of transmission. Any individual files provided electronically to the Government in 'SECURED' format, password-protected, or utilizing any other such method of file restriction shall be deemed defective and returned to the Contractor for correction. Regardless of errors encountered during the electronic submittal process the Contractor shall be responsible for delays resulting from the inadequacy of media delivery method, file-formatting, or file restriction issues. No time extensions will be granted for delays resulting from improper file formatting, file restrictions, or inadequate file transfer methods.

Discussion and decisions on a consistent Means of transfer throughout the duration of the project will be made at the pre-construction conference.

The format of electronic submittals is Adobe Acrobat Portable Document Format (PDF), compatible with Adobe X, unless agreed to and directed otherwise by the Contacting Officer's Representative. For As-built drawings, see Section 01 78 39.00 24 AS-BUILT DRAWINGS.

1.3.3 Digital File Naming

Label and name electronic files delivered to the Government in a manner that is logical and consistent throughout the duration of the project. A file naming convention that clearly indicates the transmittal number, component of submittal, and revision number associated with the submittal will be discussed and confirmed at the pre-construction kickoff conference.

1.3.4 Content

Submit one (1) set of readily copied and legible electronic documents and associated matching ENG Form 4025 Transmittal Form. Duplicate copies of electronic submittals are not desired. Content and format of the electronic submittal shall conform to all requirements listed herein. Delivery methods of both electronic and hard-copy submittals shall remain consistent throughout the duration of the Contract, in compliance with Contract specifications.

SECTION 01 33 00 Page 7

1.3.5 Delivery

Delivery of submittals will be similar to those described in the "SUBMITTAL ITEM PROCEDURES" paragraph below. Notifications of file transfers will be sent to the Government recipients listed below. The means of contact and notification by mail or email will be coordinated and confirmed at the pre-construction conference.

1.4 SUBMITTAL CLASSIFICATION

Submittals are classified as follows:

Unless directed otherwise, the words "Government Approval" associated with "G" designated submittals are interpreted in the context of the below defined submittal types. Submittal Reviewers include the following:

DO - District Office AE - Architect Engineer CR - Government Conformance Review DA - Designer of Record AO - Area Office or other designated Government Office RO - Resident Office

1.5 PREPARATION

1.5.1 Transmittal Form

1.6 VARIATIONS

Variations from contract requirements require both Designer of Record (DOR) and Government approval pursuant to contract Clause FAR 52.236-21 and will be considered where advantageous to Government.

1.6.1 Considering Variations

Discussion with Contracting Officer prior to submission, after consulting with the DOR, will help ensure functional and quality requirements are met and minimize rejections and re-submittals. When contemplating a variation which results in lower cost, consider submission of the variation as a Value Engineering Change Proposal (VECP).

Specifically point out variations from contract requirements in transmittal letters. Failure to point out deviations may result in the Government requiring rejection and removal of such work at no additional cost to the Government.

1.6.2 Proposing Variations

When proposing variation, deliver written request to the Contracting Officer, with documentation of the nature and features of the variation and why the variation is desirable and beneficial to Government, including the DOR's written analysis and approval. If lower cost is a benefit, also include an estimate of the cost savings. In addition to documentation required for variation, include the submittals required for the item.

Clearly mark the proposed variation in all documentation.

SECTION 01 33 00 Page 8

1.6.3 Warranting That Variations Are Compatible

When delivering a variation for approval, Contractor, including its Designer(s) of Record, warrants that this contract has been reviewed to establish that the variation, if incorporated, will be compatible with other elements of work.

1.6.4 Review Schedule Is Modified

In addition to normal submittal review period, a period of 10 working days will be allowed for consideration by the Government of submittals with variations.

1.7 SUBMITTAL REGISTER

Prepare and maintain submittal register, as the work progresses. Do not change data which is output in columns (c), (d), (e), and (f) as delivered by Government; retain data which is output in columns (a), (g), (h), and

(i) as approved. A submittal register showing items of equipment and materials for which submittals are required by the specifications is provided as an attachment. This list may not be all inclusive and additional submittals may be required. The Government will provide the initial submittal register in electronic format with the following fields completed, to the extent that will be required by the Government during subsequent usage.

