Draft Solicitation - FA821324RB012.pdf

SECTION

15A. NAME AND

ADDRESS

OF OFFEROR

SOLICITATION, OFFER, AND AWARD 1. This Contract is a Rated Order under the Defense Priorities and Allocations System (DPAS) - Code of Federal Regulations - at 15 CFR 700.

RATING PAGE OF PAGES

2. CONTRACT NUMBER 3. SOLICITATION NUMBER 4. TYPE OF SOLICITATION 5. DATE ISSUED 6. REQUISITION/PURCHASE NUMBER

CODE7. ISSUED BY 8. ADDRESS OFFER TO (If other than item 7)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

9. Sealed offers in original and copies for furnishings the supplies or services in the Schedule will be received at the place specified in item 8, or if hand carried, in the depository located in until local time

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision Number 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR

INFORMATION

CALL:

A. NAME B. TELEPHONE (NO COLLECT CALLS)

AREA CODE NUMBER EXTENSION

C. EMAIL ADDRESS

11. TABLE OF CONTENTS

(X) DESCRIPTION PAGE(S) (X) SECTION PAGE(S)DESCRIPTION

A B C D E F G H

I

J

K

L

M EVALUATION FACTORS FOR AWARD

INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

REPRESENTATIONS, CERTIFICATIONS AND OTHER

STATEMENTS OF OFFERORS

PART IV - REPRESENTATIONS AND INSTRUCTIONS

LIST OF ATTACHMENTS

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

CONTRACT CLAUSESSOLICITATION/CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/COSTS

DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

PACKAGING AND MARKING

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

CONTRACT ADMINISTRATION DATA

SPECIAL CONTRACT REQUIREMENTS

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

OFFER (Must be fully completed by offeror)

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause Number 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the SOLICITATION for offerors and related documents numbered and dated):

10 CALENDAR DAYS (%) 20 CALENDAR DAYS (%) 30 CALENDAR DAYS (%) CALENDAR DAYS (%)

DATEAMENDMENT NUMBERAMENDMENT NUMBER DATE

CODE FACILITY 16. NAME AND THE TITLE OF PERSON AUTHORIZED TO SIGN OFFER

(Type or print)

15B. TELEPHONE NUMBER

AREA CODE NUMBER EXTENSION

15C. CHECK IF REMITTANCE ADDRESS IS

DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

17. SIGNATURE 18. OFFER DATE

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL OPEN COMPETITION UNDER THE

UNITED STATES CODE AT:

10 U.S.C. 3204(a) ( )41 U.S.C. 3304(a)

24. ADMINISTERED BY (If other than Item 7)

26. NAME OF CONTRACTING OFFICER (Type or print)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition is unusable

23. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

25. PAYMENT WILL BE MADE BY

27. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

28. AWARD DATE

CODE

ITEM

STANDARD FORM 33 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.214 (c)

SEALED BID (IFB) INVITATION FOR BID

NEGOTIATED (RFP) REQUEST FOR

PROPOSAL

(Hour) (Date)

PART I - THE SCHEDULE PART II - CONTRACT CLAUSES

Created On:

03 Sep 2024, 09:09 AM Central Daylight Time

Section A - Solicitation/Contract Form

BBU-48 Carts

Product Service Code: 1377 Date: 09 Aug 2024

FA821324RB012

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

This acquisition is limited to qualified sources: a qualification package is required for new sources. See FAR Clause 52.209-1 for qualification requirements. PROPOSALS FROM NON-QUALIFIED SOURSES WILL NOT BE CONSIDERED IF A QUALIFICATION PACKAGE IS NOT SUBMITTED AND ACCEPTED BY THE AIR FORCE ENGINEER PRIOR TO AWARD, CONTRACT AWARD WILL NOT BE DELAYED

FOR QUALIFICATION.

Qualified Sources: Valor Tactical Cage Code: 04099 and Decryptor Cage Code: 98K83

The government intends to award a contract to each successful offeror through a split-award of available funds; however, the government reserves the right to award no contract at all or winner-take-all; depending on the number of adequate proposals and reasonableness of prices submitted.

This acquisition will utilize buy-to-budget for USG funds under the authority of 10 USC 2308. FMS funds are anticipated to buy-to-quantity the amount listed in the BBU-48 Pricing Table.

First Article test articles are expended in testing. Contractor's invoice will be approved only after delivery and approval of the First Article Test Report.

