C - SECTION F_deliveries_performance.doc

CIM-0907-3A-006-0907-01

SECTION F--DELIVERIES OR PERFORMANCE

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.arnet.gov/far/

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

0. Stop Work Order (AUG 1989) 52.242-17 Government Delay of Work (APR 1984)

AGAR 452.211-75 Effective Period of Contract The effective period of this contract is from date of contract award through August 15, 2010.

The Forest Service will issue a Notice to Proceed as soon as conditions are favorable for remediation to occur. Generally projects are delayed due to weather and/or migratory wildlife patterns. Contract time will start whichever is sooner: (1) on the date specified on the Notice to Proceed, if the notice is hand-delivered; or (2) Contract Time will start on the third-day after the post office has issued a Notice of Certified Mail to the Contractor; or (3) Contract Time will start when remediation commences. Failure of the Contractor to pick-up Certified Mail will not be considered excusable.

If contractor decides the best option for delivery to some shafts is by snowmobile, the contractor will notify the Forest Service.

Unsuitable Conditions Whenever it is determined that environmental or physical conditions become unsuitable for the safe remediation of a feature or features the Contractor shall move to another feature identified by the Contractor and agreed to by the Contracting Officer, or take other mitigating actions to improve the situation agreed to by the Contracting Officer. When there is no acceptable mitigating practice and no other area is available, the Contracting Officer shall suspend work and stop the contract time. When conditions are again suitable, the Contracting Officer will issue an oral Resume Work Order and confirm that order in writing. The count of contract time will resume on the day indicated by the Contracting Officer. If the Contractor fails to keep in contact with the COR consistent with Section C.4.8, a written Resume Work Order will be mailed and the count of days of contract time will resume on the date specified in that order. Unsuitable conditions include, but are not limited to, heavy rainfall, heavy snowfall, wildlife or archeology mitigation, temperature and humidity are outside of specifications for installation of PUF or safety related conditions.

Work completed after the performance period Whenever the Contractor fails to complete work within the performance period, and is allowed to work beyond that period, the Contractor will be assessed the actual damages. Items to be included in the actual damage include but are not limited to: wages of the COR and Government inspector(s) for quality assurance after the performance period, and costs of vehicles that are incurred while administering the contract after the performance period.

FAR 52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984).

At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.