Column (c): Lists specification section in which submittal is required.

Column (d): Lists each submittal description (SD No. and type, e.g. SD-02 Shop Drawings) required in each specification section.

Column (e): Lists one principal paragraph in specification section where a material or product is specified. This listing is only to facilitate locating submitted requirements. Do not consider entries in column (e) as limiting project requirements.

Thereafter, the Contractor is to track all submittals by maintaining a complete list, including completion of all data columns, including dates on which submittals are received and returned by the Government.

1.7.1 Use of Submittal Register

Submit submittal register. Submit with QC plan and project schedule.

Verify that all submittals required for project are listed and add missing submittals. Coordinate and complete the following fields on the register submitted with the QC plan and the project schedule:

Column (a) Activity Number: Activity number from the project schedule.

Column (g) Contractor Submit Date: Scheduled date for approving authority to receive submittals.

Column (h) Contractor Approval Date: Date Contractor needs approval of submittal.

SECTION 01 33 00 Page 9

Column (i) Contractor Material: Date that Contractor needs material delivered to Contractor control.

1.7.2 Contractor Use of Submittal Register

Update the following fields in the Government-furnished submittal register program or equivalent fields in program utilized by Contractor with each submittal throughout contract.

Column (b) Transmittal Number: Contractor assigned list of consecutive numbers.

Column (j) Action Code (k): Date of action used to record Contractor's review when forwarding submittals to QC.

Column (l) List date of submittal transmission.

Column (q) List date approval received.

1.7.3 Approving Authority Use of Submittal Register

Update the following fields.

Column (b) Transmittal Number: Contractor assigned list of consecutive numbers.

Column (l) List date of submittal receipt.

Column (m) through (p) List Date related to review actions.

Column (q) List date returned to Contractor.

1.7.4 Contractor Action Code and Action Code

Entries for columns (j) and (o), are to be used are as follows (others may be prescribed by Transmittal Form):

NR - Not Received

AN - Approved as noted

A - Approved

RR - Disapproved, Revise, and Resubmit

1.7.5 Copies Delivered to the Government

Deliver one copy of submittal register updated by Contractor to Government with each invoice request.

1.8 SUBMITTAL ITEM PROCEDURES

1.8.1 "G-DO" or "G-AE" Submittals

Except as noted below, all "G-DO" or "G-AE" hard copy submittals are to be submitted in three (3) copies. All three (3) copies are to be mailed directly to the addressee shown below using the transmittal form.

SECTION 01 33 00 Page 10

Additionally, submit one (1) copy of the transmittal form to the Area Engineer or Resident Engineer (as directed). See paragraph: ELECTRONIC SUBMITTALS for submittal items being transmitted electronically.

Technical Reviewer

District Office(DO) Russell Matthews U.S. Army Corps of Engineers Omaha District Attn: CENWO-CD-S-TS 1616 Capitol Ave Omaha, NE 68102-4901

Electronic Submittals and e-mail notifications of Electronic Submittals posted to AMRDEC SAFE or other FTP repositories should be sent to Russell Matthews at the following e-mail address:

CENWO.ConstructionSubmittal@usace.army.mil

Items not to be submitted in multiples, such as samples and test cylinders, are to be submitted to the Area or Resident Engineer (as directed), accompanied by three (3) copies of the transmittal form.

Hard Copy Drawings: Submit each required submittal, which is in the form of a drawing, as three (3) prints of the drawing. Drawing prints are to be either blue or black line permanent-type prints on a white background or blueprint and shall be sufficiently clear and suitable for making legible copies.

All hard copy submittals must be presented such that they fit into a standard size (letter) cabinet file drawer. Larger drawings must be folded to fit and not rolled. See paragraph: ELECTRONIC SUBMITTALS above for electronic submittals.