Item Supplies / Services Quantity Unit Unit Price Amount

First Article Cartrige, Impulse BBU-48 A/B FIRST

ARTICLE REQUIRED

NSN: 1377-01-640-7205, P/N

8241124-50 BBU-48A/B First Article Testing

0001AA

First Article

FIRST ARTICLE TEST PLAN

FATP IAW DD 1423 B001 - attached at Exhibit C First Article Qualification Test Plan and Procedures

National Stock Number: 1377-01-640-7205 Product Service Code: 1377 Pricing Arrangement: Firm Fixed Price

1 Lot

0001AB

First Article Production Cartridge, Impulse BBU-48 A/B FIRST

ARTICLE

NSN: 1377-01-640-7205,

P/N8241124-50, BBU-48A/B First Article

AFMC 260

National Stock Number: 1377-01-640-7205 Product Service Code: 1377 Pricing Arrangement: Firm Fixed Price

96 Each

0001AC

FIRST ARTICLE TEST REPORT

FATR IAW DD 1423 C001 - attached at Exhibit B Delivery IAW DD 1423.

National Stock Number: 1377-01-640-7205 Product Service Code: 1377 Pricing Arrangement: Firm Fixed Price

1 Lot

Cartridge Production Cartridge, Impulse BBU-48 A/B

NSN: 1377-01-640-7205, P/N

8241124-50

0002AA

USAF Cartridge Production Cartridge, Impulse BBU-48 A/B

NSN: 1377-01-640-7205, P/N

8241124-50

Quantity: To Be Determined Unit Price: To Be Determined Offeror to fill out and submit BBU-48 Pricing Table Attachment Delivery: 12 Months ARO First Article Approval

National Stock Number: 1377-01-640-7205 Product Service Code: 1377 Pricing Arrangement: Firm Fixed Price

1 Each

0002AB

FMS Cartridge Production Cartridge, Impulse BBU-48 A/B

NSN: 1377-01-640-7205, P/N

8241124-50

Quantity: To Be Determined Unit Price: To Be Determined Offeror to fill out and submit BBU-48 Pricing Table Attachment Delivery: 12 Months ARO First Article Approval

National Stock Number: 1377-01-640-7205 Product Service Code: 1377 Pricing Arrangement: Firm Fixed Price

1 Each

DATA

DATA IAW DD 1423-1 IAW Attached Exhibit A Delivery and Inspection and Acceptance in accordance with DD1423.

National Stock Number: 1377-01-640-7205 Product Service Code: 1377 Pricing Arrangement: Firm Fixed Price

1 Lot

Section C - Description/Specifications/Statement of Work

The contractor shall perform in accordance with those specifications and/or the attachments listed in Section J:

Requirements Impulse Cartridge Production, BBU-48 A/B, P/N 8241124-50, NSN 1377016407205

Section D - Packaging and Marking

See attachment 016407205 - SPI

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.246-16 Responsibility for Supplies. Apr 1984

FAR Clauses Incorporated by Full Text

52.246-11 Higher-Level Contract Quality Requirement. (Dec 2014)

As prescribed in , insert the following clause:46.311

Higher-Level Contract Quality Requirement (Dec 2014)

The Contractor shall comply with the higher-level quality standard(s) listed below.(a)

___ISO 9001:2015 or equivalent

The Contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the (b) requirement to flow down such standards, as applicable, to lower-tier subcontracts, in-

Any subcontract for critical and complex items (see 46.203(b) and (c)); or(1)

When the technical requirements of a subcontract require-(2)

Control of such things as design, work operations, in-process control, testing, and inspection; or(i)

Attention to such factors as organization, planning, work instructions, documentation control, and advanced metrology.(ii)

(End of clause)

