solicitation29-Pembina_chiller.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

27. PAYMENT WILL BE MADE BY

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

GSA Solicitation No. 47PJ0018Q0029

Simplified Acquisition Construction Contract to replace existing chiller at Customhouse, Pembina, ND

The Agreement

Table of Contents

I. Project Information A. Project Summary B. The Contract C. Period of Performance D. Work Conditions/Site Requirements E. Authorized Representative F. Contract Liquidated Damages Rate G. Buy American Exceptions H. Statement of Work, Specifications, Drawings, Exhibits, and Other Attachments

II. Prices A. Basis of Pricing

III. Terms and Conditions

A. Commencement, Prosecution, and Completion of Work B. Contractor Responsibilities C. Contractor Management and Personnel D. Material and Workmanship E. Project Schedule F. Extensions of Time G. Interpretation of Specifications and Drawings H. Submittals I. Government’s Right to Stop Work for Non-Compliance J. Other Contracts K. Substantial Completion and Contract Completion L. Use and Possession Prior to Substantial Completion M. Equitable Adjustments N. Finality of Contract Modifications O. Liquidated Damages P. Administrative Matters Q. Bonds R. Safeguarding Sensitive Data and Information Technology Resources S. Additional Terms and Conditions

IV. Contract Clauses A. Clauses Incorporated in Full Text B. Clauses Incorporated by Reference

I. Project Information

I.A. Project Summary Replace existing chiller and condenser at the Customhouse, Pembina, North Dakota.

I.B. The Contract

(1) The Contract consists of the SF 1442, the Agreement, the Statement of Work, Specifications, Drawings, Exhibits, Amendments, Modifications, and other Attachments identified herein (collectively, the Contract Documents). The Contract contains the entire agreement of the Parties, and no prior written or oral agreement, express or implied, shall be admissible to contradict or modify any part of the Contract.

(2) The Contractor shall provide and pay for all labor, materials, equipment, tools, water, heat, utilities, transportation, and other facilities and services necessary for the proper execution of the work described in and reasonably inferable from the Contract Documents (the Work), whether temporary or permanent. In consideration for, and upon condition of, the Contractor's completion of the Work, GSA shall pay the Contractor the price or prices established in Section II, subject to the terms and conditions set forth in this Contract.

I.C. Period of Performance

(1) Commencement. The Contractor shall commence performance of the Work within 10 days after the Contractor receives the Notice to Proceed (NTP).

(2) Substantial Completion. The Contractor shall achieve Substantial Completion of the Work, as that term is defined in this Agreement, no later than 95 calendar days from issuance of Notice to Proceed (NTP).

(3) Contract Completion. The Contractor shall achieve Contract Completion, as the term is defined in this Agreement, within 10 calendar days of Substantial Completion.

I.D. Work Conditions/Site Requirements Exterior work.

I.E. Authorized Representative

(1) This Contract is between the United States of America, acting by and through the Administrator of General Services (GSA), and the Contractor (the Parties). References in this Contract to "the Owner" or "the Government" shall be understood to refer to GSA. The following individual is designated as the only authorized GSA representative under this Contract, unless other warranted contracting officers are designated in writing:

Contracting Officer Name: Pam Burley Address: GSA, 657 2nd Ave. N., Room 244, Fargo, ND 58102 Telephone: 701-566-6129 Email: pam.burley@gsa.gov

(2) Authorities and Limitations

(a) All rights, responsibilities and authorities of GSA under this Contract are vested in the Contracting Officer. The Contracting Officer may delegate these rights, responsibilities, and authorities to other GSA representatives. Such delegations shall be effective and binding only if communicated in writing to the Contractor, and subject to any limitations specified therein.

(b) The Contractor shall perform the Contract in accordance with any order (including but not limited to instruction, direction, interpretation, or determination) issued by the Contracting Officer or other representative to whom the Contracting Officer has delegated authority. The Contractor assumes all the risk and consequences of performing work in accordance with an order issued by a person lacking authority to issue such order.

I.F. Contract Liquidated Damages Rate In accordance with “Liquidated Damages” clause in Section III (Terms and Conditions), liquidated damages shall be calculated at the rate of $0 per calendar day.