Catalog cuts and other descriptive data which have more than one model, size, or type or which shows optional equipment must be clearly marked to show the model, size, or type and all optional equipment which is provided. Submittals on component items forming a system or that are interrelated are to be submitted at one time as a single submittal in order to demonstrate that the items have been properly coordinated and will function as a unit.

1.8.2 Government Approved (G-AO/G-RO) and FIO Submittals

Except as noted below, data for all Government Approved submittal items are to be submitted in three (3) copies (hard copy submittals) to theArea or Resident Engineer (as directed). All three (3) copies are to be submitted using the transmittal form. Items not to be submitted in multiples, such as samples and test cylinders, are to be submitted to the Area or Resident Engineer (as directed) accompanied by three (3) copies of the transmittal form.

Except as noted below, data for all items listed as "FIO" Submittals in the various sections are to be submitted in three (3) copies (hard copy submittals). All three (3) copies are to be submitted to the Area or Resident Engineer (as directed) using the transmittal form. Items not to

SECTION 01 33 00 Page 11 be submitted in multiples, such as samples and test cylinders, are to be submitted to the Area or Resident Engineer (as directed) accompanied by three (3) copies of the transmittal form.

All hard copy submittals must be presented such that they fit into a standard sizse (letter) cabinet file drawer. Larger drawings must be folded to fit and not rolled. See paragraph: ELECTRONIC SUBMITTALS above for electronic submittals.

All submittals must be reviewed and approved by the Contractor's Quality Control Representative prior to submittal to the Government.

The Government has the option to review any For Information Only submittals.

1.8.3 Certificates of Compliance

Each certificate must be signed by an official authorized to certify in behalf of the manufacturing company and contain the name and address of the Contractor, the project name and location, and the quantity and date or dates of shipment or delivery to which the certificates apply. Copies of laboratory test reports submitted with certificates must contain the name and address of the testing laboratory and the date or dates of the tests to which the report applies. Certification is not to be construed as relieving the Contractor from furnishing satisfactory material, if, after tests are performed on selected samples, the material is found not to meet the specific requirements.

1.8.4 Purchase Orders

Copies of purchase orders are to be furnished to the Contracting Officer when the Contractor requests assistance for expediting deliveries of equipment or materials, or when requested by the Contracting Officer for the purpose of quality assurance review. Each purchase order issued by the Contractor or his subcontractors for materials and equipment to be incorporated into the project are to (1) be clearly identified with the applicable DA contract number, (2) carry an identifying number, (3) be in sufficient detail to identify the material being purchased, (4) indicate a definite delivery date, and (5) display the DMS priority rating, if applicable.

1.8.5 Operation and Maintenance Data/Manuals

Where required by various technical sections, operations and maintenance data/manuals are to be provided by the Contractor in one (1) hard copy and three (3) separate electronic copies (three (3) CD-ROM copies), unless directed otherwise. Provide legible hard copies of the operations and maintenance data that are assembled in three-ring binders with index and tabbed section dividers and having a cover indicating the contents by equipment or system name and and include the project title and location.

The legible electronic copies of the operation and maintenance data on the CD-ROMs are to be in a Adobe Acrobat .PDF format (Version 9.0) and be organized using bookmarks that define the contents by equipment or system name and includes Project Name and Location, unless directed otherwise by the Contracting Officer. Include the same information on the CD-ROM cover. Operation and maintenance data for mechanical and electrical systems are to be submitted for approval to the Contracting Officer 90 days prior to final tests of these systems, unless otherwise specified. Each operation and maintenance manual must contain a copy of all warranties .

If field testing requires these copies to be revised, they are to be

SECTION 01 33 00 Page 12 updated and resubmitted for approval within 10 calendar days after completion of tests. The Operations and Maintenance Data are to be shown as a separate activity on the Contractor prepared construction schedule bar chart or Network Analysis System (Project Schedule). In addition, all wiring and control diagrams and approved system layout drawings must be submitted and included with the O&M Data.