Overall Contract Inspection/Acceptance Locations

0001AA

Inspection and Acceptance Location

Both Destination Instructions: IAW 1423

DoDAAC: FA8213 CountryCode: USA

FA8213 AFLCMC EBHK

CP 801 586 8482, 6072 FIR AVE BLDG 1233

HILL AFB, UT 84056-5820

UNITED STATES

0001AB

Inspection and Acceptance Location

Both Source Instructions: IAW 1423

DoDAAC: FA8213 CountryCode: USA

FA8213 AFLCMC EBHK

CP 801 586 8482, 6072 FIR AVE BLDG 1233

HILL AFB, UT 84056-5820

UNITED STATES

0001AC

Party to receive Certified Inspection Report

Other

DoDAAC: FA8213 CountryCode: USA

FA8213 AFLCMC EBHK

CP 801 586 8482, 6072 FIR AVE BLDG 1233

HILL AFB, UT 84056-5820

UNITED STATES

0002AA

Party to receive Certified Inspection Report

Other

DoDAAC: FA8213 CountryCode: USA

FA8213 AFLCMC EBHK

CP 801 586 8482, 6072 FIR AVE BLDG 1233

HILL AFB, UT 84056-5820

UNITED STATES

0002AB

Party to receive Certified Inspection Report

Other

DoDAAC: FA8213 CountryCode: USA

FA8213 AFLCMC EBHK

CP 801 586 8482, 6072 FIR AVE BLDG 1233

HILL AFB, UT 84056-5820

UNITED STATES

Party to receive Certified Inspection Report

Other

DoDAAC: FA8213 CountryCode: USA

FA8213 AFLCMC EBHK

CP 801 586 8482, 6072 FIR AVE BLDG 1233

HILL AFB, UT 84056-5820

UNITED STATES

Section F - Deliveries or Performance

Ship To

Line Item Delivery Schedule Quantity Address and POC Special Handling/Notes

FoB Details Contractor Destination

0001AA

1 Lot FoB Details

Contractor Destination

0001AB

96 Each FoB Details

Contractor Other

0001AC

1 Lot FoB Details

Contractor Other

FoB Details Government Origin (Shipping Point)

0002AA

1 Each FoB Details

Government Origin (Shipping Point)

0002AB

1 Each FoB Details

Contractor Destination

1 Lot FoB Details

Contractor Other

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.211-17 Delivery of Excess Quantities. Sep 1989 52.242-17 Government Delay of Work. Apr 1984 52.247-29 F.o.b. Origin. Feb 2006 52.247-30 F.o.b. Origin, Contractor's Facility. Feb 2006 52.247-34 F.o.b. Destination. Nov 1991 52.247-65 F.o.b. Origin, Prepaid Freight-Small Package Shipments. Jan 1991

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.223-7003 Change in Place of Performance--Ammunition and Explosives. Dec 1991

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.204-7002 Payment for Contract Line or Subline Items Not Separately Priced. Apr 2020 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. (Jan 2023)

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) As used in this clause- Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as Electronic invoicing.

authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) To access WAWF, the Contractor shall- WAWF access.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice WAWF training.

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web entry, Electronic Data Interchange, or File Transfer WAWF methods of document submission.

Protocol.

(f) The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF payment instructions.

WAWF for this contract or task or delivery order:

(1) The Contractor shall submit payment requests using the following document type(s): Document type.

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

____See Schedule

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

____Invoice 2in1

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF Document routing.

when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC ____

Issue By DoDAAC FA8213____

Admin DoDAAC ____

Inspect By DoDAAC _See Schedule___

Ship To Code __See Schedule__

Ship From Code _See Schedule___

Mark For Code __See Schedule__

Service Approver (DoDAAC) _See Schedule___

Service Acceptor (DoDAAC) __See Schedule__

Accept at Other DoDAAC ___See Schedule_

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in Payment request.

accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. Receiving report.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section H - Special Contract Requirements

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.204-19 Incorporation by Reference of Representations and Certifications. Dec 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities.

Dec 2023

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

Nov 2021

52.204-27 Prohibition on a ByteDance Covered Application. Jun 2023 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. Nov 2015 52.211-5 Material Requirements. Aug 2000 52.211-15 Defense Priority and Allocation Requirements. Apr 2008 52.222-21 Prohibition of Segregated Facilities. Apr 2015 52.222-26 Equal Opportunity. Sep 2016 52.222-50 Combating Trafficking in Persons. Nov 2021 52.223-23 Sustainable Products and Services. May 2024 52.225-13 Restrictions on Certain Foreign Purchases. Feb 2021 52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving. May 2024 52.232-39 Unenforceability of Unauthorized Obligations. Jun 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. Mar 2023 52.233-1 Disputes. May 2014 52.233-3 Protest after Award. Aug 1996 52.233-4 Applicable Law for Breach of Contract Claim. Oct 2004 52.243-1 Changes-Fixed-Price. Aug 1987 52.244-6 Subcontracts for Commercial Products and Commercial Services. Feb 2024 52.246-26 Reporting Nonconforming Items. Nov 2021 52.247-15 Contractor Responsibility for Loading and Unloading. Apr 1984 52.247-68 Report of Shipment (REPSHIP). Feb 2006 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form). Apr 1984 52.253-1 Computer Generated Forms. Jan 1991

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. Dec 2022 252.204-7003 Control of Government Personnel Work Product. Apr 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. May 2024 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. Jan 2023

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

Jan 2023

252.204-7020 NIST SP 800-171 DoD Assessment Requirements. Nov 2023 252.204-7022 Expediting Contract Closeout. May 2021 252.223-7002 Safety Precautions for Ammunition and Explosives. Nov 2023 252.223-7008 Prohibition of Hexavalent Chromium. Jan 2023

252.225-7007 Prohibition on Acquisition of Certain Items from Communist Chinese Military Companies.

