DEP Restated Contract No. GC920, Page 1 of 14 (Approved Template 02/02/2017)

DEP Contract No. GC920

AMENDED AND RESTATED CONTRACT

This Amended and Restated Contract No. GC920 (Contract) is made by and between the Department of Environmental Protection (Department), an agency of the State of Florida, and Broward County Board of County Commissioners (Contractor), on the date last signed below.

WHEREAS, the Department entered into the Contract with the Contractor to perform compliance inspections within the jurisdictional (geographical) boundaries of the specified counties, effective June 26, 2017; and

WHEREAS, the parties wish to amend and restate the Contract as set forth herein.

NOW, THEREFORE, the parties agree as follows:

SERVICES AND PERFORMANCE

1. SERVICES. Department does hereby retain, and Contractor agrees to perform compliance inspections within the jurisdictional (geographical) boundaries of the specified counties, including facilities registered to the Contractor as required by an executed Task Assignment(s) and Contractor’s response thereto, incorporated herein by reference, and in accordance with Attachment A, Scope of Work - Level 1 and if applicable Attachment B, Scope of Work – Level 2 (Scope) and all exhibits and Attachments named and incorporated herein by reference. Contractor has been determined to be a vendor to the Department under this Contract.

2. WORK.

A. Contractor shall provide the services specified in the Scope (Work). Department shall authorize all work assignments by Task Assignment Notification Form (TA) or Task Assignment Change Order Form (TACO). Contractor shall perform the services required under this Contract in accordance with the guidance documents attached to each executed TA or TACO and in accordance with the provisions of this Contract. The Department reserves the right to update or amend the guidance documents as needed.

B. Contractor shall not commence Work until either 1) a TA/TACO has been fully executed, by both Department and Contractor, or 2) a PO or PO Change Order(CO) has been issued.

C. In the event services are required that are within the general description of services, but are not specifically set out in the Scope, Department and Contractor reserve the right to negotiate the Task Assignments covering performance of those required services.

D. There is no minimum amount of Work guaranteed as a result of this Contract. Any and all Work assigned will be at the sole discretion of the Department.

E. Department reserves the right to not authorize any Work, and may suspend or terminate for cause any Work assigned to Contractor under this or any other contract, if and in the event that the Department and Contractor (or any of its affiliates or authorized subcontractors) are adverse in any litigation, administrative proceeding or alternative dispute resolution, until such adverse relationship is resolved either by agreement or by final non-appealable order of a court.

3. STANDARD OF CARE FOR PERFORMANCE.

A. Contractor shall perform as an independent contractor and not as an agent, representative, or employee of the Department.

B. Contractor shall perform the services in a proper and satisfactory manner as determined by the Department.

Any and all such equipment, products or materials necessary to perform these services, or requirements as further stated herein, shall be supplied by the Contractor.

C. Contractor shall provide competent, suitably qualified personnel. Contractor must notify the Department’s Contract Manager of any changes in the personnel identified in this Contract. Notification shall include a detailed explanation of the need to change personnel and the Contractor’s documentation that proposed replacement personnel have equal or greater qualifications and experience.

D. Contractor shall perform the services in a manner consistent with that level of care and skill ordinarily

DEP Restated Contract No. GC920, Page 2 of 14 exercised by other contractors performing the same or similar services under similar circumstances at the time performed.

4. TERM OF CONTRACT.

A. Initial Term. This Contract shall begin July 1, 2017, and shall remain in effect for a period of ten

(10) years, inclusive.

B. Renewal Term. An “X” beside the correct provision in this section signifies that the provision is applicable to the Contract.

☒ This Contract may be renewed, in writing, on the same terms and conditions as the original Contract and any amendments thereto, for a period no greater than the term above, or three (3) years, whichever is longer. All renewals are contingent upon satisfactory performance by Contractor. Renewals may be for the entire period or in increments.

□ This Contract may not be renewed.

COMPENSATION

5. COMPENSATION.

A. As consideration for the services rendered by Contractor under the terms of this Contract, the Department shall pay the Contractor on a combination fee-schedule/cost-reimbursement basis not to exceed $5,424,709.00. For the monthly operation and maintenance services as well as repair and emergency service calls, the Contractor shall be compensated on a fee-schedule basis at the rates specified in the executed task assignment. It is understood that fee schedule amounts include all costs necessary to perform the work outlined herein including, but not limited to, labor, fringe benefits, overhead, supplies, and travel, but do not include reimbursement for equipment purchases.

Equipment purchases costing $1,000.00 or more shall be reimbursed on a cost-reimbursement basis and must be pre-approved by the Department.

B. CONTRACTOR SHALL NOT COMMENCE WORK ON ANY SERVICES THAT WILL EXCEED THE

COMPENSATION AMOUNT OF THE CONTRACT UNLESS AND UNTIL THE CONTRACT IS AMENDED. It is the Contractor’s responsibility to know when the authorized compensation amount of the Contract will be reached.

