526-14-111 Spec 9-1-15 - Copy.pdf

Consulting Engineers In: NY, NJ, PA, CT, VT, MA, RI

100% SPECIFICATIONS

Install Advanced Metering System Phase II Project No. 246-14-C-0170 www.fellp.com

Prepared By:

Fellenzer Engineering, LLP 22 Mulberry Street, Suite 2A

Middletown, NY 10940 845-343-1481

Contacts: Mark D. Fellenzer, P.E.:

Prepared For:

James J. Peters VA Medical Center 130 Kingsbridge Road Room 9B-62 Bronx, NY 10468-3904 Attn: Thomas Liu

September 1, 2015

F E

P ro je ct

N o.

4-

JAMES J. PETERS VA MEDICAL CENTER

130 West Kingsbridge Road

Bronx, NY 10468-3904

JAMES J. PETERS MEDICAL CENTER

INSTALL ADVANCED METERING SYSTEM PHASE II

VA PROJECT NO.246-14-C-0170

05-01-14

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 15 List of Drawing Sheets 09-11

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 10-13 01 33 23 Shop Drawings, Product Data, and Samples 11-08 01 35 26 Safety Requirements 10-14 01 42 19 Reference Standards 09-11 01 58 16 Temporary Interior Signage 08-11 01 74 19 Construction Waste Management 09-13 01 81 11 Sustainable Design Requirements 02-13 01 91 00 General Commissioning Requirements 06-13

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 04-13

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 84 00 Firestopping 10-11

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 04-11 22 05 19 Meters and Gages for Plumbing Piping 07-14 22 07 11 Plumbing Insulation 05-11 22 08 00 Commissioning of Plumbing Systems 06-13 22 11 00 Facility Water Distribution 01-14

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 11-10 23 08 00 Commissioning of HVAC Systems 06-13 23 11 23 Facility Natural-Gas Piping 02-15 23 21 13 Hydronic Piping 08-12 23 22 13 Steam and Condensate Heating Piping 02-15

DIVISION 25 – INTEGRATED AUTOMATION

25 10 10 Advanced Utility Metering System 02-10

05-01-14

00 01 10-2

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 12-12 26 05 13 Medium-Voltage Cables 12-12 26 05 19 Low-Voltage Electrical Power Conductors and Cables 07-13 26 05 26 Grounding and Bonding for Electrical Systems 12-12 26 05 33 Raceway and Boxes for Electrical Systems 05-14 26 08 00 Commissioning of Electrical Systems 06-13

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 11-09 27 05 26 Grounding and Bonding for Communications Systems 10-06 27 05 33 Raceways and Boxes for Communications Systems 12-05 27 08 00 Commissioning of Communications Systems 06-13 27 10 00 Structured Cabling 12-05 27 11 00 Communications Equipment Room Fittings 06-13 27 15 00 Communications Horizontal Cabling 06-13

09-11

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title

ELECTRICAL

GI-001 COVER & INDEX OF DRAWINGS

GI-002 GENERAL SYSTEM SCHEMATIC & SCOPE

GI-003 GENERAL INFORMATION, SUMBOLS, ABBREVIATIONS, DETAILS & NOTES

GI-004 CHILLED WATER METERING RISER DIAGRAM (CAMPUS)

GI-005 STEAM METERING RISER DIAGRAM (CAMPUS)

GI-006 NATURAL GAS METERING RISER DIAGRAM (CAMPUS)

GI-007 DOMESTIC COLD WATER METERING RISER DIAGRAM (CAMPUS)

GI-008 ELECTRICAL METERING ONE-LINE DIAGRAM (BUILDING 100)

GI-009 ELECTRICAL METERING ONE-LINE DIAGRAM (BUILDING 100,

RISERS A, B, C)

GI-010 ELECTRICAL METERING ONE-LINE DIAGRAM BUILDING 100,

RISERS D, E, F, G, DA)

GI-011 ELECTRICAL METERING ONE-LINE DIAGRAM (BUILDING 105 SOUTH)

GI-012 ELECTRICAL METERING ONE-LINE DIAGRAM (BUILDING 105 NORTH)

GI-013 ELECTRICAL METERING ONE-LINE DIAGRAM (BUILDING 106)

GI-014 ELECTRICAL METERING ONE LINE DIAGRAM (BUILDINGS 16,101,107,110)

