FA4528-16-R-0002_MAF_Cable_Fence.pdf

1)Project Title: MAF Anti-Ram Cable Fence.

2)Location: Minot AFB.

3)This acquisition is 100% Small Business Set-Aside.

4)Aw ard of this solicitation w ill result in a Firm-Fixed Price (FFP) contract.

5)365 days Period of Performance. 1 w inter exclusion period.

6) Magnitude: $1,000,000.00 - $5,000,000.00.

NOTE 1: The US Government intends to evaluate proposals and aw ard a contract w ithout discussions w ith offerors (except clarif ications as described in FAR 15.306(a)). Therefore, the offeror's initial proposal should contain the offeror's best terms from a cost or price and technical standpoint.

NOTE 2: Notice to Offerors: Funds are not presently available for this effort. Please see Section L for more information.

NOTE 3: Site Visit is HIGHLY RECOMMENDED, how ever, not mandatory. Please see Section L and FAR 52.236-27 for more information. Only one site visit w ill be conducted.

JEFF W. MORRIS 701-723-4171

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

29-Jan-2016

(RFP)

(IFB)

X

CALL:

MAF Cable Fence

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________365 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________29 Feb 2016 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______225 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

5 CONS

165 MISSILE AVENUE

MINOT AFB ND 58705-5027

FA4528

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

QJVF 07-6017

8. ADDRESS OFFER TO (If Other Than Item 7)

701-723-4173FAX:TEL: 701-723-2261 TEL: FAX:

FA4528-16-R-0002 49

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA4528-16-R-0002

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot Install MAF Anti Ram Fence

FFP

SERVICES NON-PERSONAL: The contractor will provide all plant, labor, material, tools, parts, equipment, and transportation to and from job site necessary to accomplish project QJVF 07-6017 in accordance with attached specifications and drawings. This installation will be at 15 different MAFs throughout the state of North Dakota.

Attachment 6 - Offeror Schedule shall be filled in and included with the proposal for the CLIN total.

FOB: Destination

NSN: Z1AZ-16-INS-FNCE

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.236-5 Material and Workmanship APR 1984 52.246-12 Inspection of Construction AUG 1996

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 365 dys. ADC 1 5 CONS

JEFF W. MORRIS

165 MISSILE AVENUE

MINOT AFB ND 58705-5027

701-723-4171 FOB: Destination

FA4528

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 365 days after issuance of notice to proceed.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $594.28 for the first calendar day and $553.90 for every calendar day thereafter of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.211-13 TIME EXTENSIONS (SEP 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting

Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly.

However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

Section G - Contract Administration Data

WAWF INSTRUCTIONS

WIDE AREA WORKFLOW (WAWF) INSTRUCTIONS (DEC 2011)

WAWF is a web-based tool for the electronic processing of invoices and receiving reports. The URL for WAWF is https://wawf.eb.mil. There are no charges to use WAWF. New users can obtain assistance with registration and system setup at the WAWF website under “New User”. If additional assistance is required contact the WAWF Help Desk at 866-618-5988 or email cscassig@csd.disa.mil.

Training for WAWF is available at https://wawftraining.eb.mil/. This is a web-based training tool that mirrors the WAWF production site. Be sure to review the Training Instructions prior to beginning the training course.

THE FOLLOWING INFORMATION WILL BE REQUIRED TO ROUTE YOUR INVOICES CORRECTLY

THROUGH WAWF.

When submitting an invoice in WAWF, pay particular attention to the type of invoice. Invoice types and coding used at Minot AFB are:

2 in 1Invoice Type DoDAAC = FA4528 Admn DoDAAC = FA4528

Inspect By DoDAAC = F3C3PG Service Acceptor “Ship To” Code = FA4528

The Pay Office DoDAAC is F87700

Contact email information will be provided by the contract administrator.

Additional information on Electronic Commerce is available at the Defense Finance and Accounting Service (DFAS) Electronic Commerce Tool Box website located at http://www.dfas.mil/contractorpay/electroniccommerce.html.

Questions concerning payment should be directed to the Customer Care section of the DFAS Limestone office at 866-724-0526. Please have your order number and invoice number ready when calling about payment status. If your paying office is other than Limestone, contact your Contract Administrator for the customer service phone numbers.

Should you need additional assistance with WAWF, contact your Contract Administrator.

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

Section I - Contract Clauses

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

APR 2014

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2015

52.204-13 System for Award Management Maintenance JUL 2013 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

DEC 2014

52.215-2 Audit and Records--Negotiation OCT 2010 52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.219-8 Utilization of Small Business Concerns OCT 2014 52.222-3 Convict Labor JUN 2003 52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity APR 2015 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-33 Notice of Requirement for Project labor Agreement MAY 2010 52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans OCT 2015

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2014 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-18 Availability Of Funds APR 1984 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts MAY 2014 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-1 Alt I Disputes (May 2014) - Alternate I DEC 1991 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.243-4 Changes JUN 2007 52.244-6 Subcontracts for Commercial Items OCT 2015 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2015

52.249-2 Alt I Termination for Convenience of the Government (Fixed- Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

AUG 2015

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting.