6. ANNUAL APPROPRIATION. Department's performance and obligation to pay under this Contract is contingent upon an annual appropriation by the Florida Legislature. Authorization for continuation and completion of Work and payment associated therewith may be rescinded with proper notice at the discretion of the Department if state or federal appropriations are reduced or eliminated.

7. PAYMENT METHOD.

A. Contractor shall submit invoices as specified in Attachment A and B, under Payments section.

B. All invoices submitted must have sufficient detail for a proper pre-audit and post-audit review.

C. Department must approve the final deliverable(s) before the Contractor may submit a final invoice and any forms.

D. Each invoice, including appropriate supporting documentation as required herein, shall be submitted via email to the following:

DEP Restated Contract No. GC920, Page 3 of 14

Florida Department of Environmental Protection PCAP Program Attn: Department Contract Manager Email address: STR_Invoices@dep.state.fl.us

Copy: Department District Task Manager and DEP Contract Manager

8. TRAVEL. An “X” beside the correct provision in this section signifies that the provision is applicable to the Contract.

□ Travel is not authorized under this Contract.

☒ Travel costs are included in the fee schedule amounts of this Contract.

□ Travel costs shall be paid on a cost-reimbursement basis in accordance with the paragraph contained herein of this Contract.

9. EQUIPMENT. Upon satisfactory completion of this Contract, the Contractor may retain ownership of the non-expendable personal property or equipment purchased under this Contract prior to the execution of an Amendment of said Contract. The following terms shall apply:

A. The Contractor is responsible for any loss, damage, or theft of, and any loss, damage or injury caused by the use of, non-expendable personal property or equipment purchased with state funds and held in his possession for use in a contractual arrangement with the Department.

B. In the event that the Department determines a need to loan equipment needed for the completion of services under this Contract to the Contractor, a Department Property Loan Agreement shall be completed and maintained in the Contract file.

C. The Contractor shall have title to and use of any vehicle previously purchased under a former Contract, by its authorized employees only, for the authorized purposes of this Contract as long as the required work is being satisfactorily performed. In the event that this Contract is terminated for any reason, or the use of the vehicle is no longer needed (such as completion of the Contract), title of the vehicle shall be transferred to the Department.

D. The Contractor is responsible for the implementation of adequate maintenance procedures to keep the non-expendable personal property or equipment in good operating condition.

E. If the Contractor fails to perform its obligations under this Contract, the Contractor shall deliver possession and custody of all such equipment to the nearest District Office location, unless otherwise agreed, within thirty (30) calendar days of Contract termination.

10. PROMPT PAYMENT.

A. Department's Contract Manager shall have five (5) business days, unless a greater period is specified herein, to inspect and approve an invoice. Department shall submit a request for payment to DFS within twenty (20) business days; and DFS shall issue a warrant within ten (10) business days thereafter. Days are calculated from the latter of the date the invoice is received or services received, inspected, and approved. Invoice payment requirements do not start until a proper and correct invoice has been received. Invoices which have to be returned to the Contractor for correction(s) will result in an uncompensated delay in payment. A Vendor Ombudsman has been established within DFS who may be contacted if a Contractor is experiencing problems in obtaining timely payment(s) from a State agency.

The Vendor Ombudsman may be contacted at (850) 413-5516, per Section 215.422, F.S.

B. If a warrant in payment of an invoice is not issued within forty (40) business days after receipt of a correct invoice and receipt, inspection, and approval of the goods and services, the Department shall pay the Contractor interest at a rate as established by Section 55.03(1), F.S., on the unpaid balance of the invoice. Interest payments of less than $1 will not be issued unless Contractor requests such payment. The interest rate for each calendar year for which the term of this Contract is in effect can be mailto:STR_Invoices@dep.state.fl.us

DEP Restated Contract No. GC920, Page 4 of 14 obtained from DFS’ Vendor Ombudsman at the telephone numbers provided above, or the Department's Procurements Section at (850) 245-2361, per Section 215.422, F.S.

11. RELEASE OF CLAIMS. Upon payment for satisfactory completion of any portion of the Work, the Contractor shall execute and deliver to the Department a release of all claims against the Department arising under, or by virtue of, the Work, except claims which are specifically exempted by the Contractor to be set forth therein (Contractor Release, using Attachment E, Contractor Affidavit/Release of Claims).

Receipt by the Department of the Contractor’s Release is a condition of final payment under this Contract. Unless otherwise provided in this Contract, by State law or otherwise expressly agreed to by the parties to this Contract, final payment or settlement upon termination of this Contract shall not constitute a release or waiver of the Department’s claims against the Contractor, or the Contractor’s sureties, subcontractors, successors or assigns under this Contract or as against applicable performance and payment bonds.