GS-001 CAMPUS SITE PLAN

GS-002 CAMPUS TUNNEL SYSTEM PLAN

100-EI-100W ELECTRICAL INSTRUMENTATION: BLDG 100 GROUND FLOOR PLAN – WEST

100-EI-100E ELECTRICAL INSTRUMENTATION: BLDG 100 GROUND FLOOR PLAN – EAST &

CENTRAL

100-EI-101W ELECTRICAL INSTRUMENTATION: BLDG 100 FIRST FLOOR PLAN – WEST

100-EI-101E ELECTRICAL INSTRUMENTATION: BLDG 100 FIRST FLOOR PLAN – EAST &

CENTRAL

100-EI-102W ELECTRICAL INSTRUMENTATION: BLDG 100 SECOND FLOOR PLAN – WEST

100-EI-102E ELECTRICAL INSTRUMENTATION: BLDG 100 SECOND FLOOR PLAN – EAST &

CENTRAL

100-EI-103W ELECTRICAL INSTRUMENTATION: BLDG 100 THIRD FLOOR PLAN – WEST

100-EI-103E ELECTRICAL INSTRUMENTATION: BLDG 100 THIRD FLOOR PLAN – EAST &

CENTRAL

100-EI-104 ELECTRICAL INSTRUMENTATION: BLDG 100 FOURTH FLOOR PLAN

100-EI-105 ELECTRICAL INSTRUMENTATION: BLDG 100 FIFTH FLOOR PLAN

09-11

00 01 15 - 2

100-EI-106 ELECTRICAL INSTRUMENTATION: BLDG 100 SIXTH FLOOR PLAN

100-EI-107 ELECTRICAL INSTRUMENTATION: BLDG 100 SEVENTH FLOOR PLAN

100-EI-108 ELECTRICAL INSTRUMENTATION: BLDG 100 EIGHTH FLOOR PLAN

100-EI-109 ELECTRICAL INSTRUMENTATION: BLDG 100 NINTH FLOOR PLAN

100-EI-110 ELECTRICAL INSTRUMENTATION: BLDG 100 PENTHOUSE FLOOR PLAN

16-EI-101 ELECTRICAL INSTRUMENTATION: BLDG 16 BASEMENT FLOOR PLAN

101-EI-101 ELECTRICAL INSTRUMENTATION: BLDG 101 FLOOR PLAN

105-EI-101 ELECTRICAL INSTRUMENTATION: BLDG 105 GROUND, FIRST & SECOND

FLOOR PLANS

105-EI-102 ELECTRICAL INSTRUMENTATION: BLDG 105 GROUND, THIRD, FOURTH,

FIFTH & PENTHOUSE FLOOR PLANS

106-EI-101 ELECTRICAL INSTRUMENTATION: BLDG 106 BASEMENT & FIRST FLOOR

PLANS

106-EI-102 ELECTRICAL INSTRUMENTATION: BLDG 106 SECOND & PENTHOUSE FLOOR

PLANS

107-EI-101 ELECTRICAL INSTRUMENTATION: BLDG 107 FLOOR PLAN

110-EI-101 ELECTRICAL INSTRUMENTATION: BLDG 110 FLOOR PLAN

EI-701 ELECTRICAL INSTRUMENTATION: COORDINATED METER SCHEDULES

EI-702 ELECTRICAL INSTRUMENTATION: DATA PROCESSING HARDWARE/SOFTWARE

EI-801 ELECTRICAL INSTRUMENTATION: DETAILS

EI-802 ELECTRICAL INSTRUMENTATION: DETAILS

EI-803 ELECTRICAL INSTRUMENTATION: DETAILS

EI-804 ELECTRICAL INSTRUMENTATION: DETAILS

EI-805 ELECTRICAL INSTRUMENTATION: MANUFACTURES METER DETAILS

- - - END - - -

12‐07M i

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 GENERAL INTENTION

1.2 STATEMENT OF BID ITEM(S)

1.3 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR ...................................................... …4