SEP 2015

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.223-7001 Hazard Warning Labels DEC 1991 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities FEB 2013 252.225-7048 Export-Controlled Items JUN 2013 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for

Military Operations

OCT 2010

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code - assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

4.4% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Minot Air Force Base, Ward County, North Dakota.

(End of provision)

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (JAN 1997)

(a) "Hazardous material", as used in this clause, includes any material defined as hazardous under the latest version of Federal Standard No. 313 (including revisions adopted during the term of the contract).

(b) The offeror must list any hazardous material, as defined in paragraph (a) of this clause, to be delivered under this contract. The hazardous material shall be properly identified and include any applicable identification number, such as National Stock Number or Special Item Number. This information shall also be included on the Material Safety Data Sheet submitted under this contract.

Material Identification No.

(If none, insert "None")

(c) This list must be updated during performance of the contract whenever the Contractor determines that any other material to be delivered under this contract is hazardous.

(d) The apparently successful offeror agrees to submit, for each item as required prior to award, a Material Safety Data Sheet, meeting the requirements of 29 CFR 1910.1200(g) and the latest version of Federal Standard No. 313, for all hazardous material identified in paragraph (b) of this clause. Data shall be submitted in accordance with Federal Standard No. 313, whether or not the apparently successful offeror is the actual manufacturer of these items.

Failure to submit the Material Safety Data Sheet prior to award may result in the apparently successful offeror being considered nonresponsible and ineligible for award.

(e) If, after award, there is a change in the composition of the item(s) or a revision to Federal Standard No. 313, which renders incomplete or inaccurate the data submitted under paragraph (d) of this clause, the Contractor shall promptly notify the Contracting Officer and resubmit the data.

(f) Neither the requirements of this clause nor any act or failure to act by the Government shall relieve the Contractor of any responsibility or liability for the safety of Government, Contractor, or subcontractor personnel or property.

(g) Nothing contained in this clause shall relieve the Contractor from complying with applicable Federal, State, and local laws, codes, ordinances, and regulations (including the obtaining of licenses and permits) in connection with hazardous material.

(h) The Government's rights in data furnished under this contract with respect to hazardous material are as follows:

(1) To use, duplicate and disclose any data to which this clause is applicable. The purposes of this right are to--

(i) Apprise personnel of the hazards to which they may be exposed in using, handling, packaging, transporting, or disposing of hazardous materials;

(ii) Obtain medical treatment for those affected by the material; and

(iii) Have others use, duplicate, and disclose the data for the Government for these purposes.

(2) To use, duplicate, and disclose data furnished under this clause, in accordance with subparagraph (h)(1) of this clause, in precedence over any other clause of this contract providing for rights in data.

(3) The Government is not precluded from using similar or identical data acquired from other sources.

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED ITEMS (MAY 2008)

(a) Definitions. As used in this clause--

Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall--

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to (Contracting Officer complete in accordance with agency procedures).

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: None

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Construction material description Unit of measure Quantity Price (dollars) \1\ Item 1 Foreign construction material.... ........... ___ ........ ....... ………. ___ ................ ........ ___ Domestic construction material... ........ ___ ............... .............. ___ .................. ...... ___ Item 2 Foreign construction material.... ......... ___ ............. ........ ……. ___ ............... ......... ___ Domestic construction material... ....... ___ .................. ............. ___ ................. ....... ___ Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

(a) “Irrevocable letter of credit” (ILC), as used in this clause, means a written commitment by a federally insured financial institution to pay all or part of a stated amount of money, until the expiration date of the letter, upon presentation by the Government (the beneficiary) of a written demand therefor. Neither the financial institution nor the offeror/Contractor can revoke or condition the letter of credit.

(b) If the offeror intends to use an ILC in lieu of a bid bond, or to secure other types of bonds such as performance and payment bonds, the letter of credit and letter of confirmation formats in paragraphs (e) and (f) of this clause shall be used.

(c) The letter of credit shall be irrevocable, shall require presentation of no document other than a written demand and the ILC (including confirming letter, if any), shall be issued/confirmed by an acceptable federally insured financial institution as provided in paragraph (d) of this clause, and--

(1) If used as a bid guarantee, the ILC shall expire no earlier than 60 days after the close of the bid acceptance period;

(2) If used as an alternative to corporate or individual sureties as security for a performance or payment bond, the offeror/Contractor may submit an ILC with an initial expiration date estimated to cover the entire period for which financial security is required or may submit an ILC with an initial expiration date that is a minimum period of one year from the date of issuance. The ILC shall provide that, unless the issuer provides the beneficiary written notice of non-renewal at least 60 days in advance of the current expiration date, the ILC is automatically extended without amendment for one year from the expiration date, or any future expiration date, until the period of required coverage is completed and the Contracting Officer provides the financial institution with a written statement waiving the right to payment. The period of required coverage shall be:

(i) For contracts subject to 40 U.S.C. chapter 31, subchapter III, Bonds, the later of--

(A) One year following the expected date of final payment;

(B) For performance bonds only, until completion of any warranty period; or

(C) For payment bonds only, until resolution of all claims filed against the payment bond during the one-year period following final payment.

