Solc_-FA4418-15-R-0018_-_WS.doc

Section A - Solicitation/Contract Form

SECTION A

SPECIAL INFORMATION AND INSTRUCTIONS TO ALL INTERESTED CONTRACTORS:

IT SHALL BE THE RESPONSIBILITY OF THE CONTRACTOR TO ENSURE THEY CHECK THE WWW.FBO.GOV WEB SITE FOR ANY AMENDMENTS TO THE SOLICITATION. YOU ARE ENCOURAGED TO REGISTER ON THE WWW.FBO.GOV WEB SITE TO RECEIVE NOTIFICATION OF CHANGES TO THE SOLICITATION. FAILURE TO ACKNOWLEDGE AMENDMENTS MAY RENDER YOUR PROPOSAL NONRESPONSIVE.

1. The following items represent the “Offer”, or proposal package, that should be returned in response to this solicitation (See Section L & M of the solicitation):

a. SF 1442, Solicitation, Offer, and Award

b. The Schedule, Section B

c. Cmplete the necessary fill-ins and certifications in Sections I through K. Section K shall be returned in its entirety. For Section I, the offeror shall submit only those pages that require a fill-in.

d. Sub-contracting Plan (if required)

e. Past Performance Information

f. SF 30, Amendment of Solicitation/Modification of Contract (applicable if amendments are not acknowledged on page 2 (reverse) of SF 1442)

g. Standard Form 24, Proposal Bond

2. PRE-PROPOSAL CONFERENCE/SITE VISIT:

a. A pre-proposal conference and site visit is scheduled for 12 Aug 2015 at 9:00 AM EST. Everyone will meet at PASS and ID WEAPONS STATION, 1650 Redbank Road, Building 3, Goose Creek, SC 29445. A government van will transport all to the conference/site visit. Offerors are encouraged to attend and are requested to contact Doris Peeples, Contract Specialist, at (843) 963-4498, fax number (843) 963-2829, or e-mail at doris.peeples@us.af.mil at least seven (7) days prior to the conference date if they plan to attend. Special arrangements will be required to gain access to Joint Base Charleston, SC. Offerors are cautioned that Joint Base Charleston has visitor control procedures requiring individuals not affiliated with the installation to obtain a visitor pass prior to entrance. SOME DELAYS SHOULD BE ANTICIPATED. Offerors should allow sufficient time to obtain a visitor pass (requiring valid driver’s license, vehicle registration, and current proof of insurance).

b. The purpose of this conference is to visit the construction site, clarify the statement of work and terms of the solicitation, and to answer any questions concerning the solicitation. Offerors are requested to prepare all questions in writing prior to the scheduled date of the conference. Submission of questions prior to the conference is encouraged.

The deadline for all questions pertaining to this solictation will be 19 Aug 2015 at 3:00 PM EST.

c. Remarks and explanations provided at the conference shall NOT qualify the terms of the solicitation and statement of work. Unless the solicitation is amended in writing, it will remain unchanged. Should an amendment be issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

(End Section A)

Section B - Supplies or Services and Prices

Base Bid -Upgrade Primary Elec Sv, NSide

FFP

All work as required by drawings and specifications for Project DKGV 11-2192 Upgrade Primary Service, Northside for buildings connected to existing 4.16kV Industrial feeder. Work to the 4.16kV system includes replacing equipment, overhead primary, and overhead secondary supply conductors with a new underground utility system. Work includes replacing electrical service entrance equipment inside existing buildings. Work includes all electrical, concrete, trenching, directional drilling, and site work. This excludes all buildings currently connected to 13.8kV feeder(Buildings 1662,1681, 456, 458, 459, 461, 863, and 864) and associated transformers, underground feeders, and secondary distribution systems required to upgrade the electrical utility to these buildings.

FOB: Destination

NET AMT

Repairs - Building 1662

All work as required by drawings and specifications for Project DKGV 11-2192 - Upgrade the existing electrical utilities feeding building 1662. This includes but not limited to replacing existing transformers, underground primary from transformer to overhead pole, and associated service entrance equipment.

