Atch 3 - Supplemental Contract Requirements.pdf

123 KB Posted

Attached to
Solicitation - Hill AFB, UT - Joint Advanced Tacticle Missile Storage Facility
Solicitation number
W91238-20-R-0015
Issued by

About this file

Written by GovTribe AI ·

This document outlines supplemental requirements for a federal construction contract. The contract requires construction of a 12,000 square foot reinforced concrete tactical missile storage facility at Hill Air Force Base in Utah within 720 calendar days. The facility will provide earth-covered storage for missiles and include supporting utilities, pavements, and site improvements. Liquidated damages for delays are $2,855 per day. Adverse weather days are provided for January through December, ranging from 1 to 22 days depending on the month. The contract will utilize the Davis-Bacon wage determination for Utah and incorporate standards for lightning protection, fire detection and suppression, and intrusion detection.

View the file

Other files

File Type Posted
SF 30 P0003 Amendment.pdf PDF
SF 30 Solicitation Amendment 20R00150002.pdf PDF
HAFB Missile Storage Facility Pre-Bid Site Walk_KTR sign-in roster.pdf PDF
SF 30 Mod 20R00150001.pdf PDF
SF 1442 Hill AFB JATM Facility.pdf PDF
Atch 4 - DavisBaconWagesBuilding - Davis Cty_01012021.pdf PDF
Atch 7 - Contractors Project Experience.pdf PDF
Atch 1 - SPEC 2323 FINAL RFP_MSF HAFB_082420.pdf PDF
Atch 5 - Site Walk for Missile Storage Facility 06APR2021.pdf PDF
Atch 2 - Consolidate Missile Storage Facility_drawings.pdf PDF
Atch 6_Utah Resident Office Map.pdf PDF
Show all 11

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file
Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

Attachment 2

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period: Refer to contract section 00700, FAR 52.211-10. The performance period for the work stated above shall be 720 calendar days.

2. Liquidated Damages: Refer to contract section 00700, FAR 52.211-12, Liquidated Damages-Construction. Liquidated damages for this work are $2,855.00 for each day of delay.

3. Authorities: “Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.”

4. Wage Determination: General Decision No. UT20200083, or its most current modification at the time of award is hereby applicable to work performed under this task order. The most current decision or its modification can be found at https://beta.sam.gov/wage-determination/UT20200083/0?index=wd&is_active=true&date_filter_index=0&date_rad_selecti on=date&wdType=dbra&state=UT&county=17774&page=1

6. Time Extensions For Unusually Severe Weather: Refer to FAR 52.249.10, Default (Fixed- Priced Construction). All weather delay will need to be submitted and approved by the Contracting Officer Representative.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK-HILL AFB

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(22) (19) (15) (07) (04) (03) (01) (02) (02) (05) (15) (22) https://beta.sam.gov/wage-determination/UT20200083/0?index=wd&is_active=true&date_filter_index=0&date_rad_selection=date&wdType=dbra&state=UT&county=17774&page=1 https://beta.sam.gov/wage-determination/UT20200083/0?index=wd&is_active=true&date_filter_index=0&date_rad_selection=date&wdType=dbra&state=UT&county=17774&page=1 https://beta.sam.gov/wage-determination/UT20200083/0?index=wd&is_active=true&date_filter_index=0&date_rad_selection=date&wdType=dbra&state=UT&county=17774&page=1

SUPPLEMENTAL CONTRACT REQUIREMENTS

File details come from the government source that posted it. Updated .