1.4 CONSTRUCTION SECURITY REQUIREMENTS

1.5 OSHA REQUIREMENTS-SAFETY AND HEALTH REGULATIONS

1.6 SPECIFIC MEDICAL CENTER FIRE & SAFETY POLICIES, PROCEDURES, AND

REGULATIONS

1.7 FIRE SAFETY

1.8 HOT WORK PERMIT

1.9 OPERATIONS AND STORAGE AREAS

1.10 ALTERATIONS

1.11 INFECTION PREVENTION MEASURES

1.12 DISPOSAL AND RETENTION

1.13 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS

1.14 RESTORATION

1.15 PHYSICAL DATA

1.16 PROFESSIONAL SERVICES

1.17 LAYOUT OF WORK

1.18 AS-BUILT DRAWINGS

1.19 USE OF ROADWAYS

1.20 TEMPORARY USE OF EXISTING ELEVATORS (NOT APPLICABLE)

1.21 TEMPORARY TOILETS

1.22 AVAILABILITY AND USE OF UTILITY SERVICES

1.23 NEW TELEPHONE EQUIPMENT (NOT APPLICABLE)

1.25 INSPECTION AND TESTS

1.26 INSTRUCTIONS

1.27 GOVERNMENT-FURNISHED PROPERTY (NOT APPLICABLE)

1.28 RELOCATED EQUIPMENT ITEMS

1.29 HISTORIC PRESERVATION

1.30 SMOKE BARRIER PENETRATION PERMIT

1.31 CONTRACTOR PARKING

1.32 CONTRACTOR IDENTIFICATION BADGES

1.33 CONFINED SPACE ENTRY

1.34 ACCESS INTO KEYED AREAS

1.35 PROTECTIVE CLOTHING/EQUIPMENT

1.36 FEDERAL POLICE

1.37 LOST AND FOUND

1.38 REMOVAL OF GOVERNMENT PROPERTY

12‐07M ii

1.39 SEXUAL HARASSMENT

1.40 DRUGS AND ALCOHOL

1.41 FIREARMS AND EXPLOSIVES

1.42 INJURY ACCIDENTS

1.43 RECREATIONAL FACILITIES

1.44 DUST AND FUME CONTROL

1.45 NOISE

1.46 INSPECTION AND APPROVAL

1.47 SUBMITTALS

1.48 CONTRACT WORK HOURS

1.49 CONSTRUCTION SIGN

1.50 SAFETY SIGN (Not Applicable)

1.51 CONSTRUCTION DIGITAL IMAGES (Not Applicable)

1.52 SCHEDULES FOR CONSTRUCTION CONTRACTS

1.53 MINIMUM HOURLY RATE OF WAGES

1.54 VA TRIRIGA CPMS

01 00 00 - 1

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for

James J Peters VA Medical Center, Advanced Utility Metering, as required by drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the Medical Center

Facility Management Service Center (FMSC).

C. Testing of materials is the responsibility of the Contractor. All testing is to be performed by a qualified, licensed testing laboratory selected by the Contractor, approved by the Contracting Officer. Before placement and installation of work subject to tests by testing laboratory, the Contractor shall notify the COR in sufficient time to enable testing laboratory personnel to be present at the site in time for proper taking and testing of specimens and field inspection, if elected, by a government representative. Prior notice shall be not less than three workdays unless otherwise designated by the COR.

D. The construction site (and staging areas when required) shall be enclosed with a chain link fence during construction to ensure pedestrian and vehicle safety. Furthermore, the

Contractor shall, at all times, maintain at least one clear lane for vehicle ingress and egress, and emergency vehicle access. The Contractor shall provide unimpeded access for vehicles at all times. This shall be accomplished by the use of flagmen, signage, and other directional indicators.

E. All employees of general contractor, subcontractors, and sub-subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified with a VA issued photo ID, and restricted from unauthorized access. All contractor visitors and employees identified as not having proper identification will be dismissed from the Medical Center grounds until such time as proper ID has been obtained. All employees of the general contractor, subcontractors and sub-subcontractors will be required to be made available to Police Service to apply for photo identification

01 00 00 - 2 badge and fingerprinting following badge production the employee shall return in person to receive issue of the badge. The Contractor and subcontractors are responsible to furnish the names of all employees scheduled to work to the COR within ten days of the

Notice to Proceed. The contractor shall identify on the construction schedule of work the date for start of work of short term specialty subcontractors and two weeks prior to start of work process identification badge verification for employee issue prior to starting of work (Employees not issued identification badges will have to leave the site at no addition cost to the government.) Refer to Section # 01 33 23 SAMPLES AND SHOP

DRAWINGS.

F. Prior to commencing work, general contractor shall provide proof that a OSHA certified

“competent person” (CP) (29 CFR 1926.20(b)(2) will maintain a presence at the work site whenever the general or subcontractors are present.

G. Training:

1. Beginning July 31, 2005, all employees of general contractor or subcontractors shall have the 30-hour for the Competent Person(s) and all others shall have 10-hour

OSHA certified Construction Safety course and /or other relevant competency training, as determined by VA CP with input from the ICRA team.

2. Submit training records of all such employees for approval before the start of work.

Refer to Section # 01 33 23 SAMPLES AND SHOP DRAWINGS.

I. Superintendent and Project Manager

1. The Superintendent shall be an employee of the Prime contractor or in writing assign a worksite competent superintending with authority to act as the contractor, responsible for the day-to-day operations at the construction site, planning, quality control, verification of delivery of approved material and equipment, subcontractor coordination responsibilities and execution of the complete project as per the contract documents. The superintendent shall have no hands-on construction interaction. In addition, the superintendent shall provide proof to the COR regarding completion of

30 hour OSHA.

01 00 00 - 3

2. The Superintendent shall sign-in at the beginning of each day of work and Sign-out at the end of the work day at the Office of FMSC. No work shall be performed by any contractors or subcontractors without the presence of the superintendent at the actual work site.

3. The Superintendent shall be responsible for submitting daily work logs to the COR at the end of every work day.

4. The Prime contractor shall provide services of a Project manager whose responsibilities would include but not be limited to providing support to the

Superintendent at the job site and shall be responsible for finance related tasks and scheduling.

5. FMSC Office 8:00 AM – 4:30 PM

6. Off-duty hours check-in shall be arranged with the COR.

J. Electrical Work Permit

The contractor shall complete the VA Electrical Work Permit with the COR and submit to the COR a minimum of 48 hours prior to start of electrical work within the facility.

K. The contractor shall have all employees working on this project have a background testing for Tuberculosis with results available upon request from the Medical Center.

The contractor will provide a signed memo stating the employee’s name and date of last

Tuberculosis test on company letter head. See spec section 01 35 26 Safety

Requirements.