NET AMT

Repairs - Building 1681

All work as required by drawings and specifications for Project DKGV 11-2192 - Upgrade the existing electrical utilities feeding building 1681. This includes but not limited to replacing existing transformers, underground primary from transformer to overhead pole, and associated service entrance equipment.

NET AMT

Repairs - Building 456

All work as required by drawings and specifications for Project DKGV 11-2192 - Upgrade the existing electrical utilities feeding building 456. This includes but not limited to replacing existing transformers, underground primary from transformer to overhead pole, and associated service entrance equipment

NET AMT

Repairs - Building 458

All work as required by drawings and specifications for Project DKGV 11-2192 - Upgrade the existing electrical utilities feeding building 458. This includes but not limited to replacing existing transformers, underground primary from transformer to overhead pole, and associated service entrance equipment

NET AMT

Repairs - Building 459

All work as required by drawings and specifications for Project DKGV 11-2192 - Upgrade the existing electrical utilities feeding building 459. This includes but not limited to replacing existing transformers, underground primary from transformer to overhead pole, and associated service entrance equipment

NET AMT

Repairs - Building 461

All work as required by drawings and specifications for Project DKGV 11-2192 - Upgrade the existing electrical utilities feeding building 461. This includes but not limited to replacing existing transformers, underground primary from transformer to overhead pole, and associated service entrance equipment

NET AMT

Repairs - Building 863

All work as required by drawings and specifications for Project DKGV 11-2192 - Upgrade the existing electrical utilities feeding building 863. This includes but not limited to replacing existing transformers, underground primary from transformer to overhead pole, and associated service entrance equipment

NET AMT

Repairs - Building 864

All work as required by drawings and specifications for Project DKGV 11-2192 - Upgrade the existing electrical utilities feeding building 864. This includes but not limited to replacing existing transformers, underground primary from transformer to overhead pole, and associated service entrance equipment

NET AMT

TOTAL

TOTAL LINE ITEMS 0001 – 0009 _____________________________

Section C - Descriptions and Specifications

SECTION C

ATTACHMENT

DESCRIPTION

DATE

SPECIFICATIONS 358 Pages July 10, 2015

DRAWINGS

75 SHEETS

July 10, 2015

PERFORMANCE AND PAYMENT BOND REQUIREMENTS

(IAW FAR 28.101-2 and FAR 28.102-3)

PROPOSAL BOND: The offeror shall submit a Proposal Bond (Standard Form 24) with good and sufficient surety or sureties acceptable to the Government. Proposal Bond, in the amount of 20 percent (20%) of the proposal price. The Proposal Bond penalty may be expressed in terms of a percentage of the proposal price or may be expressed in dollars and cents.

The contractor shall submit a Performance Bond (Standard Form 25) and a Payment Bond (Standard Form 25-A) with good and sufficient surety and sureties to the Government within 15 days of award. The penal sum of such bonds will be as follows:

a.

PERFORMANCE BOND: The penal sum of the performance bonds shall equal one hundred percent (100%) of the contract price.

b.

PAYMENT BOND: The penal sum of the payment bonds shall equal one hundred percent (100%) of the contract price.

BUSINESS LICENSE TAX - SOUTH CAROLINA

In accordance with Contract Clause entitled, "Federal, State and Local Taxes" dated APR 2003/FAR 52.229-3 incorporated by reference, be advised that the Cities of North Charleston, South Carolina and/or Goose Creek South Carolina imposes a business license tax on all contract work within the cities of North Charleston, South Carolina and/or Goose Creek South Carolina. The cities interpret this to include contractors performing work for the United States government within the limits of North Charleston and/or Goose Creek. Joint Base Charleston – Air Base is included within the City of North Charleston, South Carolina and Joint Base Charleston – Weapons Station is included within the city limits of Goose Creek. The cost of the license is proportional to the dollar amount of work being executed. Information for the North Charleston City Tax may be obtained by calling 843-740-2632, and for the Goose Creek City Tax by calling 843-797-6220.