1.9 SCHEDULING

Schedule and submit concurrently submittals covering component items forming a system or items that are interrelated. Allow a minimum of 20 calendar days exclusive of mailing for any Government reviews and approvals, unless directed otherwise. Include certifications to be submitted with the pertinent drawings at the same time. No delay damages or time extensions will be allowed for time lost in late submittals.

a. Coordinate scheduling, sequencing, preparing and processing of submittals with performance of work so that work will not be delayed by submittal processing. Allow for potential resubmittal of requirements.

b. Submittals called for by the contract documents will be listed on the register. If a submittal is called for but does not pertain to the contract work, the Contractor is to include the submittal in the register and annotate it "N/A" with a brief explanation. Approval by the Contracting Officer does not relieve the Contractor of supplying submittals required by the contract documents but which have been omitted from the register or marked "N/A."

c. Re-submit register and annotate monthly by the Contractor with actual submission and approval dates. When all items on the register have been fully approved, no further re-submittal is required.

d. Carefully control procurement operations to ensure that each individual submittal is made on or before the Contractor scheduled submittal date shown on the approved "Submittal Register."

1.10 GOVERNMENT APPROVING AUTHORITY

When approving authority is Contracting Officer, the Government will:

a. Note date on which submittal was received.

b. Review submittals for approval within scheduling period specified and only for conformance with project design concepts and compliance with contract documents.

c. Identify returned submittals with one of the actions defined in paragraph entitled, "Review Notations," of this section and with markings appropriate for action indicated.

Upon completion of review of submittals requiring Government approval, stamp and date approved submittals. All copies of the approved submittal will be retained by the Contracting Officer, except for two (2) copies of the submittal will be returned to the Contractor for hard copy submittals.

For electronic submittals, see paragraph: ELECTRONIC SUBMITTALS above..

SECTION 01 33 00 Page 13

1.11 DISAPPROVED OR REJECTED SUBMITTALS

Contractor shall make corrections required by the Contracting Officer. If the Contractor considers any correction or notation on the returned submittals to constitute a change to the contract drawings or specifications; notice as required under the clause entitled, "Changes," is to be given to the Contracting Officer. Contractor is responsible for the dimensions and design of connection details and construction of work.

Failure to point out deviations may result in the Government requiring rejection and removal of such work at the Contractor's expense.

If changes are necessary to submittals, the Contractor shall make such revisions and submission of the submittals in accordance with the procedures above. No item of work requiring a submittal change is to be accomplished until the changed submittals are approved.

1.12 APPROVED/ACCEPTED SUBMITTALS

The Contracting Officer's approval or acceptance of submittals is not to be construed as a complete check, and indicates only that

Approval or acceptance will not relieve the Contractor of the responsibility for any error which may exist, as the Contractor under the Contractor Quality Control (CQC) requirements of this contract is responsible for dimensions, the design of adequate connections and details, and the satisfactory construction of all work.

After submittals have been approved or accepted by the Contracting Officer, no resubmittal for the purpose of substituting materials or equipment will be considered unless accompanied by an explanation of why a substitution is necessary.

1.13 APPROVED SAMPLES

Approval of a sample is only for the characteristics or use named in such approval and is not be construed to change or modify any contract requirements. Before submitting samples, the Contractor to assure that the materials or equipment will be available in quantities required in the project. No change or substitution will be permitted after a sample has been approved.

Match the approved samples for materials and equipment incorporated in the work. If requested, approved samples, including those which may be damaged in testing, will be returned to the Contractor, at his expense, upon completion of the contract. Samples not approved will also be returned to the Contractor at its expense, if so requested.

Failure of any materials to pass the specified tests will be sufficient cause for refusal to consider, under this contract, any further samples of the same brand or make of that material. Government reserves the right to disapprove any material or equipment which previously has proved unsatisfactory in service.

Samples of various materials or equipment delivered on the site or in place may be taken by the Contracting Officer for testing. Samples failing to meet contract requirements will automatically void previous approvals.

Contractor to replace such materials or equipment to meet contract requirements.

