Attachment_2_ _3_in_MS_Word_Format.docx

33 KB Posted

Attached to
Clear Creek Rec Area Waterline Replacement
Solicitation number
AG-4146-S-13-0006
Issued by

About this file

From the source

Attachment 2 3 in MS Word Format

View the file

Other files

File Type Posted
Amendment_000001_AG-4146-S-13-0006_with_atch.pdf PDF
Solicitation_AG-4146-S-13-0006.pdf PDF
Attachment_5 _Drawings_AG-4146-S-13-006.pdf PDF
Attachment_4 _Specifications_Waterline_Replacement.pdf PDF

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file
Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

Clear Creek Waterline Replacement, Bankhead National Forest ServiceAG-4146-S-13-0006
30

ATTACHMENT 2 –Experience Questionnaire Instructions: See Box 11, remarks, if extra space is needed to answer any item below. Additional sheets may be attached.

1. Contractors Name, Address & Telephone No.

2. Type of Business __Company __Co-Partner __Non-profit __Corporation __Individual

3. Howmany years experience do you have in this line of work____Yrs

4. How many years experience as a prime contractor_____ subcontractor___

1. LIST OF PROJECTS YOUR BUSINESS HAS COMPLETED WITHIN THE LAST 3 YEARS

NOTE: The description of work performed should be in sufficient detail for the Government to determine what the work included. i.e. Type of waterline system, size, quantity, any special requirements or other related repairs/construction.) Use of only a project title does not usually provide enough detail for the Government to make an evaluation.

Project & Location ________________________________________________________________________________________________ Contract Number:_______________________________ Award Amount: ________________________________________________ Period of Performance and/or completion date: ________________________________________________________________________ Client/Company’s Name/Address: __________________________________________________________________________________ Contact Name, email and Telephone number: ________________________________________________________________________ Description of Services (refer to note in No. 5 type of waterline system, etc.) ______________________________________________________________________________________________________________

Project & Location ________________________________________________________________________________________________ Contract Number:_______________________________ Award Amount: ________________________________________________ Period of Performance and/or completion date: ________________________________________________________________________ Client/Company’s Name/Address: __________________________________________________________________________________ Contact Name, email and Telephone number: ________________________________________________________________________ Description of Services (refer to note in No. 5 type of waterline system, etc.) ______________________________________________________________________________________________________________

Project & Location ________________________________________________________________________________________________ Contract Number:_______________________________ Award Amount: ________________________________________________ Period of Performance and/or completion date: ________________________________________________________________________ Client/Company’s Name/Address: __________________________________________________________________________________ Contact Name, email and Telephone number: ________________________________________________________________________ Description of Services (refer to note in No. 5 type of waterline system, etc.) ______________________________________________________________________________________________________________

Project & Location ________________________________________________________________________________________________ Contract Number:_______________________________ Award Amount: ________________________________________________ Period of Performance and/or completion date: ________________________________________________________________________ Client/Company’s Name/Address: __________________________________________________________________________________ Contact Name, email and Telephone number: ________________________________________________________________________ Description of Services (refer to note in No. 5 type of waterline system, etc.) ______________________________________________________________________________________________________________

6a. Have you ever failed to complete any work awarded to you? __yes __ no

6b. Has work ever been completed by performance bond? __yes __ no

6. If "yes" to either item 6a or 6b specify location(s) and reason(s) why

7. List the experience of the primary individuals to perform on proposed project

INDIVIDUALS NAME
PRESENT POSITION
DEGREE/YRS EXP
TYPE OF WORK

8. Information required to complete a responsibility determination of the apparent successful offeror. (Additional information may be requested once a contractor is selected for award.. Moreover, the contractor might need to provide additional authorization from a creditor to grant access.)

a. Credit References

9. REMARKS (Additional sheets may be attached to the experience questionnaire)

CERTIFICATION: I certify that all of the statements made by me are complete and correct to the best of my knowledge and that any persons named as references are authorized to furnish the Forest Service with any information needed to verify my capability to perform this project:

Name:

Title:
Date:

CERTIFICATION: I certify that all of the statements made by me are complete and correct to the best of my knowledge and that any persons named as references are authorized to furnish the Forest Service with any information needed to verify my capability to perform this project:

Name:

Title:
Date:

ATTACHMENT 3* – Past Performance Questionnaire (PPQ)

SECTION I: CONTRACTOR INFORMATION

A. Your Company Name and Address:_____________________________________________________

_____________________________________________________
_____________________________________________________

B. Phone /Fax #: _____________________________________________________________________

C. Point of Contact/email address: ________________________________________________________

D Authorization is hereby granted to provide the information requested in SECTION II and III of this questionnaire.