PKI CERTIFICATE FOR PAST PERFORMANCE EVALUATION

Past Performance Evaluations are required on all completed DoD construction contracts. These evaluations are used in past performance evaluations conducted on your future proposals. The evaluations are placed in a computer database called Contractor Performance Assessment Reporting System (CPARS). This system requires the contractor to include their comments in their evaluation. In order to access the system, it is required that you obtain a PKI (Public Key Infrastructure) certificate. A PKI certificate is software which is purchased from an approved commercial vendor and installed on your computer. Approved vendors are listed at https://www.cpars.csd.disa.mil/main/pki_info.htm under the heading “Approved ECA Vendors”. You will be required to purchase an “Identity Certificate” to access the CPARS system or the Past Performance Information Report System (PPIRS), which will contain all past performance evaluations for your firm for any DoD contracts. The average cost for a PKI certificate is about $100 - $120 per certificate, per year.

REQUIRED INSURANCE (IAW FAR 28.306 (b))

Reference FAR clause 52.228-5 entitled “Insurance…” the Contractor shall, as its own expense, procure and thereafter maintain the following kinds of insurance with respect to performance under the contract.

Workman’s Compensation and Employers Liability Insurance as required by law except that if this contract is to be performed in a state which does not require or permit private insurance, then compliance with the statutory or administrative requirements in any such state will be satisfactory. The required Workman’s Compensation Insurance shall extend to cover employer’s liability for accidental bodily injury or death and for occupational disease with a minimum liability of $100,000.

General Liability Insurance. Bodily injury liability insurance, in the minimum limits of $500,000 per occurrence shall be required on the comprehensive form of policy.

Automobile Liability Insurance. The insurance shall be required on the comprehensive form of policy and shall provide bodily liability injury and property damage liability covering the operation of all automobiles used in connection with the performance of this contract. At least the minimum amount of $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage shall be required.

CONTRACTOR CONSENT TO BACKGROUND CHECKS

The contractor and, as applicable, subcontractor shall not employ persons for work on this contract if such employee is identified as a potential threat to the health, safety, security, general well being or operational mission of the installation and its population, nor shall the contractor or subcontractor employ persons under this contract who have an outstanding criminal warrant, are currently on probation or parole, or are on the state/national Sex Offender Register as identified by south Carolina Law Enforcement Division (SLED)/National Crime Information Center (NCIC). All contractor and subcontractor personnel must consent to NCIC criminal history background checks. Contractor and subcontractor personnel who do not consent to an NCIC check will be denied access to the installation. Information required to conduct an NCIC check includes: full name, driver’s license number, social security number, date of birth of the person entering the installation. The contractor shall provide this information using the 628 SFS/JBCHS – WS Form 74, “Application for Personnel to Work under Department of Defense Contract at Joint Base Charleston”, and shall submit it in conjunction with the contractor’s request for either base or vehicle passes. Completion of a successful NCIC check does not invalidate the requirement for an escort when contractor or subcontractor personnel are working within controlled or restricted areas. Contractors shall ensure their employees and those of their subcontracts have the proper credentials allowing them to work in the United States. Persons later found to be undocumented or illegal aliens will be remanded to the proper authorities. The contractor shall not be entitled to any compensation for delays or expenses associated with complying with the provisions of this provision. Furthermore, nothing in this provision shall excuse the contractor from proceeding with the contract as required.

Badges - Contractors and subcontractors shall submit the completed and approved JBCHS-WS Form 74, “Application for Personnel to Work Under Department of Defense Contract at Joint Base Charleston” prior to planning to work. Upon completion of the background check, the employee will report to the installation entry control center, with a photo identification issued by a Federal/State activity, for receipt of a badge with a designation of the area of the base he will be allowed access. Badges will be worn in a visible manner to government personnel at all times. At the conclusion of work for the prime contractor and any subcontractor, all badges will be turned in to the entry control center.

Contractor Registration of Vehicles on Joint Base Charleston - All contractor or contractor employees’ vehicles used for the performance of this contract shall comply with all local, state and federal regulations. To register a privately owned/commercial vehicle and obtain a vehicle pass, contractor personnel shall provide a valid driver’s license, current vehicle registration, and valid vehicle insurance certificate. Additionally, any pass shall be surrendered to Security Forces upon demand to positively identify a person’s need to be on Joint Base Charleston.