(ii) For contracts not subject to the Miller Act, the later of--

(A) 90 days following final payment; or

(B) For performance bonds only, until completion of any warranty period.

(d)(1) Only federally insured financial institutions rated investment grade by a commercial rating service shall issue or confirm the ILC.

(2) Unless the financial institution issuing the ILC had letter of credit business of at least $25 million in the past year, ILCs over $5 million must be confirmed by another acceptable financial institution that had letter of credit business of at least $25 million in the past year.

(3) The Offeror/Contractor shall provide the Contracting Officer a credit rating that indicates the financial institutions have the required credit rating as of the date of issuance of the ILC.

(4) The current rating for a financial institution is available through any of the following rating services registered with the U.S. Securities and Exchange Commission (SEC) as a Nationally Recognized Statistical Rating Organization (NRSRO). NRSRO's can be located at the Web site http://www.sec.gov/answers/nrsro.htm maintained by the SEC.

(e) The following format shall be used by the issuing financial institution to create an ILC:

[Issuing Financial Institution's Letterhead or Name and Address]

Issue Date _ ___

IRREVOCABLE LETTER OF CREDIT NO. ___

Account party's name ___ _

Account party's address ___ _

For Solicitation No. ___ _(for reference only)

TO: [ ___ U.S. Government agency]

[ ___ U.S. Government agency's address]

1. We hereby establish this irrevocable and transferable Letter of Credit in your favor for one or more drawings up to United States $ ___ . This Letter of Credit is payable at [issuing financial institution's and, if any, confirming financial institution's] office at [ ___ issuing financial institution's address and, if any, confirming financial institution's address] and expires with our close of business on ___ , or any automatically extended expiration date.

2. We hereby undertake to honor your or the transferee's sight draft(s) drawn on the issuing or, if any, the confirming financial institution, for all or any part of this credit if presented with this Letter of Credit and confirmation, if any, at the office specified in paragraph 1 of this Letter of Credit on or before the expiration date or any automatically extended expiration date.

3. [This paragraph is omitted if used as a bid guarantee, and subsequent paragraphs are renumbered.] It is a condition of this Letter of Credit that it is deemed to be automatically extended without amendment for one year from the expiration date hereof, or any future expiration date, unless at least 60 days prior to any expiration date, we notify you or the transferee by registered mail, or other receipted means of delivery, that we elect not to consider this Letter of Credit renewed for any such additional period. At the time we notify you, we also agree to notify the account party (and confirming financial institution, if any) by the same means of delivery.

4. This Letter of Credit is transferable. Transfers and assignments of proceeds are to be effected without charge to either the beneficiary or the transferee/assignee of proceeds. Such transfer or assignment shall be only at the written direction of the Government (the beneficiary) in a form satisfactory to the issuing financial institution and the confirming financial institution, if any.

5. This Letter of Credit is subject to the Uniform Customs and Practice (UCP) for Documentary Credits, International Chamber of Commerce Publication No. ___ -- (Insert version in effect at the time of ILC issuance, e.g., ``Publication 600, 2006 edition'') and to the extent not inconsistent therewith, to the laws of ___ --[State of confirming financial institution, if any, otherwise State of issuing financial institution].

6. If this credit expires during an interruption of business of this financial institution as described in Article 17 of the UCP, the financial institution specifically agrees to effect payment if this credit is drawn against within 30 days after the resumption of our business.

Sincerely, [ ___ Issuing financial institution]

(f) The following format shall be used by the financial institution to confirm an ILC:

___ [Confirming Financial Institution's Letterhead or Name and Address]

(Date) ___

Our Letter of Credit Advice Number ___

Beneficiary: ___ [U.S. Government agency]

Issuing Financial Institution: ___

Issuing Financial Institution's LC No.: ___

Gentlemen:

1. We hereby confirm the above indicated Letter of Credit, the original of which is attached, issued by ___ [name of issuing financial institution] for drawings of up to United States dollars ___ _/U.S. $ ___ and expiring with our close of business on ___ [the expiration date], or any automatically extended expiration date.

2. Draft(s) drawn under the Letter of Credit and this Confirmation are payable at our office located at ___ _.

3. We hereby undertake to honor sight draft(s) drawn under and presented with the Letter of Credit and this Confirmation at our offices as specified herein.

4. [This paragraph is omitted if used as a bid guarantee, and subsequent paragraphs are renumbered.] It is a condition of this confirmation that it be deemed automatically extended without amendment for one year from the expiration date hereof, or any automatically extended expiration date, unless:

(a) At least 60 days prior to any such expiration date, we shall notify the Contracting Officer, or the transferee and the issuing financial institution, by registered mail or other receipted means of delivery, that we elect not to consider…