12. PHYSICAL ACCESS AND INSPECTION. As applicable, the Department personnel shall be given access to and may observe and inspect Work being performed under this Contract, including by any of the following methods:

A. Contractor shall provide access to any location or facility on which the Contractor is performing Work, or storing or staging equipment, materials or documents;

B. Contractor shall permit inspection of any facility, equipment, practices, or operations required in performance of any Work; and, C. Contractor shall allow and facilitate sampling and monitoring of any substances, soils, materials or parameters at any location reasonable or necessary to assure compliance with any Work or legal requirements.

PARTY REPRESENTATIVES

13. NOTICE. All notices and written communication between the parties shall be sent by electronic mail, U.S. Mail, a courier delivery service, or delivered in person. Notices shall be considered delivered when reflected by an electronic mail read receipt, a courier service delivery receipt, other mail service delivery receipt, or when receipt is acknowledged by recipient.

14. IDENTIFICATION OF CONTRACT MANAGERS. All matters shall be directed to the Contract Managers for appropriate action or disposition. Any changes to the Contract Manager information identified below must be noticed, in writing, to the other party within ten (10) calendar days of the change.

Either party may provide notice to the other party by email identifying a change of a designated Contract Manager and providing the new contact information for the newly designated Contract Manager. Such notice is sufficient to effectuate this change without requiring a written amendment to the Contract.

Department and the Contractor Contract Managers and contact information are provided below:

15. CHANGE ORDERS AND AMENDMENTS. Department may at any time, by written order designated to be a Change Order, make any change in the Work within the general scope of this Contract (e.g., specifications, method or manner of performance, requirements, etc.). All Change Orders are subject to the

Contractor Department Broward County Board of County Commissioners Broward County

Department of Environmental Protection Division of Waste Management

Growth Management Department 2600 Blair Stone Road, MS 4500 1 North University Drive, Suite 203 Plantation, Florida, 33324

Tallahassee, Florida 32399-2400 Attn: Roger Ruiz

Attn: Ali H. Younes Phone Number: (850) 245-8854 Phone Number: (954) 519-1486 Email: ayounes@broward.org

Email: roger.ruiz@dep.state.fl.us mailto:ayounes@broward.org mailto:roger.ruiz@dep.state.fl.us

DEP Restated Contract No. GC920, Page 5 of 14 mutual agreement of both parties as evidenced in writing. Any change which causes an increase or decrease in Contractor’s cost or time shall require an appropriate adjustment and modification by Task Assignment Change Order. Following execution of this Contract, any future Amendments or Change Orders may be executed by the Department representative with appropriate delegated authority.

CONSEQUENCES FOR FAILURE TO PERFORM

16. DISPUTE RESOLUTION. Any dispute concerning performance of the Contract shall be decided as follows:

A. All claims or disputes (Claims) must be presented to the Department in writing within thirty (30) days of the date such Claim arises (Notice of Dispute). The Notice of Dispute shall set out in detail all aspects of the disputed matters to be resolved, including the specific relief sought by the Contractor.

Claims not presented by Notice of Dispute to Contract Manager shall be deemed waived by the Contractor.

B. The parties shall make a good faith attempt to resolve Claims which may arise from time to time by informal conference within ten (10) days of the Notice of Dispute.

C. Within ten (10) days of the informal conference, the Department shall provide Contractor a detailed written response to the Claim. A formal conference of the parties shall be convened no later than thirty (30) days following the Department’s response to the Notice of Dispute, unless the parties mutually agree in writing to a longer period of time within which to schedule a formal conference.

1) All persons necessary to resolution of the claim or disputed matter shall attend the formal conference.

2) Minutes of the formal conference shall be taken, recorded, transcribed, and signed by the Department and the Contractor. Any terms of settlement and/or resolution reached shall be signed by all persons authorized to resolve the Claim.

D. Either party may request mediation of unresolved Claims, with the party seeking mediation to bear the expense of mediation.

E. Any Claim not resolved at formal conference or mediation, may be the subject of a complaint filed in a court of competent jurisdiction in Leon County, Florida.

17. FINANCIAL CONSEQUENCES FOR UNSATISFACTORY PERFORMANCE.

A. No payment will be made for deliverables deemed unsatisfactory by the Department. In the event that a deliverable is deemed unsatisfactory by the Department, the Contractor shall re-perform the services needed for submittal of a satisfactory deliverable, at no additional cost to Department, within thirty (30) days of being notified of the unsatisfactory deliverable.

B. If a satisfactory deliverable is not submitted within the specified time frame, the Department may, in its sole discretion: 1) assess liquidated damages if specified in the Contract or its attachments; 2) request from the Contractor agreement to a reduction in the amount payable; 3) suspend all Work until satisfactory performance is achieved, or 4) terminate the Contract for failure to perform.

18. CORRECTIVE ACTION PLAN. In the event that deliverables are unsatisfactory or are not submitted within the specified timeframe, the Department Contract Manager may, by letter specifying the failure of performance under the Contract, request that a proposed Corrective Action Plan (CAP) be submitted by the Contractor to the Department. All CAPs must be able to be implemented and performed in no more than sixty (60) days.