Dec 2018

252.225-7028 Exclusionary Policies and Practices of Foreign Governments. Apr 2003 252.225-7048 Export-Controlled Items. Jun 2013 252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime. Jan 2023 252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region. Jun 2023 252.232-7010 Levies on Contract Payments. Dec 2006 252.243-7001 Pricing of Contract Modifications. Dec 1991 252.244-7000 Subcontracts for Commercial Products or Commercial Services. Nov 2023 252.247-7023 Transportation of Supplies by Sea. Jan 2023

FAR Clauses Incorporated by Full Text

52.204-1 Approval of Contract. (Dec 1989)

As prescribed in , insert the following clause:4.103

Approval of Contract (Dec 1989)

This contract is subject to the written approval of and shall not be binding until so approved.__Contracting Officer__

(End of clause)

52.209-1 Qualification Requirements. (Feb 1995)

As prescribed in , insert the following clause:9.206-2

Qualification Requirements (Feb 1995)

. "Qualification requirement," as used in this clause, means a Government requirement for testing or other quality assurance (a) Definition demonstration that must be completed before award.

One or more qualification requirements apply to the supplies or services covered by this contract. For those supplies or services requiring (b) qualification, whether the covered product or service is an end item under this contract or simply a component of an end item, the product, manufacturer, or source must have demonstrated that it meets the standards prescribed for qualification before award of this contract. The product, manufacturer, or source must be qualified at the time of award whether or not the name of the product, manufacturer, or source is actually included on a qualified products list, qualified manufacturers list, or qualified bidders list. Offerors should contact the agency activity designated below to obtain all requirements that they or their products or services, or their subcontractors or their products or services, must satisfy to become qualified and to arrange for an opportunity to demonstrate their abilities to meet the standards specified for qualification.

(Name) _Ellis Swenson___

(Address) _ellis.swenson@us.af.mil___

If an offeror, manufacturer, source, product or service covered by a qualification requirement has already met the standards specified, the relevant (c) information noted below should be provided.

Offeror's Name ____

Manufacturer's Name____

Source's Name ____

Item Name ____

Service Identification ____

Test Number (to the extent known)____

Even though a product or service subject to a qualification requirement is not itself an end item under this contract, the product, manufacturer, or (d) source must nevertheless be qualified at the time of award of this contract. This is necessary whether the Contractor or a subcontractor will ultimately provide the product or service in question. If, after award, the Contracting Officer discovers that an applicable qualification requirement was not in fact met at the time of award, the Contracting Officer may either terminate this contract for default or allow performance to continue if adequate consideration is offered and the action is determined to be otherwise in the Government's best interests.

If an offeror, manufacturer, source, product or service has met the qualification requirement but is not yet on a qualified products list, qualified (e) manufacturers list, or qualified bidders list, the offeror must submit evidence of qualification prior to award of this contract. Unless determined to be in the Government's interest, award of this contract shall not be delayed to permit an offeror to submit evidence of qualification.

Any change in location or ownership of the plant where a previously qualified product or service was manufactured or performed requires (f) reevaluation of the qualification. Similarly, any change in location or ownership of a previously qualified manufacturer or source requires reevaluation of the qualification. The reevaluation must be accomplished before the date of award.

(End of provision)

52.209-3 First Article Approval-Contractor Testing. (Alternate I) (Sep 1989) Alternate I (Jan 1997)

Alternate I (Jan 1997). As prescribed in 9.308-1(a)(2) and (b)(2), add the following paragraph (i) to the basic clause:

(i) The Contractor shall produce both the first article and the production quantity at the same facility.

52.209-3 First Article Approval-Contractor Testing. (Sep 1989)

As prescribed in and (b), insert the following clause:9.308-1(a)

First Article Approval-Contractor Testing (Sept 1989)

[ ]Contracting Officer shall insert details

(a) The Contractor shall test unit(s) of Lot/Item as specified in this contract. At least calendar days before the beginning of _96___ 0001AB _14___ first article tests, the Contractor shall notify the Contracting Officer, in writing, of the time and location of the testing so that the Government may witness the tests.

(b) The Contractor shall submit the first article test report within calendar days from the date of this contract to marked "First _180___ __TBD__ Article Test Report: Contract No. , Lot/Item No. " Within calendar days after the Government receives _FA8213-25-X-XXXX___ _B001___ _30___ the test report, the Contracting Officer shall notify the Contractor, in writing, of the conditional approval, approval, or disapproval of the first article.