I.G. Buy American Exceptions For the applicable Buy American clause and any exceptions, see Section IV of this Agreement.

I.H. Statement of Work, Specifications, Drawings, Exhibits, and Other Attachments The following documents are incorporated into this Contract.

(1) Statement of Work for Solicitation 47PJ0018Q0029, Dated 4/18/18

(2) Wage Determination ND34, Dated 1/12/18

Scope of Work

Chiller and Condenser replacement 04/18/2018

Project Location

Customhouse 112 W. Stutsman Street Pembina, ND 58271

Project Points of Contact

Jeff Barbari Property Manager 701-566-6126 or 701-526-6167 cell

Louis Benson Project Manager 415-770-5127 cell

Pam Burley Contracting Officer 701-566-6129

PROJECT SCOPE

Project Summary The General Services Administration, Region 8, is initiating project to replace a chiller and condenser.

Project Objectives The contractor shall provide labor, materials, equipment and supervision necessary to perform the following:

1. Remove and replace existing chiller. New chiller must be an upgrade and exceed current chiller (attached in images and charts below) in terms of energy efficiency, lower maintenance, and repair costs.

a. Recommended chiller is Air Cooled Scroll Chiller or similar machine.

b. Provide a payback report of selected chiller as a submittal after award.

2. Remove and replace existing condenser. New condenser must be an upgrade and exceed current condenser (attached in images and charts below) in terms of energy efficiency, lower maintenance, and repair costs.

3. Both new units must be sized to replace the existing unit in current size, and must connect to all existing connections such as power, feed lines (including supply and return plumbing, and drainage line).

4. Connect and program the new chiller to the Building Automation System (BAS) in the Customhouse.

a. Customhouse standard building hours are 7:00 am – 5:00 pm.

b. Current BAS system is INET Schneider.

5. Provide a test and balance report for chiller and condenser ensuring the systems have been commissioned.

Condenser is located on the roof and the chiller is the boiler room. Existing chiller is 25 tons.

Contractor shall field verify all requirements at time of on-site walk through.

New chiller must meet minimal Federal Energy Management Program (FEMP) efficiency requirements in accordance with ASHRAE 90.1.

Chiller must use acceptable refrigerants in accordance with the U.S. Environmental Protection Agency’s Significant New Alternatives Policy (SNAP) Program.

Contractor shall reclaim and recycle the refrigerant prior to the chiller removal and disposal in compliance with applicable requirements, including but not limited to Section 608 of the Clean Air Act and 40 CFR 82.

All work shall comply with codes and standards applicable to each type of work through the course of this project. Contractor shall also comply with the requirements of GSA BuildGreen Standards and the PBS P100.

All new Building Automation Systems must fully integrate with existing site controls.

1. Chiller BAS controls must meet the following requirements:

a. BACnet/IP-see GSA R8 Open Protocol Implementation Guide - BACnet - v1

b. Be on the GSA re-mediated device list and approved by Office of Facilities

Management (OFM)

c. Fully integrate with current building automation system.

d. All points must be displayed on GUI with complete functionality.

e. All system points must be accessible to BACnet/IP services.

f. All points must be labeled and approved by OFM prior to implementation in accordance with GSA_Data_Normalization_for_Building_Automation_Systems_v2.3

2. Submittals shall include:

a. Riser diagrams

b. Schematics of product assembly and installation

c. Product data sheets

d. Warranty information

3. Submittal shall be approved by GSA Region 8 (R8) Public Building Services (PBS) Office of Facility Management (OFM) Smart Building Systems (SBS) prior to proceeding:

a. All devices installed as part of this project shall be submitted for review and approval using the Device Schedule TEMPLATE.

b. All device and object names shall conform to GSA Data Normalization for Building Automation Systems and shall be submitted for review and approval using the Object Naming Submittal TEMPLATE.

c. All GUI pages shall conform to GSA Region 8 BAS Graphic Format Standard and shall be submitted for review and approval.

d. All IP network cabling and cabling installation shall conform to GSA PBS Telecommunications Distribution Design Guide.

4. IP network CAT6 cable to be installed, terminated, and tested by contractor.

a. All network cabling shall be installed in compliance with Telecommunications

Distribution Design Guide (TDDG)

Documents noted in bold are provided for reference.