A. A CAP shall be submitted within ten (10) calendar days of the date of the letter request from the Department. The CAP shall be sent to the Department Contract Manager for review and approval.

Within ten (10) calendar days of receipt of a CAP, the Department shall notify the Contractor in writing whether the CAP proposed has been accepted. If the CAP is not accepted, the Contractor shall have ten

(10) calendar days from receipt of the Department letter rejecting the proposal to submit a revised

DEP Restated Contract No. GC920, Page 6 of 14 proposed CAP. Failure to obtain the Department approval of a CAP as specified above shall result in the Department’s termination of the Contract for cause as authorized in the Contract.

B. Upon the Department’s notice of acceptance of a proposed CAP, the Contractor shall have ten

(10) calendar days, or longer if specified in the approved CAP, to commence implementation of the accepted plan. Acceptance of the proposed CAP by the Department does not relieve the Contractor of any of its obligations under the Contract. In the event the CAP fails to correct or eliminate performance deficiencies by the Contractor, the Department shall retain the right to require additional or further remedial steps, or to terminate the Contract for failure to perform. No actions approved by the Department or steps taken by the Contractor shall stop the Department from subsequently asserting any deficiencies in performance. Contractor shall continue to implement the CAP until all deficiencies are corrected. Reports on the progress of the CAP will be made to the Department as requested by the Department Contract Manager.

C. Failure to respond to a Department request for a CAP shall result in suspension or termination of the Contract.

19. PAYMENT AND PERFORMANCE BONDS. An “X” beside the correct provision in this section signifies that the provision is applicable to the Contract.

☒ No Payment or Performance bonds are required.

□ Contractor shall provide executed Payment and Performance Bonds naming the Department as obligee, issued by a surety acceptable to the Department, in the amount(s) of $ .

□ Contractor may be required to provide executed Payment and/or Performance Bonds naming the Department as obligee, issued by a surety acceptable to the Department, in an amount of up to one hundred and twenty percent (120%) of the total anticipated cost of any Work.

20. LIQUIDATED DAMAGES. An “X” beside the correct provision in this section signifies that the provision is applicable to the Contract.

☒ No liquidated damages will be assessed.

□ In addition to other remedies elsewhere in this Contract, and as provided by law, unless otherwise stipulated in the Scope, the Contractor hereby covenants and agrees to pay liquidated damages to the Department as follows:

A. Contractor acknowledges that time is of the essence for all services provided under this Contract, and whereas the actual damages to be suffered by late performance are incapable of accurate calculation, the parties agree to the following as a reasonable estimation thereof as liquidated damages. In addition to any other provisions of this Contract, in the event that the deliverable identified in the Scope, is not completed and submitted by the close of business on the date the deliverable is due, the compensation amount stated for that portion of the Work may be reduced by five percent (5%) per week for each week the deliverable is late, with the total amount of the liquidated damages not to exceed the total compensation amount of the Scope deliverable.

B. The date of submission shall be the date of receipt by the Department.

C. If no Department receipt date appears or the date is illegible, the date of submission shall be deemed to be five (5) days prior to receipt by the Contract Manager.

D. If completion is or will be justifiably delayed due to reasons as set out in paragraph contained herein, the Department may grant an extension of time as evidenced by a properly executed Amendment.

E. If the deliverable(s) fail to comply with the requirements of this Contract, or if questions arise from review and the Contractor is so notified and requested to respond, the Contractor shall furnish the required additions, deletions, or revisions in accordance with the Scope at no additional cost to the Department.

DEP Restated Contract No. GC920, Page 7 of 14

F. If the additions, deletions, and revisions are not submitted to the Department's Contract Manager in accordance with the Scope, the compensation stated for that portion of the Work may be reduced by five percent (5%) for each week that the requested deliverable is late, as specified. The total reduction shall not exceed the total amount of the Work.

G. Contractor’s failure to respond to a request to correct the deliverables will result in termination of the Work and forfeiture of any unpaid balance for such deliverables.

Additionally, the Department, at its discretion, may re-assign future Work.

21. RETAINAGE

A. Department reserves the right to establish the amount and application of retainage on the Compliance Routine Inspection (CRI) Work to a maximum of ten percent (10%). Any retainage to be applied shall be specified in the Task Assignment. Retainage shall be withheld from each payment to the Contractor pending satisfactory completion of CRI performance criteria listed in Task Assignment and approval of all deliverables.

B. Department reserves the right to withhold payment of retainage for the Contractor’s failure to meet performance criteria listed in the Task Assignment. Department shall provide written notification to the Contractor of the Department’s intent to withhold retainage on the Routine Compliance Inspection Work in the Task Assignment. Contractor’s failure to rectify the identified deficiency within the timeframe stated in the Department’s notice will result in forfeiture of retainage by the Contractor.