M. Offices of Fellenzer Engineering as Engineers will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

01 00 00 - 4

1.2 STATEMENT OF BID ITEM(S)

A. Base Bid - The contractor will furnish all materials, equipment, supervision, and personnel necessary to accomplish the job for removal and installation of the new metering systems and associated components on the new concrete pads as shown on the drawings and perform work specified herein and comply with VA specifications and VA regulations, procedures and conditions for work at the Medical Center and any applicable codes as per requirements of all governing agencies. Work shall include selective demolition and modifications of existing walls, ceilings, ductwork, registers, etc. debris disposal, all new work: ducts, ceiling systems, wall finishing, fire sprinkler and alarm work, electrical work, operational and final system testing and balancing and other related and ancillary work.

Contractor will be responsible to coordinate and schedule work to minimize to short duration and shall be expected to plan work typically during duty hours of the hospital other than utility ties ins during off duty hours.. Construction Phasing will be required to ensure that the metering system equipment, associated components; fabricated materials are stored on site at the time of shutdown of the affected department operations and timely manner to complete construction for re-activation of operations. Maintain all access to and egress from the buildings at all times for facility’s fire protection requirements and to meet the requirements of regulatory codes, laws, etc.

Completion Time of 365 Calendar Days from Notice to Proceed.

1.3 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. After award of Contract, Drawings and specifications may be obtained from the website where the solicitation is posted.

1.4 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

01 00 00 - 5

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. For working outside the “regular hours” as defined in the contract, The General

Contractor shall give one week’s notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the

Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General

Contractor’s employees off the premises in the event of a national emergency. The

General Contractor may return to the site only with the written approval of the

Contracting Officer.

C. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the

COR for the purpose of security inspections of every area of project including tool boxes and parked machines and take any emergency action.

2. The General Contractor shall turn over all permanent lock cylinders to the VA locksmith for permanent installation. See Section 08 71 00, DOOR HARDWARE and coordinate.

D. Document Control:

1. Before starting any work, the General Contractor/Sub Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of “sensitive information”.

01 00 00 - 6

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

4. Certain documents, sketches, videos or photographs and drawings may be marked

“Law Enforcement Sensitive” or “Sensitive Unclassified”. Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the Contracting Officer upon request.

5. These security documents shall not be removed or transmitted from the project site without the written approval of Contracting Officer.

6. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

7. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

8. All electronic information shall be stored in specified location following VA standards and procedures using an Engineering Document Management Software

(EDMS).

a. Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the EDMS system.

b. “Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

E. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. Separate permits shall be issued for General Contractor and its employees for parking in designated areas only.

01 00 00 - 7

1.5 OSHA REQUIREMENTS-SAFETY AND HEALTH REGULATIONS

A. Contractors are required to comply with the Occupational Safety and Health

Standard found in CFR 1910 and 1926. Copies of these statements can be acquired from the Superintendent of Documents, U.S. Government Printing Office Washington, D.C.

20420.

B. In addition, the Contractor will be required to comply with all applicable Medical

Center fire, safety, and security regulations, policies and procedures. Each of the

Contractor's employees, inclusive of subcontractors and their employees will be required to read this section, sign, and acknowledge understanding. Signed acknowledgment must be filed with the Contracting Officer prior to any employee's assignment to the work site.

C. Contractors involved with the removal, alteration, or disturbance of asbestos type insulation or materials will be required to comply strictly with the regulations found in

CFR 1910.1001 and the appropriate EPA regulations regarding disposal of asbestos.

Assistance in identifying asbestos can be requested from the Medical Center's Industrial

Hygienist and the COR.

D. Contractors entering locations of asbestos contamination shall be responsible for providing respiratory protection to their employees and ensuring respirators are worn in accordance with OSHA (CFR 1910.1001(g)). Asbestos contaminated areas shall be defined on project drawings. The minimum equipment required shall be: a half-mask air-purifying respirator equipped with high efficiency filters and disposable Type coveralls.

E. Contractor, along with other submittals, and at least two weeks prior to bringing any materials on-site, must submit a complete list of chemicals the contractor will use and MSDS for all hazardous materials brought on-site.

F. Severe or constant violations may result in an immediate work stoppage or request for a Compliance Officer from the Occupational Safety and Health

Administration.

01 00 00 - 8

1.6 SPECIFIC MEDICAL CENTER FIRE & SAFETY POLICIES, PROCEDURES,

AND REGULATIONS

A. INTRODUCTION

1. The safety and fire protection of patients, employees, members of the public and government is one of the continuous concerns of this Medical Center.

2. Contractors, their supervisors, and employees are required to comply with Medical

Center policies to ensure the occupational safety and health of all. Failure to comply may result in work stoppage.

3. While working at this Medical Center, contractors are responsible for the Occupational

Safety and Health of their employees. Contractors are required to comply with the applicable OSHA standards found in 20 CFR 1910 for general industry and 29 CFR 1926 for construction. Failure to comply with these standards may result in work stoppage and a request to the Area director of OSHA for a compliance office to inspect the work site.

4. Contractors are to comply with the requirements found in the National Fire Protection

Association (NFPA) #241, "Building construction and Demolition Operation".