Project Duration Once notice to proceed has been issued, the contractor has 105 calendar days to complete the project. 45 calendar days are reserved for the security clearance process and 60 days are for the actual project. Extensions will be granted for unforeseen conditions and other factors outside of the contractor’s control at the Contracting Officer’s discretion.

Proposal Pricing When submitting a proposal, provide a cost breakdown for each task into the following categories: Materials, equipment, labor hours, subcontractor's quotes, overhead, and profit.

General Requirements:

I. Submittals after award

A. Contractor shall submit a Method of Procedures (MOP) to the Project Manager (PM), Louis Benson, for approval prior to commencement of work. At a minimum, the MOP shall include:

1. Brief narrative describing method of accomplishment, construction techniques, etc

2. Project schedule

3. Service/Utility Outages (if necessary)

4. Phasing schedule (if necessary)

5. Any building infrastructure/BAS equipment that may be impacted

6. Payback report of chiller.

B. All products specified all products specified are to establish a standard of quality.

Submittal response by the government shall be 7 calendar days or less. If product samples are not submitted in a timely fashion, any delays caused by the contractor will not warrant a time extension. After completion of all work, the Contractor shall submit to the project manager the manufacturer's specifications, instructions and material specification sheets in original form. Additionally, the Contractor shall submit all inventory changes (removals, additions, upgrades, etc., and new condition codes) to the COR

II. Equipment A. The contractor shall provide all equipment associated with the project, operate in a safe manner and adhere to all OSHA and GSA standards.

III. Contractor Use of the Premises

A. During the period of the project, the contractor will have access to the site only during business hours of 7:00 am 5:00 pm. No on-site work shall be performed outside these hours or on holidays unless otherwise directed by the Contracting Officer. The contractor will need to coordinate with the Contracting Officer to arrange access to the parking lot. The contractor shall make every effort to cause a minimum of damage to parking lots, any other paved areas, any items that need to be moved during the course of the project, and any areas not included in this scope of work. Any damage caused will be repaired at the contractor’s expense.

IV. Progress Meetings A. Progress meetings are not required for this project. The project manager and building team representative shall make daily inspections of the work progress.

V. Fire System Impairment and Hot Work

A. When a fire suppression or alarm system impairment is required, contractor shall provide written outage request to GSA for approval in advance of impairing any systems. Contractor shall be responsible for having a GSA approved NICET certified fire alarm contractor perform all system impairments. During fire alarm/suppression impairments or hot work procedures, contractor shall provide a fire watch per the GSA Regional Fire Watch Guidelines.

VI. Badging and Security A. All contractor and sub-contractor personnel must obtain an HSPD-12 badge. An

HSPD-12 badged worker may escort up to five non-badged workers at a time for up to 15 days.

VII. Housekeeping A. The project site shall be kept in a neat, orderly, and safe condition at all times. The contractor shall provide enough containers for collecting construction debris and construction materials to be recycled.

VIII. Construction Indoor Air Quality A. The General Contractor or other qualified party shall prepare and submit a

Construction IAQ Management Plan to the Owner and Architect for approval.

The Construction IAQ Management Plan shall meet the following criteria:

i. Construction activities shall be planned to meet or exceed the standards included in Chapter 3 of the Sheet Metal and Air Conditioning National Contractors’ Association (SMACNA) “IAQ Guidelines for Occupied Buildings under Construction”, 2nd Edition 2007. This requirement includes, but is not limited to the following:

a. Protection of existing building HVAC systems, to include shutting down systems where possible and protecting supply and return ducts within the work area by covering or filtering.

b. Controlling pollution sources.

c. Suppressing dust with wetting agents or sweeping compounds.

d. Interrupting dust pathways via dust curtains or temporary enclosures.

e. Isolating areas of work to prevent contamination.

Pressure differentials shall be used where feasible to prevent migration of dust/contaminants.

ii. Absorptive materials shall be protected from moisture damage when stored on-site and after installation.

iii. Filtration media shall be installed to protect ductwork and/or equipment used during the construction process.

iv. Dust covered materials that will be disturbed during demo shall be pre-cleaned using an effective dust collecting method, such as damp cloth, wet mop, etc., and shall be immediately bagged, sealed, and removed from the project area.

v. A Sequence of Finish Installation Plan shall be developed, highlighting measures to reduce the absorption of VOCs by materials that act as ‘sinks’.

vi. Immediately prior to occupancy, the building shall be subject to an outside air flush out, OR, shall be subject to pre-occupancy air quality testing.