C. If the Contractor fails to perform the requested Scope, or fails to perform the Compliance Routine Inspection Work in a satisfactory manner, Contractor shall forfeit its right to payment for the Compliance Routine Inspection Work and the retainage called for under the Task Assignment. Failure to perform includes, but is not limited to, failure to submit the required deliverables or failure to provide adequate documentation that the work was actually performed.

D. No retainage shall be released or paid for uncompleted Compliance Routine Inspection Work while a Contract is suspended.

E. Except as otherwise provided above, the Contractor shall be paid the retainage associated with the Work, provided the Contractor has completed the work and submits an invoice for retainage held in accordance with paragraph contained herein above.

LIABILITY

22. INSURANCE. To the extent required by law, the Contractor will be self-insured against, or will secure and maintain during the life of this Contract and any renewals, Workers' Compensation Insurance for all of its employees connected with the work of this project. The Contractor shall require any and all subcontractors, if authorized under this Contract, to provide Workers' Compensation Insurance for all employees unless such employees are covered by the protection afforded by Contractor. Such self-insurance program or insurance coverage shall comply fully with the Florida Workers' Compensation law. In case any class of employees engaged in hazardous work under this Contract is not protected under the Workers' Compensation statute, the Contractor shall provide, and cause each subcontractor to provide, adequate insurance satisfactory to the Department, for the protection of its employees not otherwise protected.

23. INDEMNIFICATION. The Contractor and the Department shall each be solely responsible for the negligent or wrongful acts of its respective employees and agents acting within the scope of their employment. Further, each party shall bear its own costs of every name and description, including attorneys’ fees, arising from or relating to personal injury and damage to real or personal tangible property alleged to be caused in whole or in part by its employees and agents acting within the scope of their employment. However, nothing contained herein shall constitute a waiver by the Contractor or the Department of its sovereign immunity or waiver or modification of Section 768.28, F.S.

THIRD PARTIES

DEP Restated Contract No. GC920, Page 8 of 14

24. SUBCONTRACTING. An “X” beside the correct provision in this section signifies that the provision is applicable to the Contract.

☒ Contractor shall not subcontract any work under this Contract.

□ A. Contractor shall not subcontract any work under this Contract without the prior written consent of the Department's Contract Manager. Department reserves the right to reject any proposed subcontractor based upon the Department’s prior experience with subcontractor, subcontractor’s reputation, or the Department’s lack of adequate assurance of performance by subcontractor. Contractor agrees to be responsible for the fulfillment of all work elements included in any subcontract and agrees to be responsible for the payment of all monies due under any subcontract.

B. Department shall not be liable to any subcontractor for any expenses or liabilities incurred under any subcontract, regardless of whether the Department has approved such subcontract or subcontractor. Contractor shall be solely liable to its subcontractor(s) for all expenses and liabilities incurred under any subcontract. Any subcontracts made under or in performance of this Contract must include the same conditions specified in this Contract, with the exception of insurance requirements (paragraph contained herein), and shall include a release of any rights, claims or liabilities against the Department. The level of insurance to be carried by subcontractors performing work under this Contract shall be at the discretion of Contractor.

25. NONASSIGNABILITY. Contractor shall not sell, assign or transfer any of its rights, duties or obligations under this Contract (its Rights and Duties), without the prior written consent of the Department. Contractor shall remain liable for performance of its Rights and Duties, regardless of any assignment to or assumption by any third party, notwithstanding any approval thereof by the Department.

However, the Department may expressly release the Contractor from any and all Rights and Duties through a novation accompanying an approved assignment. Department may assign the Department’s Rights and Duties, but shall give prior written notice of its intent to do so to the Contractor. The foregoing notwithstanding, the Contractor hereby assigns to the State any and all claims it has with respect to the Contract under the antitrust laws of the United States and the State.

26. THIRD PARTY BENEFICIARIES. This Contract is neither intended nor shall it be construed to grant any rights, privileges or interest in any third party without the mutual written agreement of the parties hereto.

SUSPENSION AND TERMINATION

27. SUSPENSION.

A. Department may order the Contractor in writing to suspend, delay or interrupt all or any part of the Work for failure to perform, or as otherwise specified herein, such period of time as the Department may determine to be appropriate for any of the following reasons:

1.) Contractor fails to timely and properly correct deficiencies in or performs unsatisfactory work;

2.) Contractor’s or subcontractor’s insurer or surety notifies the Department that any of its required insurance or bonds has lapsed or will lapse, and the Contractor fails to provide replacement insurance or bonds acceptable to the Department before the insurance or bond cancellation or termination date;

3.) Contractor or subcontractor materially violates safety laws or other constraints;

4.) Department determines that there is a threat to the public health, safety or welfare that necessitates such suspension; or

5.) For the convenience of the Department.