The notice of conditional approval or approval shall not relieve the Contractor from complying with all requirements of the specifications and all other terms and conditions of this contract. A notice of conditional approval shall state any further action required of the Contractor. A notice of disapproval shall cite reasons for the disapproval.

(c) If the first article is disapproved, the Contractor, upon Government request, shall repeat any or all first article tests. After each request for additional tests, the Contractor shall make any necessary changes, modifications, or repairs to the first article or select another first article for testing.

All costs related to these tests are to be borne by the Contractor, including any and all costs for additional tests following a disapproval. The Contractor shall then conduct the tests and deliver another report to the Government under the terms and conditions and within the time specified by the Government. The Government shall take action on this report within the time specified in paragraph (b) of this subsection. The Government reserves the right to require an equitable adjustment of the contract price for any extension of the delivery schedule, or for any additional costs to the Government related to these tests.

(d) If the Contractor fails to deliver any first article report on time, or the Contracting Officer disapproves any first article, the Contractor shall be deemed to have failed to make delivery within the meaning of the Default clause of this contract.

(e) Unless otherwise provided in the contract, and if the approved first article is not consumed or destroyed in testing, the Contractor may deliver the approved first article as part of the contract quantity if it meets all contract requirements for acceptance.

(f) If the Government does not act within the time specified in paragraph (b) or (c) of this subsection, the Contracting Officer shall, upon timely written request from the Contractor, equitably adjust under the changes clause of this contract the delivery or performance dates and/or the contract price, and any other contractual term affected by the delay.

(g) Before first article approval, the acquisition of materials or components for, or the commencement of production of, the balance of the contract quantity is at the sole risk of the Contractor. Before first article approval, the costs thereof shall not be allocable to this contract for (1) progress payments, or (2) termination settlements if the contract is terminated for the convenience of the Government.

(h) The Government may waive the requirement for first article approval test where supplies identical or similar to those called for in the schedule have been previously furnished by the offeror/contractor and have been accepted by the Government. The offeror/contractor may request a waiver.

(End of clause)

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. (Sep 2000)

As prescribed in 11.503(a), insert the following clause in solicitations and contracts:

Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $____ per calendar day of delay [Contracting Officer insert amount].

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(End of clause)

52.232-1 Payments. (Apr 1984)

As prescribed in 32.111(a)(1), insert the following clause, appropriately modified with respect to payment due date in accordance with agency regulations, in solicitations and contracts when a fixed-price supply contract, a fixed-price service contract, or a contract for nonregulated communication services is contemplated:

Payments (Apr 1984)

The Government shall pay the Contractor, upon the submission of proper invoices or vouchers, the prices stipulated in this contract for supplies delivered and accepted or services rendered and accepted, less any deductions provided in this contract. Unless otherwise specified in this contract, payment shall be made on partial deliveries accepted by the Government if-

(a) The amount due on the deliveries warrants it; or

(b) The Contractor requests it and the amount due on the deliveries is at least $1,000 or 50 percent of the total contract price.

(End of clause)

52.232-8 Discounts for Prompt Payment. (Feb 2002)

As prescribed in 32.111(b)(1), insert the following clause:

Discounts for Prompt Payment (Feb 2002)

(a) Discounts for prompt payment will not be considered in the evaluation of offers. However, any offered discount will form a part of the award, and will be taken if payment is made within the discount period indicated in the offer by the offeror. As an alternative to offering a discount for prompt payment in conjunction with the offer, offerors awarded contracts may include discounts for prompt payment on individual invoices.

(b) In connection with any discount offered for prompt payment, time shall be computed from the date of the invoice. If the Contractor has not placed a date on the invoice, the due date shall be calculated from the date the designated billing office receives a proper invoice, provided the agency annotates such invoice with the date of receipt at the time of receipt. For the purpose of computing the discount earned, payment shall be considered to have been made on the date that appears on the payment check or, for an electronic funds transfer, the specified payment date. When the discount date falls on a Saturday, Sunday, or legal holiday when Federal Government offices are closed and Government business is not expected to be conducted, payment may be made on the following business day.

(End of clause)

52.232-11 Extras. (Apr 1984)

As prescribed in 32.111(c)(2), insert the following clause, appropriately modified with respect to payment due dates in accordance with agency regulations, in solicitations and contracts when a fixed-price supply contract, fixed-price service contract, or transportation contract is contemplated:

Extras (Apr 1984)

Except as otherwise provided in this contract, no payment for extras shall be made unless such extras and the price therefor have been authorized in writing by the Contracting Officer.