IX. Salvage/Recycling Requirements

A. Achieve end-of-Project rates for salvage/recycling of 50 percent minimum by weight of total waste generated by the work unless additional rates are indicated.

Practice efficient waste management in the use of materials in the course of the Work. Use all reasonable means to divert construction and demolition waste from landfills and incinerators. Facilitate recycling and salvage of materials.

i. Salvage/recycling goal is 50 percent.

ii. Mandatory minimum salvage/recycling requirement is 50 percent.

B. Required Submittals

a. To demonstrate compliance with the above listed recycling requirements, contractor shall submit the following to GSA project manager:

i. Waste Management Plan: Submit plan within 14 days of date established for the Notice to Proceed, prepare and submit a Waste Management Plan including, but not limited to, the following:

1. List of the recycling facilities, reuse facilities, municipal waste landfills and other disposal area(s) to be used. Include:

a. Name, location, and phone number.

b. Copy of permit or license for each facility.

2. Identify materials that cannot be recycled or reused. Provide explanation or justification.

3. Revise and resubmit Plan as required by Owner.

a. Approval of Contractor’s Plan will not relieve the

Contractor of responsibility for compliance with applicable environmental regulations.

ii. Waste Reduction Calculations: Before request for Substantial Completion, submit calculated end-of-Project rates for salvage, recycling, and disposal as a percentage of total waste generated by the Work.

iii. Recycling and Processing Facility Records: Indicate receipt and acceptance of recyclable waste by recycling and processing/salvaging facilities licensed to accept them. Include manifests, weight tickets, receipts, and invoices.

iv. Landfill and Incinerator Disposal Records: Indicate receipt and acceptance of waste by landfills and incinerator facilities licensed to accept them. Include manifests, weight tickets, receipts, and invoices.

X. Safety and Health Program A. Contractor Responsibility: The Contractor shall assume full responsibility and liability for compliance with applicable codes, standards and regulations pertaining to the health and safety of personnel during execution of the Work, and shall hold the Government harmless for any action on the Contractor's part, or that of the Contractor's employees or subcontractors, that results in illness, injury or death.

B. References: In addition to publications referenced in the Construction Contract Clauses, the following Code of Federal Regulations (CFR), publications apply to conduct of the work. State and local safety and health regulations that apply are not cited herein. Current editions at the date of the agreement apply. The more stringent requirements apply.

i. 29 CFR, Part 1910: Occupational Safety and Health Administration (OSHA) General Industry and Health Standards.

ii. 29 CFR, Part 1926 " Safety and Health Regulations for Construction"

iii. 40 CFR 260, "Hazardous Waste Management System"

iv. 40 CFR 261, "Identification and Listing of Hazardous Waste."

v. 40 CFR, Part 761, EPA Polychlorinated Biphenyls (PCBs), Manufacturing, Processing, Distribution in Commerce and Use Prohibitions. [GSA Project Team: Check if any work involves sealant removal as PCBs may be present.]

vi. National Fire Protection Association (NFPA) 70E Electrical Safety Requirements for Workplace Safety

vii. U.S. Army Corps of Engineers (USCOE) Safety and Health Requirements Manual, EM 385-1-1, current edition.

viii. Federal Standard: Fed. Std. 313A, Material Safety Data Sheets, Preparation and the Submission of.

C. The Contractor shall submit for approval a project safety and health program, including but not limited to the following:

i. Occupational Noise Exposure.

ii. Fall Protection.

iii. Personnel Protective Equipment.

iv. Control of Hazardous Energy.

v. Electrical Safety Related Work Practices.

vi. Lead.

vii. Asbestos.

viii. Polychorlinated Biphenyls (PCBs)

ix. Respirator Protection.

x. Confined spaces.

D. In addition to specific safety and health programs applicable to the project, Contractor shall submit firm's general safety plan at the pre-construction conference listing emergency procedures and contact persons with home addresses and telephone numbers.