DEP Restated Contract No. GC920, Page 9 of 14

B. If the performance of all or any part of the Work is suspended, delayed or interrupted for an unreasonable period of time by an act of the Department in administration of the Work, or by the Department’s failure to act within a reasonable time to review or approve an invoice, the Department shall provide an equitable extension of the time allowed to complete the Work and modify the Scope accordingly. However, no adjustment shall be made under this clause for any suspension, delay or interruption if and to the extent that:

1.) Performance would have been suspended, delayed or interrupted by any other cause, including the fault or negligence of the Contractor; or

2.) Equitable adjustment is provided for (or excluded) under any other provision of this Contract.

C. Contractor shall not be compensated for Work performed subsequent to a notice of suspension by Department.

28. TERMINATION.

A. Department may terminate this Contract at any time for cause, in the event of the failure of the Contractor to fulfill any of its obligations. Prior to termination, the Department shall provide ten (10) calendar days written notice of its intent to terminate for cause, including the reasons for such, and shall provide the Contractor an opportunity to consult with the Department regarding the reason(s) for termination. Contractor may be afforded the possibility of curing any default at the sole discretion of the Department.

B. The Department may terminate this Contract without cause and for its convenience by giving thirty (30) calendar days written notice to the Contractor. Termination for convenience shall not entitle either party to any indirect, special or resulting damages, lost profits, costs or penalties, and the Contractor shall be entitled only to recover those amounts earned by it for authorized deliverables completed up to the date of termination (or as may be agreed to in writing by the Department for completion of all or any portion of the Work in process).

GENERAL CONDITIONS

29. ATTORNEY’S FEES. In the event of any legal action to enforce the terms of this Contract, each party shall bear its own attorney’s fees and costs.

30. CONFLICT OF INTEREST. Contractor covenants and warrants that it presently has no interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance of this Contract or the Services required hereunder.

31. COMPLIANCE WITH APPLICABLE LAW. Contractor shall comply with all applicable federal, state and local rules and regulations in providing services to the Department under this Contract including, but not limited to, local health and safety rules and regulations. This provision shall be included in all subcontracts issued as a result of this Contract.

32. DISQUALIFICATION.

A. The employment of unauthorized aliens by the Contractor/vendor is considered a violation of Section 274A(e) of the Immigration and Nationality Act. If the Contractor knowingly employs unauthorized aliens, such violation shall be cause for unilateral cancellation of this Contract. Contractor shall be responsible for including this provision in all subcontracts with private organizations issued as a result of this Contract.

B. Contractor is required to use the U.S. Department of Homeland Security’s E-Verify system to verify the employment eligibility of all employees used by the Contractor under this Contract, pursuant to State of Florida Executive Order No.: 11-116. Also, the Contractor shall include in related subcontracts, if authorized under this Contract, a requirement that subcontractors performing work or providing services pursuant to this Contract utilize the E-Verify system to verify employment eligibility of all employees used by the subcontractor for the performance of the Work.

DEP Restated Contract No. GC920, Page 10 of 14

C. If Contract value exceeds one (1) million dollars, Contractor certifies that it and any of its affiliates are not scrutinized companies as identified in Section 287.135, F.S. In addition, Contractor agrees to observe the requirements of Section 287.135, F.S., for applicable sub-agreements entered into for the performance of work under this Contract. Pursuant to Section 287.135, F.S., the Department may immediately terminate this Contract for cause if the Contractor, its affiliates, or its subcontractors are found to have submitted a false certification; or if the Contractor, its affiliates, or its subcontractors are placed on any applicable scrutinized companies list or engaged in prohibited contracting activity during the term of the Contract. As provided in Subsection 287.135(8), F.S., if federal law ceases to authorize these contracting prohibitions then they shall become inoperative.

33. EXECUTION IN COUNTERPARTS. This Contract, and any Change Orders or Amendments thereto, may be executed in two or more counterparts, each of which together shall be deemed an original, but all of which together shall constitute one and the same instrument. In the event that any signature is delivered by facsimile transmission or by e-mail delivery of a.pdf format data file, such signature shall create a valid and binding obligation of the party executing (or on whose behalf such signature is executed) with the same force and effect as if such facsimile or.pdf signature page were an original thereof.

34. FORCE MAJEURE. Contractor shall not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees, subcontractors or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, hurricanes, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor shall notify the Department in writing of the delay or potential delay and describe the cause of the delay either 1) within five

(5) days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or 2) if delay is not reasonably foreseeable, within ten (10) days after the date the Contractor first had reason to believe that a delay could result. THE FOREGOING

SHALL CONSTITUTE THE CONTRACTOR’S SOLE REMEDY OR EXCUSE WITH RESPECT TO

DELAY. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy.

No claim for damages, other than for an extension of time, shall be asserted by the Contractor against the Department. Contractor shall not be entitled to an increase in the price or payment of any kind from the Department for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor shall perform at no increased cost, unless the Department determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State or to the Department, in which case the Department may 1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to the Department with respect to products subjected to allocation, or 2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the products that are the subject of the delay, which purchases may be deducted from the Contract quantity, or 3) terminate the Contract in whole or in part.