SECTION 01 33 00 Page 14

Approval of the Contractor's samples by the Contracting Officer does not relieve the Contractor of his responsibilities under the contract.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

-- End of Section --

SECTION 01 33 00 Page 15

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 1 OF 7 PAGES

Replace Transformers, F.E. Warren AFB, WY

01 41 26.04 24 SD-01 Preconstruction Submittals 3.2.1Notice of Intent 3.2.1Authorization Letter 3.2.2Storm Water Pollution Prevention

Plan 3.2.6Notice of Termination

SD-06 Test Reports 3.2.3Reports

01 57 23 SD-07 Certificates 2.1.3Mill Certificate or Affidavit

02 41 00 SD-01 Preconstruction Submittals

1.2.1 G CORDemolition Plan

G CORDeconstruction Plan 1.10Existing Conditions

SD-07 Certificates

1.7 G CORNotification

SD-11 Closeout Submittals 3.3.4Receipts

02 84 33 SD-07 Certificates 1.7.1Training certification 1.7.2Qualifications of CIH

G ROSampling and Analysis Plan 1.7.4PCB removal work plan 1.7.5PCB disposal plan 1.7.6Notification 3.8Transporter certification

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P H

C L A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

AUTH REMARKS

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r)

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 2 OF 7 PAGES

02 84 33 3.5.4Certification of Decontamination 3.5.5Post cleanup sampling

Shipping documentation 3.8.1Certificate of disposal

26 05 00.00 40 SD-01 Preconstruction Submittals 2.1Material, Equipment, and Fixture