XI. Lead Based Paint A. Paint must be tested for lead content when alterations or demolitions require the sanding, burning, welding, or scraping of painted surfaces. Lead-based paint controls must be implemented in accordance with 29 CFR 1926.62. Lead-based paint that is intact and in good condition need not be abated unless required for alteration or demolition. Lead-based paint must be abated in child care centers. Refer to PBS- P140 for specific details. Construction waste containing lead-based paint must be considered hazardous waste unless testing proves otherwise.

XII. Cleaning and Closeout A. Final inspection shall be coordinated and scheduled through the project manager and contracting officer.

B. Before commencement of the final inspection, the Contractor shall:

1. Remove all tools, equipment, surplus material, and rubbish;

2. Restore or refinish, to original condition, surfaces that are damaged due to the work of this contract;

3. Remove grease, dirt, stains, foreign materials, and labels from finished surfaces;

4. Thoroughly clean building interiors;

5. Pickup all construction debris from the site; and

C. At the time of final inspection, project shall be thoroughly cleaned and ready for use. Any as-builts/red-lines, equipment manuals, waste manifests, and project related documentation shall be submitted to the Project Manager/Contracting Officer for review and acceptance as closeout documents.

XIII. Exhibits

A. Existing Chiller Electrical Panel Tag – Exhibit 1

B. Existing Trane Chiller Information – Exhibit 2

C. Existing Copelametic Chiller Information – Exhibit 3

Model No. 4DK3-2500-TSK B/M 200 Ph 3

Volt 200 Max cont fuse 10

PH 3 Factory charged R022

HZ 60 Model # CC0A0206FA11CFSC4C361CEJ

FLA 78 Serial # L81H27232

HP 25 Rated volt 200

Max CKT Fuse 150 Utilization volt range 180-220

Min CKTAMP 99 EVP 363

High Pressure 450

Low Pressure 300

Serial No. CT 93E 00162 S

Voltage Hz R.L.A. L.R.A. Half winding L.R.A.

200 50 82.2 428 250

208/230 60 82.2 428 250

380/400 50 41.1 214 -

460 60 41.1 214 -

D. Picture of Existing Chiller – Exhibit 4

E. Existing Trane Roof Condenser Information – Exhibit 5

Model No. CAUBC20E1A00 Recommended Dual Element Fuse 10

Serial No. B81H03610 Max Fuse size 12

Rated Voltage 200 Cond Fan Motor Qty 2

HZ 60 Volts 200

Phase 3 HZ 60

Utilization voltage range 180-220 PH 3

This unit is suitable for operation on the following nominal system voltages 200-208

FLA EA 4.1

Min Circuit Ampacity 9 HP EA 1.00

25 lbs of R22

Rebates

The Contractor shall pursue any and all utility rebate and incentive programs and any government grant or incentive programs at the local, state, and federal level. Contractor is responsible for researching, submitting, and ensuring collection of all applicable rebates. Rebate opportunities must be explored for all elements of the project including but not limited to resource-saving equipment, materials, design & services (Commissioning/Recommissioning and other strategies & processes). Submit all rebate checks to:

General Services Administration Attn: Ron Burnett 1961 Stout Street Suite 01-107 Denver, CO 80294

For assistance with the rebate process please contact Doug Baughman, Regional Rebate Coordinator doug.baughman@gsa.gov (303) 941-1306

General Decision Number: ND180034 01/12/2018 ND34

Superseded General Decision Number: ND20170034

State: North Dakota

Construction Type: Building

County: Pembina County in North Dakota.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.35 for calendar year 2018 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.35 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2018. The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the

Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-

(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/05/2018

1 01/12/2018

BOIL0647-006 01/01/2014

Rates Fringes

BOILERMAKER......................$ 32.75 26.42

* ELEC1426-007 12/01/2017

ELECTRICIAN......................$ 30.50 12.71

https://maps.google.com/?q=1961+Stout+StreetSuite+01&entry=gmail&source=g https://maps.google.com/?q=1961+Stout+StreetSuite+01&entry=gmail&source=g mailto:doug.baughman@gsa.gov tel:(303)%20941-1306

ENGI0049-008 05/01/2017

POWER EQUIPMENT OPERATOR:

GROUP 1.....................$ 34.05 18.80

GROUP 2.....................$ 31.40 18.80

GROUP 3.....................$ 30.80 18.80

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Crane Operator 180' boom or jib and over any combination, all types, Crane Operator 150 tons & over, Overhead Cranes 250 tons & over, Tower Cranes 200' and up, an jib configuration 160' and over.