35. FORUM SELECTION, SEVERABILITY, AND CHOICE OF LAW. This Contract has been delivered in the State of Florida and shall be construed in accordance with substantive and procedural laws of Florida. Wherever possible, each provision of this Contract shall be interpreted in such manner as to be effective and valid under applicable law, but if any provision of this Contract shall be prohibited or invalid under applicable law, such provision shall be ineffective to the extent of such prohibition or invalidity, without invalidating the remainder of such provision or the remaining provisions of this Contract.

Any action in connection with this Contract shall be brought in a court of competent jurisdiction located in Leon County, Florida.

36. GOVERNMENTAL RESTRICTIONS. If the Contractor believes that any governmental restrictions require alteration of the material, quality, workmanship or performance of the products offered under this Contract, the Contractor shall immediately notify the Department so in writing, identifying the specific

DEP Restated Contract No. GC920, Page 11 of 14 restriction and alteration. Department reserves the right and the complete discretion to accept any such alteration or to cancel the Contract at no further expense to the Department. Contractor’s failure to timely notify the Department of its asserted belief shall constitute a waiver of such claim.

37. HEADINGS. The headings contained herein are for convenience only, do not constitute a part of this Contract and shall not be deemed to limit or affect any of the provisions hereof.

38. INTEGRATION. This Contract contains all the terms and conditions agreed upon by the parties, which terms and conditions shall govern all transactions between the Department and the Contractor.

Any alterations, variations, changes, modifications or waivers of provisions of this Contract shall only be valid when they have been reduced to writing, duly signed by each of the parties hereto, and attached to the original of this Contract, unless otherwise provided herein. No oral agreements or representations shall be valid or binding upon the Department or the Contractor. No alteration or modification of the Contract terms, including substitution of product, shall be valid or binding against the Department.

Contractor may not unilaterally modify the terms of this Contract by affixing additional terms to product upon delivery (e.g., attachment or inclusion of standard preprinted forms, product literature, “shrink wrap” terms accompanying or affixed to a product, whether written or electronic) or by incorporating such terms onto the Contractor’s order or fiscal forms or other documents forwarded by the Contractor for payment.

Department's acceptance of product or processing of documentation on forms furnished by the Contractor for approval or payment shall not constitute acceptance of the proposed modification to terms and conditions.

39. INTERPRETATION OF CONTRACT.

A. Where appropriate: the singular includes the plural and vice versa; references to statutes or regulations include all statutory or regulatory provisions consolidating, amending or replacing the statute or regulation referred to; unless otherwise indicated references to Rules are to the adopted rules in the Florida Administrative Code; the words "including," "includes" and "include" shall be deemed to be followed by the words "without limitation"; unless otherwise indicated references to sections, appendices or schedules are to this Contract; words such as "herein," "hereof" and "hereunder" shall refer to the entire document in which they are contained and not to any particular provision or section; words not otherwise defined which have well-known technical or construction industry meanings, are used in accordance with such recognized meanings; references to Persons include their respective permitted successors and assigns and, in the case of Governmental Persons, Persons succeeding to their respective functions and capacities; and words of any gender used herein shall include each other gender where appropriate.

B. Contractor acknowledges and agrees that it has independently reviewed this Contract with legal counsel, and that it has the requisite experience and sophistication to understand, interpret and agree to the particular language of the terms. Accordingly, if an ambiguity in (or dispute regarding the interpretation of) this Contract shall arise, the Contract shall not be interpreted or construed against the Department, and, instead, other rules of interpretation and construction shall be used

40. MODIFICATIONS REQUIRED BY LAW. Department reserves the right to revise this Contract to include additional language required by Federal agency(ies) or other sources awarding funding to the Department in support of this Contract, if applicable, and to include changes required by Florida Administrative Code rule changes.

41. MYFLORIDAMARKETPLACE TRANSACTION FEE. The State of Florida, through DMS, has instituted MyFloridaMarketPlace, a statewide e-procurement system. Pursuant to Rule 60A-1.031, Florida Administrative Code, payments under this Contract are exempt from the MyFloridaMarketPlace transaction fee.

42. NONDISCRIMINATION.

A. Contractor certifies that no person, on the grounds of race, creed, color, religion, national origin, age, gender, or disability, shall be excluded from participation in; be denied the proceeds or benefits of; or be otherwise subjected to discrimination in performance of this Contract.

DEP Restated Contract No. GC920, Page 12 of 14

B. Contractor certifies that neither it nor any affiliate is or has been placed on the discriminatory vendor list. An entity or affiliate who has been placed on the discriminatory vendor list may not submit a bid on a contract to provide goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not award or perform work as a contractor, supplier, subcontractor or consultant under contract with any public entity, and may not transact business with any public entity. The Florida Department of Management Services (“DMS”) is responsible for maintaining the discriminatory vendor list and posts the list on its website. Questions regarding the discriminatory vendor list may be directed to the Florida Department of Management Services, Office of Supplier Diversity at

(850) 487-0915.