Signature of Authorized Contractor Representative Date

Printed Name and Title of Authorized Contractor Representative

SECTION II: RESPONDENT INFORMATION: Request a reference from respondent by completing Section II and III and return to myeaton@fs.fed.us or Fax – 334-241-8177

A. Client/Reference Name and Address: ___________________________________________________

B. Phone/Fax #: ______________________________________________________________________

C. Point of Contact/email address: ________________________________________________________

D. Reference Contract Number: __________________________________________________________ Project Title _______________________________________________________________________ Contract Value/Type: ________________________________________________________________ Period of Performance: _______________________________________________________________ How long have you worked with the contractor: ___________________________________________ More detailed description of the work performed____________________________________________

E. Date completed: ___________________________________________________________________

RATING
DEFINITION
E= Exceptional/High Confidence
Based on the contractor’s performance record, essentially no doubt exists that the contractor will successfully perform the required effort.
VG=Very Good/Significant Confidence
Based on the contractor’s performance record, little doubt exists that the contract will successfully perform the required effort.
S=Satisfactory/Confidence
Based on the contractor’s performance record, some doubt exists that the contractor will successfully perform the required effort.
N=Neutral/Unknown Confidence
No performance record identifiable (see FAR 15.305(a)(2) (iii) and (iv)).
M=Marginal/Little Confidence
Based on the contractor’s performance record, substantial doubt exists that the contractor will successfully perform the required effort. Changes to the contractor’s existing processes may be necessary in order to achieve contract requirements.
U=Unsatisfactory/No Confidence
Based on the contractor’s performance record, extreme doubt exists that the contractor will successfully perform the required effort.

SECTION III: PERFORMANCE EVALUATION

A. CONTRACT PERFORMANCE

1.
Working relationship with your Company?
E
VG
S
N
M
U
2.
How well did the contractor provide experienced workers, managers and supervisors with the technical and administrative abilities needed?
E
VG
S
N
M
U
N/A
3.
Did the contractor exhibit knowledge of and compliance with government (or other) regulations and industry standards?
E
VG
S
N
M
U
N/A
4.
How well did the contractor provide and properly maintain operational equipment throughout the term of the contract?
E
VG
S
N
M
U
N/A
5.
Did the contractor demonstrate the ability to hire, maintain, and replace, if necessary qualified personnel during the contract?
E
VG
S
N
M
U
N/A
6.
How well did the contractor comply with Environmental, health, labor laws, safety and security requirements?
E
VG
S
N
M
U
N/A
7.
How well did the contractor coordinate and control subcontractors, if any?
E
VG
S
N
M
U
N/A
8.
Contractor’s Overall Performance
E
VG
S
N
M
U

B. QUALITY OF SERVICE/CONTROL

1.
Contractor’s accomplishment in meeting the quality standards
E
VG
S
N
M
U
N/A
2.
The contractor provided an effective quality control plan or inspection procedures to meet contract requirements? If no, please explain.
E
VG
S
N
M
U
N/A
3.
Contractor identified and corrected deficient Work
E
VG
S
N
M
U
N/A
4.
Contractor’s Overall Quality of Workmanship
E
VG
S
N
M
U

TIMELINESS OF PERFORMANCE

1.
How well did the contractor comply with the contract schedule?
E
VG
S
N
M
U
N/A
2.
Did the contractor provide timely and accurate records, submittals, and/or reports?
E
VG
S
N
M
U
N/A
3.
How well did the contractor resolve any delays?
E
VG
S
N
M
U
N/A

REMARKS: For ratings above or below satisfactory, please provide remarks to describe the reasons for the rating. If additional remarks are necessary, please attach an additional sheet. ____________________________________________________

File details come from the government source that posted it. Updated .