GROUP 2: All cranes up to 149 tons, Crane Operator up to

179' of Boom or Jib, any combination all types, Gentry

Crane operator, Overhead Cranes up to 249 tons, Tower

Cranes up to 199' and any jib configuration 159' and under.

GROUP 3: Forklift

IRON0512-010 06/05/2016

IRONWORKER, REINFORCING..........$ 30.70 9.15

PLAS0633-001 05/01/2015

CEMENT MASON/CONCRETE FINISHER...$ 27.90 13.60

PLUM0300-020 05/29/2017

PIPEFITTER.......................$ 35.54 13.82

SUND2012-015 08/18/2014

BRICKLAYER.......................$ 24.60 10.28

CARPENTER........................$ 19.40 0.00

INSULATOR - MECHANICAL

(Duct, Pipe & Mechanical

System Insulation)...............$ 16.68 2.17

IRONWORKER, STRUCTURAL...........$ 28.02 15.21

LABORER: Common or General......$ 13.50 0.00

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 22.48 4.00

OPERATOR: Bobcat/Skid

Steer/Skid Loader................$ 21.23 12.65

OPERATOR: Loader................$ 21.00 12.45

PAINTER (Brush and Roller).......$ 20.46 0.00

PLUMBER..........................$ 20.06 4.45

SHEET METAL WORKER (HVAC Duct

Installation Only)...............$ 26.80 8.52

SHEET METAL WORKER (HVAC Unit

Installation Only)...............$ 28.88 8.20

TRUCK DRIVER: Dump Truck........$ 20.95 0.00

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal

Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January employees with 1 hour of paid sick leave for every 30 hours they work, up to

56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-relate needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate

(weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010

08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and

3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage

Determinations. Write to:

Branch of Construction Wage Determinations

Wage and Hour Division

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party

(those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7).

Write to:

Wage and Hour Administrator

U.S. Department of Labor

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the

Wage Appeals Board). Write to:

Administrative Review Board

U.S. Department of Labor

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

II. Prices

II.A. Basis of Pricing

(1) Contract Prices. All Contract prices set forth in this Section include all costs necessary to complete the work for which the price is established (e.g., Base Contract, Unit Price, Options) in accordance with the Contract Documents, including, but not limited to, the cost of work performed by subcontractors and consultants, indirect costs, fees, expenses, taxes, and profit.

(2) Knowledge of Conditions Affecting Price. FAR 52.236-3, Site Investigations and Conditions Affecting the Work, is incorporated by reference in this Contract. The Contractor shall be presumed to have established all prices with knowledge of general and local conditions that may affect the cost of Contract performance at the site where the Work is to be performed, to the extent that such information is reasonably obtainable.

(3) Unit Prices and Allowances. If any portion of the Work is to be performed on a unit price basis, the Unit Price shall include all costs of coordinating and incorporating the unit-priced portion of the Work into the Base Contract Work. The Contractor shall only be obligated to perform unit-priced work to the extent that an Allowance has been established. The Contractor shall be obligated to perform such work in excess of a unit quantity for which an Allowance is established only if directed by the Contracting Officer in writing. The Contractor shall be bound to the unit price or prices set forth herein in all equitable adjustments for changes including unit priced work, and no markups shall be applied to such unit prices.

III. Terms and Conditions

III.A. Commencement, Prosecution, and Completion of Work The Contractor shall not commence the Work until the Contracting Officer has issued NTP. The Contractor shall diligently prosecute the Work so as to achieve Substantial Completion of the Work, as defined in Section III (Terms and Conditions), “Substantial Completion and Contract Completion” clause, within the time specified in Section I (Project Information), “Period of Performance” clause. If the Contract specifies different completion dates for different phases or portions of the Work, the Contractor shall diligently prosecute the Work so as to achieve Substantial Completion of such phases or portions of the Work within the times specified.

III.B. Contractor Responsibilities

(1) Unless otherwise expressly stated in the Contract, the Contractor shall be responsible for all means and methods employed in the performance of the Contract.