5. Questions regarding occupational safety and health issues can be addressed to the

Medical Center Safety and Occupational Health Manager at Ext. 6605.

B. FIRES

All fires must be reported. In the event of a fire in the work area, use the nearest pull box station and also notify Medical Center staff in the immediate area. Emergency notification can also be accomplished by dialing ext. 1111. Be sure to give the exact location from where you are calling. If a contractor has experienced a fire and it was rapidly extinguished, you still must notify the Medical Center Safety and Occupational

Health Manager so that an investigation of the fire can be accomplished. Delay in reporting a fire is unacceptable.

C. FIRE ALARMS, SMOKE DETECTION, AND SPRINKLER SYSTEM

01 00 00 - 9

If the nature of your work requires the deactivation of the fire alarm, smoke detection or sprinkler system, you must notify the Medical Center Safety and Occupational Health

Manager. Notification must be made well in advance so that ample time can be allowed to deactivate the system and provide an alternative measure for fire protection. Under no circumstance is a contractor allowed to deactivate any of the fire protection systems in this Medical Center.

D. SMOKE DETECTORS

False alarms will not be tolerated. You are required to be familiar with the location of the smoke detectors in your work area. When performing cutting, burning, or welding or any other operation that may cause smoke or dust, you must take steps to temporarily cover smoke detectors in order to prevent false alarms. Failure to take the appropriate action will result in the Contracting Officer assessing actual costs for government response for each false alarm that is preventable. Prior to covering the smoke detectors, the contractor will notify the VAMC Safety and Occupational Health Manager, who will also be notified when the covers are removed.

E. HOT WORK PERMIT

1. If the nature of the work requires the use of welding equipment, cutting torch, soldering equipment or the performance of processes which produce sparks, heat or combustion, it will be required that the contractor notify the COR no less than one day in advance of such work. The VAMC Safety and Occupational Health Manager will inspect the work area and issue a "Hot Work Permit" authorizing the performance of such work.

2. A "Hot Work Permit" will be issued only for the period necessary to perform such work.

3. Contractors will not be allowed to perform hot work processes without the appropriate permit.

F. TEMPORARY ENCLOSURES

01 00 00 - 10

Only non-combustible materials will be used to construct temporary enclosures for barriers at this Medical Center. Plastic materials and fabrics used to construct dust barriers must conform to NFPA #701, Standard Methods of fire Tests for Flame-

Resistant Textiles and Films.

G. FLAMMABLE LIQUIDS

All flammable liquids will be kept in approved safety containers. Only the amount necessary for your immediate work will be allowed in the building. Flammable liquids must be removed from the building at the end of each day.

H. COMPRESSED GAS CYLINDERS

Compressed gas shall be secured in an upright position at all times. A suitable cylinder cart will be used to transport compressed gas cylinders. Only those compressed gas cylinders necessary for immediate work will be allowed in occupied buildings. All others will be stored outside of buildings in a designated area. The contractor will comply with applicable standards for compressed gas cylinders found in 29 CFR 1910 and 1926

(OSHA).

I. INTERNAL COMBUSTION ENGINE-POWERED EQUIPMENT

Equipment powered by an internal combustion engine such as saws, compressors, generators, etc., will not be used in an occupied building. Special consideration may be given for unoccupied buildings only if the OSHA and NFPA requirements have been met.

J. POWER ACTIVATED TOOLS

In the event power activated tools are on the job site. Power activated tools will be kept in a secured manner at all times. When not in use, the tools will be kept locked

up. When in use, the operator will have the tool under his/her immediate control.

K. TOOLS

01 00 00 - 11

1. Under no circumstances are tools, equipment and other items of work to be left unattended for any reason. All tools, equipment and items of work must be under the immediate control of the employee.

2. If for some reason a work area must be left unattended, then it will be required that the tools and other equipment be placed in an appropriate box or container and locked. All tool boxes, containers or any other devices used for the storage of tools and equipment will be provided with a latch and padlock. All tool boxes, containers or any other device used for the storage of tools and equipment will be locked at all times except for putting in and removing tools.

3. All doors to work areas will be closed and locked when rooms are left unattended. Failure to comply with this directive will be considered a violation of VA

Regulation 1.218(b), "Failure to comply with signs of directive and restrictive nature posted for safety purposes", subject to a $50.00 fine. Subsequent similar violations may result in both imposition of such a fine as well, as the Contracting Officer taking action under the Contract's "Accident Prevention Clause", (FAR 52.236-13) to suspend all contract work until such violations may be satisfactorily resolved or under FAR 52.236-5

"Material and Workmanship Clause" to remove from the work site any personnel deemed by the Contracting Officer to be careless to the point of jeopardizing the welfare of

Facility patients of staff.

4. The contractor must report to the VA Police Department, Extension 2222, any tools or equipment that is missing.

5. Tools and equipment found unattended will be confiscated and removed from the work area.

L. LADDERS

It is required that ladders not be left unattended in an upright position. Ladders must be attended at all times or taken down and securely chained to a stationary object.