Access to Installation During Force Protection Conditions (FPCONs) -

Contractors will be assigned a mission essential designation IAW requirements contained in JBCIDP 31-1, Installation Security Instruction. Only the installation commander or the unit commander requesting contract support will assign the mission essential designation.

Contractors Working in Controlled or Restricted Areas - The unit requesting contract support will provide escort (s) for contractors’ at all times when within a controlled area. Contractors shall not escort other contractor employees within controlled or restricted areas. In addition, contractors shall fulfill, maintain, and comply with all security requirements IAW AFI 31-101, The Air Force Installation Security Program, and command/local directives.

Contractors Responsibilities while Working within Controlled or Restricted Areas - Only contractor personnel with proper authority and qualifications shall enter a controlled or restricted area. Certain facilities require the issuance of an AF Form 1199 or AF Form 1199CD. The government, at any time, may revoke the AF Form 1199. The procedures for the issuance of an AF Form 1199CD are contained in JBCIDP 31-1, Installation Security Instruction. Contractors shall not escort other contractor employees within controlled or restricted areas. In addition, contractors shall fulfill, maintain, and comply with all security requirements contained in JBCIDP 31-1, Installation Security Instruction.

Access To Government Facilities with Controlled or Restricted Areas -tc "5.1.2. Access to Government Facilities"The contractor shall comply with security regulations imposed by the installation commander and/or the agency responsible for the project location. Due to specific mission requirements inherent in the nature of controlled or restricted areas on Joint Base Charleston, the government may direct the contractor to leave the controlled or restricted areas at any given time.

FORCE PROTECTION CONDITIONS

Force Protection Conditions (FPCON) are implemented on the base to increase protective measures in anticipation of, or in response to, the threat of terrorist attack. The DoD FPCON consists of five progressive levels of increasing protective measures. The circumstances that apply and the purposes of each protective posture are as follows:

FPCON NORMAL: Applies when a general global threat of possible terrorist activity exists and warrants a routine security posture. At a minimum, access control will be conducted at all DoD installations and facilities.

FPCON ALPHA: Applies when there is an increased general threat of possible terrorist activity against personnel or facilities, and the nature and extent of the threat are unpredictable. ALPHA measures must be capable of being maintained indefinitely.

FPCON BRAVO: Applies when an increased or more predictable threat of terrorist activity exists. Sustaining BRAVO measures for a prolonged period may affect operational capability and military-civil relationships with local authorities.

FPCON CHARLIE: Applies when an incident occurs or intelligence is received indicating some form of terrorist action or targeting against personnel or facilities is likely.

Prolonged implementation of CHARLIE measures may create hardship and affect the activities of the unit and its personnel.

FPCON DELTA: Applies in the immediate area where a terrorist attack has occurred or when intelligence has been received that terrorist action against a specific location or person is imminent. This FPCON is usually declared as a localized condition. FPCON DELTA measures are not intended to be sustained for an extended duration.

GREEN PROCUREMENT

The Green Procurement Program (GPP) is a mandatory federal acquisition program that focuses on the purchase and use of environmentally preferable products and services. Many different items are covered by the GPP. Recycled-content products are designated by the Environmental Protection Agency (EPA). “Biobased” products made from renewable plant materials are designated by the Department of Agriculture (USDA). Energy and water efficient products are designated by the Department of Energy (DOE). GPP also requires us to avoid purchasing Ozone Depleting Substances (ODS) and EPA-designated Priority Chemicals. Environmentally preferable purchasing (EPP) is a voluntary program, and it encourages the purchase of goods and services that have decreased effects on human health and the environment (compared to the competing goods and serve the same purpose), but are not already required by one of the mandatory GPP elements.

The Environmental Protection Agency (EPA) promulgates this product information via the Federal Register and the World Wide Web/Internet http://www.epa.gov/cpg/products/htm. Green Procurement is mandated, except when the Contractor can show that the product with recycled content does not meet intended specifications, has excessive cost, or cannot be delivered in time to support the schedule of the contract. If the Contractor is unable to locate a specified product meeting the GPP requirement, identify the issue to the Contracting Officer’s Technical Representative for guidance. GPP is based on legal requirements and the Department of Defense facilities are subject to enforcement action if these requirements are ignored.