Lists SD-03 Product Data

2.1.1 GConduits and Raceways

2.1.3 GWire and Cable

3.2.1.7 GSplices and Connectors

2.1.4 GSwitches

GReceptacles

2.1.5 GOutlet Boxes, Pull Boxes and

Junction Boxes GCircuit Breakers GPanelboards GLamps and Lighting Fixtures

2.1.8 GDry-Type Distribution

Transformers

SD-06 Test Reports

3.3 GContinuity Test

3.3 GPhase-Rotation Tests

3.3 GInsulation Resistance Test

SD-08 Manufacturer’s Instructions 3.1Manufacturer's Instructions

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 3 OF 7 PAGES

26 05 13.00 40 SD-03 Product Data

2.2.1 GMultiple-Conductor Shielded

Cables

2.2.2 GMultiple-Conductor Nonshielded

Cables

2.2.3 GSingle-Conductor Shielded

Cables

2.2.4 GSingle-Conductor Nonshielded

Cables

2.2.5 GPortable Cables

2.3.3 GNonmetallic Jacket

SD-06 Test Reports

3.2 GDielectric Absorption Tests

3.2 GMedium-Voltage Tests

3.2 GRadiographic Tests

SD-07 Certificates

2.4 GCertificates

2.2.1.1 GLead Sheath

2.4.1 GFlammability

3.1.4 GMinimum Bending Radius

3.2 GMedium-Voltage Tests

3.2 GDielectric Absorption Tests

1.6 GCable Splicers

SD-08 Manufacturer’s Instructions

1.5 GMedium-Voltage Power Cables

1.5 GPothead Terminations

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 4 OF 7 PAGES

26 08 00 SD-06 Test Reports

3.1 G ROAcceptance tests and inspections

SD-07 Certificates

1.3.1 G ROQualifications

1.3.3 G ROAcceptance test and inspections

procedure 26 12 19.10 SD-02 Shop Drawings

1.5.1 G DOPad-mounted transformer

drawings

SD-03 Product Data

2.2 G DOPad-mounted transformers

SD-06 Test Reports

3.6.1 G ROAcceptance checks and tests

SD-07 Certificates

2.2.2.1 G DOTransformer Efficiencies

SD-09 Manufacturer’s Field Reports

2.7.2 G ROdesign tests

2.7.3 G ROroutine and other tests

SD-10 Operation and Maintenance Data

1.6.1 G ROTransformer(s)

SD-11 Closeout Submittals

2.7.1 G ROTransformer test schedule

26 13 01 SD-02 Shop Drawings

1.5.1 GSwitchgear Drawings

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 5 OF 7 PAGES

26 13 01 SD-03 Product Data

1.5.2 GFuse Time-Current Characteristic

Curves

2.1 GAir Insulated Pad-mounted

Switchgear

2.2 GInsulated High-Voltage

Connectors

2.3 GSurge Arresters

SD-06 Test Reports

3.4.1 GAcceptance Checks and Tests

SD-07 Certificates GPaint Coating System

SD-09 Manufacturer’s Field Reports

2.6.1 GSwitchgear design and

production tests

SD-10 Operation and Maintenance Data

1.6.1 GAir Insulated Pad-Mounted

Switchgear Operation and Maintenance

26 28 01.00 10 SD-03 Product Data Arc Flash Hazard Analysis; G, DO

Fault Current Analysis; G, DO

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 6 OF 7 PAGES

26 28 01.00 10 Protective Device Coordination Study; G, DO

Equipment; G, DO System Coordinator; G, DO Installation; G, RO

SD-06 Test Reports Field Testing; G, RO

SD-07 Certificates Devices and Equipment; G, RO

33 71 02 SD-02 Shop Drawings

1.6.1 G DOPrecast underground structures

SD-03 Product Data

2.5 G DOMedium voltage cable

2.7 G DOMedium voltage cable joints

2.6 G DOMedium voltage cable

terminations

2.12.1.1 G DOPrecast concrete structures

2.12.1.4Sealing Material 3.5.2Pulling-In Irons

2.12.2 G DOManhole frames and covers

2.12.3 G DOHandhole frames and covers

2.12.5 G DOComposite/fiberglass handholes

2.13 G DOCable supports

SD-06 Test Reports

2.17.2 G DOMedium voltage cable

qualification and production tests

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 7 OF 7 PAGES

33 71 02 3.17.1 G DOField Acceptance Checks and Tests

2.17.1 G DOArc-proofing test

3.3 G DOCable Installation Plan and

Procedure SD-07 Certificates

1.6.2 G DOCable splicer/terminator

1.6.3 G DOCable Installer Qualifications

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

TRANSMITTAL OF SHOP DRAWINGS, EQUIPMENT DATA, MATERIAL SAMPLES, OR

MANUFACTURER'S CERTIFICATES OF COMPLIANCE

For use of this form, see ER 415-1-10; the proponent agency is CECW-CE.

DATE TRANSMITTAL NO.

SECTION I - REQUEST FOR APPROVAL OF THE FOLLOWING ITEMS (This section will be initiated by the contractor)

TO:

PROJECT TITLE AND LOCATIONSPECIFICATION SEC. NO. (Cover only one section with each transmittal)

FROM: CONTRACT NO. CHECK ONE:

THIS TRANSMITTAL IS FOR: (Check one)

THIS IS A NEW TRANSMITTAL

THIS IS A RESUBMITTAL OF

TRANSMITTAL

FIO GA DA CR DA/CR DA/GA

ITEM

NO.

(See

Note 3)

USACE

ACTION

CODE

(Note 9)

SUBMITTAL

TYPE CODE

(See Note 8)

NO.

OF

COPIES

SPEC.

PARA. NO.

DRAWING

SHEET NO.

CONTRACTOR

REVIEW

CODE

VARIATION

Enter "Y" if requesting a variation

(See Note 6)

DESCRIPTION OF SUBMITTAL ITEM

(Type size, model number/etc.)

a. i.c. d. e. f. g. h.b.

CONTRACT DOCUMENT

REFERENCE

REMARKS

SECTION II - APPROVAL ACTION

I certify that the above submitted items had been reviewed in detail and are correct and in strict conformance with the contract drawings and specifications except as otherwise stated.

NAME OF CONTRACTOR SIGNATURE OF CONTRACTOR

NAME AND TITLE OF APPROVING AUTHORITY SIGNATURE OF APPROVING AUTHORITY DATEENCLOSURES RETURNED (List by item No.)