M. SCAFFOLDS

01 00 00 - 12

All scaffolds will be attended at all times. When not in use, an effective barricade

(fence) will be erected around the scaffold to prevent use by unauthorized personnel.

N. EXCAVATIONS

All excavations left unattended shall be protected with a barricade suitable to prevent entry by unauthorized persons.

O. STORAGE

The contractor must make prior arrangements with the COR for the storage of building materials. Storage will not be allowed to accumulate in Medical Center

Buildings.

P. TRASH AND DEBRIS

The contractor must remove all trash and debris from the work area on a daily basis. Trash and debris will not be allowed to accumulate in the buildings and will be allowed to accumulate outside the buildings for future pick-up. The contractor is responsible for making arrangements for the removal of trash from the Medical Center

Facility.

Q. PROTECTION OF FLOORS

It may be necessary at times to take steps to protect floors from dirt, debris, paint, etc. A tarp or other protective covering shall be used. However, the contractor must maintain a certain amount of floor space for the safe passage of pedestrian traffic.

Common sense must be used in this manner.

R. SIGNS

Signs must be placed at the entrance to work areas warning people of the construction activities. Signs must be suitable for the condition of the work. Small pieces of paper with printing or writing are not acceptable. The VAMC Safety and Occupational

Health Manager can be consulted in this matter.

01 00 00 - 13

S. ACCIDENTS AND INJURIES

Contractors must report all accidents and injuries involving employees. The contractor may use the VAMC emergency room, located on the first floor of Building

100 for emergency care.

T. FIRE/SMOKE BARRIER PENETRATION PERMIT

1. If the nature of the work requires the penetration of a fire/smoke partition or barrier the contractor must obtain the proper fire/smoke barrier penetration permit. The

VAMC Safety and Occupational Health Manager will inspect the work area and issue a

"Fire/Smoke Barrier Penetration Permit" authorizing the performance of such work.

2. A "Fire/Smoke Barrier Permit" will be issued only for the period necessary to perform such work. In the event the time necessary will exceed one day, a

"Fire/Smoke Barrier Permit" may be issued for the period needed; however, the VAMC

Safety and Occupational Health Manager will inspect the area daily.

3. Contractors will not be allowed to make any penetrations without the appropriate permit.

U. CONFINED SPACE ENTRY

The Contractor shall comply with and have documented Confined Space Entry

Procedures available at the site at all times as required by OSHA 29 CFR 1910.146. The

Contractor shall also comply with any state, and/or local requirements that are more restrictive than federal requirements. Contractor is responsible for coordinating with

Medical Center’s established policy on Confined Space.

1.7 FIRE SAFETY

A. Applicable Publications: Publications listed below form part of this Article to extent referenced. Publications are referenced in text by basic designations only.

1. American Society for Testing and Materials (ASTM):

E84-2007 ..........................Surface Burning Characteristics of Building Materials

01 00 00 - 14

2. National Fire Protection Association (NFPA):

10-2006 ............................Standard for Portable Fire Extinguishers

30-2003 ............................Flammable and Combustible Liquids Code

51B-2003..........................Standard for Fire Prevention During Welding, Cutting and

Other Hot Work

70-2005 ............................National Electrical Code

241-2004 ..........................Standard for Safeguarding Construction, Alteration, and

Demolition Operations

3. Occupational Safety and Health Administration (OSHA):

29 CFR 1926 ....................Safety and Health Regulations for Construction

B. Fire Safety Plan: Establish and maintain a fire protection program in accordance with 29

CFR 1926. Prior to start of work, prepare a plan detailing project-specific fire safety measures, including periodic status reports, and submit to COR and Safety and

Occupational Health Manager for review for compliance with contract requirements in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA AND

SAMPLES Prior to any worker for the contractor or subcontractors beginning work, they shall undergo a safety briefing provided by the general contractor’s competent person per

OSHA requirements. This briefing shall include information on the construction limits, VAMC safety guidelines, means of egress, break areas, work hours, locations of restrooms, use of VAMC equipment, etc. Documentation shall be provided to the COR that individuals have undergone contractor’s safety briefing.

C. Site and Building Access: Maintain free and unobstructed access to facility emergency services and for fire, police and other emergency response forces in accordance with

NFPA 241.

D. Separate temporary facilities, such as trailers, storage sheds, and dumpsters, from existing buildings and new construction by distances in accordance with NFPA 241. For

01 00 00 - 15 small facilities with less than 6 m (20 feet) exposing overall length, separate by 3m (10 feet). Location have to be approved by VA.

E. Temporary Construction Partitions:

1. Install and maintain temporary construction partitions to provide smoke-tight separations between construction areas and adjoining areas. Construct partitions of gypsum board or treated plywood (flame spread rating of 25 or less in accordance with ASTM E84) on both sides of fire retardant treated wood or metal steel studs.

Extend the partitions through suspended ceilings to floor slab deck or roof. Seal joints and penetrations. At door openings, install Class C, ¾ hour fire/smoke rated doors with self-closing devices.