(END SECTION C)

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLAUSES INCORPORATED BY REFERENCE

Section F - Deliveries or Performance

DELIVERY INFORMATION

JACKIE SHOKES

BUILDING 5 NAVAL WEAPONS STATION

GOOSE CREEK SC 29445

843-794-4326

F1M3E2

F1M3E2

F1M3E2

F1M3E2

F1M3E2

F1M3E2

F1M3E2

F1M3E2

F1M3E2

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 340 calendar days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $222.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

Section G - Contract Administration Data

CLAUSES INCORPORATED BY FULL TEXT

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through

WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

COMBO

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

F1M3E2

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable”.)

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF

Data to be entered in WAWF

Pay Official DoDAAC

F87700

Issue By DoDAAC

FA4418

Admin DoDAAC

FA4418

Inspect By DoDAAC

F1M3E2

Ship To Code

Ship From Code

Not Applicable

Mark For Code

Service Approver (DoDAAC)

Not Applicable

Service Acceptor (DoDAAC)

Accept at Other DoDAAC

LPO DoDAAC

DCAA Auditor DoDAAC

Other DoDAAC(s)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

Doris.peeples@us.af.mil Cheryl.Bennett@us.af.mil

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Doris.peeples@us.af.mil

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) The Contractor shall update the information in the Federal Awardee Performance and Integrity Information System (FAPIIS) on a semi-annual basis, throughout the life of the contract, by posting the required information in the System for Award Management database via https://www.acquisition.gov.

(b) As required by section 3010 of the Supplemental Appropriations Act, 2010 (Pub. L. 111-212), all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available. FAPIIS consists of two segments--

(1) The non-public segment, into which Government officials and the Contractor post information, which can only be viewed by--

(i) Government personnel and authorized users performing business on behalf of the Government; or

(ii) The Contractor, when viewing data on itself; and

(2) The publicly-available segment, to which all data in the non-public segment of FAPIIS is automatically transferred after a waiting period of 14 calendar days, except for--

(i) Past performance reviews required by subpart 42.15;

(ii) Information that was entered prior to April 15, 2011; or

(iii) Information that is withdrawn during the 14-calendar-day waiting period by the Government official who posted it in accordance with paragraph (c)(1) of this clause.

(c) The Contractor will receive notification when the Government posts new information to the Contractor's record.

(1) If the Contractor asserts in writing within 7 calendar days, to the Government official who posted the information, that some of the information posted to the non-public segment of FAPIIS is covered by a disclosure exemption under the Freedom of Information Act, the Government official who posted the information must within 7 calendar days remove the posting from FAPIIS and resolve the issue in accordance with agency Freedom of Information procedures, prior to reposting the releasable information. The contractor must cite 52.209-9 and request removal within 7 calendar days of the posting to FAPIIS.

(2) The Contractor will also have an opportunity to post comments regarding information that has been posted by the Government. The comments will be retained as long as the associated information is retained, i.e., for a total period of 6 years. Contractor comments will remain a part of the record unless the Contractor revises them.

(3) As required by section 3010 of Pub. L. 111-212, all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available.

(d) Public requests for system information posted prior to April 15, 2011, will be handled under Freedom of Information Act procedures, including, where appropriate, procedures promulgated under E.O. 12600.

(End of clause)

52.222-99 ESTABLISHING A MINIMUM WAGE FOR CONTRACTORS (DEVIATION 2014-O0017) (JUNE 2014)

This clause implements Executive Order 13658, Establishing a Minimum Wage for Contractors, dated February 12, 2014, and OMB Policy Memorandum M-14-09, dated June 12, 2014.

(a) Each service employee, laborer, or mechanic employed in the United States (the 50 States and the District of Columbia) in the performance of this contract by the prime Contractor or any subcontractor, regardless of any contractual relationship which may be alleged to exist between the Contractor and service employee, laborer, or mechanic, shall be paid not less than the applicable minimum wage under Executive Order 13658. The minimum wage required to be paid to each service employee, laborer, or mechanic performing work on this contract between January 1, 2015, and December 31, 2015, shall be $10.10 per hour.