C. Contractor shall comply with the Americans with Disabilities Act.

43. NON-SOLICITATION. Contractor covenants and warrants that it has not employed or retained any company or person, other than a bona fide employee working solely for the Contractor to solicit or secure this Contract and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for the Contractor any fee, commission, percentage, gift or other consideration contingent upon or resulting from the award or making of this Contract.

44. NON-WAIVER OF RIGHTS. No delay or failure to exercise any right, power or remedy accruing to either party upon breach or default by the other party under this Contract, shall impair any such right, power or remedy of either party; nor shall such delay or failure be construed as a waiver of any such breach or default, or any similar breach or default thereafter.

45. ORDER OF PRECEDENCE. In the event of a conflict in terms between any of the components of this Contract, the order of precedence for resolving such conflict shall be as follows (1 being the highest precedence):

1. Body of this Contract;

2. Scope;

3. All other attachments to this Contract; and

4. Documents, agreements and exhibits incorporated herein by reference.

46. OWNERSHIP OF DOCUMENTS. All plans, specifications, maps, computer files, databases and/or reports prepared or obtained under this Contract, as well as data collected together with summaries and charts derived therefrom, shall be considered works made for hire and shall be and become the property of the Department upon completion or termination of this Contract, without restriction or limitation on their use, and shall be made available upon request to the Department at any time during the performance of such services and/or upon completion or termination of this Contract. Upon delivery to the Department of said document(s), the Department shall become the custodian thereof in accordance with Chapter 119, F.S. Contractor shall not copyright any material and products or patent any invention developed under this Contract.

47. P.R.I.D.E. When possible, the Contractor agrees that any articles which are the subject of, or required to carry out, this Contract shall be purchased from P.R.I.D.E. as specified in Chapter 946, F.S., if available, in the same manner and under the same procedures set forth in Section 946.515(2) and (4), F.S.; and for purposes of this Contract the person, firm or other business entity carrying out the provisions of this Contract shall be deemed to be substituted for this agency insofar as dealings with P.R.I.D.E. are concerned.

The "Corporation identified" is PRISON REHABILITATIVE INDUSTRIES AND DIVERSIFIED ENTERPRISES, INC. (P.R.I.D.E.) which may be contacted at:

P.R.I.D.E.

12425 28th Street, North St. Petersburg, Florida 33716-1826 Toll Free: 1-800-643-8459 Website: http://www.pride-enterprises.org/ http://www.pride-enterprises.org/

DEP Restated Contract No. GC920, Page 13 of 14

48. PUBLIC ENTITY CRIMES. A person or affiliate (as defined) who has been placed on the convicted vendor list following a conviction for a public entity crime may not perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount for Category Two (as defined in Section 287.017, F.S.), for a period of 36 months from the date of being placed on the convicted vendor list, pursuant to Section 287.133, F.S. Contractor certifies that neither it nor any affiliate has been placed on such convicted vendor list, and shall notify the Department within five (5) days of its, or any of its affiliate’s, placement thereon.

49. PUBLIC RECORDS. Public Records Requirements (Attachment F), as attached to this Contract, are hereby incorporated into the Contract.

50. RECORD KEEPING AND AUDIT.

A. Contractor shall maintain books, records and documents directly pertinent to performance under this Contract in accordance with United States generally accepted accounting principles (US GAAP) consistently applied. Department, the State, or their authorized representatives shall have access to such records for audit purposes during the term of this Contract and for five (5) years following Contract completion or termination. In the event any work is subcontracted, the Contractor shall similarly require each subcontractor to maintain and allow access to such records for audit purposes.

B. The Contractor understands its duty, pursuant to Section 20.055(5), F.S., to cooperate with the Department’s Inspector General in any investigation, audit, inspection, review, or hearing. The Contractor will comply with this duty and ensure that its subcontracts issued under this Contract, if any, impose this requirement, in writing, on its subcontractors.

51. REMEDIES. All rights and remedies provided in this Contract are cumulative and not exclusive of any other rights or remedies that may be available to the Department, whether provided by law, equity, statute, in any other agreement between the parties or otherwise. Department shall be entitled to injunctive and other equitable relief, including, but not limited to, specific performance, to prevent a breach, continued breach or threatened breach of this Contract. No remedy or election hereunder shall be deemed exclusive. A failure to exercise or a delay in exercising, on the part of the Department, any right, remedy, power or privilege hereunder shall not operate as a waiver thereof; nor shall any single or partial exercise of any right, remedy, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, remedy, power or privilege.

52. RESPECT OF FLORIDA. When possible, the Contractor agrees that any articles…