2. Install one-hour temporary construction partitions as shown on drawings to maintain integrity of existing exit stair enclosures, exit passageways, fire-rated enclosures of hazardous areas, horizontal exits, smoke barriers, vertical shafts and openings enclosures.

3. Close openings in smoke barriers and fire-rated construction to maintain fire ratings.

Seal penetrations with listed through-penetration firestop materials in accordance with specifications.

F. Temporary Heating and Electrical: Install, use and maintain installations in accordance with 29 CFR 1926, NFPA 241 and NFPA 70.

G. Means of Egress: Do not block exiting for occupied buildings, including paths from exits to roads. Minimize disruptions and coordinate with COR and facility Safety Manager.

H. Egress Routes for Construction Workers: Maintain free and unobstructed egress. Inspect daily. Report findings and corrective actions weekly to COR and facility Safety and

Occupational Health Manager.

I. Fire Extinguishers: Provide and maintain extinguishers in construction areas and temporary storage areas in accordance with 29 CFR 1926, NFPA 241 and NFPA 10.

01 00 00 - 16

J. Flammable and Combustible Liquids: Store, dispense and use liquids in accordance with

29 CFR 1926, NFPA 241 and NFPA 30.

K. Standpipes: Install and extend standpipes up with each floor in accordance with 29 CFR

1926 and NFPA 241. Do not charge wet standpipes subject to freezing until weather protected.

L. Sprinklers: Install, test and activate new automatic sprinklers prior to removing existing sprinklers.

M. Existing Fire Protection: Do not impair automatic sprinklers, smoke and heat detection, and fire alarm systems, except for portions immediately under construction, and temporarily for connections. Provide fire watch for impairments more than 4 hours in a

24-hour period. Request interruptions in accordance with Article, OPERATIONS AND

STORAGE AREAS, and coordinate with COR and facility Safety and Occupational

Health Manager. All existing or temporary fire protection systems (fire alarms, sprinklers) located in construction areas shall be tested as coordinated with the medical center. Parameters for the testing and results of any tests performed shall be recorded by the medical center and copies provided to the COR.

N. Smoke Detectors: Prevent accidental operation. Remove temporary covers at end of work operations each day. Coordinate with COR and facility Safety and Occupational Health

Manager.

O. Hot Work: Perform and safeguard hot work operations in accordance with NFPA 241 and

NFPA 51B. Coordinate with COR. Obtain permits from facility Safety and Occupational

Health Manager at least 24 hours in advance. Designate contractor's responsible project-site fire prevention program manager to permit hot work. See paragraph 1.8 (Hot Work

Permit) for additional information

P. Fire Hazard Prevention and Safety Inspections: Inspect entire construction areas weekly.

Coordinate with, and report findings and corrective actions weekly to COR and facility

Safety and Occupational Health Manager.

01 00 00 - 17

Q. Smoking: Smoking is prohibited in and adjacent to construction areas inside existing buildings and additions under construction. In separate and detached buildings under construction, smoking is prohibited except in designated smoking rest areas.

R. Dispose of waste and debris in accordance with NFPA 241. Remove from buildings daily.

S. Perform other construction, alteration and demolition operations in accordance with 29

CFR 1926.

T. If required, submit documentation to the COR that personnel have been trained in the fire safety aspects of working in areas with impaired structural or compartmentalization features.

U. All temporary heating equipment shall be installed in accordance with requirements of applicable NFPA Standards and manufacturer’s instructions.

V. All flammable liquids shall be handled, stored, and used in accordance with NFPA

Standard No. 30-2015.

W. All temporary electrical wiring and equipment used for construction shall be installed and used in accordance with pertinent provisions of NFPA Standard No. 70-2014.

X. All construction activities not already covered above shall be in accordance with the latest edition of NFPA no. 241-2013 Standard for Safeguarding Construction, Alteration, and Demolition Operations, in effect at time of contract award.

1.8 HOT WORK PERMIT

A. The Contractor is responsible for requesting a “Hot Work” permit each day prior to commencing any cutting, burning, and welding or open torch work. The permit is requested and obtained through the VAMC Safety and Occupational Health Manager following an inspection by the Manager and COR of the intended area of use. The permit once issued will be for a maximum duration of one (1) day, after which a renewal, if required, must be requested by the Contractor.

01 00 00 - 18

B. Before approving any “Hot Work” permit, the Contractor’s authorized representative, the

COR, and other representatives of the Dept. of Veterans Affairs shall inspect the work area and confirm that precautions have been taken to prevent fire in accordance with

NFPA Standard No. 51B. Following a positive inspection, Safety and Occupational

Health Manager will issue the “Hot Work” permit.

C. In areas of “Hot Work” the following precautions are considered essential:

1. Sprinklers are in service where installed.

2. Cutting, welding, and other open flame torches are in good repair.

3. within 15 feet of the actual work:

a. Floors swept clean of combustible materials.

b. No combustible materials or flammable liquids are present.

c. All wall and floor openings are covered.

d. Covers suspended beneath work to collect sparks.