(b) The Contractor shall adjust the minimum wage paid under this contract each time the Secretary of Labor’s annual determination of the applicable minimum wage under section 2(a)(ii) of Executive Order 13658 results in a higher minimum wage. Adjustments to the Executive Order minimum wage under section 2(a)(ii) of Executive Order 13658 will be effective for all service employees, laborers, or mechanics subject to the Executive Order beginning January 1 of the following year. The Secretary of Labor will publish annual determinations in the Federal Register no later than 90 days before such new wage is to take effect. The Secretary will also publish the applicable minimum wage on www.wdol.gov (or any successor website). The applicable published minimum wage is incorporated by reference into this contract.

(c) The Contracting Officer will adjust the contract price or contract unit price under this clause only for the increase in labor costs resulting from the annual inflation increases in the Executive Order 13658 minimum wage beginning on January 1, 2016. The Contracting Officer shall consider documentation as to the specific costs and workers impacted in determining the amount of the adjustment.

(d) The Contractor Officer will not adjust the contract price under this clause for any costs other than those identified in paragraph (c) of this clause, and will not provide price adjustments under this clause that result in duplicate price adjustments with the respective clause of this contract implementing the Service Contract Labor Standards statute (formerly known as the Service Contract Act) or the Wage Rate Requirements (Construction) statute (formerly known as the Davis Bacon Act).

(e) The Contractor shall include the substance of this clause, including this paragraph (e) in all subcontracts.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil (End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Department of Defense Federal Acquisition Regulation Supplement (48 CFR Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

252.204-7006 BILLING INSTRUCTIONS (OCT 2005)

When submitting a request for payment, the Contractor shall--

(a) Identify the contract line item(s) on the payment request that reasonably reflect contract work performance; and

(b) Separately identify a payment amount for each contract line item included in the payment request.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

UPGRADE PRIMARY ELECTRICAL SERVICE, NORTHSIDE Project No. DKGV 11-2192

DWG G101 Index of Drawings (End of clause)

5352.201-9101 OMBUDSMAN (1 APR 2014)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the ombudsman, Mr. Gregg Oneal, AFICA/KM, 507 Symington Dr., Scott AFB, IL, 62225-5022, (618) 229-0267, fax (618) 256-6668, email: gregory.oneal@us.af.mil.. Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center/MAJCOM/DRU/HQ AFICA/SMC ombudsman level, may be brought by the interested party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (571) 256-2395, facsimile number (571) 256-2431.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

(End of clause) 5352.223-9000 ELIMINATION OF USE OF CLASS I OZONE DEPLETING SUBSTANCES (ODS) (NOV 2012)

(a) Contractors shall not:

(1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS as part of this contract/order.

[Note: This prohibition does not apply to manufacturing.]

(b) For the purposes of Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32-7086) are Class I ODSs:

(1) Halons: 1011, 1202, 1211, 1301, and 2402;

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-215, CFC-216, and CFC-217, and the blends R-500, R-501, R-502, and R-503; and

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

[NOTE: Material that uses one or more of these Class I ODSs as minor constituents do not meet the Air Force definition of a Class I ODS.]

5352.242-9000 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (NOV 2012)

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or Security Forces for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver’s license, current vehicle registration, valid vehicle insurance certificate, and JB CHS-AB/WS contract Security Worksheet for Base Access to obtain a vehicle pass.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(d) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with Joint Base Charleston Integrated Defense Plan 31-1, Contractor Access Control Program AFI 31-101 and AFI 31-501, Personnel Security Program Management.

(e) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(f) Failure to comply with these requirements may result in withholding of final payment.

Section J - List of Documents, Exhibits and Other Attachments

LIST OF DOCUMENTS /ATTACHMENT

ATTACHMENT

DESCRIPTION

PAGES

DATED

Specifications 358 Pages 7/10/2015

Drawings 75 Pages 7/10/2015

Material Submittal

(AF Form 66) 7 Pages

Green Procurement Form

2 Pages

Wage Determination

5/22/2015

(Berkeley County) SC150029 Section K - Representations, Certifications and Other Statements of Offerors

CLAUSES INCORPORATED BY REFERENCE

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (DEC 2014)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237130.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at…