70Z08524RLREP0001A0001_Solicitation Amend 1.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE 1 OF PAGES 4

2. AMENDMENT/MODIFICATION NO. 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

A0001

3. EFFECTIVE DATE

12/18/2023

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

USCG Surface Forces Logistics Center Attn:

E-mail: @uscg.mil

8. NAME AND ADRESS OF CONTRACTOR (no., street, county, State and ZIP Code) 9.A AMENDMENT OF SOLICITATION NO.

70Z08524RLRP0001

9B. DATE (SEE ITEM 11)

12/18/2023

10A. MODIFICATION OF CONTRACT/ORDER

NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended. Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing Items 8 and 15, and returning 1 copy of the amendment; (b) By acknowledging receipt of this amendment on each copy of the Offer submitted: or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT/.ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc) SET FORTH IN ITEM 14, PURSUANT TO AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority).

E. IMPORTANT: Contractor is not, is required to sign this document and return 1 copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

DS FY2 FYQ Rev1 See next page.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remain unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070 30-105 STANDARD FORM 30 (REV. 10-83)

)PREVIOUS EDITION UNUSABLE Prescribed by GSA, FAR (48 CFR) 53.

CONTINUATION OF SF 30 – BLOCK 14

70Z08524RLREP0001 is hereby amended (70Z08524RLREP0001A0001) as follows:

The Solicitation document has been updated with 70Z08524RLREP0001A0001 to add the SF 1449 document Pages 1 & 2.

Attached are responses to four Requests for Clarification (see attached).

3. The solicitation closing date and time remains unchanged as 21 December 2023 at 1500 Pacific Standard Time.

4. All other terms and conditions remain unchanged.

Request for Clarification Attachment (5)

Solicitation No.: 70Z08524RLREP0001

Request for Clarification

Solicitation No.: 70Z08524RLREP0001

Date: 12/15/2023

Question No. 1

Section: Requirements for Quote Content Para. No.:

Work Item No.: Para. No.:

Title: Proposal Submission Para. No.:

Question: The solicitation package specifically lists what is to be included in Parts I – III and submitted. There are several other submissions required under Paragraph B of Instructions to Offerors that are not mentioned in the

Requirements for Quote Content. Which Part/Factor should these additional items be included with? Or should they be submitted as single pdf files for each item or combined and sent as a single additional PDF?

Answer: The items listed under Paragraph B should be submitted as single pdf file for each of the required document. For example, all welding Certification documents can be submitted as a single PDF document. The

PDF document can contain multiple pages if necessary.

Request for Clarification

Solicitation No.: 70Z08524RLREP0001

Date: 12/15/2023

Question No. 2

Section: Instructions to Offerors Para. No.:

Work Item No.: Para. No.:

Title: Required Documents Para. No.: iii

Question: What is the government preferred program for use for the Integrated Production Schedule? Is Microsoft

Project adequate for use to submit the Integrated Production Schedule?

Answer: The government doesn’t have a preferred program for the Integrated Production Schedule. MS

Project is adequate for providing the Integrated Production Schedule.

Request for Clarification

Solicitation No.: 70Z08523RLREP0004

Date: 12/15/2023

Question No. 3

Section: Para. No.:

Work Item No.: ALL WORK ITEMS 1-8 Para. No.:

Title: CRITICAL PATH ITEMS Para. No.:

Question: REQUESTING OF THE 8 ITEMS WHICH ONE DO YOU CONSIDER A CRITICAL PATH ITEM?

Request for Clarification Attachment (5)

Solicitation No.: 70Z08524RLREP0001 Answer: The Government doesn’t identify which items should be labeled as critical Path items. That determination is left to the contractor to decide. However, any work item designated as a critical path item by the contractor should be clearly identified.

Request for Clarification

Solicitation No.: 70Z08523RLREP0004

Date: 12/18/2023 10:51 AM EST

Question No. 4

Section: SOLICITATION Para. No.:

Work Item No.: none Para. No.:

Title: 1449 and SF-30 Para. No.:

Question: I don’t not see a 1449 or SF-30s in the REV1 Solicitation. Are we supposed to use the original ones?

Answer: The solicitation has been updated to include the SF 1449 document.