4. When working on enclosed equipment and in confined space, equipment and area is free of flammable vapors.

5. Fire watch provided during and 30 minutes after operation (60 minutes for torch applied roofing operations).

1.9 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on

Government premises to areas authorized or approved by the Contracting Officer. The

Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the Contracting Officer and shall be built with

01 00 00 - 19 labor and materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the Contractor and shall be removed by the Contractor at its expense upon completion of the work. With the written consent of the Contracting Officer, the buildings and utilities may be abandoned and need not be removed.

C. The Contractor shall, under regulations prescribed by the Contracting Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

D. Working space and space available for storing materials shall be as determined by the

COR. The Contractor shall consider that storage of excavated materials on roadways, walkways and parking areas is prohibited. Remote stockpile location shall be as determined by the COR.

E. Workmen are subject to rules of Medical Center applicable to their conduct.

F. Execute work so as to interfere as little as possible with normal functioning of Medical

Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and patients, visitors, staff and/ or with work being done by others. Provide unobstructed access to Medical Center areas required to remain in operation. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space. Keep roads clear of construction materials, debris, standing construction equipment and vehicles at all times. Do not block crosswalks and / or handicap access.

01 00 00 - 20

1. Do not store materials and equipment in other than assigned areas. Storage of construction equipment and excess materials is prohibited within the workspace.

Store all construction materials and other equipment only in lockable, watertight secure trailers.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of Veterans Affairs in quantities sufficient for not more than two work days. Provide unobstructed access to Medical

Center areas required to remain in operation. The Contractor shall be on site to receive all scheduled deliveries. The Medical Center Warehouse will not accept deliveries; do not use the warehouse as a shipping destination. The Contracting

Officer / COR will assign routes for the delivery of materials and supplies to the jobsite if such routes are not designated in the Contract Document. Under no circumstances will Government accept deliveries for the Contractor. The Contractor will advise the Contracting Officer / COR, in writing, 48 Hours in advance of delivery of materials or equipment requiring the blocking of any Medical Center road, street, walkway, or building egress and await a written reply prior to effecting any such blockage. Building loading docks and landings may be used to load and unload construction materials when requested by the Contractor in writing and approved by the COR. Approval to utilize loading dock areas may contain restrictions as to areas which can be utilized by the Contractor. Loading Docks are not to be used as storage areas nor are the docks to be considered as a parking area for more than 20 minutes.

3. Provide unobstructed access to Medical Center areas required to remain in operation. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

G. Phasing: To insure such executions, Contractor shall furnish the COR with a schedule of approximate phasing and dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or

01 00 00 - 21 portion thereof. Arrange such phasing and dates to insure accomplishment of this work in successive phases mutually agreeable to COR and Contractor, as follows:

Phase I: Submittals. . Contractor shall submit all required submittals in Division No. 1 as required by the Contracting Officer (CO) in the time stipulated by the CO to issue the Award Notification and Notice to Proceed. Critical submittals as indicated herein are to be submitted within 30 days of the Notice to Proceed and until approval No work shall commence on the job site. The remaining submittals must be submitted within 60 Calendar Days of the Notice to Proceed (or as per Submittal Log Submission Chart approved by the Contracting Officer’s COR), in a timely fashion to enable receipt and approval. Delays and lack to progress work on schedule will be borne by the Contractor.

Critical submittals shall include Division No. 1, 2, 7, and Division No. 25.

Phase II: VAMC shall review critical submittals and return to contractor. Submittals will be returned within 30 days of receipt of submittal.

DURATION 30 Calendar Days

Phase III: Due to needed use of these facilities by numerous medical clinics for procedures each work area will need to be coordinated with the VA prior to any shutdowns. If necessary, work shall be done in W.H.E.N. hours to mitigate any disturbance. Contractor shall commence there-after and then complete construction for base bid in a period of 365 Calendar Days from the Notice to Proceed.

Phase IV: Contractor shall cleanup site within 10 Calendar Days of the above-indicated completion. Safety and Occupational Health Manager shall perform a final inspection after site is cleaned by contractor.

Contract Completion shall be 365 Calendar Days from the Notice to Proceed. The Contractor shall bear the costs for the operations of the temporary affected department operations for delay time.

H. When a building is turned over to Contractor, Contractor shall accept entire responsibility therefore.

1. Contractor shall maintain a minimum temperature of 4 degrees C (40 degrees F) at all times, except as otherwise specified.

2. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make

01 00 00 - 22 arrangements for pre-inspection of site with Safety and Occupational Health

Manager.

I. Utilities Services: Maintain existing utility services for Medical Center at all times.

Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services. Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of

COR. Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without the Medical Center

Director’s prior knowledge and written approval. Refer to specification for additional requirements.

2. Contractor shall submit a request to interrupt any such services to COR, in writing, 48 hours in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical

Center. Interruption time approved by Medical Center may occur at other than

Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

01 00 00 - 23

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the

Government and not the Contractor.

J. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

K. To minimize interference of construction activities with flow of Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances must be approved by the COR.

L. Coordinate the work for this contract with other construction operations as directed by

COR. This includes the…