REPLACES EDITION OF MAR 95, WHICH IS OBSOLETE.ENG FORM 4025-R, MAR 2012

INSTRUCTIONS

1. Section I will be initiated by the Contractor in the required number of copies.

2. Each Transmittal shall be numbered consecutively. The Transmittal Number typically includes two parts separated by a dash (-). The first part is the specification section number. The second part is a sequential number for the submittals under that spec section. If the Transmittal is a resubmittal, then add a decimal point to the end of the original Transmittal Number and begin numbering the resubmittal packages sequentially after the decimal.

3. The "Item No." for each entry on this form will be the same "Item No." as indicated on ENG FORM 4288-R.

4. Submittals requiring expeditious handling will be submitted on a separate ENG Form 4025-R.

5. Items transmitted on each transmittal form will be from the same specification section. Do not combine submittal information from different specification sections in a single transmittal.

6. If the data submitted are intentionally in variance with the contract requirements, indicate a variation in column h, and enter a statement in the Remarks block describing he detailed reason for the variation.

7. ENG Form 4025-R is self-transmitting - a letter of transmittal is not required.

8. When submittal items are transmitted, indicate the "Submittal Type" (SD-01 through SD-11) in column c of Section I.

Submittal types are the following:

SD-01 - Preconstruction SD-02 - Shop Drawings SD-03 - Product Data SD-04 - Samples SD-05 - Design Data SD-06 - Test Reports

SD-07 - Certificates SD-08 - Manufacturer's Instructions SD-09 - Manufacturer's Field Reports SD-10 - O&M Data SD-11 - Closeout

9. For each submittal item, the Contractor will assign Submittal Action Codes in column g of Section I. The U.S. Army Corps of Engineers approving authority will assign Submittal

Action Codes in column i of Section I. The Submittal Action Codes are:

A -- Approved as submitted.

B -- Approved, except as noted on drawings. Resubmission not required.

C -- Approved, except as noted on drawings. Refer to attached comments.

Resubmission required.

D -- Will be returned by separate correspondence.

E -- Disapproved. Refer to attached comments.

10. Approval of items does not relieve the contractor from complying with all the requirements of the contract.

F -- Receipt acknowledged.

X -- Receipt acknowledged, does not comply with contract requirements, as noted.

G -- Other action required (Specify)

K -- Government concurs with intermediate design. (For D-B contracts)

R -- Design submittal is acceptable for release for construction. (For D-B contracts)

ENG FORM 4025-R, MAR 2012

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 41 26.04 24

(WYOMING) NPDES PERMIT REQUIREMENTS FOR STORM WATER DISCHARGES FROM

CONSTRUCTION SITES

10/03

PART 1 GENERAL

1.1 REFERENCES (Not Applicable)

1.2 SUBMITTALS

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION

3.1 GENERAL

3.2 IMPLEMENTATION

3.2.1 Notice of Intent

3.2.2 Storm Water Pollution Prevention Plan

3.2.3 Inspections and Reporting

3.2.4 Retention of Records

3.2.5 Construction Project Identification

3.2.6 Notice of Termination

3.2.7 Continuation of Coverage Under a Renewed Permit

SECTION 01 41 26.04 24 Page 1

SECTION 01 41 26.04 24

(WYOMING) NPDES PERMIT REQUIREMENTS

FOR STORM WATER

DISCHARGES FROM CONSTRUCTION SITES

10/03

PART 1 GENERAL

Attachment:

"Authorization to Discharge Storm Water Associated with Large Construction Activity Under the National Pollutant Discharge Elimination System (NPDES)" General Permit WYR10-0000

NOTE: If construction area can be kept to under one acre including the staging area then a NPDES permit would not be required. The staging area does not have to be included in the one acre if it can be on concrete or black-top.

1.1 REFERENCES (Not Applicable)

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Notice of Intent.

Authorization Letter.

Storm Water Pollution Prevention Plan.

Notice of Termination.

SD-06 Test Reports

Reports.