(End of clause)

52.232-25 Prompt Payment. (Jan 2017)

As prescribed in 32.908(c), insert the following clause:

Prompt Payment (Jan 2017)

Notwithstanding any other payment clause in this contract, the Government will make invoice payments under the terms and conditions specified in this clause. The Government considers payment as being made on the day a check is dated or the date of an electronic funds transfer (EFT).

Definitions of pertinent terms are set forth in sections 2.101, 32.001, and 32.902 of the Federal Acquisition Regulation. All days referred to in this clause are calendar days, unless otherwise specified. (However, see paragraph (a)(4) of this clause concerning payments due on Saturdays, Sundays, and legal holidays.)

(a) Invoice payments-

(1) Due date.

(i) Except as indicated in paragraphs (a)(2) and (c) of this clause, the due date for making invoice payments by the designated payment office is the later of the following two events:

(A) The 30 thday after the designated billing office receives a proper invoice from the Contractor (except as provided in paragraph (a)(1)(ii) of this clause).

(B) The 30 thday after Government acceptance of supplies delivered or services performed. For a final invoice, when the payment amount is subject to contract settlement actions, acceptance is deemed to occur on the effective date of the contract settlement.

(ii) If the designated billing office fails to annotate the invoice with the actual date of receipt at the time of receipt, the invoice payment due date is the 30 thday after the date of the Contractor's invoice, provided the designated billing office receives a proper invoice and there is no disagreement over quantity, quality, or Contractor compliance with contract requirements.

(2) Certain food products and other payments.

(i) Due dates on Contractor invoices for meat, meat food products, or fish; perishable agricultural commodities; and dairy products, edible fats or oils, and food products prepared from edible fats or oils are-

(A) For meat or meat food products, as defined in section 2(a)(3) of the Packers and Stockyard Act of1921 (7 U.S.C.182(3)), and as further defined in Pub.L.98-181, including any edible fresh or frozen poultry meat, any perishable poultry meat food product, fresh eggs, and any perishable egg product, as close as possible to, but not later than, the 7 thday after product delivery.

(B) For fresh or frozen fish, as defined in section 204(3) of the Fish and Seafood Promotion Act of1986 (16 U.S.C.4003(3)), as close as possible to, but not later than, the 7 thday after product delivery.

(C) For perishable agricultural commodities, as defined in section 1(4) of the Perishable Agricultural Commodities Act of1930 (7 U.S.C.499a(4)), as close as possible to, but not later than, the 10 thday after product delivery, unless another date is specified in the contract.

(D) For dairy products, as defined in section 111(e) of the Dairy Production Stabilization Act of1983 (7 U.S.C.4502(e)), edible fats or oils, and food products prepared from edible fats or oils, as close as possible to, but not later than, the 10 thday after the date on which a proper invoice has been received. Liquid milk, cheese, certain processed cheese products, butter, yogurt, ice cream, mayonnaise, salad dressings, and other similar products, fall within this classification. Nothing in the Act limits this classification to refrigerated products. When questions arise regarding the proper classification of a specific product, prevailing industry practices will be followed in specifying a contract payment due date. The burden of proof that a classification of a specific product is, in fact, prevailing industry practice is upon the Contractor making the representation.

(ii) If the contract does not require submission of an invoice for payment (e.g., periodic lease payments), the due date will be as specified in the contract.

(3) Contractor's invoice. The Contractor shall prepare and submit invoices to the designated billing office specified in the contract. A proper invoice must include the items listed in paragraphs (a)(3)(i) through (a)(3)(x) of this clause. If the invoice does not comply with these requirements, the designated billing office will return it within 7 days after receipt (3 days for meat, meat food products, or fish; 5 days for perishable agricultural commodities, dairy products, edible fats or oils, and food products prepared from edible fats or oils), with the reasons why it is not a proper invoice.

The Government will take into account untimely notification when computing any interest penalty owed the Contractor.

(i) Name and address of the Contractor.

(ii) Invoice date and invoice number. (The Contractor should date invoices as close as possible to the date of the mailing or transmission.)

(iii) Contract number or other authorization for supplies delivered or services performed (including order number and line item number).

(iv) Description, quantity, unit of measure, unit price, and extended price of supplies delivered or services performed.

(v) Shipping and payment terms (e.g., shipment number and date of shipment, discount for prompt payment terms). Bill of lading number and weight of shipment will be shown for shipments on Government bills of lading.

(vi) Name and address of Contractor official to whom payment is to be sent (must be the same as that in the contract or in a proper notice of assignment).