(2) The Contractor shall be responsible for providing professional design services in connection with performance of the Work or portions of the Work only if this responsibility is expressly stated and the Contract Documents provide the performance and design criteria that such services will be required to satisfy. In the performance of such work, the Contractor shall be responsible for retaining licensed design professionals, who shall sign and seal all drawings, calculations, specifications and other submittals that the licensed professional prepares. The Contractor shall be responsible for, and GSA shall be entitled to rely upon, the adequacy and completeness of all professional design services provided under this Contract.

(3) The Contractor shall be responsible for coordinating all activities of subcontractors. This responsibility includes coordination of: preparation of shop drawings produced by different subcontractors where their work interfaces or may potentially conflict or interfere and the installation of such work; scheduling of work by subcontractors; and use of the Project site for staging and logistics.

(4) Where installation of separate Work components as shown in the Contract Documents will result in conflict or interference between such components or with existing conditions, including allowable tolerances, it is the Contractor's responsibility to bring such conflict or interference to the attention of the Contracting Officer and seek direction before fabrication, construction, or installation of any affected work. If the Contractor fabricates, constructs, or installs any work prior to receiving such direction, the Contractor shall be responsible for all cost and time incurred to resolve or mitigate such conflict or interference.

(5) Where drawings show work without specific routing, dimensions, locations, or position relative to other work or existing conditions, and such information is not specifically defined by reference to specifications or other information supplied in the Contract Documents, the Contractor is responsible for routing, dimensioning, and locating such work in coordination with other work or existing conditions in a manner consistent with Contract requirements.

(6) The Contractor shall secure and pay for all necessary permits and governmental fees, licenses, and inspections that are customarily secured after award of the Contract and that are legally required at the time of award. The Contractor shall provide a copy of the permits required for execution of the work to the Contracting Officer prior to commencement of any related work.

(7) The Contractor shall immediately bring to the Contracting Officer's attention any hazardous materials or conditions not disclosed in the Contract Documents discovered by or made known to the Contractor during the performance of the Contract

(8) The Contractor must submit a safety plan before commencing work.

(9) It is not the Contractor's responsibility to ensure that the Contract Documents comply with applicable laws, statutes, building codes, and regulations. If it comes to the attention of the Contractor that any of the Contract Documents do not comply with such requirements, the Contractor shall promptly notify the Contracting Officer in writing. If the Contractor performs any of the Work prior to notifying and receiving direction from the Contracting Officer, the Contractor shall assume full responsibility for correction of such work and any fees or penalties that may be assessed for non-compliance.

(10) The Contractor assumes the risk of, and shall be responsible for, any loss, damage, destruction, or theft of Government property upon its delivery to the Contractor as Government-furnished property. However, the Contractor is not responsible for reasonable wear and tear to Government property or for Government property properly consumed in performing this Contract.

III.C. Contractor Management and Personnel

(1) The Contractor shall employ sufficient management and contract administration resources, including personnel responsible for project management, field superintendence, change order administration, estimating, coordination, inspection, and quality control, to ensure the proper execution and timely completion of the Work. The Contractor shall designate a principal of the firm or other senior management official to provide executive oversight and problem resolution resources to the Project for the life of the Contract.

(2) The Contractor shall employ, and require its subcontractors to employ, qualified personnel to perform the Work. The Government reserves the right to exclude, or remove from the site or building, any personnel for reasons of incompetence, carelessness, or insubordination, who violate rules and regulations concerning conduct on federal property, or whose continued employment on the site is otherwise deemed by the Government to be contrary to the public interest.

(3) Repeated failure or excessive delay by the Contractor to provide qualified personnel shall be deemed a default for the purposes of the “Termination for Default” clause.

III.D. Material and Workmanship All equipment, material, and articles incorporated into the Work shall be new and of the most suitable grade for the purpose intended, unless otherwise specified in this Contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number shall be regarded as establishing a standard of quality and performance and shall not be construed as limiting competition.

Unless specifically directed by the Contracting Officer, the Contractor may use any equipment, material, article, or process that is equal to that named in the specifications, so long as it is of comparable quality and meets specified characteristics, or, if no such characteristics are specified, the relevant performance characteristics of the specified item.