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION

3.1 GENERAL

The Contractor shall be responsible for implementing the terms and requirements of the attached copy of the "Authorization To Discharge Storm Water Associated With Large Construction Activity Under The National Pollutant Discharge Elimination System (NPDES)" general NPDES permit WYR10-0000 and the Pollution Prevention Plan. The Contractor shall be

SECTION 01 41 26.04 24 Page 2 considered the "permittee". All submissions to the State shall be by certified mail. Copies of the return receipt for each submission shall be included with the submittal to the Contracting Officer's Representative.

3.2 IMPLEMENTATION

3.2.1 Notice of Intent

The Contractor shall complete and submit a Notice of Intent (NOI) in accordance with the general NPDES permit. Construction may not begin until the Contractor receives a written notice from the Wyoming Department of Environmental Quality that the Notice of Intent has been accepted. A copy of the submitted Notice of Intent and Authorization Letter shall be furnished to the Contracting Officer's Representative at least 2 days prior to the commencement of construction activities.

3.2.2 Storm Water Pollution Prevention Plan

The Contractor shall prepare and implement a Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general NPDES permit. Any temporary or permanent erosion and sediment control measures shown on the drawings shall be incorporated into the Contractor's SWPPP. A copy of the SWPPP shall be submitted to the Contracting Officer's Representative at least 2 days prior to the commencement of construction activities.

3.2.3 Inspections and Reporting

The Contractor shall be responsible for all inspections and reporting required under the general NPDES permit. Copies of all reports shall be furnished to the Contracting Officer's Representative.

3.2.4 Retention of Records

The Contractor shall retain copies of the SWPPP and all reports in accordance with the general NPDES permit.

3.2.5 Construction Project Identification

The Contractor shall post a copy of the authorization letter at the construction site in a prominent and safe place in accordance with the NPDES permit.

3.2.6 Notice of Termination

The Contractor shall complete and submit a Notice of Termination (NOT) in accordance with the general NPDES permit. A copy of the submitted NOT shall be furnished to the Contracting Officer's Representative.

3.2.7 Continuation of Coverage Under a Renewed Permit

If the current NDPES general permit expires prior to completion of construction, the Contractor shall continue coverage in accordance with the new permit.

-- End of Section --

SECTION 01 41 26.04 24 Page 3

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 57 20.00 10

ENVIRONMENTAL PROTECTION

04/06

PART 1 GENERAL

1.1 REFERENCES

1.2 DEFINITIONS

1.2.1 Environmental Pollution and Damage

1.2.2 Environmental Protection

1.2.3 Contractor Generated Hazardous Waste

1.2.4 Installation Pest Management Coordinator

1.2.5 Land Application for Discharge Water

1.2.6 Pesticide

1.2.7 Pests

1.2.8 Surface Discharge

1.2.9 Waters of the United States

1.2.10 Wetlands

1.3 GENERAL REQUIREMENTS

1.4 SUBCONTRACTORS

1.5 PAYMENT

1.6 SUBMITTALS

1.7 ENVIRONMENTAL PROTECTION PLAN

1.7.1 Compliance

1.7.2 Contents

1.7.3 Appendix

1.8 PROTECTION FEATURES

1.9 ENVIRONMENTAL ASSESSMENT OF CONTRACT DEVIATIONS

1.10 NOTIFICATION

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 ENVIRONMENTAL PERMITS, REVIEWS, APPROVALS, AND NOTIFICATIONS

3.1.1 (WYOMING) NPDES PERMIT REQUIREMENTS FOR STORM WATER DISCHARGE

FROM CONSTRUCTION SITES

3.1.2 WYOMING'S AIR QUALITY DIVISION

3.1.3 STATE OF WYOMING DEPARTMENT OF ENVIRONMENTAL QUALITY, WATER

QUALITY DIVISION REQUIREMENTS AND OTHER LOCAL PERMITS IN WYOMING

3.1.4 City of Larmaie, Wyoming Building Permit

3.2 LAND RESOURCES

3.2.1 Work Area Limits

3.2.2 Landscape

3.2.3 Erosion and Sediment Controls

3.2.4 Contractor Facilities and Work Areas

3.3 WATER RESOURCES

3.3.1…