(vii) Name (where practicable), title, phone number, and mailing address of person to notify in the event of a defective invoice.

(viii) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(ix) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision (e.g., 52.232-38, Submission of Electronic Funds Transfer Information with Offer), contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer-System for Award Management, or 52.232- 34, Payment by Electronic Funds Transfer-Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(x) Any other information or documentation required by the contract (e.g., evidence of shipment).

(4) Interest penalty. The designated payment office will pay an interest penalty automatically, without request from the Contractor, if payment is not made by the due date and the conditions listed in paragraphs (a)(4)(i) through (a)(4)(iii) of this clause are met, if applicable. However, when the due date falls on a Saturday, Sunday, or legal holiday, the designated payment office may make payment on the following working day without incurring a late payment interest penalty.

(i) The designated billing office received a proper invoice.

(ii) The Government processed a receiving report or other Government documentation authorizing payment, and there was no disagreement over quantity, quality, or Contractor compliance with any contract term or condition.

(iii) In the case of a final invoice for any balance of funds due the Contractor for supplies delivered or services performed, the amount was not subject to further contract settlement actions between the Government and the Contractor.

(5) Computing penalty amount. The Government will compute the interest penalty in accordance with the Office of Management and Budget prompt payment regulations at 5 CFR Part 1315.

(i) For the sole purpose of computing an interest penalty that might be due the Contractor, Government acceptance is deemed to occur constructively on the 7 thday (unless otherwise specified in this contract) after the Contractor delivers the supplies or performs the services in accordance with the terms and conditions of the contract, unless there is a disagreement over quantity, quality, or Contractor compliance with a contract provision. If actual acceptance occurs within the constructive acceptance period, the Government will base the determination of an interest penalty on the actual date of acceptance. The constructive acceptance requirement does not, however, compel Government officials to accept supplies or services, perform contract administration functions, or make payment prior to fulfilling their responsibilities.

(ii) The prompt payment regulations at 5 CFR1315.10(c) do not require the Government to pay interest penalties if payment delays are due to disagreement between the Government and the Contractor over the payment amount or other issues involving contract compliance, or on amounts temporarily withheld or retained in accordance with the terms of the contract. The Government and the Contractor shall resolve claims involving disputes and any interest that may be payable in accordance with the clause at FAR 52.233-1, Disputes.

(6) Discounts for prompt payment. The designated payment office will pay an interest penalty automatically, without request from the Contractor, if the Government takes a discount for prompt payment improperly. The Government will calculate the interest penalty in accordance with the prompt payment regulations at 5 CFR Part 1315.

(7) Additional interest penalty.

(i) The designated payment office will pay a penalty amount, calculated in accordance with the prompt payment regulations at 5 CFR Part 1315 in addition to the interest penalty amount only if-

(A) The Government owes an interest penalty of $1 or more;

(B) The designated payment office does not pay the interest penalty within 10 days after the date the invoice amount is paid; and

(C) The Contractor makes a written demand to the designated payment office for additional penalty payment, in accordance with paragraph (a)(7)(ii) of this clause, postmarked not later than 40 days after the invoice amount is paid.

(ii)

(A) The Contractor shall support written demands for additional penalty payments with the following data. The Government will not request any additional data. The Contractor shall-

(1) Specifically assert that late payment interest is due under a specific invoice, and request payment of all overdue late payment interest penalty and such additional penalty as may be required;

(2) Attach a copy of the invoice on which the unpaid late payment interest is due; and

(3) State that payment of the principal has been received, including the date of receipt.

(B) If there is no postmark or the postmark is illegible-

(1) The designated payment office that receives the demand will annotate it with the date of receipt, provided the demand is received on or before the 40th day after payment was made; or

(2) If the designated payment office fails to make the required annotation, the Government will determine the demand's validity based on the date the Contractor has placed on the demand, provided such date is no later than the 40th day after payment was made.

(iii) The additional penalty does not apply to payments regulated by other Government regulations (e.g., payments under utility contracts subject to tariffs and regulation).

(b) Contract financing payment. If this contract provides for contract financing, the Government will make contract financing payments in accordance with the applicable contract financing clause.

(c) Fast payment procedure due dates. If this contract contains the clause at 52.213-1, Fast Payment Procedure, payments will be made within 15 days after the date of receipt of the invoice.

(d) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall-

(1) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the-

(i) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(ii) Affected contract number and delivery order number if applicable;

(iii) Affected line item or subline item, if applicable; and

(iv) Contractor point of contact.