III.E. Project Schedule

(1) The Contractor shall use a Project Schedule to plan, coordinate, and perform the Work.

The Project Schedule shall show all critical milestones in a MS Word or Excel format.

(2) The Project Schedule shall be a rational, reasonable and realistic plan for completing the Work, and conform to requirements specified in this clause and elsewhere in this Contract.

(3) The Contractor understands and acknowledges that the preparation and proper management of the Project Schedule is a material component of the Work, and that the Contract price includes all costs of compliance with Project Schedule requirements.

(4) The Project Schedule shall depict all major activities necessary to complete the Work.

(5) Prior to NTP, the Contractor shall submit its Project Schedule to the Contracting Officer.

The Contractor shall submit the Project Schedule in both electronic and hardcopy print format.

(6) The Project Schedule shall also include Contractor-defined milestones to identify target dates for critical events, based upon the Contractor's chosen sequence of work and be linked to the tasks that drive those milestones.

(7) If the Contractor revises the Project Schedule after initial submission, the Contractor shall provide in writing to the Contracting Officer a narrative describing the substance of the revision, the rationale for the revision, and the impact of the revision on the Completion date.

(8) If at any time the Contracting Officer finds that the Project Schedule does not comply with any Contract requirement, the Contractor shall, upon written notice of exceptions taken by the Contracting Officer, revise the Project Schedule, adjust activity progress, or provide sufficient information demonstrating compliance. Regardless of whether the Contracting Officer takes any such exception, the Contractor shall not be relieved of its responsibility for the rationality, reasonableness or realism of the Project Schedule,

(9) If the Contractor fails to sufficiently address the Contracting Officer's exceptions to the Project Schedule within thirty (30) calendar days of written notice of same, the Contracting Officer may withhold retainage until the Project is Substantially Complete or until such time as the Contractor has complied with Project Schedule requirements.

(10) The Contracting Officer shall be entitled, but not required, to rely upon the Project Schedule to evaluate the Contractor's progress, evaluate entitlement to extensions of time.

III.F. Extensions of Time

(1) If the Contractor requests an extension of the time for Substantial Completion, the Contractor shall base its request on analysis of time impact using the Project Schedule as its baseline, and the new Substantial Completion date projected by the Project Schedule as revised to account for the impact. The Contractor's request must be submitted to the Contracting Officer in writing, and set forth facts and analysis in sufficient detail to enable the Contracting Officer to evaluate the Contractor's entitlement to an extension of time.

(2) The Contractor shall only be entitled to an extension of time to the extent that Substantial Completion of the Work is delayed by causes for which the Contractor is not responsible under this Contract and to the extent that the actual or projected Substantial Completion date is later than the date required by this Contract for Substantial Completion.

(3) The Contractor shall not be entitled to an extension of time if the Contractor has not updated the Project Schedule in accordance with this Contract.

(4) The Government shall not be liable for any costs to mitigate time impacts incurred by the Contractor that occur less than 30 calendar days after the date the Contractor submits a request for extension of time complying with this clause.

III.G. Interpretation of Specifications and Drawings

(1) The specifications and drawings shall be interpreted to complement each other.

Requirements set forth in the specifications and not shown on the drawings, or shown on the drawings and not set forth in the specifications, shall be of like effect as if shown or set forth in both.

(2) Different requirements within the Contract Documents shall be deemed inconsistent only if compliance with both cannot be achieved.

(3) If a requirement set forth in one location is more restrictive than that set forth elsewhere in the Contract Documents, requirements set forth in specifications shall govern over requirements set forth in drawings; otherwise, the more restrictive shall govern.

(4) In case of inconsistent requirements within the drawings, the following order of precedence shall apply:

(a) Requirements indicated in large-scale drawings shall govern over inconsistent requirements indicated in small-scale drawings.

(b) Requirements indicated in schedules shall govern over inconsistent information shown in drawings.

(5) Unless otherwise noted, the drawings shall be interpreted to provide for a complete construction, assembly, or installation of the Work, without regard to the detail with which material components are shown in the drawings.

(6) If any inconsistency within the drawings or specifications cannot be reconciled by reference to this clause, the Contractor shall promptly request a determination from the Contracting Officer as to which requirement shall govern.