(2) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(End of clause)

52.247-1 Commercial Bill of Lading Notations. (Feb 2006)

As prescribed in 47.104-4 , insert the following clause:

Commercial Bill of Lading Notations (Feb 2006)

When the Contracting Officer authorizes supplies to be shipped on a commercial bill of lading and the Contractor will be reimbursed these transportation costs as direct allowable costs, the Contractor shall ensure before shipment is made that the commercial shipping documents are annotated with either of the following notations, as appropriate:

(a) If the Government is shown as the consignor or the consignee, the annotation shall be:

Transportation is for the ____[name the specific agency] and the actual total transportation charges paid to the carrier(s) by the consignor or consignee are assignable to, and shall be reimbursed by, the Government.

(b) If the Government is not shown as the consignor or the consignee, the annotation shall be:

Transportation is for the ____[name the specific agency] and the actual total transportation charges paid to the carrier(s) by the consignor or consignee shall be reimbursed by the Government, pursuant to cost-reimbursement contract No. ____. This may be confirmed by contacting ____________[Name and address of the contract administration office listed in the contract].

(End of clause)

52.252-2 Clauses Incorporated by Reference. (Feb 1998)

As prescribed in , insert the following clause:52.107(b)

Clauses Incorporated By Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://acquisition.gov/daffars https://acquisition.gov/dfars https://acquisition.gov/browse/index/far (End of clause)

52.252-4 Alterations in Contract. (Apr 1984)

As prescribed in 52.107(d), insert the following clause in solicitations and contracts in order to revise or supplement, as necessary, other parts of the contract, or parts of the solicitation that apply after contract award, except for any clause authorized for use with a deviation. Include clear identification of what is being altered.

Alterations in Contract (Apr 1984)

Portions of this contract are altered as follows:

(End of clause)

52.252-6 Authorized Deviations in Clauses. (Nov 2020)

As prescribed in , insert the following clause in solicitations and contracts that include any FAR or supplemental clause with an authorized 52.107(f) deviation. Whenever any FAR or supplemental clause is used with an authorized deviation, the contracting officer shall identify it by the same number, title, and date assigned to the clause when it is used without deviation, include regulation name for any supplemental clause, except that the contracting officer shall insert "(DEVIATION)" after the date of the clause.

Authorized Deviations in Clauses (Nov 2020)

The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated (a) by the addition of "(DEVIATION)" after the date of the clause.

The use in this solicitation or contract of any (48 CFR Chapter 1 ) clause with an authorized (b) ___Defense Federal Acquisition Regulation ____ deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of clause)

DFARS Clauses Incorporated by Full Text

252.211-7003 Item Unique Identification and Valuation. (Jan 2023)

As prescribed in 211.274-5(a), use the following clause:

ITEM UNIQUE IDENTIFICATION AND VALUATION (JAN 2023)

(a) . As used in this clause- Definitions

"Automatic identification device" means a device, such as a reader or interrogator, used to retrieve data encoded on machine-readable media.

"Concatenated unique item identifier" means-

(1) For items that are serialized within the enterprise identifier, the linking together of the unique identifier data elements in order of the issuing agency code, enterprise identifier, and unique serial number within the enterprise identifier; or

(2) For items that are serialized within the original part, lot, or batch number, the linking together of the unique identifier data elements in order of the issuing agency code; enterprise identifier; original part, lot, or batch number; and serial number within the original part, lot, or batch number.

"Data matrix" means a two-dimensional matrix symbology, which is made up of square or, in some cases, round modules arranged within a perimeter finder pattern and uses the Error Checking and Correction 200 (ECC200) specification found within International Standards Organization (ISO)/International Electrotechnical Commission (IEC) 16022.

"Data qualifier" means a specified character (or string of characters) that immediately precedes a data field that defines the general category or intended use of the data that follows.

"DoD recognized unique identification equivalent" means a unique identification method that is in commercial use and has been recognized by DoD. All DoD recognized unique identification equivalents are listed at . https://www.acq.osd.mil/asda/dpc/ce/ds/unique-id.html

"DoD item unique identification" means a system of marking items delivered to DoD with unique item identifiers that have machine-readable data elements to distinguish an item from all other like and unlike items. For items that are serialized within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier and a unique serial number. For items that are serialized within the part, lot, or batch number within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier; the original part, lot, or batch number; and the serial number.

" Enterprise " means the entity (e.g., a manufacturer or vendor) responsible for assigning unique item identifiers to items.

" Enterprise identifier" means a code that is uniquely assigned to an enterprise by an issuing agency.

"Government's unit acquisition cost" means-

(1) For fixed-price type line, subline, or exhibit line items, the unit price identified in the contract at the time of…